Loading...
R-04-12-02-9E2 - 12/2/2004 RESOLUTION NO. R-04-12-02-9E2 WHEREAS, the City of Round Rock desires to retain engineering services for the I&I Flow Monitoring Study, and WHEREAS, GSWW, Inc. has submitted a Contract for Engineering Services to provide said services, and WHEREAS, the City Council desires to enter into said contract with GSWW, Inc. , Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK, TEXAS, That the Mayor is hereby authorized and directed to execute on behalf of the. City a Contract for Engineering Services with GSWW, Inc . for the I&I Flow Monitoring Study, a copy of said contract being attached hereto as Exhibit "A" and incorporated herein for all purposes . The City Council hereby finds and declares that written notice of the date, hour, place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. RESOLVED this 2nd day of December, 2004 . NY W Mayor C'aT: f Round Rock, Texas T: CHRISTINE R. MARTINEZ, City Secreta @PFDPsktop\::ODMA/WORLDOX/O:/WDOX/RESOLUTI/R41202E2.WPD,/SC r j!ROUND�MCK,TEXAS P09,PASSION.PROSPERITY, CITY OF ROUND ROCK CONTRACT FOR ENGINEERING SERVICES FIRM: GSWW, Inc. _("Engineer") ADDRESS: 1016 Mopac Circle, Suite 201, Austin,TX 78746 PROJECT: I&I FLOW MONITORING STUDY THE STATE OF TEXAS § COUNTY OF WILLIAMSON § THIS CONTRACT FOR ENGINEERING SERVICES ("Contract") is made and entered into on this the_day of , 2004 by and between the CITY OF ROUND ROCK, a Texas home- rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664-5299, (hereinafter referred to as "City"), and Engineer, and such Contract is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW, THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: EXHIBIT nAn Engineering Services Contract Rev.09/07/04 File Name: gsww-I&Iflowmonitoring;76569 00064494 1 CONTRACT DOCUMENTS The Contract Documents consist of this Contract and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Contract) and all Supplemental Contracts (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Contract as if attached to this Contract or repeated herein. ARTICLE 1 CITY SERVICES City shall perform or provide services as identified in Exhibit A entitled"City Services." ARTICLE 2 ENGINEERING SERVICES Engineer shall perform Engineering Services as identified in Exhibit B entitled "Engineering Services." Engineer shall perform the Engineering Services in accordance with the Work Schedule as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineering Services under this Contract may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all Engineering Services. Should the review times or Engineering Services take longer than shown on the Work Schedule, through no fault of Engineer, Engineer may submit a timely written request for additional time, which shall be subject to the approval of the City Manager. ARTICLE 3 CONTRACT TERM (1) Term. The Engineer is expected to complete the Engineering Services described herein in accordance with the above described Work Schedule. If Engineer does not performed the Engineering Services in accordance with the Work Schedule, then City shall have the right to terminate this Contract as set forth below in Article 20. So long as the City elects not to terminate this Contract, it shall continue from day to day until such time as the Engineering Services are completed. Any Engineering Services performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably anticipates,that the Engineering Services will not be completed in accordance with the Work Schedule. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of Engineering Services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all Engineering Services required under this Contract in a professional manner. 2 (3) Notice to Proceed. After execution of this Contract, Engineer shall not proceed with Engineering Services until authorized in writing by City to proceed as provided in Article 7. ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for the Engineering Services performed and to be performed under this Contract. The amount payable under this Contract, without modification of the Contract as provided herein, is the sum of One Hundred Ninety-four Thousand Two Hundred Eighty&No/100 Dollars($ 194,280.00 ) as shown in Exhibit D. The lump sum amount payable shall be revised equitably only by written Supplemental Contract in the event of a change in Engineering Services as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the Engineering Services and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B. Satisfactory progress of Engineering Services shall be an absolute condition of payment. The fee herein referenced may be adjusted for additional Engineering Services requested and performed only if approved by written Supplemental Contract. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer shall be made while Engineering Services are in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of Engineering Services accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of Engineering Services identified in Exhibit D. Progress payments shall be made by City based upon Engineering Services actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination,that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her/its negligence. 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the Engineering Services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Contract or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non-disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED The Engineer shall not proceed with any task listed on Exhibit B until the City has issued a written Notice to Proceed regarding such task. The City shall not be responsible for work performed or costs incurred by Engineer related to any task for which a Notice to Proceed has not been issued. ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Contract is as follows: Michael D.Thane, P.E. Engineering Manager 2008 Enterprise Drive Round Rock, Texas 78664 Telephone Number(512) 218-3236 Fax Number(512) 218-5563 Email Address mthane@round-rock.tx.us 4 City's Designated Representative shall be authorized to act on City's behalf with respect to this Contract. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineering Services. Engineer's Designated Representative for purposes of this Contract is as follows: David Koberlein, P.E. Associate 1016 Movac Circle, Suite 201 Austin, TX 78746 Telephone Number (512) 306-9266 Fax Number (512) 306-9550 Email Address kdavid@gsw-inc.com ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the Engineering Services, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the Engineering Services. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of the Engineering Services. Should City determine that the progress in Engineering Services does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the Engineering Services, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to meet the objectives of the Work Schedule, or preclude the attainment of project Engineering Services units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the Work Schedule goals sooner than anticipated. 5 ARTICLE 10 SUSPENSION Should City desire to suspend the Engineering Services, but not to terminate this Contract, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty-day notice may be waived in writing by agreement and signature of both parties. The Engineering Services may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the Engineering Services. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If this Contract is suspended for more than thirty (30) days, Engineer shall have the option of terminating this Contract. If City suspends the Engineering Services, the contract period as determined in Article 3, and the Work Schedule, shall be extended for a time period equal to the suspension period. City assumes no liability for Engineering Services performed or costs incurred prior to the date authorized by City for Engineer to begin Engineering Services, and/or during periods when Engineering Services is suspended, and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL ENGINEERING SERVICES If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is beyond the scope of this Contract and as such constitutes extra work, he/she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Contract will be executed between the parties as provided in Article 13. Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Contract. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the Engineering Services authorized in this Contract or any amendments thereto. ARTICLE 12 CHANGES IN ENGINEERING SERVICES If City deems it necessary to request changes to previously satisfactorily completed Engineering Services or parts thereof which involve changes to the original Engineering Services or character of Engineering Services under this Contract, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional Engineering Services and paid for as specified under Article 11. Engineer shall make revisions to Engineering Services authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such Engineering Services. 6 ARTICLE 13 SUPPLEMENTAL CONTRACTS The terms of this Contract may be modified by written Supplemental Contract if City determines that there has been a significant change in (1) the scope, complexity or character of the Engineering Services, or(2) the duration of the Engineering Services. Any such Supplemental Contract must be duly authorized by the City. Engineer shall not proceed until the Supplemental Contract has been executed. Additional compensation, if appropriate, shall be identified as provided in Article 4. It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until the City authorizes full execution of the written Supplemental Contract and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Contract are the exclusive property of City and shall be furnished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Contract. Engineer, at its own expense, may retain copies of such documents or any other data which it has furnished City under this Contract. ARTICLE 15 PERSONNEL,EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services, and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the Engineering Services shall immediately be removed from association with the project when so instructed by City. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the Engineering Services under this Contract without prior written approval from City. All subcontracts shall include the provisions required in this Contract and shall be approved as to form, in writing, by City prior to Engineering Services being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Contract. 7 ARTICLE 17 EVALUATION OF ENGINEERING SERVICES City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the Engineering Services performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Contract may be terminated as set forth below. (1) By mutual agreement and consent, in writing,of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the Engineering Services set forth herein in a satisfactory manner. (3) By either parry, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all Engineering Services and obligations described herein. Should City terminate this Contract as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the Engineering Services performed by Engineer prior to termination, City shall be the sole judge. Compensation for Engineering Services at termination will be based on a percentage of the Engineering 8 Services completed at that time. Should City terminate this Contract under Subsection (4) immediately above,then the amount charged during the thirty-day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Contract or if City terminates this Contract for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the Engineering Services to the date of default, the amount of Engineering Services required which was satisfactorily completed to date of default, the value of the Engineering Services which are usable to City, the cost to City of employing another firm to complete the Engineering Services required and the time required to do so, and other factors which affect the value to City of the Engineering Services performed at the time of default. The termination of this Contract and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Contract, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Contract is due to the failure of Engineer to fulfill his/her/its contractual obligations,then City may take over the project and prosecute the Engineering Services to completion. In such case, Engineer shall be liable to City for any additional and reasonable costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the Engineering Services under this Contract. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Contract, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her/its compliance. Engineer shall further obtain all permits and licenses required in the performance of the Engineering Services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the Engineering Services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales,Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this Contract, which are caused by or which result from the negligent error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. 9 Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such negligent activities by Engineer, its agents, or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her/its Engineering Services and shall promptly make necessary revisions or corrections to its work product resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions in its work product, or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON-COLLUSION,FINANCIAL INTEREST PROHIBITED (1) Non-collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Contract, and that he/she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City reserves and shall have the right to annul this Contract without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission,percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Contract is in effect professional liability insurance coverage in the minimum amount of One Million Dollars from a company authorized to do insurance business in Texas and otherwise 10 acceptable to City. Engineer shall also notify City, within twenty-four (24) hours of receipt, of any notices of expiration, cancellation, non-renewal, or material change in coverage it receives from its insurer. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Contract to maintain during the term of this Contract, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional policy conditions as shown below in Article 26, Section(3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Contract, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: (a) Each policy shall require that thirty (30) days prior to the expiration, cancellation, non- renewal or reduction in limits by endorsement a notice thereof shall be given to City by certified mail to: City Manager, City of Round Rock 221 East Main Street Round Rock, Texas 78664 (b) The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self-Insured Retentions of whatever nature. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit E herein entitled "Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. 11 ARTICLE 28 SUCCESSORS AND ASSIGNS This Contract shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Contract, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Contract shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Contract shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Contract constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Contract may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Contract. ARTICLE 32 NOTICES All notices to either party by the other required under this Contract shall be personally delivered or mailed to such party at the following respective addresses: City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 12 and to: Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: David Koberlein, P.E. Associate GSWW, Inc. 1016 Movac Circle, Suite 201 Austin, TX 78746 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the Engineering Services for each phase of this Contract within the agreed Work Schedule may constitute a material breach of this Contract. Engineer shall be fully responsible for his/her/its delays or for failures to use his/her/its reasonable efforts in accordance with the terms of this Contract and the Engineer's standard of performance as defined herein. Where damage is caused to City due to Engineer's negligent failure to perform City may accordingly withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Contract if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Contract shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Contract shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. (4) Standard of Performance. The standard of care for all professional engineering, consulting and related services performed or furnished by Engineer and its employees under this Contract will be the care and skill ordinarily used by members of Engineer's profession practicing under the same or similar circumstances at the same time and in the same locality. Excepting Articles 25 and 34 herein, Engineer makes no warranties, express or implied, under this Contract or otherwise, in connection with the Engineering Services. 13 (5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer's experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s') methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual project or construction cost will not vary from opinions of probable cost Engineer prepares. (6) Opinions and Determinations. Where the terms of this Contract provide for action to be based upon opinion,judgment, approval, review, or determination of either party hereto, such terms are not intended to be and shall never be construed as permitting such opinion,judgment, approval, review, or determination to be arbitrary, capricious, or unreasonable. ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Contract and that he/she has full and complete authority to enter into this Contract on behalf of the firm. The above-stated representations and warranties are made for the purpose of inducing City to enter into this Contract. IN WITNESS WHEREOF,the City of Round Rock has caused this Contract to be signed in its corporate name by its duly authorized City Manager or Mayor and Engineer, signing by and through its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK, TEXAS APPROVED AS TO FORM: By: Nyle Maxwell,Mayor Stephan L. Sheets, City Attorney ATTEST: By: Christine Martinez, City Secretary GSWW, Inc. By: Si�gnature of Principal Printed Name: A4 !D 14 LIST OF EXHIBITS ATTACHED (1)Exhibit A City Services (2)Exhibit B Engineering Services (3)Exhibit C Work Schedule (4) Exhibit D Fee Schedule (5) Exhibit E Certificates of Insurance 15 Exhibit A— City Services The CITY OF ROUND ROCK shall provide the following information and services: 1. One reproducible print of the existing sewer system showing the location and size of existing sewer lines, manholes, lift stations, and other pertinent topographic information such as right-of-way lines, street names, etc. This information shall also be provided in an electronic format, if available. 2. Liaison with THE CITY OF ROUND ROCK to provide effective coordination and cooperation between the fire, police, security, and traffic control departments and GSWW, as necessary during execution of field work. 3. Access to manholes and/or lift stations. 4. Assistance by THE CITY OF ROUND ROCK, knowledgeable of manhole and cleanout locations, in locating buried or hidden manholes and cleanouts. 5. Expose for entry, manholes that require excavation, cutting of pavement, and/or have lids fastened or frozen in place. 6. Provide manhole and/or pipeline cleaning if required for meter installation (prior to meter installation) or allow a reasonable and customary additional charge for GSWW to perform the line cleaning or have this task performed by others. Page 1 Exhibit B — Engineering Services Background This project will consist of the performance of certain field tasks relative to field installation, maintenance, calibration, and data collection for six (6) velocity-depth style wastewater flow monitors and related data analysis. Formatting of the collected data and engineering evaluation and wet and dry weather analysis of the collected data is also presented. The final product will result in a written report outlining the findings from the data collection exercise and engineering evaluations. Task 100- Preparatory Work, Project Kick-off Meeting,and Site Investigation This task consists of the following items, all of which are customary and necessary to the success of the overall project: • Printing of all field forms and preparation of maps to be used for the field investigation portion of the project. • Project kickoff meeting to discuss the proposed locations of the flow monitoring points and alternative monitoring points, rain gage locations, public relations requirements, any additional security and safety requirements for The City of Round Rock, work hours, field reporting requirements, and traffic control requirements. • Transportation of the appropriate personnel and equipment to the project site. • Procedures for use in case a primary flow monitoring site is found to be undesirable for flow monitoring based on site hydraulics, traffic issues, site conditions, etc. In the case where an alternative site is desirable, GSWW will notify the City of Round Rock of the conditions at the primary monitoring site that make it an undesirable flow-monitoring site and suggest alternatives. The compensation for this task shall be on a lump sum basis. Task 200 — Flow Monitor Installation, Maintenance, Calibration, Data Collection, and Equipment Removal This task provides for the installation, maintenance, calibration, data collection and equipment removal of flow metering equipment. The installation of the flow metering equipment shall begin at the direction of the City of Round Rock and will be completed within two weeks of receipt of approval of the flow monitoring sites determined under Task 100. Each meter will be field calibrated prior to installation. Calibration of each meter will consist of an independent verification of the flow depth and velocity. The flow sensors will be secured to a mounting band that fits snugly in the pipeline. The data logger for each site will then be installed and secured in the top of each manhole. The sampling interval for the data loggers shall be two (2) minutes and the data shall be stored in 15-minute increments. Written logs of each site visit will be maintained and will be used to record date and time of visit, meter velocity and depth reading, corresponding independent velocity and depth reading, and maintenance items such as battery voltage, etc. Routine maintenance and service will be undertaken on a seven (7) day Page 1 cycle to confirm normal operation during the first 60 days of the monitoring period and on a 14- day cycle for the remainder of the monitoring period. The metering equipment will be capable of recording flow under surcharged conditions During collection, data from each unit will be uploaded in the field to an electronic data collection device. Each data transfer unit will then be uploaded to the central project computer in the office for data integrity checks. Data integrity checks shall be performed to ensure that the flow meters are operating within manufacturer's specified tolerances. Any meter found to be performing outside of specified tolerances will be diagnosed and the issues associated with the inaccurate readings will be resolved or the meter will be replaced. No additional compensation will be requested for this task. Assumptions: Rainfall gages will be installed by the CITY OF ROUND ROCK personnel at locations identified in Task 100. Rainfall gage data will be provided to GSWW in electronic format(txt, csv, or Microsoft Excel) with a logged interval of 15-minutes. The data will provided on a 14-day cycle corresponding with the flow monitoring data. The compensation for this task shall be on a "per meter day" basis for the 12-month monitoring period. Task 300—Monthly Technical Memorandum This task provides for the delivery of the collected flow and rainfall data to the CITY OF ROUND ROCK and the preparation of a monthly brief technical memorandum including data summary, conditions found in the field, data integrity issues, site maintenance and calibration data for each monitored site. One (1) hardcopy and four (4) electronic copies of the brief technical memorandum and data will be delivered to the CITY OF ROUND ROCK monthly. The compensation for this task shall be on a monthly basis. Task 400—Data Formatting, Engineering Analysis and Reporting This task provides for the formatting and engineering analysis of the collected flow and rainfall data and development of an engineering report. The following data will be provided for each metering site, in 15-minute increments: • Average daily flow for dry weather • Peak flow for dry weather • Average daily flow for wet weather • Peak flow for wet weather • Peak inflow rates • Total quantity of inflow and infiltration The final report will include the following information as a minimum: • Development of discrete flow data for each metering site • Development of the volume of inflow/infiltration estimates • Ranking of each sub basin by severity of inflow/infiltration • Hydrographs and tabular listings of the flow and rainfall data • Locations of flow metering stations • Location of rainfall gages • Monitored rainfall data by gage location by storm event Page 2 • Standard wastewater flow parameters by flow meter, including average and peak flow for dry weather, average and peak flow for wet weather, peak inflow rates, total inflow/infiltration volumes, and design storm projected flows • Hydrographs for each flow meter station (Overall metering period and one-week hydrographs) • Summary tables of recorded rain events • Location map depicting the location of the rainfall gages in the study area • Equipment maintenance logs Five (5) hardcopies and five (5) electronic copy of the report and data will be delivered to the CITY OF ROUND ROCK, no later than 30 days after the completion of the flow monitoring period. The compensation for this task shall be on a"per meter per month"basis. Task 500—Relocation of Flow Monitoring Equipment(Optional) This task consists of the relocation of flow monitoring equipment and development of additional wastewater flow parameters based on the requirements of the CITY OF ROUND ROCK. The project team desires to have a facility by which flow-monitoring equipment can be relocated to other portion of the collection system during the flow-monitoring period. This task is included to compensate for additional site investigations (if required), removal, reinstallation, and recalibration of the flow monitors and the additional engineering and data management associated with each relocated flow monitor. The Project Team will provide sufficient notice Q days)to GSWW to move a meter. The compensation for this task shall be on a"per meter"basis. Task 600—Training (Optional) This task will include two eight (8) hour training periods on meter operation, maintenance, data collection, reduction, quality assurance and evaluation. The training sessions will performed at a monitoring site (field training) or at a CITY OF ROUND ROCK conference facility (classroom training). Flow monitoring site training will include meter maintenance, calibration, diagnostics and data collection. Classroom training will include flow meter software, data reduction and evaluation instruction. In addition to the classroom training, CITY OF ROUND ROCK personnel will be invited to join our field crews during meter maintenance and data collection activities during the contract period. This will afford CITY OF ROUND ROCK personnel an opportunity to observe and participate during actual field operations. Compensation for this task shall be per each eight(8) hour training session. Page 3 Exhibit C —Work Schedule The work will be initiated within one week of receipt of Authorization to Proceed by the CITY OF ROUND ROCK. Monitoring equipment shall be installed within two weeks of the completion of Task 100. Work for Tasks 200-600 will be completed within thirteen (13) months of the project initiation, unless extended for monitoring is initiated. Page 1 Exhibit D — Fee Schedule The total estimated compensation to provide all services described under the Scope of Work including the necessary equipment and supplies is ONE HUNDRED AND EIGHTY - FOUR THOUSAND EIGHT HUNDRED EIGHTY DOLLARS ($184,880.00) not including optional tasks. The compensation amount is based on the estimated work unit quantities delineated under the Scope of Work and the quantities outlined herein. It should be noted that the quantities outlined in this contract are estimated based on the best available information and may vary from the actual quantities found during field investigations. In no case will the total contract amount exceed ONE HUNDRED AND NINETY - FOUR THOUSAND TWO HUNDRED EIGHTY DOLLARS ($194,280.00), including optional tasks without prior written authorization from the CITY OF ROUND ROCK. Invoices will be rendered monthly and due within thirty (30) days. Invoices will be computed based on the quantities of work completed to date, multiplied by the unit price for that work and/or percentage of task completion. Table 1—Com nsation for Basic and Optional Tasks Task Description Unit Unit Cost Estimated Extended uanti Cost 100 Preparatory Work, Project Kick-off Lump $2,000.00 1 Meeting, and Site Investigation Sum $2,000.00 Flow Monitor Installation, Meter- 200 Maintenance, Calibration, DataDay $60.00 2,160 $129,600.00 Collection and Equipment Removal 300 Monthly Technical Memorandum Month950.00 12 11 400.00 400 Data Formatting, Engineering Analysis Meter- $3,490.00 12 and Reporting Month $41,880.00 Total w out Options: 184 880.00 500 Relocation of Flow Monitoring Meter $1,200.00 2 $2,400.00 Equipment 0 tional 600 Software Training (8 hour session) - Each Optional $3,000.00 1 $3,000.00 601 Equipment Installation and Calibration Each Training8 hour session —Optional $4,000.00 1 $4,000.00 Total O tions: $9,400.00 Tota/W1 0060175.- , 194280.00 Extended Metering Rate is$52.65 per meter er da . To be performed at the City's discretion. * Optional Task A lease/purchase option is available to the CITY OF ROUND ROCK under this contract for purchase of the temporary flow monitoring equipment used to collect data for this project. In order to exercise this option, THE CITY OF ROUND ROCK will be required to notify (in writing) GSWW within one (1) month of the expiration of the basic 12-month flow monitoring period. If exercised, GSWW will apply 70% (based on manufacturer policy) of the per meter rental paid to GSWW (as a portion of the daily meter compensation) to the purchase price of the meter, up to the purchase price of a particular meter. The purchase price of the meter shall be made available — --- Page 1 to the CITY OF ROUND ROCK within one (1) month of the basic 12 month metering period. The purchase price is dependent upon the manufacturer, model, and accessories installed at a particular location and will not be finally determined until the completion of Task 200 activities. -- _Page 2 EXHIBIT E Certificates of Insurance CERTIFICATE OF LIABILITY INSURANCE Date: 11/03/04 PROFESSIONAL SERVICES PRODUCER COMPANIES AFFORDING COVERAGE McLaughlin Brunson Insurance Agency 9535 Forest Lane, #118 A Liberty Insurance Underwriters, Inc. Dallas, Texas 75243 B INSURED GSWW, Inc. C 11117 Shady Trail Dallas, Texas 75229 D THIS IS TO CERTIFY THAT the Insured named above is insured by the Companies listed above with respect to the business operations hereinafter described, for the types of insurance and in accordance with the provisions of the standard policies used by the companies, and further hereinafter described. Exceptions to the policies are noted below. CO TYPE OF INSURANCE POLICY EFFECTIVE EXPIRATION LIMITS LTR NUMBER DATE DATE A PROFESSIONAL LIABILITY AEE197283-0104 7/15/2004 7/15/2005 $1,000,000 Per Claim/Annl Agg. DESCRIPTION OF SPECIAL ITEMS/EXCEPTIONS The claims made professional liability coverage is the total aggregate limit for all claims presented within the policy period and is subject to a deductible. Should any of the above described policies be cancelled or changed before the expiration date thereof, the issuing company will mail thirty(30)days written notice to the certificate holder named below. CERTIFICATE HOLDER: City of Round Rock 221 E. Main Street Round Rock,Texas 78664 attn: Christine Martinez, City Secretary SIGNATURE OF AUTHORIZED REPRESENTATIVE P- lxlxell—a� Typed Name: Patrick P. McLaubhlin Title: Agent Rev'd 2/10/03-Professional Liability Certificate.doc DATE: November 23, 2004 SUBJECT: City Council Meeting - December 2, 2004 ITEM: 9.E.2. Consider a resolution authorizing the Mayor to execute a Contract for Engineering Services with GSWW, Inc. for the I&I Flow Monitoring Study. Department: Water and Wastewater Utilities Staff Person: Tom Clark, Director of Utilities Michael Thane, Engineering Manager Justification: Six velocity-depth wastewater flow monitors will be installed at various locations within the City's wastewater collection system for a 12-month period. The City is divided into sub-basins based on natural drainage and the direction of flow within the wastewater system. The flow meters for this study will be strategically placed in sub-basins that have recently been rehabilitated, sub-basins that have not been rehabilitated with older wastewater systems, and sub-basins that have not been rehabilitated with newer wastewater systems. The information obtained from these flow meters, along with City installed rain gauges, will allow the City to determine the effectiveness of the current Wastewater Collection System Inspection and Rehabilitation Program. The data will provide information to the City in order to evaluate the difference in the amount of flow during dry conditions versus wet conditions. The difference in these conditions is the amount of inflow and infiltration (I&I) that is entering the City's wastewater collection system. This I&I of surface and groundwater add to the treatment cost that is incurred by the City. As part of this study, the City staff will be trained by GSWW, Inc. on meter operation, maintenance, data collection, quality assurance and evaluation, so that at the completion of this contract, City staff should be able to continue a flow monitoring program in-house on an as needed basis. Funding• Cost: $194,280.00 Source of funds: Capital Project Funds (Self Financed Utility) Outside Resources: GSWW, Inc. Background Information: Currently, the Lower Colorado River Authority (LCRA) provides an I&I credit to the City for the regional wastewater lines that are owned by the LCRA and that extend thru the City to the treatment plant. The results of this flow monitoring study will provide information to the City that will verify if the current LCRA credit for I&I is accurate. If the results of the study indicate that more I&I is entering the system than previously determined, then additional credit should be provided to the City; therefore, reducing treatment cost. Public Comment: N/A EXECUTED DOCUMENT FOLLOWS ROUND ROCK,TEXAS P POCF P45�10A PHOSYfIiiTl CITY OF ROUND ROCK CONTRACT FOR ENGINEERING SERVICES FIRM: GSWW, Inc. ("Engineer") ADDRESS: 1016 Mopac Circle, Suite 201, Austin, TX 78746 - PROJECT: I&I FLOW MONITORING STUDY THE STATE OF TEXAS § COUNTY OF WILLIAMSON § TLIIS CONTRACT FOR ENGINEERING SERVICES ("Contract") is made and entered into on this the ay of Ep p6k, , 2004 by and between the CITY OF ROUND ROCK, a Texas home- rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664-5299, (hereinafter referred to as "City"), and Engineer, and such Contract is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW, THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: Engineering Services Contract- Rev.09/07/04 File Name: gsww-I&Iflowmonitoring;76569 00064494 1 CONTRACT DOCUMENTS The Contract Documents consist of this Contract and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Contract) and all Supplemental Contracts (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Contract as if attached to this Contract or repeated herein. ARTICLE 1 CITY SERVICES City shall perform or provide services as identified in Exhibit A entitled "City Services." ARTICLE 2 ENGINEERING SERVICES Engineer shall perform Engineering Services as identified in Exhibit B entitled "Engineering Services." Engineer shall perform the Engineering Services in accordance with the Work Schedule as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineering Services under this Contract may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all Engineering Services. Should the review times or Engineering Services take longer than shown on the Work Schedule, through no fault of Engineer, Engineer may submit a timely written request for additional time, which shall be subject to the approval of the City Manager. ARTICLE 3 CONTRACT TERM (1) Term. The Engineer is expected to complete the Engineering Services described herein in accordance with the above described Work Schedule. If Engineer does not performed the Engineering Services in accordance with the Work Schedule, then City shall have the right to terminate this Contract as set forth below in Article 20. So long as the City elects not to terminate this Contract, it shall continue from day to day until such time as the Engineering Services are completed. Any Engineering Services performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably anticipates, that the Engineering Services will not be completed in accordance with the Work Schedule. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of Engineering Services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all Engineering Services required under this Contract in a professional manner. 2 (3) Notice to Proceed. After execution of this Contract, Engineer shall not proceed with Engineering Services until authorized in writing by City to proceed as provided in Article 7. ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for the Engineering Services performed and to be performed under this Contract. The amount payable under this Contract, without modification of the Contract as provided herein, is the sum of One Hundred Ninety-four Thousand Two Hundred Eighty&No/100 Dollars ($ 194,280.00 ) as shown in Exhibit D. The lump sum amount payable shall be revised equitably only by written Supplemental Contract in the event of a change in Engineering Services as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the Engineering Services and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B. Satisfactory progress of Engineering Services shall be an absolute condition of payment. The fee herein referenced may be adjusted for additional Engineering Services requested and performed only if approved by written Supplemental Contract. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer shall be made while Engineering Services are in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of Engineering Services accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of Engineering Services identified in Exhibit D. Progress payments shall be made by City based upon Engineering Services actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her/its negligence. 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the Engineering Services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Contract or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non-disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED The Engineer shall not proceed with any task listed on Exhibit B until the City has issued a written Notice to Proceed regarding such task. The City shall not be responsible for work performed or costs incurred by Engineer related to any task for which a Notice to Proceed has not been issued. ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Contract is as follows: Michael D. Thane, P.E. Engineering Manager 2008 Enterprise Drive Round Rock, Texas 78664 Telephone Number(512) 218-3236 Fax Number(512) 218-5563 Email Address mthane@round-rock.tx.us 4 City's Designated Representative shall be authorized to act on City's behalf with respect to this Contract. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineering Services. Engineer's Designated Representative for purposes of this Contract is as follows: David Koberlein, P.E. Associate 1016 Movac Circle, Suite 201 Austin, TX 78746 Telephone Number (512) 306-9266 Fax Number (512) 306-9550 Email Address kdavid@gsw-inc.com ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the Engineering Services, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the Engineering Services. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of the Engineering Services. Should City determine that the progress in Engineering Services does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the Engineering Services, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to meet the objectives of the Work Schedule, or preclude the attainment of project Engineering Services units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the Work Schedule goals sooner than anticipated. 5 ARTICLE 10 SUSPENSION Should City desire to suspend the Engineering Services, but not to terminate this Contract, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty-day notice may be waived in writing by agreement and signature of both parties. The Engineering Services may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the Engineering Services. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If this Contract is suspended for more than thirty (30) days, Engineer shall have the option of terminating this Contract. If City suspends the Engineering Services, the contract period as determined in Article 3, and the Work Schedule, shall be extended for a time period equal to the suspension period. City assumes no liability for Engineering Services performed or costs incurred prior to the date authorized by City for Engineer to begin Engineering Services, and/or during periods when Engineering Services is suspended, and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL ENGINEERING SERVICES If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is beyond the scope of this Contract and as such constitutes extra work, he/she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Contract will be executed between the parties as provided in Article 13. Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Contract. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the Engineering Services authorized in this Contract or any amendments thereto. ARTICLE 12 CHANGES IN ENGINEERING SERVICES If City deems it necessary to request changes to previously satisfactorily completed Engineering Services or parts thereof which involve changes to the original Engineering Services or character of Engineering Services under this Contract, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional Engineering Services and paid for as specified under Article 11. Engineer shall make revisions to Engineering Services authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such Engineering Services. 6 ARTICLE 13 SUPPLEMENTAL CONTRACTS The terms of this Contract may be modified by written Supplemental Contract if City determines that there has been a significant change in (1) the scope, complexity or character of the Engineering Services, or (2) the duration of the Engineering Services. Any such Supplemental Contract must be duly authorized by the City. Engineer shall not proceed until the Supplemental Contract has been executed. Additional compensation, if appropriate, shall be identified as provided in Article 4. It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until the City authorizes full execution of the written Supplemental Contract and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Contract are the exclusive property of City and shall be furnished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Contract. Engineer, at its own expense, may retain copies of such documents or any other data which it has furnished City under this Contract. ARTICLE 15 PERSONNEL,EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services, and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the Engineering Services shall immediately be removed from association with the project when so instructed by City. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the Engineering Services under this Contract without prior written approval from City. All subcontracts shall include the provisions required in this Contract and shall be approved as to form, in writing, by City prior to Engineering Services being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Contract. 7 ARTICLE 17 EVALUATION OF ENGINEERING SERVICES City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the Engineering Services performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Contract may be terminated as set forth below. (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the Engineering Services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all Engineering Services and obligations described herein. Should City terminate this Contract as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the Engineering Services performed by Engineer prior to termination, City shall be the sole judge. Compensation for Engineering Services at termination will be based on a percentage of the Engineering 8 Services completed at that time. Should City terminate this Contract under Subsection (4) immediately above, then the amount charged during the thirty-day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Contract or if City terminates this Contract for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the Engineering Services to the date of default, the amount of Engineering Services required which was satisfactorily completed to date of default, the value of the Engineering Services which are usable to City, the cost to City of employing another firm to complete the Engineering Services required and the time required to do so, and other factors which affect the value to City of the Engineering Services performed at the time of default. The termination of this Contract and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Contract, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Contract is due to the failure of Engineer to fulfill his/her/its contractual obligations, then City may take over the project and prosecute the Engineering Services to completion. In such case, Engineer shall be liable to City for any additional and reasonable costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the Engineering Services under this Contract. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Contract, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her/its compliance. Engineer shall further obtain all permits and licenses required in the performance of the Engineering Services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the Engineering Services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this Contract, which are caused by or which result from the negligent error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. 9 Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such negligent activities by Engineer, its agents, or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her/its Engineering Services and shall promptly make necessary revisions or corrections to its work product resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions in its work product, or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON-COLLUSION,FINANCIAL INTEREST PROHIBITED (1) Non-collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Contract, and that he/she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City reserves and shall have the right to annul this Contract without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission,percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Contract is in effect professional liability insurance coverage in the minimum amount of One Million Dollars from a company authorized to do insurance business in Texas and otherwise 10 acceptable to City. Engineer shall also notify City, within twenty-four (24) hours of receipt, of any notices of expiration, cancellation, non-renewal, or material change in coverage it receives from its insurer. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Contract to maintain during the term of this Contract, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional policy conditions as shown below in Article 26, Section (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Contract, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: (a) Each policy shall require that thirty (30) days prior to the expiration, cancellation, non- renewal or reduction in limits by endorsement a notice thereof shall be given to City by certified mail to: City Manager, City of Round Rock 221 East Main Street Round Rock, Texas 78664 (b) The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self-Insured Retentions of whatever nature. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit E herein entitled "Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. 11 ARTICLE 28 SUCCESSORS AND ASSIGNS This Contract shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Contract, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Contract shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Contract shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Contract constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Contract may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Contract. ARTICLE 32 NOTICES All notices to either party by the other required under this Contract shall be personally delivered or mailed to such party at the following respective addresses: City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 12 and to: Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: David Koberlein, P.E. Associate GSWW, Inc. 1016 Movac Circle, Suite 201 Austin, TX 78746 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the Engineering Services for each phase of this Contract within the agreed Work Schedule may constitute a material breach of this Contract. Engineer shall be fully responsible for his/her/its delays or for failures to use his/her/its reasonable efforts in accordance with the terms of this Contract and the Engineer's standard of performance as defined herein. Where damage is caused to City due to Engineer's negligent failure to perform City may accordingly withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Contract if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Contract shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Contract shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. (4) Standard of Performance. The standard of care for all professional engineering, consulting and related services performed or furnished by Engineer and its employees under this Contract will be the care and skill ordinarily used by members of Engineer's profession practicing under the same or similar circumstances at the same time and in the same locality. Excepting Articles 25 and 34 herein, Engineer makes no warranties, express or implied, under this Contract or otherwise, in connection with the Engineering Services. 13 (5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer's experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s') methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual project or construction cost will not vary from opinions of probable cost Engineer prepares. (6) Opinions and Determinations. Where the terms of this Contract provide for action to be based upon opinion,judgment, approval, review, or determination of either party hereto, such terms are not intended to be and shall never be construed as permitting such opinion,judgment, approval, review, or determination to be arbitrary, capricious, or unreasonable. ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Contract and that he/she has full and complete authority to enter into this Contract on behalf of the firm. The above-stated representations and warranties are made for the purpose of inducing City to enter into this Contract. IN WITNESS WHEREOF,the City of Round Rock has caused this Contract to be signed in its corporate name by its duly authorized City Manager or Mayor and Engineer, signing by and through its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF R R T S APP O ED AS TO tORM: By: �* Nyl ell, or Stepha L. Sheets, City Attorney ATTE T: By: Christine Martinez, City Secretary GSWW, I/n�c. BY: Signature of Principal Printed Name: PA✓ID /Gc7igC-2GEi,,� 14 LIST OF EXHIBITS ATTACHED (1) Exhibit A City Services (2) Exhibit B Engineering Services (3) Exhibit C Work Schedule (4) Exhibit D Fee Schedule (5) Exhibit E Certificates of Insurance 15 Exhibit A— City Services The CITY OF ROUND ROCK shall provide the following information and services: 1. One reproducible print of the existing sewer system showing the location and size of existing sewer lines, manholes, lift stations, and other pertinent topographic information such as right-of-way lines, street names, etc. This information shall also be provided in an electronic format, if available. 2. Liaison with THE CITY OF ROUND ROCK to provide effective coordination and cooperation between the fire, police, security, and traffic control departments and GSWW, as necessary during execution of field work. 3. Access to manholes and/or lift stations. 4. Assistance by THE CITY OF ROUND ROCK, knowledgeable of manhole and cleanout locations, in locating buried or hidden manholes and cleanouts. 5. Expose for entry, manholes that require excavation, cutting of pavement, and/or have lids fastened or frozen in place. 6. Provide manhole and/or pipeline cleaning if required for meter installation (prior to meter installation) or allow a reasonable and customary additional charge for GSWW to perform the line cleaning or have this task performed by others. Page 1 Exhibit B — Engineering Services Background This project will consist of the performance of certain field tasks relative to field installation, maintenance, calibration, and data collection for six (6) velocity-depth style wastewater flow monitors and related data analysis. Formatting of the collected data and engineering evaluation and wet and dry weather analysis of the collected data is also presented. The final product will result in a written report outlining the findings from the data collection exercise and engineering evaluations. Task 100 - Preparatory Work, Project Kick-off Meeting,and Site Investigation This task consists of the following items, all of which are customary and necessary to the success of the overall project: • Printing of all field forms and preparation of maps to be used for the field investigation portion of the project. • Project kickoff meeting to discuss the proposed locations of the flow monitoring points and alternative monitoring points, rain gage locations, public relations requirements, any additional security and safety requirements for The City of Round Rock, work hours, field reporting requirements, and traffic control requirements. • Transportation of the appropriate personnel and equipment to the project site. • Procedures for use in case a primary flow monitoring site is found to be undesirable for flow monitoring based on site hydraulics, traffic issues, site conditions, etc. In the case where an alternative site is desirable, GSWW will notify the City of Round Rock of the conditions at the primary monitoring site that make it an undesirable flow-monitoring site and suggest alternatives. The compensation for this task shall be on a lump sum basis. Task 200 — Flow Monitor Installation, Maintenance, Calibration, Data Collection, and Equipment Removal This task provides for the installation, maintenance, calibration, data collection and equipment removal of flow metering equipment. The installation of the flow metering equipment shall begin at the direction of the City of Round Rock and will be completed within two weeks of receipt of approval of the flow monitoring sites determined under Task 100. Each meter will be field calibrated prior to installation. Calibration of each meter will consist of an independent verification of the flow depth and velocity. The flow sensors will be secured to a mounting band that fits snugly in the pipeline. The data logger for each site will then be installed and secured in the top of each manhole. The sampling interval for the data loggers shall be two (2) minutes and the data shall be stored in 15-minute increments. Written logs of each site visit will be maintained and will be used to record date and time of visit, meter velocity and depth reading, corresponding independent velocity and depth reading, and maintenance items such as battery voltage, etc. Routine maintenance and service will be undertaken on a seven (7) day Page 1 cycle to confirm normal operation during the first 60 days of the monitoring period and on a 14- day cycle for the remainder of the monitoring period. The metering equipment will be capable of recording flow under surcharged conditions During collection, data from each unit will be uploaded in the field to an electronic data collection device. Each data transfer unit will then be uploaded to the central project computer in the office for data integrity checks. Data integrity checks shall be performed to ensure that the flow meters are operating within manufacturer's specified tolerances. Any meter found to be performing outside of specified tolerances will be diagnosed and the issues associated with the inaccurate readings will be resolved or the meter will be replaced. No additional compensation will be requested for this task. Assumptions: Rainfall gages will be installed by the CITY OF ROUND ROCK personnel at locations identified in Task 100. Rainfall gage data will be provided to GSWW in electronic format(txt, csv, or Microsoft Excel) with a logged interval of 15-minutes. The data will provided on a 14-day cycle corresponding with the flow monitoring data. The compensation for this task shall be on a "per meter day" basis for the 12-month monitoring period. Task 300—Monthly Technical Memorandum This task provides for the delivery of the collected flow and rainfall data to the CITY OF ROUND ROCK and the preparation of a monthly brief technical memorandum including data summary, conditions found in the field, data integrity issues, site maintenance and calibration data for each monitored site. One (1) hardcopy and four (4) electronic copies of the brief technical memorandum and data will be delivered to the CITY OF ROUND ROCK monthly. The compensation for this task shall be on a monthly basis. Task 400—Data Formatting, Engineering Analysis and Reporting This task provides for the formatting and engineering analysis of the collected flow and rainfall data and development of an engineering report. The following data will be provided for each metering site, in 15-minute increments: • Average daily flow for dry weather • Peak flow for dry weather • Average daily flow for wet weather • Peak flow for wet weather • Peak inflow rates • Total quantity of inflow and infiltration The final report will include the following information as a minimum: • Development of discrete flow data for each metering site • Development of the volume of inflow/infiltration estimates • Ranking of each sub basin by severity of inflow/infiltration • Hydrographs and tabular listings of the flow and rainfall data • Locations of flow metering stations • Location of rainfall gages • Monitored rainfall data by gage location by storm event Page 2 • Standard wastewater flow parameters by flow meter, including average and peak flow for dry weather, average and peak flow for wet weather, peak inflow rates, total inflow/infiltration volumes, and design storm projected flows • Hydrographs for each flow meter station (Overall metering period and one-week hydrographs) • Summary tables of recorded rain events • Location map depicting the location of the rainfall gages in the study area • Equipment maintenance logs Five (5) hardcopies and five (5) electronic copy of the report and data will be delivered to the CITY OF ROUND ROCK, no later than 30 days after the completion of the flow monitoring period. The compensation for this task shall be on a"per meter per month"basis. Task 500—Relocation of Flow Monitoring Equipment(Optional) This task consists of the relocation of flow monitoring equipment and development of additional wastewater flow parameters based on the requirements of the CITY OF ROUND ROCK. The project team desires to have a facility by which flow-monitoring equipment can be relocated to other portion of the collection system during the flow-monitoring period. This task is included to compensate for additional site investigations (if required), removal, reinstallation, and recalibration of the flow monitors and the additional engineering and data management associated with each relocated flow monitor. The Project Team will provide sufficient notice (7 days)to GSWW to move a meter. The compensation for this task shall be on a"per meter"basis. Task 600—Training (Optional) This task will include two eight (8) hour training periods on meter operation, maintenance, data collection, reduction, quality assurance and evaluation. The training sessions will performed at a monitoring site (field training) or at a CITY OF ROUND ROCK conference facility (classroom training). Flow monitoring site training will include meter maintenance, calibration, diagnostics and data collection. Classroom training will include flow meter software, data reduction and evaluation instruction. In addition to the classroom training, CITY OF ROUND ROCK personnel will be invited to join our field crews during meter maintenance and data collection activities during the contract period. This will afford CITY OF ROUND ROCK personnel an opportunity to observe and participate during actual field operations. Compensation for this task shall be per each eight(8) hour training session. Page 3 Exhibit C —Work Schedule The work will be initiated within one week of receipt of Authorization to Proceed by the CITY OF ROUND ROCK. Monitoring equipment shall be installed within two weeks of the completion of Task 100. Work for Tasks 200-600 will be completed within thirteen (13) months of the project initiation, unless extended for monitoring is initiated. Page 1 Exhibit D — Fee Schedule The total estimated compensation to provide all services described under the Scope of Work including the necessary equipment and supplies is ONE HUNDRED AND EIGHTY - FOUR THOUSAND EIGHT HUNDRED EIGHTY DOLLARS ($184,880.00) not including optional tasks. The compensation amount is based on the estimated work unit quantities delineated under the Scope of Work and the quantities outlined herein. It should be noted that the quantities outlined in this contract are estimated based on the best available information and may vary from the actual quantities found during field investigations. In no case will the total contract amount exceed ONE HUNDRED AND NINETY - FOUR THOUSAND TWO HUNDRED EIGHTY DOLLARS ($194,280.00), including optional tasks without prior written authorization from the CITY OF ROUND ROCK. Invoices will be rendered monthly and due within thirty (30) days. Invoices will be computed based on the quantities of work completed to date, multiplied by the unit price for that work and/or percentage of task completion. Table 1—Compensation for Basic and Optional Tasks Task Description Unit Unit Cost Estimated Extended Quantity Cost 100 Preparatory Work, Project Kick-off Lump $2,000.00 1 $2,000.00 Meeting, and Site Investigation Sum Flow Monitor Installation, Meter- 200 Maintenance, Calibration, Data Day $60.00 2,160 $129,600.00 Collection and Equipment Removal 300 Monthly Technical Memorandum Month $950.00 12 $11,400.00 400 Data Formatting, Engineering Analysis Meter- $3 and Reporting Month 1490.00 12 $41,880.00 Total w out Options: 184 880.00 500 Relocation of Flow Monitoring Meter Equipment O tional $1,200.00 2 $2,400.00 600 Software Training (8 hour session) - Each Optional $3,000.00 1 $3,000.00 601 Equipment Installation and Calibration Each $4,000.00 1 $4,000.00 Training8 hour session —Optional Total Options: $9,400.00 Tota/wl Options., , 194280.00 Extended Metering Rate is$52.65 per meter per day. To be performed at the City's discretion. * Optional Task A lease/purchase option is available to the CITY OF ROUND ROCK under this contract for purchase of the temporary flow monitoring equipment used to collect data for this project. In order to exercise this option, THE CITY OF ROUND ROCK will be required to notify (in writing) GSWW within one (1) month of the expiration of the basic 12-month flow monitoring period. If exercised, GSWW will apply 70% (based on manufacturer policy) of the per meter rental paid to GSWW (as a portion of the daily meter compensation) to the purchase price of the meter, up to the purchase price of a particular meter. The purchase price of the meter shall be made available Page 1 to the CITY OF ROUND ROCK within one (1) month of the basic 12 month metering period. The purchase price is dependent upon the manufacturer, model, and accessories installed at a particular location and will not be finally determined until the completion of Task 200 activities. Page 2 EXHIBIT E Certificates of Insurance CERTIFICATE OF LIABILITY INSURANCE Date: 11/03/04 PROFESSIONAL SERVICES PRODUCER COMPANIES AFFORDING COVERAGE McLaughlin Brunson Insurance Agency 9535 Forest Lane, #118 A Liberty Insurance Underwriters, Inc. Dallas, Texas 75243 B INSURED GSWW, Inc. C 11117 Shady Trail Dallas, Texas 75229 D THIS IS TO CERTIFY THAT the Insured named above is insured by the Companies listed above with respect to the business operations hereinafter described, for the types of insurance and in accordance with the provisions of the standard policies used by the companies, and further hereinafter described. Exceptions to the policies are noted below. CO TYPE OF INSURANCE POLICY EFFECTIVE EXPIRATION LIMITS LTR NUMBER DATE DATE A PROFESSIONAL LIABILITY AEE197283-0104 7/15/2004 7/15/2005 $1,000,000 Per Claim/Annl Agg. DESCRIPTION OF SPECIAL ITEMS/EXCEPTIONS The claims made professional liability coverage is the total aggregate limit for all claims presented within the policy period and is subject to a deductible. Should any of the above described policies be cancelled or changed before the expiration date thereof, the issuing company will mail thirty (30)days written notice to the certificate holder named below. CERTIFICATE HOLDER: City of Round Rock 221 E. Main Street Round Rock, Texas 78664 attn: Christine Martinez, City Secretary SIGNATURE OF AUTHORIZED REPRESENTATIVE Qac P- Typed Name: Patrick P. McLaubhlin Title: Agent Rev'd 2/10/03-Professional Liability Certificate.doc