Loading...
R-03-10-23-11E2 - 10/23/2003RESOLUTION NO. R -03-10-23-11E2 WHEREAS, the City of Round Rock desires to retain engineering services for the design of the Barton Hill 2MG Elevated Water Tank Improvements, and WHEREAS, HDR Engineering, Inc. has submitted an Agreement for Engineering Services to provide said services, and WHEREAS,. the City Council desires to enter into said agreement with HDR Engineering, Inc., Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK,TEXAS, That the Mayor is hereby authorized and directed to execute on behalf of the City an Agreement for Engineering Services with HDR Engineering, Inc. for the design of the Barton Hill 2MG Elevated Water Tank Improvements, a copy of said agreement being attached hereto as Exhibit "A" and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date, hour, place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. RESOLVED this 23rd day of October, 2003. ATT N' Lu� • W LL, Mayor City of Round Rock, Texas CHRISTINE R. MARTINEZ, City Secretary 0:\wdox\RESOLUTI\R31023E2.WPD/sc CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH HDR ENGINEERING, INC. FOR BARTON HILL ELEVATED WATER TANK IMPROVEMENTS THE STATE OF TEXAS COUNTY OF WILLIAMSON THIS AGREEMENT FOR ENGINEERING SERVICES ("Agreement") is made and entered into on this the day of the month of , 2003, by and between the CITY OF ROUND ROCK, a Texas home -rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664-5299, (hereinafter referred to as "City"), and HDR ENGINEERING, INC., whose principal place of business is located at 2211 South IH -35, Suite 300, Austin, TX 78741, (hereinafter called "Engineer"), and such Agreement is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW, THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: CONTRACT DOCUMENTS The Contract Documents consist of this Agreement and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Agreement) and all Supplemental Agreements (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Agreement as if attached to this Agreement or repeated herein. 56659 File name: Revised -Barton Hill Tank-agrmt-HDR-10-03.d. EXHIBIT Engineering Sery Agreement Rev.4/1/03 ARTICLE 1 SCOPE OF SERVICES TO BE PERFORMED BY CITY City shall perform or provide services as identified in Exhibit A entitled "Services to be Performed by City." ARTICLE 2 SCOPE OF SERVICES TO BE PERFORMED BY ENGINEER Engineer shall perform engineering services as identified in Exhibit B entitled "Services to be Performed by Engineer." Engineer shall develop a mutually acceptable schedule of work as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineer's Scope of Services under this Agreement may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all work performed. Should the review times take longer than shown on the Work Schedule, through no fault of Engineer, additional time may be authorized by City through a written Supplemental Agreement only if same is requested by a timely written request from Engineer which is approved by City. ARTICLE 3 CONTRACT TERM (1) Term. This Agreement shall be from the date hereof and shall terminate at the close of business on the 31st day of the month of December, 2004, unless extended by written Supplemental Agreement executed by Engineer and City prior to the date of termination, or as otherwise terminated as provided in Article 20 entitled "Termination." Any work performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably anticipates, that the work under this Agreement will not be completed before the termination date. In that event City may, at its sole discretion, extend the contract term by timely written Supplemental Agreement. Engineer shall allow adequate time for review and approval of his/her/its request for time extension by City prior to expiration of this Agreement. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all services required under this Agreement in a professional manner. (3) Notice to Proceed. After execution of this Agreement, Engineer shall not proceed with work delineated in Article 2 entitled "Scope of Services to be Performed by Engineer" and in Exhibit B Rev. 4/1/03 2 entitled "Services to be Performed by Engineer" until authorized in writing by City to proceed as provided in Article 7 entitled "Notice to Proceed." ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for all engineering services performed and to be performed under this Agreement. The amount payable under this Agreement, without modification of the Agreement as provided herein, is the sum of eighty-four thousand one hundred forty-seven dollars ($84,147.00) as shown in Exhibit D entitled "Fee Schedule." The total amount payable may be revised only by written Supplemental Agreement in the event of a change in scope, additional complexity from that originally anticipated, or change in character of work as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the work and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B entitled "Services to be Performed by Engineer." Satisfactory progress of work shall be maintained as an absolute condition of payment. The fee herein referenced may be adjusted for additional work requested and performed only if approved by written Supplemental Agreement. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer for services rendered shall be made while work is in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of work accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of work tasks identified in Exhibit D entitled "Fee Schedule." Progress payments shall be made by City based upon work actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which, notwithstanding anything herein to the contrary, is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory work performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. Rev. 4/1/03 3 The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her/its negligence. ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which City receives the supplies, materials, equipment, or within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for the supplies, materials, equipment, or services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply to payments made by City in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Agreement or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non -disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED City shall issue a written authorization to proceed with work identified in the Scope of Services. City shall not be responsible for actions by Engineer or any costs incurred by Engineer relating to additional work not included in Exhibit B entitled "Services to be Performed by Engineer." Rev. 4/1/03 4 ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Agreement is as follows: Don M. Rundell, P.E. 2008 Enterprise Drive Round Rock, Texas 78664 Telephone Number: (512) 218-5554 Fax Number: (512) 218-5563 Email Address: drundell@round-rock.tx.us City's Designated Representative shall be authorized to act on City's behalf with respect to this project. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineer's services. Engineer's Designated Representative for purposes of this Agreement is as follows: James K. Haney, P.E. HDR Engineering, Inc. 2211 South IH -35, Suite 300 Austin, TX 78741 Telephone Number: 512-912-5100 Fax Number: 512-345-5158 Email Address: ken.haney@hdrinc.com ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the work, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the work. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of Engineer's services and work. Should City determine that the progress in production of work does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the work, including but not limited to the following: Rev. 4/1/03 5 (1) Problems, delays, adverse conditions which may materially affect the ability to attain program objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the work schedule goals sooner than anticipated. ARTICLE 10 SUSPENSION Should City desire to suspend the work, but not to terminate this Agreement, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty -day notice may be waived in writing by agreement and signature of both parties. The work may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the work. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If City suspends the work, the contract period as determined in Article 3 is not affected and this Agreement will terminate on the date specified unless this Agreement is amended indicating otherwise. City assumes no liability for work performed or costs incurred prior to the date authorized by City for Engineer to begin work, and/or during periods when work is suspended, and/or subsequent to the contract completion date. Engineer's compensation will be equitably adjusted in the event its costs increase due to suspension and resumption of the work by the City, or other delay not caused by Engineer. ARTICLE 11 ADDITIONAL WORK If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is beyond the scope of this Agreement and as such constitutes extra work, he/she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Agreement will be executed between the parties as provided in Article 13 entitled "Supplemental Agreements." Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Agreement. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the work authorized in this Agreement or any amendments thereto. ARTICLE 12 CHANGES IN WORK If City deems it necessary to request changes to previously satisfactorily completed work or Rev. 4/1/03 6 parts thereof which involve changes to the original scope of services or character of work under this Agreement, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional work and paid for as specified under Article 11 entitled "Additional Work." Engineer shall make revisions to work authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such work. ARTICLE 13 SUPPLEMENTAL AGREEMENTS The terms of this Agreement may be modified by written Supplemental Agreement if City determines that there has been a significant change in (1) the scope, complexity or character of the service to be performed, or (2) the duration of the work. Any such Supplemental Agreement must be duly authorized by City Council Resolution. Where such City Council authorization is required, Engineer shall not proceed until the appropriate Resolution has been adopted. Additional compensation, if appropriate, shall be identified as provided in Article 4 entitled "Compensation." Both parties must execute any written Supplemental Agreement within the contract period specified in Article 3 entitled "Contract Term." It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until City grants full execution of the written Supplemental Agreement and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory work performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Agreement are the exclusive property of City and shall be furnished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Agreement. Engineer, at his/her/its own expense, may retain copies of such documents or any other data which he/she/it has furnished City under this Agreement. Any release of information shall be in conformance with requirements of the Texas Open Records Act. ARTICLE 15 PERSONNEL, EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at his/her/its own expense, quarters for the performance of all services, and adequate and sufficient personnel and equipment to perform the services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform Rev. 4/1/03 7 the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the work shall immediately be removed from association with the project when so instructed by City. Engineer certifies that he/she/it presently has adequate qualified personnel in his/her/its employment for performance of the services required under this Agreement, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the work under this Agreement without prior written approval from City. All subcontracts shall include the provisions required in this Agreement and shall be approved as to form, in writing, by City prior to work being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Agreement. ARTICLE 17 EVALUATION OF WORK City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the work performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Agreement, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Agreement may be terminated before the stated termination date by any of the following conditions. Rev. 4/1/03 8 (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all services and obligations described herein. Should City terminate this Agreement as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the work performed by Engineer prior to termination, City shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should City terminate this Agreement under Subsection (4) immediately above, then the amount charged during the thirty -day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Agreement or if City terminates this Agreement for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the work to the date of default, the amount of work required which was satisfactorily completed to date of default, the value of the work which is usable to City, the cost to City of employing another firm to complete the work required and the time required to do so, and other factors which affect the value to City of the work performed at the time of default. The termination of this Agreement and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Agreement, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Agreement is due to the failure of Engineer to fulfill his/her/its contractual obligations, then City may take over the project and prosecute the work to completion. In such case, Engineer shall be liable to City for any additional and reasonable costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the scope of services under this Agreement. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Agreement, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her/its Rev. 4/1 /03 9 compliance. Engineer shall further obtain all permits and licenses required in the performance of the professional services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this Agreement, which are caused by or which result from the negligent error, omission, or act of Engineer or of any person employed by Engineer or under Engineer's direction or control. Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such activities by Engineer, its agents, or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her/its work and shall promptly make necessary revisions or corrections resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed. "Errors" and "omissions" as the terms are used in this Article shall mean violations of the standard of performance contained in Article 33, section 4, of this Agreement ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. Rev. 4/1/03 10 ARTICLE 25 NON -COLLUSION, FINANCIAL INTEREST PROHIBITED (1) Non -collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Agreement, and that he/she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City reserves and shall have the right to annul this Agreement without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Agreement is in effect professional liability insurance coverage in the minimum amount of One Million Dollars from a company authorized to do insurance business in Texas and otherwise acceptable to City. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Agreement to maintain during the term of this Agreement, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional policy conditions as shown below in Article 26, Section (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Agreement, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: 1. Each policy shall require that thirty (30) days prior to the expiration, cancellation, non- renewal or any change in the limit or scope of coverage, a notice thereof shall be given to City by certified mail to: City Manager, City of Round Rock 221 East Main Street Round Rock, Texas 78664 Rev. 4/1/03 11 Engineer shall also notify City, within 24 hours of receipt, of any notices of expiration, cancellation, non -renewal, or material change in coverage it receives from its insurer. 2. Companies issuing the insurance policies shall have no recourse against City for payment of any premiums or assessments for any deductibles which are the sole responsibility of and at the sole risk of Engineer. 3. City shall be an additional insured on Engineer's insurance policies other than professional liability and workers' compensation. For the purposes of this paragraph, the term "City" or "City of Round Rock" shall include all authorities, boards, commissions, departments, and officers of City and the individual members and employees thereof in their official capacities, and/or while acting on behalf of the City of Round Rock. 4. The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self -Insured Retentions of whatever nature. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit F herein entitled "Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty -free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. ARTICLE 28 SUCCESSORS AND ASSIGNS This Agreement shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Agreement, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. Rev. 4/1/03 12 ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Agreement constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Agreement may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Agreement. ARTICLE 32 NOTICES All notices to either party by the other required under this Agreement shall be personally delivered or mailed to such party at the following respective addresses: City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 and to: Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: James K. Haney, P.E. HDR Engineering, Inc. 2211 South IH -35, Suite 300 Austin, TX 78741 13 Rev. 4/1/03 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the services for each phase of this Agreement within the agreed Work Schedule may constitute a material breach of this Agreement. Engineer shall be fully responsible for his/her/its delays or for failures to use his/her/its best efforts in accordance with the terms of this Agreement and the Engineer's standard of performance defined herein. Where damage is caused to City due to Engineer's failure to perform accordingly, City may withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Agreement if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Agreement shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Agreement shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. (4) Standard of Performance. The standard of care for all professional engineering, consulting and related services performed or furnished by Engineer and its employees under this Agreement will be the care and skill ordinarily used by members of Engineer's profession practicing under the same or similar circumstances at the same time and in the same locality. Excepting Articles 25 and 34 herein, Engineer makes no warranties, express or implied, under this Agreement or otherwise, in connection with Engineer's services. (5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer's experience and qualifications, and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s') methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual project or construction cost will not vary from opinions of probable cost Engineer prepares. This provision does not relieve Engineer of its obligation to render judgments about probable cost using the standard of care described in the preceding paragraph. (6) Opinions and Determinations. This Agreement shall not permit any opinion, judgment, approval, review, or determination of either party hereto to be arbitrary, capricious, or unreasonable. Rev. 4/1 /03 14 ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Agreement and that he/she has full and complete authority to enter into this Agreement on behalf of the firm. The above -stated representations and warranties are made for the purpose of inducing City to enter into this Agreement. IN WITNESS WHEREOF, the City of Round Rock has caused this Agreement to be signed in its corporate name by its Mayor, duly authorized to execute the same on its behalf by Resolution No. , approved by the City Council on the day of the month of , 2003, and Engineer, HDR Engineering, Inc., signing by and through his/her/its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK, TEXAS: By: Nyle Maxwell, Mayor ATTEST: By: Christine Martinez, City Secretary HDR ENGINEE ' NG, INC.: By: James K. Haney, P.E., its Acezedet vet pvraid '� 15 Rev. 4/1/03 LIST OF EXHIBITS ATTACHED (1) Exhibit A "Services to be Performed by City" (2) Exhibit B "Services to be Performed by Engineer" (3) Exhibit C "Work Schedule" (4) Exhibit D "Fee Schedule" (5) Exhibit E "Work Authorizations" (6) Exhibit F "Certificates of Insurance" Rev. 4/ 1 /03 16 ATTACHMENT A SERVICES TO BE PROVIDED BY THE City The City of Round Rock shall furnish to the Engineer the following items, information, and assistance: 1. Provide timely review of requests for information, change proposal requests, change orders, pay applications and as -built drawings. 2. Provide on-site construction inspection services. 3. Provide and coordinate construction materials testing. 4. Attend construction progress meetings and phase kickoff meetings. 1 ATTACHMENT B SERVICES TO BE PROVIDED BY THE Engineer DESIGN PHASE and DESIGN PHASE 1. These services were completed in the Agreement authorized by Resolution R -01-08-09-13E3. CONSTRUCTION PHASE 1. Consult with and advise City as set forth herein and as provided in the General Conditions and Supplementary General Conditions of the Contract for Construction included in the Contract Documents for the project. The extent and limitations of the duties and responsibilities of Engineer as assigned in said Contract Documents shall not be modified, except as Engineer may otherwise agree in writing. City shall issue all instructions to the contractor performing the Work (hereinafter called "Contractor") except as otherwise provided in writing. 2. Make periodic visits to the site to observe the progress and quality of the executed work and to determine in general if the work is proceeding in accordance with the Contract Documents. In performing this service, the Engineer will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the work or material; he will not be responsible for the techniques and sequences of construction or the safety precautions incident thereto, and he will not be responsible or liable in any degree for the contractors' failure to perform the construction work in accordance with the Contract Documents. During visits to the construction site, and on the basis of the Engineer's on-site observations as an experienced and qualified design professional, he will keep the City informed of the extent of the progress of the work, and advise the City of material and substantial defects and deficiencies in the work of contractors which are discovered by the Engineer or otherwise brought to the Engineer's attention in the course of construction, and may, on behalf of the City, exercise whatever rights the City may have to disapprove work and materials as failing to conform to the Contract Documents. 3. Make recommendations to City concerning the disapproval or rejection of Contractors' Work while it is in progress if Engineer believes that such Work will not produce a completed project that conforms generally to the Contract Documents or that it will prejudice the integrity of the design concept of the project as reflected in the Contract Documents. Engineer shall have access to the Work at all times wherever it is in preparation or progress. 4. Consult and advise with the City; issue all instructions to the contractor requested by the City; and prepare routine change orders as required. 1 5. Evaluate and determine the acceptability of substitute materials and equipment proposed by Contractor. 6. Make recommendations to City regarding the advisability of requiring special inspections or testing of the Work and have City, for the purposes of this paragraph, receive and review all certificates of inspections, testing and approvals required by laws, rules, regulations, ordinances, codes, orders or the Contract Documents to determine generally that their content complies with the requirements of, and the results certified indicate compliance with, the Contract Documents. 7. Act as initial interpreter of the requirements of the Contract Documents, judge the acceptability of the Work and make decisions on all claims of City and Contractor relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the execution and progress of the Work. Engineer shall not be liable for the results of any such interpretations or decisions rendered in good faith. 8. Review samples, catalog data, schedules, shop drawings, laboratory, shop and mill tests of materials and equipment and other data which the contractor is required to submit, only for conformance with the design concept of the Project and compliance with the information given by the Contract Documents; and assemble written guarantees which are required by the Contract Documents. 9. Determine the amount owing to Contractor based on Engineer's observations at the site and the data comprising the Application for Payment, and recommend in writing payments to Contractor in such amounts. Such recommendations of payment will constitute a representation to City that the Work has progressed to the point indicated and that, to the best of Engineer's knowledge, information and belief, the quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, to results of subsequent tests and inspections of others, to minor deviations from the Contract Documents correctable prior to completion and to specific qualifications expressed by Engineer. The issuance of a recommendation will further constitute a representation that the Contractor is entitled to payment in the amount certified. However, the issuance of a recommendation for payment will not be a representation that the Engineer has (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work; (2) reviewed construction means, methods, techniques, sequences or procedures; (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the City to substantiate the Contractor's right to payment; or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Price. 10. Receive and review maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection and tests and approvals of equipment, which are to be provided by Contractor in accordance with the Contract Documents. Determine that their content 2 complies with the requirements of the Contract Documents and transmit them to City with written comments. 11. Conduct, in company with the City, a preliminary and a final inspection of the Project for assessing conformance with the design concept and compliance with the Contract Documents, determining the substantial completion date for the Project, and recommending final payment to the contractor in writing. 12. Revise contract drawings, with the assistance of the City's representative, to provide record drawings of the completed Project. Furnish one set of reproducible drawings, electronic files (AutoCAD 2000i on CD ROM), and two sets of prints of the record drawings to the City. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60 -day acceptance period will be corrected by the party delivering the electronic files. Engineer shall not be responsible to maintain documents stored in electronic media format after acceptance by the City. When transferring documents in electronic media format, Engineer makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by Engineer at the beginning of this Project. The City may make and retain copies of Documents for information and reference in connection with use on the Project by the City. Such Documents are not intended or represented to be suitable for reuse by the City or others on extensions of the Project or on any other project. Any such reuse or modification without written verification or adaptation by Engineer, as appropriate for the specific purpose intended, will be at the City's sole risk and without liability or legal exposure to Engineer or to Engineer's subconsultants. The City shall indemnify and hold harmless Engineer and Engineer's subconsultants from all claims, damages, losses, and expenses, including attorneys' fees arising out of or resulting there from. If there is a discrepancy between the electronic files and the hard copies, the hard copies will govern. 13. Compile, review, and comment on operation and maintenance manuals, which will be provided by Contractor in accordance with the Contract Documents. 14. Assist City staff during start-up of the project. The Engineer shall provide technical support and professional advice regarding any unforeseen problems with the operation and maintenance of the Project for a period of 1 year to the City. 3 ATTACHMENT C WORK SCHEDULE The Work Schedule is on the next page. Z I- LLI g O w c~l) J H IM n Y w 0 O 1- w re > 0 Z • J CO O= w V • C') w LL E in0 O P• ry N it - J O J Z 0 1- 0 0 N 0 z 0 Q 1 1 2 Q 2 LL M 0 0 N 0 Z 0 Q 2 Q 2 LL Construction Start-up and Testing 0 d 0 0 0 ' o L a C al 0) c - 3 L 0 . 0 a HDR Engineering, Inc. ATTACHMENT D FEE SCHEDULE The Fee Schedule is on the next page. so l so 1 City of Round Rock BARTON HILL 2.7 MG ELEVATED STORAGE TANK CONSTRUCTION PHASE SERVICES Budget Hours Task Description Meetings/Site Visit 40 Weeks Est. Project Duration 0.5 Site Visits per Week Hours per Visit Visit Time Allowance Pre -Construction Meeting Correspondence 2 Hours per Week Project Correspondence Administrative (monthly reports, files, biting, subcontract admin) Pay Applications 3 Hours per Contractor Payment Requests Submittal Review Hours per Shop Drawing Review 47 Shop Drawing Submittals Hours per O&M Manaul Review 7 O&M Manuals Hours per Misc. Or Resubmittal 11 Misc and Resubmittal Review (20%) Requests for Information and Field Orders Hours per Response 20 Responses Inspection - Preliminary & Final Start-up Observation and Advice Record Drawings - approx 20 sheets Close-out Document Review 11' lhti2ROMIAMW' Project Project Senior Project Admin. Principal Manager Engineer Engineer Technician Assist. Task Fee R,���.. '`✓,x„,,. .3 n i m: 11111112111S au. ,N,. 8 1 4 4 20 80 80 4 4 8 8 0.5 10 8 4 2 8 40 80 40 10 20 1 4 47 188 2 4 14 28 1 2 11 22 1 20 16 8 2 8 1 20 16 16 16 60 24 40 30 $20,500 $1,700 $7,600 $12,900 $3,000 0.5 23.5 $21,900 0.5 3.5 $4,300 0.5 5.5 $3,500 16 16 $5,800 $4,700 $3,600 $7,700 $4,700 TOTAL HOURS TOTAL DIRECT LABOR COST Hourly Rates 8 87 294 622 76 155 $65.00 $41.00 $43.00 $22.00 $29.00 $12.00 $101,900 !TOTAL LABOR FEE $101,900 Postage & Delivery Travel Expenses Miscellaneous Printing & Photocopying Printing of Record Sets Telephone Engineering Applications CADD Applications 10 Months $50.00 per month lump sum mileage 10 Months $50.00 per month 10 Months $0.10 per copy 10 Sets $100.00 per set 10 Months $100.00 per month 30 hours @ $10 76 hours @ $15 $500 $1,000 $500 200 copies/mn $200 $1,000 $1,000 $300 $1,100 TOTAL REIMBURSABLE DIRECT COSTS $5,600 !TOTAL NON_REIMBURSABLE DIRECT COSTS Baker Aicklen !TOTAL SUBCONSULTANTS !TOTAL CONSTRUCTION FEE $107,500 Estimated Construction: Percentage of Construction: $2,504,000 4.29 Amount Invoiced Under Agreement Authorized by Resolution R -01-08-09-13E3 !TOTAL CONSTRUCTION FEE $23,353 $84,147 ATTACHMENT E WORK AUTHORIZATIONS There are no Work Authorizations with the Agreement. ATTACHMENT F CERTIFICATES OF INSURANCE 1 CERTIFICATE OF LIABILITY INSURANCE Date: 10/1 /03 PROFESSIONAL SERVICES PRODUCER COMPANIES AFFORDING COVERAGE Lockton Companies 444 W. 47th Street, Suite 900 Kansas City, MO 64112-1906 INSURED HDR Engineering, Inc. 8404 Indian Hills Drive Omaha, NE 68114-4049 B C D Continental Casualty (V.O. Schinnerer) THIS IS TO CERTIFY THAT the Insured named above is insured by the Companies listed above with respect to the business operations hereinafter described, for the types of insurance and in accordance with the provisions of the standard policies used by the companies, and further hereinafter described. Exceptions to the policies are noted below. CO TYPE OF INSURANCE POLICY EFFECTIVE EXPIRATION LTR NUMBER DATE DATE LIMITS A PROFESSIONAL LIABILITY PLN113978408 6/1/03 6/1/04 Per Claim: $1,000,000 'Aggregate: $1,000,000 DESCRIPTION OF SPECIAL ITEMS/EXCEPTIONS RE: Barton Hill elevated storage tank. Should any of the above described policies be cancelled oncinged before the expiration date thereof, the issuing company will mail thirty (30) days written notice to the certificate holder named below. CERTIFICATE HOLDER: City of Round Rock 221 E. Main Street Round Rock, Texas 78664 attn: Christine Martinez, City Secretary Rev'd 2/10/03 - Professional Liability Certificate.doc SIGNATURE OF AUTHORIZED REPRESENTATIVE AdittAir mftwAi&Adildwir Typed Name: Grover S imp s on Title: President Proposed Location of 2.7 MG Tank ,,,> ovso�. S��NG� Water Plant Proposed Barton Hill Tank ROUND ROCK. TEXAS S/GRAPHICS/COUNCIL AGENDA ITEMS/PROPOSED BARTON HILL TANK RLR DATE: October 17, 2003 SUBJECT: City Council Meeting - October 23, 2003 ITEM: *11.E.2. Consider a resolution authorizing the Mayor to execute an Agreement for Engineering Services with HDR Engineering, Inc. for the design of the Barton Hill 2MG Elevated Water Tank Improvements. Resource: Tom Word, Chief of P. W. Operations Tom Clark, Director of Utilities History: HDR's 2001- East Transmission Line Preliminary Engineering Report, which modeled our water system demand scenarios at 31 MGD for Year 2005, 36.5 MGD for Year 2010 and 46.8 MGD for Year 2017 to determine what system improvements are required for each scenario. Based on these demand trends the timing of required system improvements was determined. Phase I, improvement a 48 -inch water line from the Water Treatment Plant to Barton Hill is currently under design. This Phase II improvements, a 36 -inch water line along Chandler Road and FM 1460 to Old Settlers Drive and a 2 million gallon elevated tank on Barton Hill, are to be in place by the Spring of 2003. This resolution is required, because the contract time was not extended prior to the original May 31, 2003 termination date. The project is under construction and scheduled to be completed mid-September 2004. The total fee for these professional services was $272,100.00 when approved by council on August 9, 2001. There are no additional funds or change of scope associated with this resolution. This resolution will extend the existing contract with a new termination date of December 31, 2004. Funding: Cost: $84,147.00 Source of funds: Capital Project Funds (Self -Financed Utility) Water Impact Fees and Transfer from Fund 24-LCRA Outside Resources: HDR Engineering, Inc. Impact/Benefit: To provide adequate storage, pumping, and distribution lines to the east side distribution system as defined in the Preliminary Engineering Report for the North-South Water Transmission Line, dated January 1999. Public Comment: N/A Sponsor: N/A Executed Document Follows CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH HDR ENGINEERING, INC. FOR BARTON HILL ELEVATED WATER TANK IMPROVEMENTS THE STATE OF TEXAS COUNTY OF WILLIAMSON THIS AGREEMENT FOR ENGINEEtIN ERVICES ("Agreement") is made and entered into on this the o33 - dayof the month of 2003, by and between the CITY OF ROUND ROCK, a Texas home -rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664-5299, (hereinafter referred to as "City"), and HDR ENGINEERING, INC., whose principal place of business is located at 2211 South 111-35, Suite 300, Austin, TX 78741, (hereinafter called "Engineer"), and such Agreement is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW, THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: CONTRACT DOCUMENTS The Contract Documents consist of this Agreement and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Agreement) and all Supplemental Agreements (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Agreement as if attached to this Agreement or repeated herein. 56659 File name: Revised -Barton Hill Tank-agrmt-HDR-10-03.doc R -03 -ho -e23 -116,2j Engineering Sery Agreement Rev.4/1/03 ARTICLE 1 SCOPE OF SERVICES TO BE PERFORMED BY CITY City shall perform or provide services as identified in Exhibit A entitled "Services to be Performed by City." ARTICLE 2 SCOPE OF SERVICES TO BE PERFORMED BY ENGINEER Engineer shall perform engineering services as identified in Exhibit B entitled "Services to be Performed by Engineer." Engineer shall develop a mutually acceptable schedule of work as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineer's Scope of Services under this Agreement may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all work performed. Should the review times take longer than shown on the Work Schedule, through no fault of Engineer, additional time may be authorized by City through a written Supplemental Agreement only if same is requested by a timely written request from Engineer which is approved by City. ARTICLE 3 CONTRACT TERM (1) Term. This Agreement shall be from the date hereof and shall terminate at the close of business on the 31St day of the month of December, 2004, unless extended by written Supplemental Agreement executed by Engineer and City prior to the date of termination, or as otherwise terminated as provided in Article 20 entitled "Termination." Any work performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably anticipates, that the work under this Agreement will not be completed before the termination date. In that event City may, at its sole discretion, extend the contract term by timely written Supplemental Agreement. Engineer shall allow adequate time for review and approval of his/her/its request for time extension by City prior to expiration of this Agreement. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all services required under this Agreement in a professional manner. (3) Notice to Proceed. After execution of this Agreement, Engineer shall not proceed with work delineated in Article 2 entitled "Scope of Services to be Performed by Engineer" and in Exhibit B Rev. 4/1/03 2 entitled "Services to be Performed by Engineer" until authorized in writing by City to proceed as provided in Article 7 entitled "Notice to Proceed." ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for all engineering services performed and to be performed under this Agreement. The amount payable under this Agreement, without modification of the Agreement as provided herein, is the sum of eighty-four thousand one hundred forty-seven dollars ($84,147.00) as shown in Exhibit D entitled "Fee Schedule." The total amount payable may be revised only by written Supplemental Agreement in the event of a change in scope, additional complexity from that originally anticipated, or change in character of work as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the work and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B entitled "Services to be Performed by Engineer." Satisfactory progress of work shall be maintained as an absolute condition of payment. The fee herein referenced may be adjusted for additional work requested and performed only if approved by written Supplemental Agreement. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer for services rendered shall be made while work is in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of work accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of work tasks identified in Exhibit D entitled "Fee Schedule." Progress payments shall be made by City based upon work actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which, notwithstanding anything herein to the contrary, is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory work performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. Rev. 4/1/03 3 The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her/its negligence. ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which City receives the supplies, materials, equipment, or within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for the supplies, materials, equipment, or services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply to payments made by City in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Agreement or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non -disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED City shall issue a written authorization to proceed with work identified in the Scope of Services. City shall not be responsible for actions by Engineer or any costs incurred by Engineer relating to additional work not included in Exhibit B entitled "Services to be Performed by Engineer." Rev. 4/1/03 4 ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Agreement is as follows: Don M. Rundell, P.E. 2008 Enterprise Drive Round Rock, Texas 78664 Telephone Number: (512) 218-5554 Fax Number: (512) 218-5563 Email Address: drundell@round-rock.tx.us City's Designated Representative shall be authorized to act on City's behalf with respect to this project. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineer's services. Engineer's Designated Representative for purposes of this Agreement is as follows: James K. Haney, P.E. HDR Engineering, Inc. 2211 South IH -35, Suite 300 Austin, TX 78741 Telephone Number: 512-912-5100 Fax Number: 512-345-5158 Email Address: ken.haney@hdrinc.com ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the work, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the work. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of Engineer's services and work. Should City determine that the progress in production of work does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the work, including but not limited to the following: Rev. 4/1/03 5 (1) Problems, delays, adverse conditions which may materially affect the ability to attain program objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the work schedule goals sooner than anticipated. ARTICLE 10 SUSPENSION Should City desire to suspend the work, but not to terminate this Agreement, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty -day notice may be waived in writing by agreement and signature of both parties. The work may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the work. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If City suspends the work, the contract period as determined in Article 3 is not affected and this Agreement will terminate on the date specified unless this Agreement is amended indicating otherwise. City assumes no liability for work performed or costs incurred prior to the date authorized by City for Engineer to begin work, and/or during periods when work is suspended, and/or subsequent to the contract completion date. Engineer's compensation will be equitably adjusted in the event its costs increase due to suspension and resumption of the work by the City, or other delay not caused by Engineer. ARTICLE 11 ADDITIONAL WORK If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is beyond the scope of this Agreement and as such constitutes extra work, he/she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Agreement will be executed between the parties as provided in Article 13 entitled "Supplemental Agreements." Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Agreement. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the work authorized in this Agreement or any amendments thereto. ARTICLE 12 CHANGES IN WORK If City deems it necessary to request changes to previously satisfactorily completed work or Rev. 4/1/03 6 parts thereof which involve changes to the original scope of services or character of work under this Agreement, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional work and paid for as specified under Article 11 entitled "Additional Work." Engineer shall make revisions to work authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such work. ARTICLE 13 SUPPLEMENTAL AGREEMENTS The terms of this Agreement may be modified by written Supplemental Agreement if City determines that there has been a significant change in (1) the scope, complexity or character of the service to be performed, or (2) the duration of the work. Any such Supplemental Agreement must be duly authorized by City Council Resolution. Where such City Council authorization is required, Engineer shall not proceed until the appropriate Resolution has been adopted. Additional compensation, if appropriate, shall be identified as provided in Article 4 entitled "Compensation." Both parties must execute any written Supplemental Agreement within the contract period specified in Article 3 entitled "Contract Term." It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until City grants full execution of the written Supplemental Agreement and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory work performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Agreement are the exclusive property of City and shall be furnished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Agreement. Engineer, at his/her/its own expense, may retain copies of such documents or any other data which he/she/it has furnished City under this Agreement. Any release of information shall be in conformance with requirements of the Texas Open Records Act. ARTICLE 15 PERSONNEL, EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at his/her/its own expense, quarters for the performance of all services, and adequate and sufficient personnel and equipment to perform the services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform Rev. 4/1/03 7 the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the work shall immediately be removed from association with the project when so instructed by City. Engineer certifies that he/she/it presently has adequate qualified personnel in his/her/its employment for performance of the services required under this Agreement, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the work under this Agreement without prior written approval from City. All subcontracts shall include the provisions required in this Agreement and shall be approved as to form, in writing, by City prior to work being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Agreement. ARTICLE 17 EVALUATION OF WORK City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the work performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Agreement, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Agreement may be terminated before the stated termination date by any of the following conditions. Rev. 4/1/03 8 (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all services and obligations described herein. Should City terminate this Agreement as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the work performed by Engineer prior to termination, City shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should City terminate this Agreement under Subsection (4) immediately above, then the amount charged during the thirty -day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Agreement or if City terminates this Agreement for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the work to the date of default, the amount of work required which was satisfactorily completed to date of default, the value of the work which is usable to City, the cost to City of employing another firm to complete the work required and the time required to do so, and other factors which affect the value to City of the work performed at the time of default. The termination of this Agreement and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Agreement, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Agreement is due to the failure of Engineer to fulfill his/her/its contractual obligations, then City may take over the project and prosecute the work to completion. In such case, Engineer shall be liable to City for any additional and reasonable costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the scope of services under this Agreement. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Agreement, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her/its Rev. 4/1/03 9 compliance. Engineer shall further obtain all permits and licenses required in the performance of the professional services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this Agreement, which are caused by or which result from the negligent error, omission, or act of Engineer or of any person employed by Engineer or under Engineer's direction or control. Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such activities by Engineer, its agents, or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her/its work and shall promptly make necessary revisions or corrections resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed. "Errors" and "omissions" as the terms are used in this Article shall mean violations of the standard of performance contained in Article 33, section 4, of this Agreement ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. Rev. 4/1/03 10 ARTICLE 25 NON -COLLUSION, FINANCIAL INTEREST PROHIBITED (1) Non -collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Agreement, and that he/she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City reserves and shall have the right to annul this Agreement without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Agreement is in effect professional liability insurance coverage in the minimum amount of One Million Dollars from a company authorized to do insurance business in Texas and otherwise acceptable to City. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Agreement to maintain during the term of this Agreement, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional policy conditions as shown below in Article 26, Section (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Agreement, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: 1. Each policy shall require that thirty (30) days prior to the expiration, cancellation, non- renewal or any change in the limit or scope of coverage, a notice thereof shall be given to City by certified mail to: City Manager, City of Round Rock 221 East Main Street Round Rock, Texas 78664 Rev. 4/1/03 11 Engineer shall also notify City, within 24 hours of receipt, of any notices of expiration, cancellation, non -renewal, or material change in coverage it receives from its insurer. 2. Companies issuing the insurance policies shall have no recourse against City for payment of any premiums or assessments for any deductibles which are the sole responsibility of and at the sole risk of Engineer. 3. City shall be an additional insured on Engineer's insurance policies other than professional liability and workers' compensation. For the purposes of this paragraph, the term "City" or "City of Round Rock" shall include all authorities, boards, commissions, departments, and officers of City and the individual members and employees thereof in their official capacities, and/or while acting on behalf of the City of Round Rock. 4. The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self -Insured Retentions of whatever nature. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit F herein entitled "Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty -free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. ARTICLE 28 SUCCESSORS AND ASSIGNS This Agreement shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Agreement, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. Rev. 4/1/03 12 ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Agreement constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Agreement may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Agreement. ARTICLE 32 NOTICES All notices to either party by the other required under this Agreement shall be personally delivered or mailed to such party at the following respective addresses: City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 and to: Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: James K. Haney, P.E. HDR Engineering, Inc. 2211 South l 1-35, Suite 300 Austin, TX 78741 13 Rev. 4/1 /03 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the services for each phase of this Agreement within the agreed Work Schedule may constitute a material breach of this Agreement. Engineer shall be fully responsible for his/her/its delays or for failures to use his/her/its best efforts in accordance with the terms of this Agreement and the Engineer's standard of performance defined herein. Where damage is caused to City due to Engineer's failure to perform accordingly, City may withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Agreement if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Agreement shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Agreement shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. (4) Standard of Performance. The standard of care for all professional engineering, consulting and related services performed or furnished by Engineer and its employees under this Agreement will be the care and skill ordinarily used by members of Engineer's profession practicing under the same or similar circumstances at the same time and in the same locality. Excepting Articles 25 and 34 herein, Engineer makes no warranties, express or implied, under this Agreement or otherwise, in connection with Engineer's services. (5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer's experience and qualifications, and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s') methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual project or construction cost will not vary from opinions of probable cost Engineer prepares. This provision does not relieve Engineer of its obligation to render judgments about probable cost using the standard of care described in the preceding paragraph. (6) Opinions and Determinations. This Agreement shall not permit any opinion, judgment, approval, review, or determination of either party hereto to be arbitrary, capricious, or unreasonable. Rev. 4/1/03 14 ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Agreement and that he/she has full and complete authority to enter into this Agreement on behalf of the firm. The above -stated representations and warranties are made for the purpose of inducing City to enter into this Agreement. IN WITNESS WHEREOF, the City of Round Rock has caused this Agreement to be signed in its corporate name by its Mayor, duly authorized to execute the same on its behalf by Resolution No. /2 -03 -/0 -a3 -//C1 , approved by the City Council on the 013 day of the month of O 27O3R , 2003, and Engineer, HDR Engineering, Inc., signing by and through his/her/its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK, B axwell, Mayor Christine Martinez, City Secretary HDR ENGINEERING, INC.: By: James K. Haney, P.E., its & ecrc4ve Vitt 4/.401-01. 15 Rev. 4/1/03 LIST OF EXHIBITS ATTACHED (1) Exhibit A "Services to be Performed by City" (2) Exhibit B "Services to be Performed by Engineer" (3) Exhibit C "Work Schedule" (4) Exhibit D "Fee Schedule" (5) Exhibit E "Work Authorizations" (6) Exhibit F "Certificates of Insurance" Rev. 4/1/03 16 ATTACHMENT A SERVICES TO BE PROVIDED BY THE City The City of Round Rock shall furnish to the Engineer the following items, information, and assistance: 1. Provide timely review of requests for information, change proposal requests, change orders, pay applications and as -built drawings. 2. Provide on-site construction inspection services. 3. Provide and coordinate construction materials testing. 4. Attend construction progress meetings and phase kickoff meetings. 1 ATTACHMENT B SERVICES TO BE PROVIDED BY THE Engineer DESIGN PHASE and DESIGN PHASE 1. These services were completed in the Agreement authorized by Resolution R -O1 -08-09-13E3. CONSTRUCTION PHASE 1. Consult with and advise City as set forth herein and as provided in the General Conditions and Supplementary General Conditions of the Contract for Construction included in the Contract Documents for the project. The extent and limitations of the duties and responsibilities of Engineer as assigned in said Contract Documents shall not be modified, except as Engineer may otherwise agree in writing. City shall issue all instructions to the contractor performing the Work (hereinafter called "Contractor") except as otherwise provided in writing. 2. Make periodic visits to the site to observe the progress and quality of the executed work and to determine in general if the work is proceeding in accordance with the Contract Documents. In performing this service, the Engineer will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the work or material; he will not be responsible for the techniques and sequences of construction or the safety precautions incident thereto, and he will not be responsible or liable in any degree for the contractors' failure to perform the construction work in accordance with the Contract Documents. During visits to the construction site, and on the basis of the Engineer's on-site observations as an experienced and qualified design professional, he will keep the City informed of the extent of the progress of the work, and advise the City of material and substantial defects and deficiencies in the work of contractors which are discovered by the Engineer or otherwise brought to the Engineer's attention in the course of construction, and may, on behalf of the City, exercise whatever rights the City may have to disapprove work and materials as failing to conform to the Contract Documents. 3. Make recommendations to City concerning the disapproval or rejection of Contractors' Work while it is in progress if Engineer believes that such Work will not produce a completed project that conforms generally to the Contract Documents or that it will prejudice the integrity of the design concept of the project as reflected in the Contract Documents. Engineer shall have access to the Work at all times wherever it is in preparation or progress. 4. Consult and advise with the City; issue all instructions to the contractor requested by the City; and prepare routine change orders as required. 1 5. Evaluate and determine the acceptability of substitute materials and equipment proposed by Contractor. 6. Make recommendations to City regarding the advisability of requiring special inspections or testing of the Work and have City, for the purposes of this paragraph, receive and review all certificates of inspections, testing and approvals required by laws, rules, regulations, ordinances, codes, orders or the Contract Documents to determine generally that their content complies with the requirements of, and the results certified indicate compliance with, the Contract Documents. 7. Act as initial interpreter of the requirements of the Contract Documents, judge the acceptability of the Work and make decisions on all claims of City and Contractor relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the execution and progress of the Work. Engineer shall not be liable for the results of any such interpretations or decisions rendered in good faith. 8. Review samples, catalog data, schedules, shop drawings, laboratory, shop and mill tests of materials and equipment and other data which the contractor is required to submit, only for conformance with the design concept of the Project and compliance with the information given by the Contract Documents; and assemble written guarantees which are required by the Contract Documents. 9. Determine the amount owing to Contractor based on Engineer's observations at the site and the data comprising the Application for Payment, and recommend in writing payments to Contractor in such amounts. Such recommendations of payment will constitute a representation to City that the Work has progressed to the point indicated and that, to the best of Engineer's knowledge, information and belief, the quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, to results of subsequent tests and inspections of others, to minor deviations from the Contract Documents correctable prior to completion and to specific qualifications expressed by Engineer. The issuance of a recommendation will further constitute a representation that the Contractor is entitled to payment in the amount certified. However, the issuance of a recommendation for payment will not be a representation that the Engineer has (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work; (2) reviewed construction means, methods, techniques, sequences or procedures; (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the City to substantiate the Contractor's right to payment; or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Price. 10. Receive and review maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection and tests and approvals of equipment, which are to be provided by Contractor in accordance with the Contract Documents. Determine that their content 2 complies with the requirements of the Contract Documents and transmit them to City with written comments. 11. Conduct, in company with the City, a preliminary and a final inspection of the Project for assessing conformance with the design concept and compliance with the Contract Documents, determining the substantial completion date for the Project, and recommending final payment to the contractor in writing. 12. Revise contract drawings, with the assistance of the City's representative, to provide record drawings of the completed Project. Furnish one set of reproducible drawings, electronic files (AutoCAD 2000i on CD ROM), and two sets of prints of the record drawings to the City. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60 -day acceptance period will be corrected by the party delivering the electronic files. Engineer shall not be responsible to maintain documents stored in electronic media format after acceptance by the City. When transferring documents in electronic media format, Engineer makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by Engineer at the beginning of this Project. The City may make and retain copies of Documents for information and reference in connection with use on the Project by the City. Such Documents are not intended or represented to be suitable for reuse by the City or others on extensions of the Project or on any other project. Any such reuse or modification without written verification or adaptation by Engineer, as appropriate for the specific purpose intended, will be at the City's sole risk and without liability or legal exposure to Engineer or to Engineer's subconsultants. The City shall indemnify and hold harmless Engineer and Engineer's subconsultants from all claims, damages, losses, and expenses, including attorneys' fees arising out of or resulting there from. If there is a discrepancy between the electronic files and the hard copies, the hard copies will govern. 13. Compile, review, and comment on operation and maintenance manuals, which will be provided by Contractor in accordance with the Contract Documents. 14. Assist City staff during start-up of the project. The Engineer shall provide technical support and professional advice regarding any unforeseen problems with the operation and maintenance of the Project for a period of 1 year to the City. 3 ATTACHMENT C WORK SCHEDULE The Work Schedule is on the next page. CITY OF ROUND ROCK, TEXAS z a W a cc 0 i/) J ca m Wo I—w < Z > 0 W C) J 1- W V 0 W N. N a J J Z 0 H cc Q m HDR Engineering, Inc. ATTACHMENT D FEE SCHEDULE The Fee Schedule is on the next page. City of Round Rock BARTON HILL 2.7 MG ELEVATED STORAGE TANK CONSTRUCTION PHASE SERVICES Task Description CONSTRUCTION Meetings/Site Visit: 40 Weeks Est. Project Duration 0.5 Site Visits per Week Hours per Visit Visit Time Allowance Pre -Construction Meeting Correspondence 2 Hours per Week Project Correspondence Administrative (monthly reports, files, billing, subcontract admin) Construction Administration Pay Applications 3 Hours per Contractor Payment Requests Submittal Review Hours per Shop Drawing Review 47 Shop Drawing Submittals Hours per O&M Manaul Review 7 O&M Manuals Hours per Misc. Or Resubmittal 11 Misc and Resubmittal Review (20%) Requests for Information and Field Orders Hours per Response 20 Responses Inspection - Preliminary & Final Start-up Observation and Advice Record Drawings - approx 20 sheets Close-out Document Review LABOR TOTALS Budget Hours Project Project Senior Project Admin. Princi al MgeranaEngineer Engineer Technician Assist. 8 1 4 4 20 80 80 4 4 8 8 0.5 10 8 4 2 8 40 80 40 10 20 1 4 47 188 2 4 14 28 1 2 11 22 20 16 8 2 8 1 20 16 16 16 60 24 40 30 Task Fee $20,500 $1,700 $7,600 $12,900 $3,000 0.5 23.5 $21,900 0.5 3.5 $4,300 0.5 5.5 $3,500 16 16 $5,800 $4,700 $3,600 $7,700 $4,700 TOTAL HOURS TOTAL DIRECT LABOR COST Hourly Rates 87 294 622 76 155 $65.00 $41.00 $43.00 $22.00 $29.00 $12.00 $101,900 (TOTAL LABOR FEE $101,900 1 REIMBURSABLE DIRECT COSTS Postage & Delivery Travel Expenses Miscellaneous Printing & Photocopying Printing of Record Sets Telephone Engineering Applications CADD Applications 10 Months $50.00 per month lump sum mileage 10 Months $50.00 per month 10 Months $0.10 per copy 10 Sets $100.00 per set 10 Months $100.00 per month 30 hours @ $10 76 hours @ $15 $500 $1,000 $500 200 copies/mn $200 $1,000 $1,000 $300 $1,100 ITOTAL REIMBURSABLE DIRECT COSTS $5,600 I NON REIMBURSABLE lDIRECT COSTS TOTAL NON_REIMBURSABLE DIRECT COSTS SUBCONSULTANTS Baker Aicklen $01 (TOTAL SUBCONSULTANTS $0 (TOTAL CONSTRUCTION FEE $107,500 Estimated Construction: Percentage of Construction: $2,504,000 4.29 Amount Invoiced Under Agreement Authorized by Resolution R -01-08-09-13E3 $23,353 TOTAL CONSTRUCTION FEE $84,147 1 ATTACHMENT E WORK AUTHORIZATIONS There are no Work Authorizations with the Agreement. ATTACHMENT F CERTIFICATES OF INSURANCE 1 CERTIFICATE OF LIABILITY INSURANCE Date: 10 / 1 /03 PROFESSIONAL SERVICES PRODUCER COMPANIES AFFORDING COVERAGE Lockton Companies 444 W. 47th Street, Suite 900 Kansas City, MO 64112-1906 INSURED HDR Engineering, Inc. 8404 Indian Hills Drive Omaha, NE 68114-4049 B C D Continental Casualty (V.O. Schinnerer) THIS IS TO CERTIFY THAT the Insured named above is insured by the Companies listed above with respect to the business operations hereinafter described, for the types of insurance and in accordance with the provisions of the standard policies used by the companies, and further hereinafter described. Exceptions to the policies are noted below. CO TYPE OF INSURANCE POLICY EFFECTIVE EXPIRATION LTR NUMBER DATE DATE LIMITS A PROFESSIONAL LIABILITY PLN 1139 78408 6/1/03 6/1/04 Per Claim: $1,000,000 'Aggregate: $1,000,000 DESCRIPTION OF SPECIAL ITEMS/EXCEPTIONS RE: Barton Hill elevated storage tank. Should any of the above described policies be cancelled oncipagezi before the expiration date thereof, the issuing company will mail thirty (30) days written notice to the certificate holder named below. CERTIFICATE HOLDER: City of Round Rock 221 E. Main Street Round Rock, Texas 78664 attn: Christine Martinez, City Secretary Rev'd 2/10/03 - Professional Liability Certificate.doc SIGNATURE OF AUTHORIZED REPRESENTATIVE Typed Name: Grover Simpson Title: President