Loading...
R-11-03-10-10C2 - 3/10/2011RESOLUTION NO. R -11-03-10-10C2 WHEREAS, the City of Round Rock ("City") is planning a redevelopment and beautification project for West Main Street ("Project"), and WHEREAS, Southwestern Bell Telephone Company d/b/a AT&T Texas ("AT&T") has existing aerial facilities located at N. Harris Street and the corner of W. Main Street and Blair Street which must be relocated in order to proceed with the Project, and WHEREAS, the City and AT&T wish to enter into an Application and Letter of Agreement for Construction Services regarding the relocation of said facilities, Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK, TEXAS, That the Mayor is hereby authorized and directed to execute on behalf of the City said Application and Agreement, a copy of same being attached hereto as Exhibit "A" and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date, hour, place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. RESOLVED this 10th day of March, 2011. AEN MCGRAW, Mayor City of Round Rock, Texas ATTEST: SARA L. WHITE, City Secretary O:\wdox\SCCInts\0112\ 1104\MUNICIPAL \00215 777.DOC/rmc • .F110)4 AT&T AUSTIN C1(C at&t NON) 8. 23'10 9:12/ST, 9:11/N0.4860711391 P 3 AT&T Texas Page 1 APPLICATION and LETTER OF AGREEMENT FOR CONSTRUCTION SERVICES August 23, 2010 CWOTS Record Number: 1429T10 BILL TO: City of Round Rook WORK SiTE LOCATION; At N. Horde St. & corner of W. Main St & Blair St. DESCRIPTION OP CONSTRUCTION The work will cannist of relocating the aerial facilities. SERVICES TO BE PERFORMED: LABOR EXPENSE: $25,404.89 OVERHEAD EXPENSE: $D MATERIAL EXPENSE; $8,305.94 TARIFF/ LICENSE AGREEMENT EXPENSE: $0 ESTIMATED CHARGE FOR ESTIMATED COST: $33,710.83 CONSTRUCTION SERVICES: "' (Actual charges may exceed this estimated cost.) •__ Applicant requests that Southwestern Bell Telephone Company d/b/a AT&T Texas, (hereafter "SWBT") perform the above-described construction services on the Applicant's behalf. Applicant agrees to pay the charge(s) Indicated above for such services plus applicable taxes. The work Is to be done on an "Actual Cost" basis, ell • charge(s) will be computed in accordance with Southwestern Bell Telephone Company's ordinary accounting practices and will Include allocated costs for labor, engineering, materials, transportation, motor vehicles, tool and supply expenses and sundry billings from subcontractors and suppliers for work and materials related to the job. The Applicant affirms that the cost estimate furnished by the Telephone Company has been considered only as an estimate of approximate costs and that the actual costs incurred by the Telephone Company In doing the work at the particular time and location might be higher. Satd estimated cost Is subject to change due to any number of factors including, but not limited to, changing conditions in the field, weather delays, or changes in the scope of the work. ESTIMATED PRiCE QUOTE The above estimated price is guaranteed for 60 days from August 23, 2010. 0 the charges are not accepted within 60 days the order will be cancelled and a new order will need to be placed. The second estimate may be higher than the estimated price set out above. PAYMENT Applicant agrees to make an advance payment of $33,710.83 prior to commencement of the work. Charges for construction services and applicable taxes will be billed on a special bill separate from the bill that Applicant receives for telephone service. Applicant, Its agents, servants, or employees agree to make payment on change orders within thirty (80) days of the date of signature on the change order. Failure to make payment within the designated thirty (30) day time period will operate to cancel the change order and Southwestern Bell Telephone Company, will cease all work activity on the project until payment Is made. When the Parties agree to Interval Billing R, the balance of the Contract Price or Aotual Cost (as applicable) will be made !nimbly payments. If the Actual Cost made varies from the estimated Cost, then a correcting adjustment will be made in the last payment. if the parties cannot agree to interval Billing, Applicant will make an advanced payment as Indicated above, • Applicable to orders over $2$,000 and work wll1 take 6 or more months to complete. EXHIBIT „A„ .FROM AT&T AUSTIN C1;iC (MON) 8.23' 10 9:12/ST, 9:11/i 0.4860711391 P 4 AT&T Texas Page 2 at&'t TAXES Applicant will pay and indemnify SWBT against all sales, use and other taxes (excluding income and franchise taxes), including fees, levies, other similar charges, Interest and penalties imposed upon and pald by or assessed on SWBT by reason of its sale and Installation of material and provision of construction services under this Application except to the extent a valid tax exemption certificate Is provided by Applicant to SWBT prior to the delivery of material and provisioning of construction services. STOP WORN ORDER In the event that Applicant issues a stop work order, or places the project "on hold", at any point during the progress of the work, said stop work order or request to "hold" work must be issued in writing and must be delivered via certified mail, return receipt requested to Karen Benton, 817 W. North Loop Blvd., Room 200, Austin, IX 78756, If Applicant issues a stop work order, or a request to "hold" work, the contract price quoted herein will remain valid until sixty (60) days from the date of the stop work or "hold" work order. At the expiration of the sixty (60) days, the contract price quoted herein will expire and a new contract price will be determined and provided, in writing, to Applicant. The new contract price may be higher than the contract price quoted In this custom work order. If, after issuing a stop work, or "hold" work order, Applicant elects to cancel the contract, Applicant muse inform Southwestern Bell Telephone Company, in writing of the cancellation. Southwestern Bell Telephone Company, will deduct any expenses incurred in performing the work from Applicant's advance payment and refund any remaining funds to Applicant. Under no circumstances will Southwestern Bell Telephone Company, be responsible to Applicant for any alleged damages or additional expenses incurred by Applicant as a result of a stop work order or an order to "hold" work on the project. CANCELLATION if the Applicant cancels the work prior to completion, Applicant must notify Southwestern Bali Telephone Company, in writing of said cancellation. If Applicant elects to cancel the work prior to completion, Applicant agrees to pay Southwestern Bell Telephone Company for the costs it has incurred in starting performance under the contract. if Applicant has made an advance payment, Southwestern Bell Telephone Company will deduct its costs and expenses incurred as of the date of Applicant's notice of cancellation from the amount of -the advance payment. Any amount remaining will be refunded to Applicant. CN4NQES IN SCOPE OF WORK OR CHA gES IN FiEt,Q CONDITIO,�IS Should concealed conditions exist, including conditions that may exist below the surface of the ground, or If conditions exist that could not have been anticipated by Southwestern Bell Telephone Company at the time of this agreement, Southwestern Bell Telephone Company, will be entitled to additional funds and/or additional time 10 complete the work. Southwestern Bell Telephone Company will request such additional funding and/or additional time through a request for a change order. Conditions that may materially alter the scope of the work and/or the cost associated with the work Include but are not limited to conditions that exist below the surface of the ground and could not have been anticipated at the time of the price quote, above ground barriers, Acts of God affecting the progress or sequencing of the work. labor disputes, and other conditions or circumstances that Southwestern Bell Telephone Company, could not reasonably anticipate at the time of providing the above referenced price quote to Applicant. FROM AT&T AUSTIN MC at&t NON) 8. 23` 10 9:12/ST. 9:11/NO. 4860711391 P 5 AT&T Texas Page 3 Should Applicant or its agents, servants, or employees order or seek changes In -the scope of the work, Southwestern Bell Telephone Company Is entitled to seek from Applicant, its agents, servants, or employees, additional funds as necessary to perform the work, and additional time, as necessary to complete the work. Said request for additional funds and/or additional time will be through change order. Ali change orders will be in writing. All change orders will be submitted and accepted by Applicant, its agents, servants or employees, before Southwestern Bell Telephone Company, proceeds to execute the work or, if work has been initiated on the project, continues with executing the work except in an emergency endangering fife or property. Applicant, its agents, servants or employees, are deemed to have accepted the terms of any change order by signing where indicated on the change order. Under no circumstances will Southwestern Bell Telephone Company request for a change order be deemed or used as evidence of delay on the project. Nor will any change order issued in this project be used to charge Southwestern Bell Telephone Company with responsibility for any alleged delay on the project. NO DAMAGE FOR DELAY Under no circumstances will Southwestern Bell Telephone Company be held liable to Applicant, Applicant's agents, employees or contractors, for any alleged delay on the project that forms the basis for this agreement for construction services. TIME TO COMPLETE Any representation by Southwestern Bell Telephone Company, its agents, servants or employees that the project, or any additional work authorized by change order, will be complete by a certain date or certain time period is strictly an estimate and not binding on Southwestern Ball Telephone Company, Its agents, servants, or employees_ All estimated completion dates are subject to changing conditions in the field, changes in the scope of the work, relocation of existing utilities not within Southwestern Bell Telephone Company control, Acts of God, weather delays, labor disputes, vendor/contractor disputes, and other conditions or circumstances that Southwestern Bell Telephone Company, its agents, servants, or employees, could not reasonably anticipate at the time of the estimate. CHOICE OF LAW AND ARBITRATION Should any dispute arise between the parties ooncerning the subject matter of this agreement, or any term contained therein, the parties agree that the dispute or claim shall be submitted to binding arbitration before the American Arbitration Association. The parties further agree that the prevailing party in any such dispute will be entitled 10 recover attorney's fees and costs of arbitration. Texas law governs the application of this agreement and all terms contained therein. INDEMNIFICATION AND HOLD HARMLESS Applicant, its agents, servants, and employees hereby agree to Indemnify and hold harmless Southwestern Bell Telephone Company, and its employees, agents and contractors, from and against any and all claims, costs, expenses, judgments or actions for damage to property or injury or death to persons, and/or arising from or relating to the work that is the subject of this agreement, to the extent any such claims are caused by the negligent acts or omissions of the Applicant, its agents, servants, or employees. FROM.AT&T AT&T AUSTIN CMC 040N) 8. 23' 10 9:12/81'. 9:11/NO. 4860711391 P 6 Page 4 at&t ENTIRE AGREEMENT The parties agree that the terms set forth herein constitute the entire agreement and there are no other agreements regarding the project that is the subject of this agreement between the parties. MODIFICATION & NOTICE Any modification to this agreement must be made In writing and signed by both parties. Any party to this agreement may provide the other party with notice of any fact or condition by providing such Information In writing and serving said writing via certified mail return receipt requested ACCEPTED FOR CUSTOMER: Authorized Signature Title or Relationship to Company or Individual ACCEPTED FOR SOUTHWESTER BELL TELEP, ONE COMPANY: A ' ,Iv L4 ".tf L "-oil- Title: .'f'nager- ustom Work Order Department Company: Company: Southwestern Bell Telephone Cortluanv Printed Name: Printed Name: Karen Benton Date: Date: AuaL L 3 e4e � Zai a,61 t/ ROUND ROCK, TEXAS PURPOSE. PASSION. PROSPERITY Agenda Item No. 10C2. City Council Agenda Summary Sheet Agenda Caption: Consider a resolution authorizing the Mayor to execute an Application and Letter of Agreement for Construction Services with Southwestern Bell Telephone Company, dba AT&T Texas for the West Main Street Duct Bank Project. Meeting Date: March 10, 2011 Department: Infrastructure Development and Construction Management Staff Person making presentation: Tom Word, P.E. Chief of Public Works Operations Item Summary: The Southwest Downtown project required the relocation of dry utility infrastructure. This Application and Letter for Construction Services is for Southwestern Bell Telephone Company, d/b/a AT&T Texas to replace the existing overhead communications facilities with equivalent communication facilities utilizing manholes, duct banks and installation of pedestals by the City of Round Rock in accordance with Southwestern Bell Telephone Company, d/b/a AT&T Texas specifications for the Southwest Downtown District project. Construction for this project started in December of 2010, and is scheduled for completion in September 2011. The project provides for the reconstruction of Main Street, sidewalks and landscaping from San Saba Street to Blair Street. This is the first of two documents required by Southwestern Bell Telephone Company, d/b/a AT&T Texas. The second document is the Utility Adjustment Agreement and that document covers the actual details and costs for the adjustments. The estimated cost of the relocations is $33,710.83 to be paid by the City. Strategic Plan Relevance: 26.0 - Construct major elements of the transportation and mobility system as approved by Council in the Master Transportation Plan. Cost: N/A Source of Funds: N/A Date of Public Hearing (if required): N/A Recommended Action: Approval EXECUTED DOCUMENT FOLLOWS FROM AT&T AUSTIN C)4C at&t (l(ONi) 8. 23' 10 9:12/ST, 9:11/NO. 4860711391 P 3 AT&T Texas Page 1 APPLICATION and LETTER OF AGREEMENT FOR CONSTRUCTION SERVICES August 23, 2010 BILL TO: City of Round Rock WORK SITE LOCATION: DESCRIPTION Of CONSTRUCTION SERVICES TO BE PERFORMED: LABOR EXPENSE: $25,404.89 OVERHEAD EXPENSE: $0 ESTIMATED CHARGE FOR CONSTRUCTION SERVICES: CWOTS Record Number: 1429T10 At N. Harri9 St, & corner of W. Main St & Blair St. The work will consist of relocating the aerial facilities. MATERIAL EXPENSE: $8,305.04 TARIFF/ LICENSE AGREEMENT EXPENSE: $0 ESTIMATED COST: $33,710.83 "' (Actual charges may exceed this estimated cost.) •** Applicant requests that Southwestern Bell Telephone Company d/b/e AT&T Texas, (hereafter "SWBT")perform the above-described construction services on the Applicant's behalf. Applicant agrees to pay the charge(s) indicated above for such services plus applicable taxes. The work is to be done on an "Actual Cost" basis, all charge(s) will be computed In accordance with Southwestern Bell Telephone Company's ordinary accounting practices and will include allocated costs for labor, engineering, materials, transportation, motor vehicles, tool and supply expenses and sundry billings from subcontractors and suppliers for work and materials related to the job. The Applicant affirms that the cost estimate furnished by the Telephone Company has been considered only as an estimate of approximate costs and that the actual costs incurred by the Telephone Company In doing the work at the particular time and location might be higher. Satd estimated cost is subject to change due to any number of factors including, but not limited to, changing conditions In the field, weather delays, or changes In the scope of the work. ESTIMATED PRICE QUOTE The above estimated price is guaranteed for 60 days from August 23, 2010. If the charges are not accepted within 60 days the order will be cancelled and a new order will need to be placed. The second estimate may be higher than the estimated price set out above. PAYMENT Applicant agrees to make an advance payment of $33,710,83 prior to commencement of the work. Charges for construction services and applicable taxes will be billed on a special bill separate from the bill that Applicant receives for telephone service. Applicant, its agents, servants, or employees agree to make payment on ohange orders within thirty (30) days of the date of signature on the change order. Failure to make payment within the designated thirty (30) day time period will operate to cancel the change order and Southwestern Bell Telephone Company, will cease all work activity on the project until payment is made, When the Parties agree to interval Billing °, the balance of the Contract Price or Actual Cost (as applicable) will be made in monthly payments. If the Actual Cost rnade varies from the Estimated Cost, then a correcting adjustment will be made In the last payment. If the parties cannot agree to interval Billing, Applicant will make an advanced payment as indicated above, * Applicable to orders over $25,000 and work will. take 6 or more months to complete. .FROM AT&T AUSTIN CNC (I(ON) 8. 23' 10 9:12/ST, 9:1 I/NO. 4860711391 P 4 AT&T Texas Page 2 at&t TAXES Applicant will pay and indemnify SWBT against all sales, use and other taxes (excluding income and franchise taxes), including fees, levies, other similar charges, interest and penalties imposed upon and paid by or assessed on SWBT by reason of its sale and Installation of material and provision of construction services under this Application except to the extent a valid tax exemption certificate Is provided by Applicant to SWBT prior to the delivery of material and provisioning of construction services. STOP WORK ORDER In the event that Applicant issues a stop work order, or places the project "on hold", at any point during the progress of the work, said stop work order or request to "hold" work must be Issued In writing and must be delivered via certified mail, return receipt requested to Karen Benton, 817 W. North Loop Blvd., Room 200, Austin, TX 78756, If Applicant Issues a stop work order, or a request to `'hold" work, the contract price quoted herein will remain valid until sixty (80) days from the date of the stop work or "hold" work order. At the expiration of the sixty (60) days, the contract price quoted herein will expire and a new contract price will be determined and provided, in writing, to Applicant. The new contract price may be higher than the contract price quoted in this custom work order. if, after issuing a stop work, or *hold" work order, Applicant elects to cancel the contract, Applicant must inform Southwestern Bell Telephone Company, in writing of the cancellation. Southwestern Bell Telephone Company, will deduct any expenses incurred in performing the work from Applicant's advance payment and refund any remaining funds to Applicant. Under no circumstances will Southwestern Bell Telephone Company, be responsible 10 Applicant for any alleged damages or additional expenses Incurred by Applicant as a result of a stop work order or an order to "hold" work on the project. CANCELLATION if the Applicant cancels the work prior to completion, Applicant must notify Southwestern Bell Telephone Company, in writing of said cancellation. if Applicant elects to cancel the work prior to completion, Applicant agrees to pay Southwestern Bell Telephone Company for the costs it has incurred in starting performance under the contract. If Applicant has made an advance payment, Southwestern Bell Telephone Company will deduct its costs and expenses incurred as of the date of Applicant's notice of cancellation from the amount of -the advance payment. Any amount remaining will be refunded to Applicant. CHANGES IN SCOP - OF WORK OR QHAWAS_IN FIELD CONDI_T_t_Q, t4 Should concealed conditions exist, including conditions that may exist below the surface of the ground, or if conditions exist that could not have been anticipated by Southwestern Bell Telephone Company at the time of this agreement, Southwestern Bell Telephone Company, will be entitled to additional funds and/or additional time to complete the work. Southwestern Bell Telephone Company will request such additional funding and/or additional time through a request for a change order, Conditions that may materially alter the scope of the work and/or the cost associated with the work include but are not limited to conditions that exist below the surface of the ground and could not have been anticipated at the time of the price quote, above ground barriers, Acts of God affecting the progress or sequencing of the work. labor disputes, and other conditions or circumstances that Southwestern Bell Telephone Company, could not reasonably anticipate at the time of providing the above referenced price quote to Applicant. FROM AT&T AUSTIN CMC at&t (10R) 8. 23` 10 9:12/ST. 9:11/N0, 4860711391 P 5 AT&T Texas Page 3 Should Applicant or its agents, servants, or employees order or seek changes in -the scope of the work, Southwestem Bell Telephone Company Is entitled to seek from Applicant, its agents, servants, or employees, additional funds as necessary to perform the work, and additional time, as necessary to complete the work. Said request for additional funds and/or additional time wiil be through change order. All change orders will be in writing. All change orders will be submitted and accepted by Applicant, its agents, servants or Southwestern Bell Telephone Company, proceeds to execute the work or, if work has continues with executing the work except in an emergency endangering life or property Applicant, its agents, servants or employees, are deemed to have accepted the terms signing where indicated on the change order. Under no circumstances will Southwestern Bell Telephone Company request for a change order be deemed or used as evidence of delay on the project. Nor will any change order issued in this protect be used to charge Southwestern Belt Telephone Company with responsibility for any alleged delay on the project. JQ DAMAQE POR DEL'Av Under no circumstances will Southwestern Bell Telephone Company be held liable to Applicant, Applicant's agents, employees or contractors, for any alleged delay on the project that forms the basis for this agreement for construction services. TIME TO COMPLETE employees, before been Initiated on the project, of any change order by Any representation by Southwestern Bell Telephone Company, Its agents, servants or employees that the project, or any additional work authorized by change order, will be complete by a certain date or certain time period is strictly an estimate and not binding on Southwestern Sell Telephone Company, its agents, servants, or employees. All estimated completion dates are subject to changing conditions in the field, changes in the scope of the work, relocation of existing utilities not within Southwestern Bell Telephone Company control, Acts of God, weather delays, labor disputes, vendor/contractor disputes, and other conditions or circumstances that Southwestern Bell 'Telephone Company, its agents, servants, or employees, could not reasonably anticipate at the time of the estimate. CHOICE d�W AND ARBITRAT10N Should any dispute arise between the patties concerning the subject matter of this agreement, or any term contained therein, the parties agree that the dispute or claim shall be submitted to binding arbitration before the American Arbitration Association. Tho parties further agree that the prevailing party in any such dispute will be entitled 10 recover attorney's fees and costs of arbitration, Texas law governs the application of this agreement and all terms contained therein, iNDEM FICATION AND HOLD HA9MLESS Applicant, its agents, servants, and employees hereby agree to indemnify and hold harmless Southwestern Bell Telephone Company, and Its employees, agents and contractors, from and against any and ail claims, costs, expenses, judgments or actions for damage to property or Injury or death to persons, and/or arising from or relating to the work that is the subject of this agreement, to the extent any such claims are caused by the negligent acts or omissions of the Applicant, its agents, servants, or employees. FROM.AT&T AUSTIN C?IfC (?ION) 8. 23' 10 9:12/ST. 9:11/,NO. 4860711391 P 6 Page 4 atilt ENTIRE AGREEMENT The parties agree that the terms set forth herein constitute the enure agreement and there are no other agreements regarding the project that is the subject of this agreement between the parties. FICATION & ICE Any modification to this agreement must be made in writing and signed by both parties. Any party to this agreement may provide the other party with notice of any fact or condition by providing such information in writing and serving said writing via certified mail, return receipt requested ACC PTSD FOR CUSTOMER: Authorized Signature Tit�Aeonship to Company or Individual Company: Printed Name: Date: 1 O ACCEPTED FOR SOUTHWESTER BELL TELEPHONE COMPANY: Title: Manager-Custorn Work Order Department Company: Southwestern Bell Telephone Comoanv Printed Name: Karen Benton Date: Alkn1Jet 23 4,,,0 ti„cot_a_cti‘fry, 26) /