Loading...
R-12-02-09-10E1 - 2/9/2012 RESOLUTION NO. R-12-02-09-10E1 WHEREAS, the City of Round Rock desires to retain engineering services for the 2012 Regional Interceptor Rehabilitation Inspection Project,and WHEREAS, RJN Group Inc. has submitted a Contract for Engineering Services to provide said services,and WHEREAS, the City Council desires to enter into said contract with RJN Group Inc., Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK,TEXAS, That the Mayor is hereby authorized and directed to execute on behalf of the City a Contract for Engineering Services with RJN Group Inc. for the 2012 Regional Interceptor Rehabilitation Inspection Project, a copy of said contract being attached hereto as Exhibit "A" and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date, hour, place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. RESOLVED this 9th day of February, 2012. -aim ALAN MCGRAW, Mayor City of Round Rock, Texas ATTEST: IHrOV4 A+A Sty NKs, Ar'4- ycleKK 0:\wdox\SCC1nts\0112\1204\MUNICIPAL\00240630.DOC/me EXHIBIT �,A" , 1 O ROUND R04CK TEXAS PUIlP06E.PASSIQ`l PROSPEMiY CITY OF ROUND ROCK CONTRACT FOR ENGINEERING SERVICES FIRM: RJN GROUP INC ("Engineer") ADDRESS: 12160 Abrams Road Suite 400 Dallas TX 75243 PROJECT: 2012 Regional Interceptor Rehabilitation Inspection THE STATE OF TEXAS § COUNTY OF WILLIAMSON § THIS CONTRACT FOR ENGINEERING SERVICES ("Contract") is made and entered into on this the day of ,2012 by and between the CITY OF ROUND ROCK,a Texas home- rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664-5299, (hereinafter referred to as "City'), and Engineer, and such Contract is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers;and WHEREAS, City and Engineer desire to contract for such professional engineering services;and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW,THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto,it is agreed as follows: Engineering Services Contract Rev.05110 00240299 00192831 1 CONTRACT DOCUMENTS The Contract Documents consist of this Contract and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Contract) and all Supplemental Contracts (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Contract as if attached to this Contract or repeated herein. ARTICLE 1 CITY SERVICES City shall perform or provide services as identified in Exhibit A entitled"City Services." ARTICLE 2 ENGINEERING SERVICES Engineer shall perform Engineering Services as identified in Exhibit B entitled "Engineering Services." Engineer shall perform the Engineering Services in accordance with the Work Schedule as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineering Services under this Contract may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all Engineering Services. Should the review times or Engineering Services take longer than shown on the Work Schedule, through no fault of Engineer, Engineer may submit a timely written request for additional time, which shall be subject to the approval of the City Manager. ARTICLE 3 CONTRACT TERM (1) Term. The Engineer is expected to complete the Engineering Services described herein in accordance with the above described Work Schedule. If Engineer does not perform the Engineering Services in accordance with the Work Schedule,then City shall have the right to terminate this Contract as set forth below in Article 20. So long as the City elects not to terminate this Contract,it shall continue from day to day until such time as the Engineering Services are completed. Any Engineering Services performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if helshe/it determines, or reasonably anticipates,that the Engineering Services will not be completed in accordance with the Work Schedule. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of Engineering Services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all Engineering Services required under this Contract in a professional manner. 2 (3) Notice to Proceed. After execution of this Contract,.Engineer shall not proceed with Engineering Services until authorized in writing by City to proceed as provided in Article 7. ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for the Engineering Services performed and to be performed under this Contract. The amount payable under this Contract, without modification of the Contract as provided herein, is the sum of Thirty Thousand Three Hundred Seventy-Nine and 60/100 Dollars($30,379.60)as shown in Exhibit D. The lump sum amount payable shall be revised equitably only by written Supplemental Contract in the event of a change in Engineering Services as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the Engineering Services and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B. Satisfactory progress of Engineering Services shall be an absolute condition of payment. The fee herein referenced may be adjusted for additional Engineering Services requested and performed only if approved by written Supplemental Contract. ARTICLE 5 - METHOD OF PAYMENT Payments to Engineer shall be made while Engineering Services are in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of Engineering Services accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of Engineering Services identified in Exhibit D. Progress payments shall be made by City based upon Engineering Services actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination,that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/herrts negligence. 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for services, whichever is later. Engineer may charge a late fee(fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials,or equipment delivered or the services performed that causes the payment to be late;or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds;or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the Engineering Services performed which causes the payment to be late;or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order,or this Contract or other such contractual agreement. City shall document to Engineer-the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non-disputed invoices shall be considered correct and payable per the terms of Chapter 2251,V.T.C.A.,Texas Government Code. ARTICLE 7 NOTICE TO PROCEED The Engineer shall not proceed with any task listed on Exhibit B until the City has issued a written Notice to Proceed regarding such task. The City shall not be responsible for work performed or costs incurred by Engineer related to any task for which a Notice to Proceed has not been issued. i ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Contract is as follows: Eddie Zapata Project Manager 2008 Enterprise Drive Round Rock,Texas 78664 Telephone Number(512)218-6605 Fax Number(512)218-5563 Email Address ezapata@round-rock.tx.us 4 City's Designated Representative shall be authorized to act on City's behalf with respect to this Contract. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineering Services. Engineer's Designated Representative for purposes of this Contract is as follows: Kevin Chumbley,P.E. Project Manager 12160 Abrams Road,Suite 400 Dallas,TX 75243 Telephone Number(972)437-4300 Fax Number(972)437-2707 Email Address kchumbley@rjn.com ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the Engineering Services, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the Engineering Services. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City,or at other locations designated by City. When requested by City,such conferences shall also include evaluation of the Engineering Services. Should City determine that the progress in Engineering Services does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. i Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the Engineering Services, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to meet the objectives of the Work Schedule,or preclude the attainment of project Engineering Services units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the Work Schedule goals sooner than anticipated. 5 ARTICLE 10 SUSPENSION Should City desire to suspend the Engineering Services, but not to terminate this Contract,then such suspension may be effected by City giving Engineer thirty(30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty-day notice may be waived in writing by agreement and signature of both parties. The Engineering Services may"be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the Engineering Services. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If this Contract is suspended for more than thirty(30)days,Engineer shall have the option of terminating this Contract. If City suspends the Engineering Services, the contract period as determined in Article 3, and the Work Schedule,shall be extended for a time period equal to the suspension period. City assumes no liability for Engineering Services performed or costs incurred prior to the date authorized by City for Engineer to begin Engineering Services,and/or during periods when Engineering Services is suspended,and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL ENGINEERING SERVICES If Engineer forms a reasonable opinion that any work he/shelit has been directed to perform is r beyond the scope of this Contract and as such constitutes extra work, he/she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Contract will be executed between the parties as provided in Article 13. Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Contract. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the Engineering Services authorized in this Contract or any amendments thereto. ARTICLE 12 CHANGES IN ENGINEERING SERVICES If City deems it necessary to request changes to previously satisfactorily completed Engineering Services or parts thereof which involve changes to the original Engineering Services or character of Engineering Services under this Contract, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional Engineering Services and paid for as specified under Article 11. Engineer shall make revisions to Engineering Services authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such Engineering Services. i 6 ARTICLE 13 SUPPLEMENTAL CONTRACTS The terms of this Contract may be modified by written Supplemental Contract if City determines that there has been a significant change in (1) the scope, complexity or character of the Engineering Services,or(2)the duration of the Engineering Services. Any such Supplemental Contract must be duly authorized by the City. Engineer shall not proceed until the Supplemental Contract has been executed.Additional compensation,if appropriate,shall be identified as provided in Article 4. It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until the City authorizes full execution of the written Supplemental Contract and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. ARTICLE 14 USE OF DOCUMENTS All documents, including but not limited to drawings, specifications and data or programs stored electronically, (hereinafter referred to as "Instruments of Service') prepared by Engineer and its subcontractors are related exclusively to the services described in this Contract and are intended to be used with respect to this Project. However, it is expressly understood and agreed by and between the parties hereto that all of Engineer's designs ander this Contract (including but not limited to tracings, drawings, estimates, specifications, investigations,studies and other documents, completed or partially completed), shall be the property of City to be thereafter used in any lawful manner as City elects. Any such subsequent use made of documents by City shall be at City's sole risk and without liability to Engineer, and,to the extent permitted by law, City shall,indemnify, defend and hold harmless Engineer from all claims, damages, losses and expenses, including but not limited to attorneys fees, resulting therefrom. By execution of this Contract and in confirmation of the fee for services to be paid under this Contract, Engineer hereby conveys, transfers and assigns to City all rights under the Federal Copyright Act of 1976 (or any successor copyright statute), as amended, all common law copyrights and all other intellectual property rights acknowledged by law in the Project designs and work product developed under this Contract. Copies may be retained by Engineer. Engineer shall be liable to City for any loss or damage to any such documents while they are in the possession of or while being worked upon by Engineer or anyone connected with Engineer, including agents,employees, Engineers or subcontractors. All documents so lost or damaged shall be replaced or restored by Engineer without cost to City. Upon execution of this Contract, Engineer grants to City permission to reproduce Engineer's work and documents for purposes of constructing,using and maintaining the Project,provided that City shall comply with its obligations,including prompt payment of all sums when due, under this Contract. Engineer shall obtain similar permission from Engineer's subcontractors consistent with this Contract.If and upon the date Engineer is adjudged in default of this Contract, City is permitted to authorize other similarly credentialed design professionals to reproduce and,where permitted by law,to make changes, corrections or additions to the work and documents for the purposes of completing, using and maintaining 1 the Project. 7 City shall not assign, delegate, sublicense, pledge or otherwise transfer any permission granted herein to another party without the prior written contract of Engineer. However, City shall be permitted to authorize the contractor, subcontractors and material or equipment suppliers to reproduce applicable portions of the Instruments of Service appropriate to and for use in their execution of the Work. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is permitted. Any unauthorized use of the Instruments of Service shall be at City's sole risk and without liability to Engineer and its Engineers. Prior to Engineer providing to City any Instruments of Service in electronic form or City providing to Engineer any electronic data for incorporation into the Instruments of Service, City and Engineer shall by separate written contract set forth the specific conditions governing the format of such Instruments of Service or electronic data, including any special limitations not otherwise provided in this Contract. Any electronic files are provided by Engineer for the convenience of City, and use of them is at City's sole risk. In the case of any defects in electronic files or any discrepancies between them and any hardcopy of the same documents prepared by Engineer, the hardcopy shall prevail. Only printed copies of documents conveyed by Engineer shall be relied upon. Engineer shall have no liability for changes made to the drawings by other engineers subsequent to the completion of the Project. Any such change shall be sealed by the engineer making that change and shall be appropriately marked to reflect what was changed or modified. ARTICLE 15 PERSONNEL,EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services,and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of Engineering Ci tY, p to the is incompetent or whose conduct becomes detrimental Services shall immediately be removed from association with the project when so instructed by City. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than City.Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the Engineering Services under this Contract without prior written approval from City. All subcontracts shall include the provisions required in this Contract and shall be approved as to form, in writing, by City prior to Engineering Services being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Contract. 8 ARTICLE 17 EVALUATION OF ENGINEERING SERVICES City,or any authorized representatives of it,shall have the right at all reasonable times to review or otherwise evaluate the Engineering Services performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Contract may be terminated as set forth below. (1) By mutual agreement and consent,in writing,of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the Engineering Services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer,upon not less than thirty(30)days' written notice to Engineer. (5) By satisfactory completion of all Engineering Services and obligations described heroin. Should City terminate this Contract as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the Engineering Services performed by Engineer prior to termination, City shall be the sole judge. Compensation for Engineering Services at termination will be based on a percentage of the Engineering 9 Services completed at that time. Should City terminate this Contract under Subsection (4) immediately above,then the amount charged during the thirty-day notice period shall not exceed the amount charged during the preceding thirty(30)days. If Engineer defaults in the performance of this Contract or if City terminates this Contract for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the Engineering Services to the date of default, the amount of Engineering Services required which was satisfactorily completed to date of default, the value of the Engineering Services which are usable to City, the cost to City of employing another firm to complete the Engineering Services required and the time required to do so, and other factors which affect the value to City of the Engineering Services performed at the time of default. The termination of this Contract and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Contract, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Contract is due to the failure of Engineer to fulfill his/her/its contractual obligations,then City may take over the project and prosecute the Engineering Services to completion. In such case, Engineer shall be liable to City for any additional and reasonable costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the Engineering Services under this Contract. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Contract, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her/its compliance. Engineer shall further obtain all permits and licenses required in the performance of the Engineering Services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the Engineering Services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales,Excise,and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this Contract, which are caused by or which result from the negligent error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. 10 Engineer shall also save and hold City harmless from any and all expenses, including but not limited to reasonable attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such negligent activities by Engineer, its agents,or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her/its Engineering Services and shall promptly make necessary revisions or corrections to its work product resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions in its work product, or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and datd all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON-COLLUSION,FINANCIAL INTEREST PROHIBITED (1) Non-collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Contract, and that he/she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City reserves and shall have the right to annul this Contract without liability or, in its discretion and at its sole election,to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission,percentage,brokerage fee,gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Contract is in effect professional liability insurance coverage in the minimum amount of One Million Dollars per claim from a company authorized to do insurance business in Texas and 11 otherwise acceptable to City.Engineer shall also notify City,within twenty-four(24)hours of receipt,of any notices of expiration, cancellation, non-renewal, or material change in coverage it receives from its insurer. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Contract to maintain during the term of this Contract, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional policy conditions as shown below in Article 26, Section(3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Contract, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: (a) Each policy shall require that thirty (30) days prior to the expiration, cancellation, non- renewal or reduction in limits by endorsement a notice thereof shall be given to City by certified mail to: City Manager,City of Round Rock 221 East Main Street Round Rock,Texas 78664 (b) The policy clause"Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self-Insured Retentions of whatever nature. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit E herein entitled"Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. 12 ARTICLE 28 SUCCESSORS AND ASSIGNS This Contract shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and Iegal representatives. Engineer may not assign, sublet or transfer any interest in this Contract, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Contract shall for any reason be I held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Contract shall be construed as if such invalid,illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Contract constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Contract may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times.The City reserves the right to review all records it deems relevant which are related to this Contract. ARTICLE 32 NOTICES All notices to either party by the other required under this Contract shall be personally delivered or mailed to such party at the following respective addresses: City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock,TX 78664 13 and to: Stephan L.Sheets City Attorney 309 East Main Street Round Rock,TX 78664 Engineer: Kevin Chumbley,P.E. Project Manager 12160 Abrams Road, Suite 400 Dallas,TX 75243 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the Engineering Services for each phase of this Contract within the agreed Work Schedule may constitute a material breach of this Contract. Engineer shall be fully fesponsible for his/her/its delays or for failures to use his/her/its reasonable efforts in accordance with the terms of this Contract and the Engineer's standard of performance as defined herein.Where damage is caused to City due to Engineer's negligent failure to perform City may accordingly withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. O J 2 Force Majeure. Neither City nor Engineer shall be deemed in violation of this Contract if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given,and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Contract shall be enforceable in Round Rock, Williamson County,Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Contract shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. (4) Standard of Performance. The standard of care for all professional engineering, consulting and related services performed or furnished by Engineer and its employees under this Contract will be the care and skill ordinarily used by members of Engineer's profession practicing under the same or similar circumstances at the same time and in the same locality. Excepting Articles 25 and 34 herein, Engineer makes no warranties, express or implied, under this Contract or otherwise, in connection with the Engineering Services. 14 i I I (5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer's experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s') methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual project or construction cost will not vary from opinions of probable cost Engineer prepares. (b) Opinions and Determinations. Where the terms of this Contract provide for action to be based upon opinion,judgment, approval, review,or determination of either party hereto,such terms are not intended to be and shall never be construed as permitting such opinion,judgment, approval,review, or determination to be arbitrary,capricious,or unreasonable. ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Contract and that he/she has full and complete authority to enter into this Contract on behalf of the firm. The above-stated representations and warranties are made for the purpose of inducing City to enter into this Contract. IN WITNESS WHEREOF,the City of Round Rock has caused this Contract to be signed in its corporate name b'Y its duly authorized City Manager or Mayor, as has Engineer, signing by and ugh its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK,TEXAS APPROVED AS TO FORM: By: Alan McGraw,Mayor Stephan L. Sheets,City Attorney ATTEST: By: Sara L.White,City Secretary RIN GROU ,INC. By: Signature of Principal r6 9R Z Printed Name: 15 LIST OF EXHIBITS ATTACHED i (1)Exhibit A City Services (2)Exhibit B Engineering Services (3)Exhibit C Work Schedule (4)Exhibit D Fee Schedule (5)Exhibit E Certificates of Insurance 16 Exhibit A City Services 1. Designate a person to act as the Owner's representative with respect to services to be rendered under this contract. Such person shall have complete authority to transmit instructions, receive information, and interpret and define Owner/s policies and decisions. 2. Provide all criteria and full information as to the Owner's requirements for the project, including design objectives and constraints, space, capacity and performance requirements, and any budgetary limitations; and furnish copies of all, which Owner will require to be included in the project. 3. Place at the Engineer's disposal all available information including previous reports and any other data relative to the project. 4. Arrange for access to and make provisions for Engineer and their Subconsultants to enter upon public and private property as required for Engineer to perform the services under this contract. 5. Provide CCTV inspection of designated mains in project area and provide inspection forms and videos to Engineer. 6. Examine all studies, reports, sketches, drawings specifications, proposals and other documents presented by the Engineer, and render in writing decisions pertaining thereto within a reasonable time so as not to delay the services of the Engineer. 7. Furnish approvals and permits for all governmental authorities having jurisdiction over the Project and such approvals and consent from others as may be necessary for completion of the project. Pay all fees associated with approvals and permits. 8. Give prompt notice to the Engineer whenever Owner observes or otherwise becomes aware of any development that affects the scope or timing of Engineer's services. i Exhibit B Engineering Services This scope to the City of Round Rock is to perform TV and review recommendations on the Regional Interceptor located within the Edwards Aquifer Recharge Zone. The Aquifer Interceptors range from 12 inches to 72 inches in diameter with a combined total footage of 41,288 linear feet. The portion located within the Edwards Aquifer Recharge Zone is required to be inspected every 5 years per TCEQ rules. The Onion Creek Interceptor was not included in the cost estimate since it was prior inspected by City staff. At this time an estimate was not prepared for sewer out side the Recharge Zone. The interceptors outside the Recharge Zone are not subject to the same requirement. But it should be noted its condition is unknown and a relatively high risk associated with the potential failure of defects in the interceptors exist especially in the creek. Due to the uncertainty of the condition of the Interceptors no estimates are included for sewer rehabilitation design or construction at this time. The general scope of services is as follows: 1. Bidding and Contract Assistance—Engineer will assist the City in advertising, obtaining, and evaluating Bid Proposals for the Inspection contract and awarding. Provide assistance to the City in responding to bidder inquiries during advertisement of the inspection contract, and participate in project pre- bid conference. Provide and distribute bidding documents and addendum. Assist the City in reviewing the bids for completeness and accuracy. Provide the successful bidder(s)with the contract specifications for execution and the insertion of the required insurance certificates. 11. CCN/Sonar/Laser and Cleaning-To be bid out. Work completed by other than Engineer: This will include CCN(closed circuit TV), or a combination of laser and or sonar where applicable depending on pipe size and debris depth. Ill. TV Inspection Administration—Work with TV inspector to assure proper data collection. Coordinate and organize TV inspection data for completeness. Update GIS with date of Inspection performed and provide to City upon completion of TV. IV. CCN Review and Recommendations—It is anticipated that CCTV/Laser or Sonar will be performed on 41,288 LF of sanitary sewer pipe'and cleaning will be performed when possible. RJN will review the video and summarize the recommendations. We recommend utilizing a PACP (Pipeline Assessment Certification Program)for defect coding and rating. Pipe defects will be prioritized for repair and an associated construction cost will be assigned to each line segment. EXHIBIT C WORK SCHEDULE 3 2011 2012 Task Name NOV DEC JAN FEB MAR APR MAY JUN JUL AUG SEPT OCT NOV PROJECT KICKOFF PROJECT ADMIN/MEETINGS BIDDING AND CONTRACT SERVICES TAPE REVIEW RECOMMENDATIONS PROJECT: 2012 REGIONAL INSPECTION ROUND ROCK,TEXAS TIME LINE _ INTERCEPTOR DATE: 10/20/11 Critical milestone: must receive all TV video to meet September 2012 completion Exhibit D Fee Schedule Total Total Other Task Labor Hours Loaded Labor Cost Direct Costs Subconsultants TOTALS Task 1: (e.g. bid phase services) 30 ,,$3,300.00 $600.00 $0.00 $3,900.00 Task 2: (e.g.TV Inspection Review) 104 $9,760.00 $300.00 $0.00 $10,060.00 Task 3:(e.g. Recommendations) 98 $10,320.00 $219.60 $0.00 $10,539.60 Ta ' sk 4:(e.g. p ect management) 40 $4,680.00 $1,200.00 $0.00 $5,880.00 GRAND TOTAL: 272 $28,060.00 $2,319.60 $0.00 $30,379.60 K EXHIBIT E Certificates of Insurance Attached Behind This Page CERTIFICATE OF LIABILITY INSURANCE Date:January 3,2012 TDI number required.Please refer to the MCsEM M WWW � Texas Dept of Insurance website: httu:pwww.tdLstate.tx.usl HUB liftOondUffA CW0q%L 60 COMPANIES AFFORDING COVERAGE TDI . Chbapo,N.8060�i Phone:sw-s22.eeoo Email:nnwnoMatwnnYautean A Hartford Fire Insurance Co. 19882 INSURED: RJn poop,Ino. B 81.Paul Fire and Madne Ins.Co. 24767 20ow.Fmnl SL C Twin Chy Fire Insurance Co. 29459 wbat&%L WW - Phone: min m!xA7m F-malld BA*4q roro D Essex Insurance Co. 39020 THIS IS TO CERTIFY THAT the Insured named above Is Insured by the Companies Fisted above with respect to the business operations hersinafter described,for the types of Insurance and in accordance with the provisions of the standard policies used by the companies. and further herelnafterdesedbod. Exceptfmw to the policies are noted below. CO TYPE OF POLICY EFFECTIVE EXPIRATION LIMITS LTR INSURANCE NUMBER DATE DATE GENERAL LIABILITY GENERAL AGGREGATE $ I 0000 A utxsuu1517 0OWD11 OWV2012 PRODUCTS-COMPIOPAGG. S 300,000 PERSONAL&ADV.INJURY $ 10,000 EACH OCCURRENCE $ 1,000,000 FIRE DAMAGE(Any one fine) $ 2,000,000 MED.EXPENSE(Any one penin) S 1,000,000 i AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT S 1,000,000 A 03UDWI a a OSM112011 08MV2012 BODILY INJURY(Per penton) $ BODILY INJURY(Per aeddent) $ PROPERTY DAMAGE $ EXCESS LIABILITY FACH.00CURRENCE S 10.000,000 13 CM1202M 08/01!2011 0MV22012 AGGREGATE S 10.000.000 WORKERS'COMPENSATION STATUTORY LIMITS S X AND EMPLOYERS'LIABILITY EACH ACCIDENT 3 500,000 `. $3WEP05e5 001/2011 08/01/2012 DISEASE-POLICY LIMIT $ SK000 DISEASE-EACH EMPLOYEE $ 500,000 D PROFESSIONAL LIABILITY i ICPLoos27 08101/2011 WOW= $3,000,000 Per ClainV$3.000,000 Aggregate BUILDERS'RISK INSURANCE OR INSTALLATION INSURANCE DESCRIPTION OF OPERATIONSA.00ATIONSIVEHICLEWSPECIAL ITEMSIEXCEPTIONS The City of Rotlnd Rods M named as additional Insulted with respect N all policies except 99NOW Compensation and Employers• LlaMIW and'P al"Wonl LlsbMW. Should any of the above described policies be milled or dransed before the expiration date thereof,the issuing company will mail thirty(80)days written notice to the certlflcate holder named below. CERTIFICATE HOLDER: Ctly Manager City or Round Rods SIGNATURE OF AGENT LICENSED IN STATE OF TEXAS 221 E.Main StreetEck y Round Rode,Texas 78604 Typed Name: Sc t o n License ID* 1397057 Page 1 �SO 7-Zppy Certirrcateoft.fabilily Insurance OOOt+06S6 DROCK,TEXAS City Council Agenda Sunny Sheet PURPOSE.PASSION PROSPEM Agenda Item No. *10E1. Consider a resolution authorizing the Mayor to execute a Contract for Engineering Services with RJN Group, Inc. for the 2012 Regional Interceptor Rehabilitation Inspection Agenda Caption: Project. Meeting Date: February 9,2012 Department: Utilities and Environmental Services Staff Person making presentation: Michael Thane Utilities Director Item Summary: The scope of engineering services to be performed under this contract includes preparation of bid documents, assistance in bidding, recommendation of award, review of the video and other information collected, as well as preparation of a report recommending repairs to the lines, if needed. This contract provides all of the engineering services necessary to select a contractor to video, and collect and analyze additional information on the Brushy Creek Regional Wastewater Interceptors located within the Edwards Aquifer Recharge Zone.The interceptors range from 12-inches to 84-inches in diameter and total 41,288 linear feet in length. The wastewater lines located within the Edwards Aquifer Recharge Zone are mandated to be inspected per TCEQ rules. Listed below are the percentages associated with each of the entities ownership in the Regional lines on this project: City of Cedar Park-29.80% City of Austin-26.15% City of Round Rock-28.42% City of Leander-11.51% Brushy Creek MUD-2.85% Fern Bluff MUD- 1.27% Round Rock's share of this engineering contract is $8,605.46. Since the City will administer the contract, and be reimbursed for the other city's shares of the costs per the Master Agreement with the partners in the Brushy Creek Regional Wastewater System (BCRWWS),we are requesting approval of the entire$30,279.60. Cost: $30,279.60 Source of Funds: Self-Financed Wastewater Construction Date of Public Hearing(if required): N/A Recommended Action: Approval EXECUTED DOCUMENTS FOLLOW r K,P rY CITY OF ROUND ROCK CONTRACT FOR ENGINEERING SERVICES FIRM: RJN GROUP INC. ("Engineer") ADDRESS: 12160 Abrams Road,Suite 400,Dallas,TX 75243 PROJECT: 2012 Regional Interceptor Rehabilitation Inspection THE STATE OF TEXAS § § COUNTY OF WILLIAMSON § THIS CONTRACT FOR ENGINEERING SERVICES ("Contract') is made and entered into on this theft day of t ,2012 by and between the CITY OF ROUND ROCK,a Texas home- rule municipal corporation, whoi e offices are located at 221 East Main Street, Round Rock, Texas 78664-5299, (hereinafter referred to as "City"), and Engineer, and such Contract is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2XA)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers;and WHEREAS,City and Engineer desire to contract for such professional engineering set vices;and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW,THEREFORE,WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto,it is agreed as follows: Engineering Services Contract Rev.05110 00240299 00192831 1 CONTRACT DOCUMENTS The Contract Documents consist of this Contract and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Contract) and all Supplemental Contracts (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Contract as if attached to this Contract or repeated herein. ARTICLE 1 CITY SERVICES City shall perform or provide services as identified in Exhibit A entitled"City Services." ARTICLE 2 ENGINEERING SERVICES Engineer shall perform Engineering Services as identified in Exhibit B entitled "Engineering Services." Engineer shall perform the Engineering Services in accordance with the Work Schedule as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineering Services under this Contract may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all Engineering Services. Should the review times or Engineering Services take longer than shown on the Work Schedule, through no fault of Engineer, Engineer may submit a timely written request for additional time, which shall be subject to the approval of the City Manager. ARTICLE 3 CONTRACT TERM (1) Term. The Engineer is expected to complete the Engineering Services described herein in accordance with the above described Work Schedule. If Engineer does not perform the Engineering Services in accordance with the Work Schedule,then City shall have the right to terminate this Contract as set forth below in Article 20. So long as the City elects not to terminate this Contract,it shall continue from day to day until such time as the Engineering Services are completed. Any Engineering Services performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably anticipates,that the Engineering Services will not be completed in accordance with the Work Schedule. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of Engineering Services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all Engineering Services required under this Contract in a professional manner. 2 (3) Notice to Proceed. After execution of this Contract, Engineer shall not proceed with Engineering Services until authorized in writing by City to proceed as provided in Article 7. ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for the Engineering Services performed and to be performed under this Contract. The amount payable under this Contract, without modification of the Contract as provided herein, is the sum of Thirty Thousand Three Hundred Seventy Nine and 60/100 Dollars ($30,379.60)as shown in Exhibit D. The lump sum amount payable shall be revised equitably only by written Supplemental Contract in the event of a change in Engineering Services as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the Engineering Services and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B. Satisfactory progress of Engineering Services shall be an absolute condition of payment. The fee herein referenced may be adjusted for additional Engineering Services requested and performed only if approved by written Supplemental Contract. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer shall be made while Engineering Services are in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of Engineering Services accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of Engineering Services identified in Exhibit D. Progress payments shall be made by City based upon,Engineering Services actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination,that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her/its negligence. 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for services, whichever is later.Engineer may charge a late fee(fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials,or equipment delivered or the services performed that causes the payment to be late;or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds;or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the Engineering Services performed which causes the payment to be late;or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order,or this Contract or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non-disputed invoices shall be considered correct and payable per the terms of Chapter 2251,V.T.C.A.,Texas Government Code. ARTICLE 7 NOTICE TO PROCEED i The Engineer shall not proceed with any task listed on Exhibit B until the City has issued a written Notice to Proceed regarding such task. The City shall not be responsible for work performed or costs incurred by Engineer related to any task for which a Notice to Proceed has not been issued. i ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Contract is as follows: Eddie Zapata Project Manager 2008 Enterprise Drive Round Rock,Texas 78664 Telephone Number(512)218-6605 Fax Number(512)218-5563 Email Address ezapata@round-rock.tx.us 4 i City's Designated Representative shall be authorized to act on City's behalf with respect to this Contract. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineering Services. Engineer's Designated Representative for purposes of this Contract is as follows: Kevin Chumbley,P.E. Project Manager 12160 Abrams Road, Suite 400 Dallas,TX 75243 Telephone Number(972)437-4300 Fax Number(972)437-2707 Email Address kchumbley@rjn.com rjn.com ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the Engineering Services, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the Engineering Services. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City,or at other locations designated by City. When requested by City,such conferences shall also include evaluation of the Engineering Services. Should City determine that the progress in Engineering Services does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the Engineering Services,including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to meet the objectives of the Work Schedule,or preclude the attainment of project Engineering Services units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the Work Schedule goals sooner than anticipated. 5 ARTICLE 10 SUSPENSION Should City desire to suspend the Engineering Services, but not to terminate this Contract,then such suspension may be effected by City giving Engineer thirty(30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty-day notice may be waived in writing by agreement and signature of both parties. The Engineering Services may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the Engineering Services. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If this Contract is suspended for more than thirty(30)days,Engineer shall have the option of terminating this Contract. If City suspends the Engineering Services, the contract period as determined in Article 3, and the Work Schedule,shall be extended for a time period equal to the suspension period. City assumes no liability for Engineering Services performed or costs incurred prior to the date authorized by City for Engineer to begin Engineering Services,and/or during periods when Engineering Services is suspended,and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL ENGINEERING SERVICES If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is beyond the scope of this Contract and as such constitutes extra work, he/she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Contract will be executed between the parties as provided in Article 13. Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Contract. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the Engineering Services authorized in this Contract or any amendments thereto. ARTICLE 12 CHANGES IN ENGINEERING SERVICES If City deems it necessary to request changes to previously satisfactorily completed Engineering Services or parts thereof which involve changes to the original Engineering Services or character of Engineering Services under this Contract, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional Engineering Services and paid for as specified under Article 11. Engineer shall make revisions to Engineering Services authorized hereunder as are necessaiy to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such Engineering Services. 6 ARTICLE 13 SUPPLEMENTAL CONTRACTS The terms of this Contract may be modified by written Supplemental Contract if City determines that there has been a significant change in (1) the scope, complexity or character of the Engineering Services,or(2)the duration of the Engineering Services. Any such Supplemental Contract must be duly authorized by the City. Engineer shall not proceed until the Supplemental Contract has been executed.Additional compensation, if appropriate,shall be identified as provided in Article 4. It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until the City authorizes full execution of the written Supplemental Contract and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. ARTICLE 14 USE OF DOCUMENTS All documents, including but not limited to drawings, specifications and data or programs stored electronically, (hereinafter referred to as "Instruments of Service") prepared by Engineer and its subcontractors are related exclusively to the services described in this Contract and are intended to be used with respect to this Project. However, it is expressly understood and agreed by and between the parties hereto that all of Engineer's designs under this Contract (including but not limited to tracings, drawings, estimates, specifications, investigations, studies and other documents, completed or partially completed), shall be the property of City to be thereafter used in any lawful manner as City elects. Any such subsequent use made of documents by City shall be at City's sole risk and without liability to Engineer, and,to the extent permitted by law, City shall indemnify, defend and hold harmless Engineer from all claims, damages, losses and expenses, including but not limited to attorneys fees, resulting therefrom. By execution of this Contract and in confirmation of the fee for services to be paid under this Contract, Engineer hereby conveys, transfers and assigns to City all rights under the Federal Copyright Act of 1976 (or any successor copyright statute), as amended, all common law copyrights and all other intellectual property rights acknowledged by law in the Project designs and work product developed under this Contract.Copies may be retained by Engineer. Engineer shall be liable to City for any loss or damage to any such documents while they are in the possession of or while being worked upon by Engineer or anyone connected with Engineer, including agents,employees, Engineers or subcontractors. All documents so lost or damaged shall be replaced or restored by Engineer without cost to City. Upon execution of this Contract, Engineer grants to City permission to reproduce Engineer's work and documents for purposes of constructing, using and maintaining the Project,provided that City shall comply with its obligations, including prompt payment of all sums when due, under this Contract. Engineer shall obtain similar permission from Engineer's subcontractors consistent with this Contract. if and upon the date Engineer is adjudged in default of this Contract, City is permitted to authorize other similarly credentialed design professionals to reproduce and,where permitted by law,to make changes, corrections or additions to the work and documents for the purposes of completing, using and maintaining the Project. 7 City shall not assign, delegate, sublicense, pledge or otherwise transfer any permission granted herein to another party without the prior written contract of Engineer. However, City shall be permitted to authorize the contractor, subcontractors and material or equipment suppliers to reproduce applicable portions of the Instruments of Service appropriate to and for use in their execution of the Work. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is permitted. Any unauthorized use of the Instruments of Service shall be at City's sole risk and without liability to Engineer and its Engineers. Prior to Engineer providing to City any Instruments of Service in electronic form or City providing to Engineer any electronic data for incorporation into the Instruments of Service, City and Engineer shall by separate written contract set forth the specific conditions governing the format of such Instruments of Service or electronic data,including any special limitations not otherwise provided in this Contract. Any electronic files are provided by Engineer for the convenience of City, and use of them is at City's sole risk. In the case of any defects in electronic files or any discrepancies between them and any hardcopy of the same documents prepared by Engineer, the hardcopy shall prevail. Only printed copies of documents conveyed by Engineer shall be relied upon. Engineer shall have no liability for changes made to the drawings by other engineers subsequent to the completion of the Project. Any such change shall be sealed by the engineer making that change and shall be appropriately marked to reflect what was changed or modified. ARTICLE 15 PERSONNEL,EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services,and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the Engineering Services shall immediately be removed from association with the project when so instructed by City. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the Engineering Services under this Contract without prior written approval from City. All subcontracts shall include the provisions required in this Contract and shall be approved as to form, in writing, by City prior to Engineering Services being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Contract. 8 ARTICLE 17 EVALUATION OF ENGINEERING SERVICES City,or any authorized representatives of it,shall have the right at all reasonable times to review or otherwise evaluate the Engineering Services performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Contract may be terminated as set forth below. (1) By mutual agreement and consent,in writing,of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the Engineering Services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer,upon not less than thirty(30)days' written notice to Engineer. (5) By satisfactory completion of all Engineering Services and obligations described herein. Should City terminate this Contract as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the Engineering Services performed by Engineer prior to termination, City shall be the sole judge. Compensation for Engineering Services at termination will be based on a percentage of the Engineering 9 Services completed at that time. Should City terminate this Contract under Subsection(4) immediately above,then the amount charged during the thirty-day notice period shall not exceed the amount charged during the preceding thirty(30)days. If Engineer defaults in the performance of this Contract or if City terminates this Contract for fault on the pant of Engineer,then City shall give consideration to the actual costs incurred by Engineer in performing the Engineering Services to the date of default, the amount of Engineering Services required which was satisfactorily completed to date of default, the value of the Engineering Services which are usable to City, the cost to City of employing another firm to complete the Engineering Services required and the time required to do so, and other factors which affect the value to City of the Engineering Services performed at the time of default. The termination of this Contract and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Contract, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Contract is due to the failure of Engineer to fulfill his/her/its contractual obligations,then City may take over the project and prosecute the Engineering Services to completion. In such case, Engineer shall be liable to City for any additional and reasonable costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the Engineering Services under this Contract. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Contract including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations.Engineer shall furnish City with satisfactory proof of his/her/its compliance. Engineer shall further obtain all permits and licenses required in the performance of the Engineering Services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the Engineering Services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales,Excise,and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this Contract, which are caused by or which result from the negligent error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. 10 Engineer shall also save and hold City harmless from any and all expenses, including but not limited to reasonable attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such negligent activities by Engineer, its agents,or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her/its Engineering Services and shall promptly make necessary revisions or corrections to its work product resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions in its work product, or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON-COLLUSION,FINANCIAL INTEREST PROHIBITED (1) Non-collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Contract, and that he/she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City reserves and shall have the right to annul this Contract without liability or, in its discretion and at its sole election,to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission,percentage,brokerage fee,gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Contract is in effect professional liability insurance coverage in the minimum amount of One Million Dollars per claim from a company authorized to do insurance business in Texas and 11 otherwise acceptable to City.Engineer shall also notify City,within twenty-four(24)hours of receipt,of any notices of expiration, cancellation, non-renewal, or material change in coverage it receives from its insurer. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Contract to maintain during the term of this Contract, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional policy conditions as shown below in Article 26, Section(3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Contract, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: (a) Each policy shall require that thirty (30) days prior to the expiration, cancellation, non- renewal or reduction in limits by endorsement a notice thereof shall be given to City by certified mail to: City Manager,City of Round Rock 221 East Main Street Round Rock,Texas 78664 (b) The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self-Insured Retentions of whatever nature. 4 Cost of Insurance. The cost of all insurance required herein to be secured and maintained ( ) q by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit E herein entitled"Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. 12 ARTICLE 28 SUCCESSORS AND ASSIGNS This Contract shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Contract, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Contract shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Contract shall be construed as if such invalid,illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Contract constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Contract may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times.The City reserves the right to review all records it deems relevant which are related to this Contract. ARTICLE 32 NOTICES All notices to either party by the other required under this Contract shall be personally delivered or mailed to such party at the following respective addresses: City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock,TX 78664 13 and to: Stephan L. Sheets City Attorney 309 East Main Street Round Rock,TX 78664 Engineer: Kevin Chumbley,P.E. Project Manager 12160 Abrams Road, Suite 400 Dallas,TX 75243 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the Engineering Services for each phase of this Contract within the agreed Work Schedule may constitute a material breach of this Contract. Engineer shall be fully responsible for his/her/its delays or for failures to use his/her/its reasonable efforts in accordance with the terms of this Contract and the Engineer's standard of performance as defined herein.Where damage is caused to City due to Engineer's negligent failure to perform City may accordingly withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Contract if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given,and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Contract shall be enforceable in Round Rock, Williamson County,Texas,and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Contract shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. (4) Standard of Performance. The standard of care for all professional engineering, consulting and related services performed or furnished by Engineer and its employees under this Contract will be the care and skill ordinarily used by members of Engineer's profession practicing under the same or similar circumstances at the same time and in the same locality. Excepting Articles 25 and 34 herein, Engineer makes no warranties, express or implied, under this Contract or otherwise, in connection with the Engineering Services. 14 i I i (5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer's experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s')methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual project or construction cost will not vary from opinions of probable cost Engineer prepares. (6) Opinions and Determinations. Where the terms of this Contract provide for action to be based upon opinion,judgment, approval, review,or determination of either party hereto,such terms are not intended to be and shall never be construed as permitting such opinion,judgment, approval,review, or determination to be arbitrary,capricious,or unreasonable. ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Contract and that he/she has full and complete authority to enter into this Contract on behalf of the firm. The above-stated representations and warranties are made for the purpose of inducing City to enter into this Contract. IN WITNESS WHEREOF,the City of Round Rock has caused this Contract to be signed in its corporate name by its duly authorized City Manager or Mayor, as has Engineer, signing by and through its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF.ROUND ROCK,TEXAS APP ED AST FORM: By: ' r ` Ala cGraw, Mayor Ste_phid4,. Sheets,City Attorney ATTEST: By: meAQrA*4%Yt04I(S, Ash. UAq C edc. RJN GROUP,INC. By: Signature of Principal n�T�� L �„T, Printed Name: 1 15 LIST OF EXHIBITS ATTACHED i I (1)Exhibit A City Services (2)Exhibit B Engineering Services (3)Exhibit C Work Schedule (4)Exhibit D Fee Schedule (5)Exhibit E Certificates of Insurance 16 Exhibit A City Services 1. Designate a person to act as the Owner's representative with respect to services to be rendered under this contract. Such person shall have complete authority to transmit instructions, receive information, and interpret and define Owneds policies and decisions. 2. Provide all criteria and full information as to the Owner's requirements for the project, including design objectives and constraints, space, capacity and performance requirements, and any budgetary limitations; and furnish copies of all, which Owner will require to be included in the project. 3. Place at the Engineer's disposal all available information including previous reports and any other data relative to the project. 4. Arrange for access to and make provisions for Engineer and their Subconsultants to enter upon public and private property as required for Engineer to perform the services under this contract. 5. Provide CCN inspection of designated mains in project area and provide inspection forms and videos to Engineer. 6. Examine all studies, reports, sketches, drawings specifications, proposals and other documents presented by the Engineer, and render in writing decisions pertaining thereto within a reasonable time so as not to delay the services of the Engineer. 7. Furnish approvals and permits for all governmental authorities having jurisdiction over the Project and such approvals and consent from others as may be necessary for completion of the project. Pay all fees associated with approvals and permits. 8. Give prompt notice to the Engineer whenever Owner observes or otherwise becomes aware of any development that affects the scope or timing of Engineer's services. Exhibit B Engineering Services This scope to the City of Round Rock is to perform TV and review recommendations on the Regional Interceptor located within the Edwards Aquifer Recharge Zone. The Aquifer Interceptors range from 12 inches to 72 inches in diameter with a combined total footage of 41,288 linear feet. The portion located within the Edwards Aquifer Recharge Zone is required to be inspected every 5 years per TCEQ rules. The Onion Creek Interceptor was not included in the cost estimate since It was prior inspected by City staff. At this time an estimate was not prepared for sewer out side the Recharge Zone. The interceptors outside the Recharge Zone are not subject to the same requirement. But it should be noted its condition is unknown and a relatively high risk associated with the potential failure of defects in the interceptors exist especially in the creek. Due to the uncertainty of the condition of the Interceptors no estimates are included for sewer rehabilitation design or construction at this time. The general scope of services is as follows: 1. Bidding and Contract Assistance—Engineer will assist the City in advertising, obtaining, and evaluating Bid Proposals for the Inspection contract and awarding. Provide assistance to the City in responding to bidder inquiries during advertisement of the inspection contract, and participate in project pre- bid conference. Provide and distribute bidding documents and addendum. Assist the City in reviewing the bids for completeness and accuracy. Provide the successful bidder(s)with the contract specifications for execution and the insertion of the required insurance certificates. II. CCN/Sonar/Laser and Cleaning—To be bid out. Work completed by other than Engineer. This will include CCN(closed circuit TV), or a combination of laser and or sonar where applicable depending on pipe size and debris depth. 111. TV Inspection Administration—Work with TV inspector to assure proper data collection. Coordinate and organize TV inspection data for completeness. Update GIS with date of Inspection performed and provide to City upon completion of TV. IV. CCN Review and Recommendations—It is anticipated that CCTV/Laser or Sonar will be performed on 41,288 LF of sanitary sewer pipe and cleaning will be performed when possible. RJN will review the video and summarize the recommendations. We recommend utilizing a PACP (Pipeline Assessment Certification Program)for defect coding and rating. Pipe defects will be prioritized for repair and an associated construction cost will be assigned to each line segment. EXHIBIT C WORK SCHEDULE 2011 2012 Task Name NOV DEC JAN FEB MAR APR MAY JUN JUL AUG SEPT OCT NOV PROJECT KICKOFF PROJECT ADMIN/MEETINGS BIDDING AND CONTRACT SERVICES TAPE REVIEW RECOMMENDATIONS PROJECT: 2012 REGIONAL INSPECTION ROUND ROCK,TEXAS TIME LINE _ INTERCEPTOR DATE: 10/20/11 Critical milestone: must receive all TV video to meet September 2012 completion Exhibit D Fee Schedule Total Total Other Task Labor Hours Loaded Labor Cost Direct Costs Subconsultants TOTALS Task 1: (e.g. bid phase services) 30 $3,300.00 $600.00 $0.00 $3,900.00 Task 2: (e.g.TV Inspection Review) 104 $9,760.00 $300.00 $0.00 $10,060.00 Task 3:(e.g. Recommendations) 98 $10,320.00 $219.60 $0.00 $10,539.60 Task 4: (e.g. p 'ect ma ement) 40 L $4,680.00 1 $1,200.00 $0.00 $5,880.00 GRAND TOTAL: 272 $28,060.00 $2,319.60 $0.00 $30,379.60 EXHIBIT E Certificates of Insurance Attached Behind This Page i CERTIFICATE OF LIABILITY INSURANCE Date: January 3,2012 TDI number required.Please refer to the fPRODUCsEson.t �L4naW Texas Dept of Insurance webatte: h1la W1.1tatcu msi aseAbd"ena Chbaaa N.601 COMPANIES AFFORDING COVERAGE TDl Phops:aw-22l.snm E•mau:un.x..oawWn.lwrean A Hanford Fire Insurance Co. 19882 FUNO,,,pReIM B St.Paul Fire and Marine Ins.Co. 24767 02S M 81- C TvAn City Fire Insurance Co. 29459 wwa%IL satyr Phone: aan.ane_om E4na0: cons D Essex Insurance Co. 139020 THIS IS TO CERTIFY THAT the Insured named above Is Insured by the Companies listed above with respect to the business operations hereinafter described,for the types of Insurance and In accordance with the provisions of the standard policies used by the companies, and further hereinsfterdesedbed. Exceptions to the policies are noted below. CO TYPE OF POLICY EFFECTIVE EXPIRATION LIMITS LTR INSURANCE NUMBER DATE DATE GENERAL LIABILITY GENERAL AGGREGATE $ 1,000,000 A sx UMJ1317 001/2011 08/01/2012 PRODUCTS-COMP/OP AGO. S 300,000 PERSONAL&ADV.INJURY S 10,000 EACH OCCURRENCE S 1,000.000 FIRE DAMAGE(Any one ft) $ 2,000,000 i MED.EXPENSE(Any one person) S 1,000,000 AUTOMOBILE UABtiITY COMBINED SINGLE LIMIT $ 1,000,000 A &VJMN141 s 08/01/2011 08101/2012 BODILY INJURY(Per person) $ BODILY INJURY(Per accident) $ PROPERTY DAMAGE $ EXCESS LIABILITY EACHACCURRENCE S 10,000,000 13 OX012MM9 08/01/2011 08101/2012 AGGREGATE S 10,000.000 WORKERS'COMPENSATION STATUTORY LIMITS S X AND EMPLOYERS'LIABILITY EACH ACCIDENT S 500,000 `. 63WEPLI505 0810112011 08/01/2012 DISEASE-POLICY LIMIT $ 500,000 DISEASE-EACH EMPLOYEE $ 500,000 D PROFESSIONAL.LIABILITY 11CPLooesr 00112011 08101/2012 $3,000,000 Per Clafmi$3,000,000 Aggregate BUILDERS'RISK INSURANCE OR INSTALLATION INSURANCE DESCRIPTION OF OPERATIONSILOCATIONSIVEHICLES/SPECIAL ITEMS/EXCEPTIONS The City of Round Rods is named as additional Insured with respect to all policies exceptWorkers'Compensation and Employers' Uabnfty'and 'Protesslonal 1.1011W. Should any of the above described policies be cancelled or changed before the expiration date thereof,the looming company will mail thirty(30)days written notice to the certificate holder named below. CERTIFICATE HOLDER City Manager City or Round Rock SIGNATURE OF AGENT LICENSED IN STATE OF TEXAS 221 E.Main Street Round Rods,Taxes 78884 Typed Name: Sc t o nj B ,): y License 10: 1397057 Page 1 00650 7-20D9 Cenifitme of Liability Insurance 00090656