CM-2020-048 - 2/14/2020c
l OV
City of Round Rock Agreement
for Architectural Services for
City of Round Rock
Prete Main Street Plaza Restroom Project
With
RHad Enterprises, Inc.
(DBA MODE Design Company)
AGREEMENT made as ofthe ^. f j} I ( I11- ) da% of the month of
Two
in they ear
Thousand T%tient} (2020).
� !
BETWEEN the Architect's client identified as the Cit% or the Owner:
City of Round Rock
221 Fast Main Street
Round Rock- NVilliamson and Travis Counties. Texas 78664
and the Architect:
RI lad Enterprises, hte.
D13A MODE Design Compact}
103 Woods Lane
Cedar Park, Texas 78613
ror the foIlo%tiing Project:
Professional architectural services and design services related to the design and construction of a stand-alone
restroorn building in the Prete Main Street Plaza located in Round Ruck,
Texas,
Professional ser%ices lbr this Project shall include but not be limited to, Schematic
Design, Design De%clopment.
Construction Documents, Bidding Phase and Construction Obser%ation.
The Owner and the Architect agree as folio%%s:
ARTICLE 1.1 INITIAL INFORMATION
I.I.1 This Agreement is based on the folio►%ing information and assumptions
TheArchitect shall furnish the delineated services, including but not limited to meeting With the Ouner's
representatives and others designated by the Onner to determine needs and requirements', rendering professional
consultation and ad%ice, furnishing al[ necessam design and contract administration services for the referenced
Project: and prodding other specialized services.
Architectural services shall include the submittal of plans for Texas Accessibility Standards (TAS) revic%%, «hick is
a requirement of federal la" to comph. with the ADA if [lie construction budget exceeds S50.000- Owner shall pay
the fees related to the submittal of plans for TAS rev iew-
1.1.2 PROJECT PARAMETERS
1.1.2.1 The objective or use is: Stand-alone public restroom building.
00438333 ss2
61Y-252(>-Oq?
nth
The referenced Project consists of professional planning, design, and construction sen-ices related to the follow ing:
Two (2) single user restroom spaces %%ith required chases and storage areas-
1. 1.2.2 The physical parameters are,
The Project is to be located on City -owned property at 221 Last Main Street across from Cit) 1-IaIL in Round Rock,
Texas.
1.1.2.3 The O►vner's Program is:
The program of development shall include but not be limited to the follo%%ing elements: Confirm Project Program
and Space Requirements. Schematic Design Phase, Design Development Phase, Construction Documents Phase,
Bidding Phase and Construction Administration Phase. The tasks performed as a part of each element shall be as
stated in Exhibit "A" attached hereto and incorporated herein for all purposes. The parties agree that elements or
portions thereof, may be omitted by the Opener for reasons including meeting the Project budget and Project
requirements.
Schedule
Initial proposed schedule for the Project is incorporated in Exhibit "B," attached hereto and incorporated
herein for all purposes_ The Architect till maintain a detailed project schedule in Microsoft Project or in
an alternati►e format approved by the 0%►ner througllout the duration of the Project.
1.1.2.4 1 he financial parameters are as follo%%s:
I _ The Fee Schedule relative to this Agreement is set forth in lixhibit "A," and is as follows.
A. Professional Services
In consideration for the professional services to be performed b% the Architect, the Owner agrees
to pay the Architect a total sum not to exceed Ten Thousand Five hundred and MAN Dollars
(SI0r500.00). Said sum is a fixed not -to -exceed amount, and shall be paid as delineated in the
attached Exhibit "A" %%hich is incorporated herein by reference for all purposes. Such not -to -
exceed sum includes amounts paid for Architect's services; for consultant fees for \IEP engineers,
structural engineers, civil engineers, and AD,A consultants as needed.
B. Reimbursable Expenses Allowance
Payment for reimbursable expenses, including administratke charges and out -of pocket expenses.
shall not exceed the maximum sum of Five !Hundred and No/100 Dollars (S500.00), and such
amount is inchulecl in the not -to -exceed total fee for Professional Senices of S10,500.00.
Reimbursable expenses shall be paid as set forth herein and as in L•'xhibit "A."
Tra%el reimbursements may be made for meals, travel, lodging as follons:
(1) all travel shall be in coach and not in business class;
(2) loll road charges if provided %%ith documentation of the date and time the toil charges were
incurred;
(3) lodging shall be in a standard room in a hotel located within Round Rock's City limits; and
(4) meals shall be reimbursed at an amount not -to -exceed S50,00 per day . This amount includes
tips.
Tra►el reimbursements shall only appl% to travel in excess of forty (40) miles. Architect is
responsible for providing all receipts to Owner for the reimbursement of items set forth abo%e.
2
T
Receipts shall be pro%ided to the Owner within sixt) (60) days ofthe expenditure to qualif) for
reimbursement and shall provide enough detail for the Owner to determine the requested
reimbursements meet the criteria set forth herein_ It shall be in the sole discretion of time Owner to
determine if expenses submitted by Architect are reasonable and qualify for reimbursement
pursuant to the terms of the Agreement,
Cost of personal entertainment, amusements_ alcoholic beverages, traffic citations, personal items
or illegal activities will not be reimbursed. Expenses due to %acations or personal trips in
conjunction with tra%el are not reimbursable. Adequate travel time is allowed, but travel expenses
are not paid for absences not required hy Ottner business-
C. Additional Services
Additional senices are defined as an) services not included as part of the scope of work of the
project including revisions to previously -approved plans that necessitate additional work for the
Architectr substantive changes in Project scope, or additional work necessitated by unknown or
reasonably unforeseen circumstances. Any additional services shall be performed under a
supplemental agreement negotiated at a time subsequent to this Agreement.
1.1.2.5 The time parameters are,
Services hereunder shall commence within ten (10) days upon receipt by the Architect of Notice to Proceed from
the Owner. Completion date shall be agreed upon hp Owner and Architect and shall be incorporated in Exhibit ` B."
Other time parameters or adjustments to time parameters matt be determined at a later date by mutual agreement of
the parties_
1.1.2.E 1 he proposed procurement or delis en method for the Project is: Undetermined.
Professional sen ices such as architectural engineering will be engaged b) negotiated contract.
1.1.3 PROJECT TEAM
1.1.3.1 fhe Owner's Designated Representatives are
Laurie I ladley, City _Manager
City of Round Rock
22 l Bast ;Hain Street
Round Rock, Texas 78661
Aneil Naik, Development Construction Manager
General Services Department
City of Round Rock
221 East Clain Street
Round Rock, Texas 78664
1.1.3.2 The Owner's consultants and contractors are-.
Architect of Record ; Prime Firm:
RHad Enterprises, Inc,
DBA LMODF Design Company
Consultants:
Civil Engineer: 2P Consultants
Structural Engineer: Robert Hammond
MEP Engineer: Bacom Brothers Engineering
Any additional Consultants are to be submitted to Owner and appro%ed by Owner.
1.1.3.3 The Architect's Designated Representative is:
Rf-lad Enterprises, Inc.
DBA MODE Design Company
Ryan Hansanuwat, RA, NCARB, LEED AP
103 Woods Lane
Cedar Park, Texas 78613
1.1.3.4 The consultants retained at the Architect's expense shall be submitted to and approved by Owner.
1.1.4 Duties, responsibilities and limitations of authority of the Architect shall not be restricted, modified or
extended without written agreement of the Owner and the Architect.
1.1.5 It is expressly understood and agreed by and between the parties hereto that any alteration in schedule.
compensation and Change in Services shall be effected onI% by Supplemental Agreement hereto. Any such
Supplemental Agreement to this Agreement must be duly authorized by appropriate City Council or City Manager
action.
AWFICLE 1.2 RESPONSIBILITIES OF THE PARTIES
1.2.1 The Owner and the Architect shall fully cooperate with one another to fulfill all of their respective
obligations required under this Agreement. Both parties shall endca%or during the full term hereof to maintain good
working relationships among all members of the Project team. `
1.2.2 0WNER
1.2.2.1 finless otherwise provided under this Agreement. the Owner shall provide full information in a timcl%
manner regarding requirements for and limitations on [lie Project.
1.2.2.2 The Owner shall establish and periodical]% update the budget for the Project, including that portion
allocated for the Cost of the Work. the Owner's other costs, and reasonable contingencies related to all costs.
1.2.2.3 The Owwner's Designated Representatives identified in Paragraph I.I.+.1 shall he authorized to act on the
Owner's behalf with respect to the Project. The Owner or Owner's Designated Representatives shall render
decisions in a timely manner pertaining to documents submitted by the Architect in order to avoid unreasonable
delay in the orderly and sequential progress of the Architect's scr%ic'
1.2.2.4 The Owner may furnish the services of consultants other than those designated in Paragraph 1.1.3.2 or
authorize the Architect to furnish them as a Change in Ser%ices when such services are requested by the Architect
and are reasonably required by the scope of the Project or a change in the scope of the Project, Any service
furnished by the Architect at the Owner's request must be approved by the Owner.
1.2.2.5 Unless otherwise provided in this Agreement. and if requested in .%riting. the Owner shall furnish or pay
for tests, inspections and reports required b% law or the Contract Documents, such as structural, mechanical, and
chemical tests. tests firr air and water pollution, and tests for hazardous materials.
1.2.2.6 The O%►ner shall fumish all legal, insurance and accounting ser%ices, including auditing services, which
may be reasonably necessary at any time for the Project to meet the Owner's needs and interests.
1.2.2.7 Each party shall pro%ide prompt mitten notice to the other if either becomes aware of any fault or detect in
the Project, including any errors, omissions or inconsistencies in the _Architect's Instruments of Ser%ice.
0-
1:2.2.8 The Owner will furnish building permits without charge Electrical, plumbing and other trade permits willbe the responsibility of the construction contractor. Any charges which may be assessed for tap fees ►till be paid by
the Owner and are not to be included by the Architect in the specifications for the Project.
1.2.2.9 Owner agrees to pay the actual costs of review fees associated with Texas Building Accessibility reviews,
reviews by other authorities having jurisdiction, and any other required filing fees.
1.2.2.10 The Owner will provide the Architect with miscellaneous items such as the Project Facility Program, one
digital copy of the City of hound Rock Genera] and Supplementary Conditions for Building Construction, Wage
Rates, Contract and Bond Forms, and such other information and materials as may be necessary and practicable for
the orderly and expeditious progress of the ►►ork and the awarding of the construction contract. To the extent
practicable. these documents shall be utilized in the preparation of the construction documents.
1.2.2.11 The Owner will provide timely re► iew and response to inquiries in order to maintain an orderly progression.
1.2.2.12 Any information related to design standards and O►►ner-furnished equipment specifications not pro►ided
pursuant to Section 1.2.2.10 above and desired by the Architect from the Owner must be requested by the Architect
in w riting during the initial Phase of the Project.
1.2.3 ARCHITECT
1.2.3.1 The services performed by the Architect, the Architect's employees and the Architect's consultants shall he
as enumerated in Article 1.4 and as enumerated elsewhere herein, in attached and accompaming documents, in
supplemental documents. and in related documents_
1.2.3.2 The Architect's services shall be performed as expeditious]) as is consistent with professional skill and care
and the orderly progress of the Project_ The Architect shall submit for the Owner's approval a detailed schedule in
Alicrosofl Project or an approved alternative format for the performance of the Architect's services which initially
shall be consistent with the time periods established in Exhibit " B" and which may be adjusted, if necessan and
approved by the Owner, as the Project proceeds_ This schedule shall include allowances for periods of time required
for the Owner's review, for the performance of the Owner's consultants, and for approval of submissions by
authorities having jurisdiction over the Project, Time limits established by this schedule approved by the Owner
shall not, except for reasonable cause, be exceeded by the Architect or the Owner.
1.2.3.3 The Architect's Designated Representative identified in Paragraph 1.1.3.3 shall be authorized to act on the
Architect's behalf w ith respect to the Project.
1.2.3.4 The Architect shall maintain the confidentiality of information speciftcalh designated as confidential b► the
O%%ner, unless withholding such information would violate the law. create the risk of significant harm to the public
or prevent file Architect from establishing a claim or defense in an adjudicator proceeding. The Arclikect shall
require of the Architect's consultants, similar agreements to maintain the confidentiality of information specificalh
designated as confidential by the Ow tier.
1.2.3.5 Except with the Owner's knowledge and written consent, the Architect shall not engage in an%y activity, or
accept any employment, interest or contribution that would reasonably appear to compromise the Architect's
professional judgment ►v ith respect to this Project or compromise the performance of the approved schedule for this
Project.
1.2.3.6 The architect shall review laws, codes, and regulations applicable to the Architect's services. The architect
shall respond in the design of the project to requirements imposed by governmental authorities having jurisdiction
0%er the Project,
1.2.3.7 The .architect shall be entitled to reasonabl% rely on the accuracy and completeness of sere ices and
information furnished by the Owner, Each party shall' prompt written notice to the other if either becomes
aware of any errors, omissions or inconsistencies in such services or information.
ARTICLE 1.3 TERMS AND CONDITIONS
1.3.1 COST OF TH E WORK
1.3.1.1 The Cost of the Work shall be the total cost or, to the extent the Project is not completed, the estimated cost
to the Owner of all elements of the Project designed by the Architect.
1.3.1.2 The Cost of the Work shall include the cost at reasonable current market rates of labor and materials
furnished by the Owner and equipment designed, specified, selected or specially provided for by the Architect,
including the costs of management or super ision of construction or installation provided by a separate construction
manager or contractor, for the Contractor's overhead and profit.
1.3.1.3 The Cost of the Work does not include tite compensation of t[te Architect and the Architect's consultants.
the costs of the land, rights -of --way and financing or other costs that are the responsibility of the Owner.
1.3.2 INSTRUMENTS OF SERVICE
1.3.2.1 Drawings, specifications and other documents, including those in electronic form, prepared by the
Architect and the Architect's consultants are Instruments of Service for use solely by the Owner. All of the
Architect's designs and work product under this Agreement, including but not limited to Tracings, Drawings,
Estimates. Specifications. Investigations, Studies and other documents, shall be the properq of the Owner, to be
used as the Owner desires; by execution of this Agreement and in confirmation of the fee far sen ices to be paid
under this Agreement, the Architect hereby conveys, transfers and assigns to the Owner all rights under the federal
Copyright Act of 1976 (or any successor copy right statute), as amended, all common lave copyrights and all other
intellectual property rights ackno%%[edged by law in the Project designs and work product developed under this
Agreement. Copies may be retained by the Architect. The Architect shall be liable to the Owner for anv loss or
damage to an% such documents while they are in the possession of or while being worked upon by the Architect or
anyone connected with the Architect, including agents, employees, consultants or subcontractors. All documents so
lost or damaged shall be replaced or restored by the Architect w ithout cost to the Owner.
1.3.2.2 Upon execution of this Agreement, the Architect grants to the Owner permission to reproduce the
Architect's Instruments of Sen ice for purposes of constructing, using and maintaining the Project, provided that the
Owner shall comply with all obligations, including prompt payment of all sums when due, under this Agreement.
The Architect shall obtain similar permission from the Architect's consultants consistent with this Agreement.
Upon termination of the Agreement, the Owner is permitted to authorize other similarly credentialed design
professionals to reproduce and, where permitted by iavn, to make changes, corrections or additions to the Instruments
of Scn ice for the purposes of completing, using and maintaining the Project or additional projects.
1.3.2.3 The Owner shall not assign, delegate, sublicense, pledge or otherwise transfer any permission granted
herein to another party without the prior written agreement of the .architect. Howcver, the Owner shall be permitted
to authorize the Contractor. Subcontractors. Sub -subcontractors and material or equipment suppliers to reproduce
applicable portions of the Instruments of Sery ice appropriate to and for use in their execution of the Work,
Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes
in connection with the Project is permitted. Any unauthorized use of the Instruments of Service shall be at the
Owner's sole risk and without liabiliq to the Architect and the Architect's consultants.
1.3.2.4 Prior to the Architect providing to the Owner an Instruments of Senice in electronic form or the Owner
providing to the Architect am electronic data for incorporation into the Instruments of Service. the Owner and the
Architect shall by separate written agreement set forth the specific conditions governing the format of such
Instruments of Senice or electronic data, including any special limitations not otltenvise provided in this
Agreement.
1.3.2.5 All plans and drawings will be prepared and submitted digitally by the Architect to the Owner for approval
on a minimum 24-inch by 36-inch format, with all lettering processed in ink or pencil and clearly legible when the
sheets are reproduced and reduced to half size.
1.3.2.6 Upon completion of the construction of the Project, the Architect shall, within thirty (30) calendar days
from receipt of final -as -built mark-ups from the contractor, deliver to the O«ner the reproducible Record Drawings
and Record Specifications as described supplemental]) herein. In addition, the Architect shall submit originals of all
documents listed under Section 1.3 —1 modified to actual as -built conditions as provided by the General Contractor.
1.3.2.7 The Architect shall have no liability for changes made to the drawings. Any such change shall be sealed b)
the architect making that change and shall be appropriatel% marked to reflect %iftat "as changed or modified. To the
extent permitted by law, the Ouner agrees to indemnify,
Service. defend and hold harmless the Architect for an% claims,
damages, suits and loss of even kind and nature for the unauthorized re -use of the Architect's Instruments of
1.3.3 CHANGE IN SERVICES
1.3.3.1 Change in Ser%ices of the Architect, including services required of the Architect's consultants, ma} be
accomplished after execution of this Agreement, without invalidating the Agreement, if mutually agreed in writing.
It is express]) understood and agreed b) and beween the parties hereto that an) alteration in schedule.
compensation and Change in Serf ices shall be effected only b) Supplemental Agreement hereto. Am such
Supplemental Agreement to this contract must he duly authorized b) appropriate Cit) Council or City 1lanager
action.
1.3.4 ;MEDIATION
1.3.4.1 Ant claim, dispute or other matter in question arising out of or related to this Agreement shall be subject to
mediation. If such matter relates to or is the subject of a lien arising out of the Architect's ser%ices, the Architect
niay proceed in accordance %%ith applicable lak% to comp]) With lien notice or filing deadlines prior to resolution of
the matter b) mediation_
1.3.4.2 The O«ner and the Architect shall endeavor to resolve claims, disputes and other matters in question
bel%%cen them by mediation_ Request for mediation shall be filed in %%citing with the other party to this Agreement,
and mediation shall proceed in ad%ance of legal or equitable proceedings, "hick shall be stay ed pending mediation
for a period of 60 day s from the date of filing, unless stayed for a longer period b) agreement of the parties or court
order.
1.3.4.3 The parties shall share the mediator's fee and any filing foes equally. The mediation shall be held in the
place %there the Project is located, unless another location is mutually agreed upon, Agreements reached in
mediation shall he enforceable as settlement agreements in any court ha%ing jurisdiction thereof.
1.3.5 ARBITRATION
1.3.5.1 The Owner and the Architect hereby expressly agree that no claims or disputes between the Oiuier and the
Architect arising out of or relating to the contract documents or a breach thereof shall be decided b) an) arbitration
proceeding, including. without limitation, any proceeding under the Federal Arbitration Act (9 U,S.C. Section 1-14)
or any applicable state arbitration statute, except that in tiie Cent that the Onner is subject to an arbitration
proceeding related to the Project, the lrchitect consents to be joined in the arbitration proceeding if tite Architect's
presence is required or requested b) the 0%%ner for complete relief to be accorded in the arbitration proceeding.
1.3.6 CLAIMS FOR CONSEQUENTIAL IAL DAMAGES
1,3.6.1 The architect and the Oiener matte consequential damages for claims, disputes or other matters in question
arising out of or relating to this ,Agreement. I'll is mutual waiver is applicable, %%ithout limitation. to all consequential
damages due to either party 's termination in accordance nitli Section 1.3.8,
1��
1.3.7 ,N11SCELLa,\EOUS PROVISIONS
1.3.7.1 This agreement shall be governed by the laws of the state of Texas, and venue shall lie in Williamson
County, Texas.
1.3.7.2 Causes of action between the parties to this Agreement pertaining to acts or failures to act shall be deemed
to have accrued and the applicable statutes of limitations shall commence to run not later than either the date of
Substantial Completion for acts or failures to act occurring prior to Substantial Completion or the date of issuance of
the final Certificate for Payment for acts or failures to act occurring after Substantial Completion. in no event shall
such statutes of limitations commence to run any later than the date when cite architect's services are substantially
completed.
1.3.7.3 To the extent damages are covered by property insurance during construction, the Ovwner and the Architect
%%aiwc all rights against each otter. The Ovwner, as appropriate, shall require of the contractors, consultants, agents
and employ ces of any of them similar waivers in favor of the other parties enumerated herein.
1.3.7.4 Nothing contained in this Agreement shall create a contractual relationship with or a cause of action in
favor of a third part against either the Owner or the architect.
1.3.7.5 Villess otherwise provided in this Agreement, the Architect and the Architect's consultants shall have no
responsibility for the discovery, presence, handling, remo%al or disposal of or exposure of persons to hazardous
materials or toxic substances in am form at file Project site.
1.3.7.6 The Architect shall have the right to include photographic or artistic representations of the design of the
Project among the architect's promotional and professional materials. The architect shall be given reasonable
access to the completed Project to make such representations. 1Io%kever, the Architect's materials shall not include
file Owner's confidential or proprictar) information.
1.3.7.7 if the Ovyner requests the Architect to execute certificates, the proposed language of such certificates shall
be submitted to the Architect for review at least seven (7) days prior to the requested dates of execution. 'fire
Architect shall not be required to execute certificates that %would require kno%0edge, services or responsibilities
beyond the scope of this Agreement.
1.3.7.8 The Owner and the Architect, respectively, bind themselves, their partners, successors, assigns and legal
representatives to the other party to this Agreement and to the partners, successors, assigns and legal representatives
of such other part)- with respect to all covenants of this Agreement. Neither the Owner nor the Architect shall assign
this Agreement %%ithout the written consent of the other.
1.3.7.9 All Exhibits to the Contract are incorporated herein as a part of the Contract. An% inconsistencies or
conflicts in Contract and Exhibits shall be resolved b% gi%ing preference to pages one ( I ) through ten (10) of the
Contract.
1.3.7.10. In accordance with Chapter 2270, Texas Government Code, a governmental entity may not enter into a
contract uith a company for goods or services unless the contract contains written verification from the company
that it: (I) does not boycott Israel; and (2) will not boycott Israel during the term of this contract. The signatory
executing this Agreement on behalf of architect verifies Architect does not boy colt Israel and vy ill not boy colt Israel
during the tern of this Agreement.
1.3.8 TERMINATION OR SUSPENSION
1.3.8.1 If the Owvner fails to make payments to the Architect in substantial compliance with this Agreement, such
failure ma) be considered substantial nonperformance and cause for suspension of performance of services under
this agreement. Ifthe Architect elects to suspend services, prior to suspension of services, lite Architect shall ai%e
Fifteen (15) days' %kritten notice to the Owner. In the event of a suspension of services, the Architect shall have no
liability to Cite Onner for dela) or damage caused the O►yner because of such suspension of services. Before
resuming services, tite Architect shall be paid all non -disputed sums due prior to suspension. 'file Architect's fees
for the remaining serf ices and the time schedules shall be equitably adjusted.
1.3.8.2 In connection %%ith the work outlined in this Agreement, it is agreed and fulh understood by the Architect
that the Ottner may cancel or indefinitel3 suspend further work hereunder or terminate this contract either for cause
or for the convenience of the Ottner, upon fifteen (15) days' written notice to the Architect, with the understanding
that immediately upon receipt of said notice all work and labor being performed under this Agreement shall cease,
The Architect shall invoice the 0%%ner for all work satisfactorily completed and shall be compensated in accordance
with tite terms of this Agreement for all %%ork accomplished prior to the receipt of said notice. No amount shall be
due for lost or anticipated profits. All plans, field surveys, maps, cross sections and other data, designs and stork
related to the Project shall become the property of the Ottner upon termination of [Iris agreement, and shall be
prompt[-. dcli%ered to tite 0%%ner in a reasonably organized form %%ithout restriction on future use. Should the
O►►ner subsequentl) contract with a new architect for continuation of services on the Project, the architect shall
cooperate in prat iding information.
1.3.8.3 nothing contained in Section 1.3.8.2 immediately above shall require the Owner to pay for an) work which
is unsatisfactory as determined by the Owner's representative or «hick is not submitted in compliance ttith the
terms of this Agreement. The Owner shall not be required to make am payments to the Architect when the
Architect is in default under this contract, nor shall this section constitute a waiver of any rib -lit. at law or at equity,
►►hich the Ot►ner may hate if the Architect is in defauh, including the right to bring legal action for damages or to
force specific performance of this Agreement.
1.3.9 PAVNIENTS TO ARC MTECT
1.3.9.1 Payments on account of services rendered shall be made montlily upon presentation of the Architect's
statement ofserwices.
1.3.9.2 Reimbursable Expenses, in an amount not to exceed $500.00. are included in the not -to -exceed suns for
compensation for the Architect's professional services and include expenses incurred by the Architect and the
Architect's employees and consultants directly related to tite Project, as described in 1.1.2.4.B.
1.3.9.3 Records of Reimbursable Expenses, of expenses pertaining to a Change in Sert ices, and of sort ices
perforated ors the basis of hourly rates or a multiple of Direct Personnel Expense shall be promptly provided to the
Owner or the Owner's authorized representatites.
1.3.9.4 Direct Personnel Expense is defined as the direct salaries of the .architect's personnel engaged on the
Project and the portion of the cost of their mandator% and customary contributions and benefits related thereut, such
as employment taxes and other statutor3 employee benefits, insurance, sick leave, holidays. vacations, employee
retirement plans and similar contributions.
\RriCLE I.-4 SCOPE OF SERVICES AiND 07'IIER SPECIAL TER\IS;%ND CO\D[T[O\S
I.4.1 Lnumeration of Paris of the Agreement_ This Agreement represents the entire and integrated agreement
between the Owner and the Architect and supersedes all prior negotiations, representations or aereements, either
►tritten or oral. This Agreement nia% be amended only by written instrument signed b) both the Otaner and the
Architect. This Agreement comprises the documents listed below.
1.4.1.1 Architectural Services agreement between Owner and Architect.
1.4.1.2 Other documents as hollow's:
Exhibit " A" Fee Proposal and Scope of Sert ices
Exhibit "B" Project Schedule
"Supplemental ,•lgreentent No. I" supplementing architectural Ser%ices Agreement between Owner and Architect
9
1.4.2 Special Terms and Conditions. Special terms and conditions that modify this Agreement are as follows:
Americans with Disabilities Act (ADA) and Texas Accessibility Standards (TAS) provide that it is a violation of
ADAJAS to design and construct a facilit% for first occupancy later than Januar% 26. 1993 that does not meet the
accessibility and usability requirements of the ADA:'TAS except "here an entity can demonstrate that it is
structuralh impractical to meet such requirements. The Architect %%ill use its best professional efforts to interpret
and meet applicable ADA,TAS requirements and other federal. state and local laws, rules, codes, ordinances and
regulations as they appl} to the Project,
_ARTICLE 1.5 COMPENSATION
1.5.1 Payments for services shall be made monthly, and "here applicable, shall be in proportion to services
performed on the basis set forth in this Agreement and in format requested b% the Wner.
1.5.2 Payments are due and pa%able thirty (30) da%s from the date of the Architect's invoice, or not later than the
time period required under the Texas Prompt Ila-,ment Act. "hiche%er is later. Non -disputed amounts unpaid sixt%
(60) da%s after the invoice date shall bear interest at the rate entered belo". or in the absence thereof at the legal rate
prevailing from time to time at the principal place of business of the Architect.
Pay ments hereunder shall be made in accordance %%ith the Prompt Pay menl Act
I his kercement entered into as of the da% and } ear first «ritten abo%e,
ISignaitures on the follorl ing page.1
M,
OWNER
CITl" OF ROUND ROCK, TEXAS
ARCHITECT
R HAD ENTERPRISES, INC.,
DBA MODE DESIGN COLNIPANV
B•: gx;
Innager, -ItA61
�1
Date: 2.11-. ozo
ATTEST:
By: �gf� -4cqk�L7
Sara L. White, Cite Clerk
FOR CITY, APPROVED ,►S TO FORM:
BF: �
Stephan L. M cts, ('its Ilturnn
Uate: 3 I -,-1 { Zd`bo
Exhibit "A"
1/13/2020
Aneil Naik
City of Round Rock
RE: Fee Proposal for Prete Plaza Restroom in Round Rock, TX
MODE Design Company is pleased to subm,t the following proposal for Architectural Consulting and Engineering Services.
The following proposal is based on the understanding that this project w'll be a freestanding restroom building with two (2)
single user restroom spaces with applicable chases and storage areas. Design includes both interior and exterior of the
restrooms Three (3) initial concept designs to be included for approval by city staff prior to construction documentation. Up
to two (2) minor rev'sions are included in scope for changes during design or construction. Scope shall also include signage
required for the building as well as any wayfinding signage for the plaza.
Basic services include schematic design, code analysis, design documents, construct on documents to be used for permitting,
bidding and construct;on. Basic services also include bidding assistance and construction observation services as described
herein. The construction documents will include industry standard architectural, mechanical engineering, electrical
engineering and plumbing engineering drawings and specifications.
Structural engineering to consist of foundation, stab, and reinforcement design based on owner provided geotechnical soils
report. MEP Engineering to provide electrical load analysis and one -line diagram, power and lighting schedule, fixture
schedule, plumbing water and wastewater design and plumbing fixture schedule
Landscape Architecture, Geotechnical, Surveying, Audio Visual, Security and Informatio*+ Technology (IT) design services are
not included in this contract. Architectural fees include all necessary coordination between disciplines with the owner's
engineers of choice.
Below is a summary of the fees for each phase and design discipline:
Compensation (Lump -Sum):
Schematic Construction Bidding & Construction
Design Documents Permitting Observation Totals
Architecture $2,000.00 $2,500.00 5500.00 $500.00 $5,500.00
Civil Engineering $1,500.00
Mechanical, Electrical and Plumbing Engineering S2,500.00
Structural Engineering $1,000.00
Total S10,500.00
1r er.a wt11 1 03 (w P„W
ODE I
N'""V7• 7ri13
an - madrnlc uc I — '.0iml: us
• 1 512 733 1153
Exhibit "A"
The following are our general compensation provisions_
Reimbursable Expenses are in addition to compensation for Basic and Additional Services and include expenses
incurred by the Architect and Architect's employees directly related to the project as identified below;
1. Fees paid for securing approval of authorities' jurisdiction over the project; including but not limited to- TAS
registration, review or inspection fees.
2. Reproductions, plots, standard form documents, travel, postage, handling and delivery of Instruments of
Service;
3. Expense of overtime work requiring higher than regular rates if authorized in advance by the Owner /
Contractor;
Reimbursable Expenses are balled at 1.15 times the expense incurred by the Architect,
HOURLY RATE SCHEDULE
Principal
$200.00
Project Manager
$150.00
Interior Designer
$140.00
Designer
$1 10.00
Administrative/Clerical
$90.00
Ma E
r/rsir�P rr•i�i �rii�� 1 0 3
rpn- mod.1cu:i.ve.w:ro'!u:4tes
- 1 512 733 1153
Vk
Exhibit 4A"
BASIC SERVICES DESCRIPTION
Schematic Design
The Architect shall review the program with the Owner and evaluate potential space plan configurations. The Architect will
perform an initial onalys's of the layout to conform with apphcable codes and regulations. The Schematic Design documents
shall consist of drawings and other documents including a two-dimensional floor plan layout of the space, interior elevations
of walls and/or millwork, reflected ceiling plan and a finishes norrat<ve. Two (2) revisions of design resulting in an increase in
scope Va increase in square footage over 10% or construction cost of 10% are anticipated in this phase. Additional changes
beyond inira1 two (2) revisions will be charged at the hourly rate listed above.
Design Deve.'opment
Based upon the Owner's approval of the Schemak Design Documents, the Architect shall produce Design Development
documents that w1l consist of further detailing of the selected design. Design Development Documents shall consist of plans,
sect;ons, elevation, typical construction details and layouts of systems such as structural, mechanical and electrical systems.
One (1) revision of design resulting in an increase in scope via increase in square footage over 10% or construction cost of
10% are anticipated in this phase. Additional changes beyord initial revision will be charged at the hourly rate listed above.
Construction Documents
Based upon the Owner's approval of the Design Development Documents, the Architect shall incorporate the design into a
working set of construction documents that will be used for the construction of the space and for bidding and permitting. The
Construction Documents shall consist of Drawings and/or Specifications setting forth the design intent, quality of materials
and systems and other requirements for the project. Zero (0) revisions of design resulting in an increase in scope via increase
in square footage over 10% or construction cost of 10% are anticipated in this phase. Additional changes at this phase will
be charged of the hourly rate listed above
Bidding and Permitting
The Architect shall assist the owner in reviewing the list of potential bidders and responding to bidder questions as needed.
Owner shall be responsible for securing all permits required for construction and as needed for their business function.
Architect shall assist owner in providing information needed by the authority having jurisdiction to obtain a building permit on
an as needed basis.
Construction Observation
The Architect shall advise and consult with the Owner during construction to ensure design intent, quality of materials and
system and other requirements for the project are being met by the contractor. The Architect shall visit the site as needed to
IN
�O (SJ✓�// DE
I'( /// X///y 0 '3 ceder pork, e. 72613
ryun n a�cd_.u: I w..w..modcd: u!
1 512 733 1 t5D
Exhibit ON'
review any condTans the Owner requires assistance on. As needed, the Architect shall review applications for payment
provided by the Contractor to review conformance with the Contract Documents and construction progress.
As needed, the Architect shall review submittals provided by the Contractor to review for conformance with the design intent
and quality of materials and/or systems, As needed, the Architect shall review and respond to requests for information {RFI's)
and provide a response within seven (7) work'ng days. At pro;ect close out, the Architect shall review contractor's certification
of substantial completion and review contractor's final punch list. Architect shall review contractor's final as -built plans and
provide a pdf of updated f nal as-b0t documents.
vo%% sir i0i��) I—F
y
1 0 3eciarc�cls Inner:
pu,t 7
'ion madcd: t.' wKw,11rojed: d: US vs �
1 512 T33 1153
Exhibit "A"
If this proposal is acceptable, please sign Part I and return one (f) copy to our office. Signature of Part I also
acknowledges and accepts the terms and conditions set forth in Part II of this proposal. These documents will
serve as our contract for this project unless superseded by a standard form agreement. We appreciate your
consideration and look forward to working with you,
Respectfully submitted,
MODE Design Company
Ryon Hansonuwat
NCARB, LEED AP
ACKNOWLEDGEMENT:
Name & Title Date
Q***!1"
5J/7P %( 90.0ftHy ! 03 cedar oork,'. 78613 1Y
r�s: L. modvd: u. i rvs- mcleJ: 07 {j'�C•�
• 1 512 733 1150
• +
019RATION
DATTEESTART
D
END DATE DESCRP7ION
{days]
14120
117120
Review Lrogrorn and Mo 1o"Wrl
I
IU/20
71d120
Input ec4lsro ini. CAD
I
1!l120
119120
Prekrm code onellsa
1
l I4120
MOM
AreluleeturOlSchernahe Detgn I CM E.O.
1113/20
1131/20
Str4chlml and MEP EnOi,eern0
19
1113/20
iI17I20
Review O!detpn
4
1120120
1131120
Comhml;On Decurtvnts
I I
213120
217120
Rev4ow Ot Censlruclion Documents
4
2110120
V 14120
COrr,ale!an O1 Carelruetien Documents
4
PROPOSED PROJECT SCHEDULE b _k, .r
L'a L9
R«rw V W'Im �.a �r•4rwnn r
•a�.�,Ima m,r r.u, ■
FINin r0� IM>r,� �
vrnan�ar ke.mx r pn.i,Ic nalrt -
tr'vl+Y eM 441' Fna een rt
®t
eorurra. Wne•.�a1 �`
Pnrr el rr,MS,v'wrOxun.rrl l�
r: *M.rararr�.n,uvre,w, obevm,.a.
7�
ON
V. A
, � S
SUPPLEMENTAL AGREEMENT NO. I
CITY OF ROUND ROCK §
STATE OF TEXAS §
§ KNOW ALL BY THESE PRESENTS:
COUNTY OF WILLIAMSON §
COUNTY OF TRAVIS §
This document is entitled Supplemental Agreement No, I, and it supplements "City of Round
Rock Agreement for Architectural Services for Cite of Round Rock Prete Main Street Plaza Restroont
Project %%ith RI -lad Enterprises. Inc. (dba MODE Design Company)- for the following Project:
Professional architectural services and design services related to the folio«ing:
Design and Construction of a stand-alone restroom building in the Prete Main Street
Plana located in Round Rock. Texas.
Professional services for this Project shall include, but not be limited to Schematic
Design. Design Development. Construction Documents, Bidding Phase and Construction
Observation. Architect shall be (fie Architect of Record, and shall be in charge of
coordination ofconsultants.
This Supplemental Agreement No. 1 is made and entered into as of the same date of the
Agreement that it supplements, that being the � day o1 �$RUQ 2020, and likeMse is by
and bemeen the same parties, those being the CITY Or ROUND k00 , a home -rule municipal
corporation of Williamson and Travis Counties. Texas (hereinafter referred to as "Cit)-" and/or " O�%ncC)
and RHad Enterprises. Inc. (dba MODE Design Company), nitlt offices located at 103 Woods Lane.
Cedar Park. Texas 78613 (hereinafter referred to as "Architect").
WITNESSETH:
WHEREAS, as is recited in the Agreement this document supplements. City intends to provide
services for the design and construction of the Project. Architect's sen-ices are desired for purposes
including but not limited to being architect of record, coordinating consultants, planning, civil.
architectural, design, structural, mechanical/electrical/plumbing engineering services, confining project
program and space requirements. document production, bidding -related services, and construction
obser-ation services related to the Project: and
WHEREAS, the Cit}'s total liabilit} for payments pursuant to this Agreement shall not exceed
Ten Thousand Five Hundred and No/100 Dollars (S10,500.00): and
WHEREAS, payment for reimbursable expenses shall not exceed the maximum stun of SS00.00
and is incluclecl in the total compensation for services of $10,500.00: and
WHEREAS, as is recited in the Agreement this document supplements. City desires to contract
t� ith Architect Cor the delineated professional services. and Cor the administration of the Construction
Contract during construction of the Project: and
00438336-ss?
WHEREAS, as is stipulated in the Agreement this document supplements, Architect has agreed
to provide such professional services for the compensation delineated previoush and herein;
NOW, THEREFORE, Cit,. and Architect, in consideration of the terms, covenants and
conditions contained in the Agreement this document supplements and herein, hereby agree as follo%%s:
ARTICLE I
SCOPE OF SERVICES AND COMPENSATION
1.01 Scope. Architect, as an independent contractor and professional consultant in its relationship
%%ith the Cit}. shall perform all professional services for the Project as set forth in the Agreement this
document supplements and herein.
1.02 Compensation. City shall compensate Architect in accordance with the terms and conditions as
recited in the Agreement this document supplements and herein.
Unless subsequentlN changed b% additional Supplemental Agreement to this Agreement. duh
authorized by Cite Council Resolution or City Manager action, Architect's total compensation hereunder
shall not exceed Ten Thousand Five Hundred and No/100 Dollars (S10,500.00). hIL'11111ing a not -to -
exceed amount of Five Hundred and No1100 Dollars ($500.00) for approved Reimbursable Expenses.
These amounts represent the absolute limit of CitN's liability to Architect under this Agreement, unless
same shall be changed b) additional Supplemental Agreement hereto.
The times and further conditions of payment shall be as described in Article VI hereof.
ARTICLE 11
ARCHITECT'S SERVICES
2.01 Basic Services. Architect's Basic Services consist generally of the phases described Belo►%. and
include complete planning, civil, architectural, design, structural, mechanical/electrical/plumbing
engineering services, project program and space requirements, document production, bidding -related
services, and construction observation services, and such other services as mm be necessan to assist the
City in the design and construction of the Project. Architect agrees that upon execution of this
Agreement. it Will submit to Cit% within ten (10) days a list of all additional consultants it intends to
utilize, not previously identified in Architect's proposal, delineating their respective tasks. All of
Architect's consultants shall be subject to the approval of the City through its City Manager. and Cit)
resen-es the right to reject an,, consultant. Architect shall coordinate its services i%ith the Cite,
represented b� its Cit\ Manager or his designee, hereinafter referred to as "Director." A Performance
Schedule in Microsoft project or an alternative program approved bN the Cit). shall be agreed upon by
Architect and the Cit%, and Architect agrees to use its best efforts to complete all services hereunder in
accordance «ith such Performance Schedule. All services shall be performed to the highest professional
standard.
2.02 Schematic Design Phase, Architect shall provide the fallo«ing Schematic Design Phase
Services: as delineated in the Agreement this document supplements.
F�
2.03 Design Documents Phase. Architect shall provide the following Design Documents Phase
Services: as delineated in the Agreement this document supplements and herein, and as follows:
(1) Architect shall prepare Design Documents based on the appro% ed Schematic Design
Documents and updated budget for the Cost of the Work. said Design Documents to
include adequate specifications for elements of the Project for consideration and approval
by the City. One (1) digital copy each of said documents shall be submitted to City. each
consisting of drawings and other documents to fix and describe the size. cross sections
and character of the Project as to architectural, structural, mechanical and electrical
systems, materials, and such other essentials as ma% be necessar% and appropriate. Said
documents shall illustrate and describe the refinement of the design of the Project.
establishing the scope. relationships, forms. size and appearance of the Project b% means
of plans, sections and elevations. typical construction details. and equipment layouts.
Said documents shall include outline specifications that identif% major materials and
systems and establish in general theirqualit%y levels. 'flte Design Document Pltase shall be
completed within the agreed Performance Schedule.
2.04 Construction Documents Phase. Architect shall provide the fallowing Construction
Documents Phase Sen-ices: as delineated in the Agreement this document supplements and herein, and as
follows:
(I) Architect shall prepare from the approved Prototype Update and Site Adaptation Phase
Documents, for consideration of and approval by the City. Construction Documents,
which documents shall set forth in detail the requirements of the entire Project, including
the necessary bidding information prepared in such a %ta% to allow City, ifit so desires, to
advertise for the a►%ard of one or more contracts for the construction of the entire Project.
or any phase thereof, and Architect shall assist City in preparation of the Bidding Forms.
shall utilize without modification City's standard General and Supplementary General
Conditions, and shall draft all Special Conditions of the Contract. City's standard form of
Contract bet"een City and the Contractor shall also be utilized, along w ith City's form of
Bid Bond. Performance Bond and Payment Bond. Architect shall also compile the
Project Manual that includes the Conditions of the Contract for Construction and
Specifications and may include bidding requirements and sample forms.
(2) Architect shall provide the City a digital copy of a complete set of proposed Construction
Documents for re%iew and official approval prior to the advertisement of bids for the
construction of the Project, and within the agreed Performance Schedule following
approval of the Prototy pe Update and Site Adaptation Phase Doctunents.
(3) Architect shall be solely responsible for submitting the Architect's Instruments ofSen ice
for approval of the Texas Department of Licensing and Regulation prior to submittal of
all Construction Documents to City for approval. Am fees charged by the Department
for this approval shall be paid by the City.
2.05 Bidding and/or Negotiation Phase. Architect shall provide the following Bidding!Negotiation
Ser% ices: as delineated in the Agreement this document supplements and herein, and as follows:
folio« ing City's approval of the Construction Documents. Architect shall assist City in awarding
construction contract following legal public bid requirements. Architect shall transmit Construction
Documents to the 0%%ner for reproduction and distribution_ 0%%ner shall be responsible for payment for
the costs of reproduction of such documents, either directly or through reimbursement to Architect.
During the bid process. Architect shall assist Cit% as follows:
(1) Jointly conducting pre -bid conferences. including on -site visits as required, to assist the
bidders with an understanding of the Construction Documents, the various on -site
conditions, and the coordination and scheduling requirements.
(2) Preparing responses to questions from prospective bidders. and providing clarifications
and interpretations of the Bidding Documents to all prospective bidders in the required
form of addenda to Contract Documents.
(3) Assisting in the opening of bids, tabulation and evaluation ol'bids received, and advising
on award of the contract-
(4) Jointly conducting pre -award conferences where necessar%.
Architect's assistance to City shall include submitting «ritten re%-ie►%s and recommendations for
awards based upon the acceptability of bids. Architect's role during the Bidding and?or Negotiation
Phase shall be limited to advising and consulting w ith the CitN. and the Cit% retains all responsibility for
the actual selection of the Contractor.
2.06 Construction Observation Phase. Architect shall provide the followving Construction
Observation Phase Services: as delineated in the Agreement this document supplements and herein. and
as follows:
The Construction Phase will commence with the award ofthe first Construction Contract and will
terminate following the final one-year warrant) inspection of the completed Project, correction of all
defects in Project materials and workmanship, and resolution of all Project -related claims and disputes.
During the Construction Phase. Architect shall provide the folio« ing services:
(1) Architect shall provide administration of the Construction Contract as set forth in the
Construction Documents, specifically the General and Supplementan General
Conditions. Architect's assigned authority thereunder will not be substantial]% modified
without Architect's written consent.
(2) Architect shall review properly prepared, timely requests by the Contractor for additional
information about the Contract Documents. A proper] prepared request for additional
information about the Contract Documents "ill be in a fonn prepared or approved bN
Architect and will include a detailed written statement that indicates the specific
Drawings or Specifications in need of clarification and the nature of the clarification
requested.
(3) II'deemed appropriate b} Architect. Architect will on Owner's behalf prepare. reproduce
and distribute supplemental Dra%%irn(Ts and Specifications in response to requests for
information b% the Contractor.
(4) Interpretations and decisions of Architect will be consistent «ith the intent of and
reasonabh inferable from the Contract Documents and will be in writing or in tite form
\v�
of drawings. \Vhen making such interpretations and initial decisions, Architect will
endeavor to secure faithful performance by both Owner and the Contractor, will not show
partiality to either, and will not be liable for the results of interpretations or decisions so
rendered in good faith_
(�) Architect shall render initial decisions on claims, disputes or other matters in question
between Owner and the Contractor as provided in the Contract Documents. Iloweever.
Architect's decisions on matters relating to aesthetic effect will be final only if consistent
w ith the intent expressed in the Contract Documents,
(6) Architect shall report to Owner all known substantial dexiations from the Contract
Documents and most recent construction schedule submitted by the Contractor.
However. Architect will not be responsible f'or the Contractor's failure to perform work
in accordance with requirements of the Contract Documents. Architect will be
responsible for Architect's acts or omissions, but will not hake control o\er or charge of
and will not be responsible far acts or omissions of the Contractor. Subcontractors, or
their agents or employees, or any other persons or entities performing portions of the
work.
(7) Architect gill at all times hake access to the Mork wherever it is in preparation or in
progress.
(8) Owner will endeavor to communicate with the Contractor through Architect about
matters arising out of or relating, to the Contract Documents. Communications by and
with Architect's subconsultants will be through Architect.
(9) Architect, as a representative of Cite, shall advise and consult w ith Director and will keep
City informed in writing through him of the progress of the Project, including percent
complete on a monthly basis, during the Construction Phase; and after issuance of the
"work order" to proceed with the work, all of City's instructions to its Contractors will be
issued through Architect. Architect w ill have authority to act on behalf of Owner onh to
the extent provided in this Agreement unless othencise properly modified by written
amendment.
(10) Architect shall provide, during construction, adequate and competent on -site construction
observation. periodically visiting the site to the extent necessary to personally familiarize
itself' with the progress and quality of the work. and to determine if' the work is
proceeding in substantial accordance with the Contract Documents. Architect's site
observations may be conducted with Owner's designated representati\ a to check
conformance of the work with the requirements of the Contract Documents and to verif's
the accuracy and completeness of the list submitted by the Contractor of work to be
completed or corrected. Field Reports of each visit shall be prepared by Architect and
submitted to Cit\ . Architect shall employ reasonable measures to safeguard Cite against
defects and deficiencies in the work of the Contractor. Architect shall not be responsible
for the construction means. methods, techniques, sequences of procedures, nor for the
safety precautions and programs employed in connection with the «ork. I lowever.
Architect will immediately inform Director whenever defects and deficiencies in the
work are obsen-ed, or when any observed actions or omissions are undertaken b\ the
Contractor w hich are not in the best interests of City and the Project.
{ I I) Based on such observations at the site and on the Contractor's Application and Certificate
for Payment. Architect shall determine. monthly, the amount o►%ing to the Contractor and
shall certify and Forward the Contractor's Application and Certificate for Payment to
Director for approval and payment. These certifications shall constitute a representation
by Architect to Cit%. based on observations at the site and other data comprising the
application for payment, that the work has progressed to the point indicated; that to the
best of Architect's kno%%Iedge, information and belief. the quality of the %%ork is in
accordance with the Contract Documents (subject to an e,.aluation of the work as a
functioning whole upon substantial completion, to the results of an) subsequent tests
required by the Contract Documents, to minor deviations from the Contract Documents
correctable prior to Project completion. and to ant specific qualifications stated in the
Certificate): and that the Contractor is entitled to payment in the amount certified.
(12) Architect shall have authority to reject work which does not conform to the Contract
Documents. Whene, er Architect considers it necessan or advisable. Architect will have
authorit% to require inspection or testing of the work in accordance ttith the provisions of
the Contract Documents, whether or not such work is fabricated. installed or completed.
lo"ever, neither this authority of Architect nor a decision made in good faith either to
exercise or not exercise such authority shall gi, c rise to a duty or responsibility of
Architect to the Contractor. Subcontractors, material and equipment suppliers, their
agents or emplo%ees or other persons or entities performing portions of the work.
(13) Architect shall make recommendations on all claims and disputes of City or the
Contractor relating to the execution and progress of the work or the interpretation of the
Contract Documents, based upon such review and analysis by Architect as may
reasonabl% be required. In the e%ent of litigation, where Architect is named as an
additional park with the City. such assistance «ill include the availability of
kn0%N ledgeable tt itnesses in the employ of Architect for expert testimom .
(1 4) Architect shall use its best efforts to promptly revie" and approve or reject shop
drawings, product data and samples and other submissions of the Contractor for
conformance only with the design concept of the Project and With the information given
in the Contract Documents. Architect shall establish and implement precise procedures.
to be approved by Citv's Director. for expediting the processing and approval of these
submissions without delay. Prompt review by Architect of submissions is of prime
importance to City and an absolute necessity under the time constraints of the Project.
(1 i) Architect shall prepare Change Orders an&or Construction Change Directix es to the
construction contract. in six (6) copies, alter review and approval by City. Each Change
Order shall be specific and final as to prices and extensions of time. With no reservations
or other provisions allot ing for future additional money or time as a result of the
particular changes identified and fiilh compensated in the Change Order. Architect's
compensation for preparation of Change Orders, if any, shall be determined by Section
2.09(l) blow.
(16) Architect shall conduct inspections to detennine the dates of'substantial completion and
final completion. shall receive %%ritten guarantees and related documents assembled bN
Contractor for submittal with the final Certificate of Payment, and shall prepare and
present final Certificate for Payment to Director for City's approval and payment. In
R
addition, Architect shall make inspection ofthe Project at least thirty (30) days before the
expiration of the one (I) tear W arrant% contained in the Contractor's Performance Bond.
(17) Architect shall conduct regularly scheduled progress meetings with City, the Contractor
and major Subcontractors. Minutes of same shall be prepared by Architect With copies
submitted to City's Director.
(1 S) Architect shall have authority to order minor changes in the construction Work, consistent
With the Contract Documents, and not involving an adjustment in the Contractor's bid
price or an extension of the Project Schedule. Such changes shall be accomplished by
Field Order. In addition. Architect may issue Written Field Orders Which interpret the
Plans and Specifications, W ith copies submitted to City's Director.
(19) Architect shall assemble and deli%er to City a set of reproducible Record Construction
Drawings shoving significant changes in the Work during the construction process and
final location of mechanical and electrical service lines and outlets, based upon marked -
up prints of draw ings and other data furnished by the Contractor to Architect. Architect
shall provide Record Construction Specifications Which Will identif, the changes in the
specifications on a sheet. Which sheet Will be inserted at the beginning of each section to
Which they pertain.
(20) Architect shall obtain from the Contractor and fon%ard to Owner the following: (1)
consent of surety or sureties, if any, of reduction in or partial release of retainage or the
making of final payment: and (2) afiida%its. receipts, releases and WaiNers of liens or
bonds indemnifying Owner against liens.
2.07 Warranq, Phase. Architect shall assist Owner in scheduling corrections to be made b% the
Contractor during the Warranty period. During llte eleventh month folloning completion of' the prime
general contract. Architect W ill arrange for a warranty inspection tour of the entire Project by authorized
representatives of City, the Subconsultants and of each prime contractor engaged on the Project.
Architect shall then prepare a list of Work Which needs to be done by each prime contractor to satisfi that
prime contractor's «arrant% obligations to City. For any non -Warranty involvement of Architect.
payments shall be made based upon the I-lourl Rate Schedule contained in this Agreement.
2.08 Project Representation Beyond Basic Sen-ices. In the e%ent that circumstances should de%elop
Whereby continuous, fill -time representation at the Project site is required, the conditions under Which
such representation shall be lurnished and the Project Representatives selected, employed and directed
shall be governed by an additional Written Supplemental Agreement between City and Architect.
2.09 Additional Services. Architect shall perform Additional Services. as requested by Cite, after a
not -to -exceed amount has been mutually agreed upon in Writing by Director and Architect. Architect
shall not proceed until the appropriate Resolution or directive for such Additional Sen ices has been
delivered from the City Council or City Manager. The following services are not cotered under Article If.
Which defines and outlines Architect's Basic Sen-ices. If any of these Additional Services are authorized
in Writing by Director in advance of their performance, they shall be paid for in the manner agreed to at
the time ofauthorization.
([) Preparing Change Orders and supporting data and -or revising previously approved plans
When the changes in approved Plans and Specifications are required by the Cit%-. If
changes are required to be made because of error, oversight. clarification. discrepancy. or
budget overruns in the wort: of Architect. Cite shall not be liable to compensate Architect
for Additional Services or expenses in such connection.
(2) Providing consultation concerning replacement of any Project work damaged by fire or
other cause during construction, and furnishing professional sen ices as may be required
in connection nith the replacement of such work, unless damage was the result of
Architect's error.
(3) Providing other extraordinary professional services over and above the contract
requirements, where required and requested by Cite, including extraordinary professional
services which might result if the Cite decides to "fast -track" the Project.
(4) Prov iding construction phase services more than twelve (12) months after the start of
construction of the Contractor's Notice to Proceed, whichever occurs first.
(5) Performing more than mo (2) reviews of each shop drawing. product data item. sample
or similar submittal from the Contractor.
(6) Providing more than menty-four (24) site visitslconstruction meetings over the duration
of the Project.
(7) Providing more than two (2) inspections for any portion of the Work to determine
whether such portion of the Work is substantially complete in accordance with the
requirements of the Contract Documents.
(8) Providing more than one (1) inspection for any portion of the Work to determine Final
Completion.
ARTICLE III
CITY'S RESPONSIBILITIES
3.01 Full information. City shall prop ide full information regarding requirements for the Project
3.02 Designate representatives. City shall designate, when necessary. representatives authorized to
act in its behalf. City shall examine documents submitted by Architect and render decisions pertaining
thereto prompth to avoid unreasonable delay in the orderly progress of Architect's work.
3.03 Tests and inspections. City shall furnish. or pa% for structural. mechanical. chemical, soil
mechanics. and other laboratory tests, reports and inspections as required by late or the Contract
Documents.
3.O4 Permits. City will furnish the building permit without charge. L-:lectrical. plumbing and other
trade permits w ill be the responsibility of the construction contractor. Any charges which mat be assessed
for tap fees will be paid by City and are not to be included by Architect in the Specifications for the
Project.
Os
3.05 Fees. City shall pay for fees required for Architect's submittal and approval of documents as set
forth in the Agreement this document supplements.
3.06 Miscellaneous items. City will also provide Architect %%ith City of Round Rock General and
Supplementary General Conditions for Building Construction. Instructions to Bidders. Proposal Forms,
Wage Rates, Contract and Bond Forms, Bid Advertisement Form, and such other information and
materials as may be necessary and practicable for the orderly and expeditious process of the work and the
a►%arding of the Construction Contract. To the extent practicable, these documents shall be utilized in the
preparation of the Construction Documents.
ARTICLE IV
FIXED LIMIT OF TOTAL BUDGETED CONSTRUCTION COST
4.01 Budgeted Construction Costs. The fixed limit of total Budgeted Construction Cost for this
Project has not been litlly ascertained as of the date of making of these Contract Documents. Architect. in
consultation %%ith City. shall determine ►►hat materials, equipment, component systems and types of
construction are to be included in the Contract Documents. and will make reasonable adjustments in the
scope of the Project to bring, it %%ithin the limits ►►hen fixed. With City approval, Architect may also
include in the Contract Documents alternate bids to adjust the construction cost to the fixed limit. If the
lo►%est responsible bid is ►►ithin the fixed limit of total Budgeted Construction Cost for the Project is still
less than the fixed limit of total Budgeted Construction Cost for the Project. City shall pay Architect fees
for Basic Ser►ices in accordance ►%ith this Agreement.
4.02 Procedures if Bid(s) Exceed Budgeted Construction Costs. It' the lo►►est responsible bid
exceeds its portion of the Iixed limit of total Budgeted Construction Cost for the Project. City at its option
may either (1) give Witten approval ol' an increase in such fixed limit. %%ith no obligation to increase
Architect's fee, or (2) authorize rebidding %%ithin a reasonable time. or (3) cooperate in re%ising the
Project scope and quality as required to reduce the Probable Construction Cost. In the case of (3). if the
lo%%est responsible bid exceeds the Budgeted Construction Cost by more than ten (10%). Architect,
►►ithout additional charge, shall immediately modify the Drawings and Specifications as necessary to
bring the Project cost %%ithin the budgeted fixed limit, or ►yithin an,. higher fixed limit subsequently
authorized by City. Providing this ser► ice shall be the limit of Architect's responsibility in this regard,
and hawing done so. Architect shall be entitled to his fees in accordance %%ith this Agreement. If the
lowest responsible bid is %%ithin ten percent (10%) of the Budgeted Construction Cost. the Architect shall.
upon the City's request and as an Additional Service, make revisions to Dra►►ings and Specifications to
reduce the Probable Construction Cost. Ilo►%e%er. «hen the excess is due to changes initiated by
Architect in scope, basic systems or the kinds and quality of materials. finishes or equipment. Architect
shall make revisions at no additional cost to City.
ARTICLE V
REIMBURSABLE EXPENSES
5.01 Reimbursable Expenses. Reimbursable Expenses are included in the total not -to -exceed sm-ices
fee delineated in the Agreement this document supplements and herein, and include the actual
expenditures and actual costs set forth in the Agreement this document supplements.
V1:4
ARTICLE VI
PAYMENTS TO THE ARCHITECT
6.01 Basic Services. Payments on account of Architect's Basic Services shall be made monthh in
proportion to the degree of completion of each phase, as delineated in the Agreement this document
supplements and herein.
As to the Construction Observation Phase fee apportionment. Architect shall invoice for equal
monthly pay ments based upon the contractuall%--stipulated Construction Period.
6.02 Reimbursable Expenses. Payments for authorized Reimbursable I xpenses for Architect, as
hereinbefore referred to and in an amount not to exceed S500.00, shall be made folloxting presentation.
re%-ie%% and approval of Architect's detailed inoice in triplicate.
6.03 Deductions. No deductions shall be made from Architect's compensation on account of penalt%.
liquidated damages or other sums «ithheld from payments to Contractors.
6.04 Additions. No additions shall be made to Architect's compensation based upon Project
construction claims. whether paid by City or denied.
6.05 Abandonment. If any %kork designed or specified by Architect during an% phase or subphase is
abandoned or suspended. in ►%hole or in part. Architect is to be paid for the services performed on account
of it prior to receipt of %% ritten notice from City through its Director of such abandonment or suspension.
6.06 Invoices. Architect's inoices to Cite shall provide complete information and documentation to
substantiate Architect's charges, and shall be in a form to be specified by Director. All payments to
Architect shall be made on the basis of the invoices submitted by Architect and approved by Director.
Such invoices shall conform to the schedule of sen ices and costs in connection therewith set out
hereinabove. All Reimbursable Expenses shall be clearly sho«n. Should additional backup material be
requested by Director. Architect shall comply promptly N%ith such request. In this regard, should Director
determine it necessary. Architect shall make all records and books relating to this Agreement available to
City for inspection and auditing purposes.
6.07 Payment of Invoices. City reserves the right to correct am error that may be discovered in any
invoice that may have been paid to Architect and to adjust the same to meet the requirements of the
Agreement. Follo"ing appro%al of in -voices. City "ill endeavor to pay Architect promptly. but not later
than the time period required tinder the Texas Prompt Payment Act; however. under no circumstances
shall Architect be entitled to receive interest on pay ments which are late because of a good faith dispute
bettteen Architect and City or because of amounts tthich City has a right to ►%ithhold under this
Agreement or state la%%.
6.08 Offsets. City may, at its option. offset an amounts due and payable tinder this Agreement against
an,, debt (including taxes) lawfully due to City from Architect. regardless of "hether the amount due
arises pursuant to the terms of this Agreement or other%ise and regardless of %%hether or not the debt due
to Cite has been reduced to judgment by a court.
10
ARTICLE VII
ARCHITECT'S ACCOUNTING RECORDS
7.01 Accounting Records. Records of Architect's Consultant and Reimbursable Expenses pertaining
to the Project, and records of accounts beween City and Architect shall be kept on a generally recognized
accounting basis and shall be available to City or its authorized representatives at mutually convenient
times.
ARTICLE VI11
TERMINATION AND DEFAULT
8.01 Termination. In connection %%ith the "ork outlined in this Agreement. it is agreed and fully
understood by Architect that Director may cancel or indefinitely suspend further %%ork hereunder or
terminate this Agreement either for cause or for the convenience of city, upon fifteen (15) days' %%ritten
notice to Architect, with the understanding that immediate]) upon receipt ofsaid notice all cork and labor
being perfonned tinder this Agreement shall cease. Architect shall invoice Cit% f'or all %%ork satisfactorily
completed and shall be compensated in accordance %%ith the tenns of this Agreement For all Mork
accomplished prior to the receipt ofsaid notice. No amount shall be due for lost or anticipated profits, All
plans. field surveys. maps, cross sections and other data. designs and %%ork related to the Project shall
become the property of City upon termination of this Agreement. and shall be promptly delivered to City
in a reasonably organized form without restriction on future use. Should City subsequently contract %%ith a
ne%% architect for continuation of services on the Project. Architect shall cooperate in providing
information.
8.02 Default. Nothing contained in Section 8.01 above shall require Cite to pay for any work ►%hich is
unsatisfactory as detennined by Director or «hick is not submitted in compliance ►Kith the terms of this
Agreement. City shall not be required to make any payments to Architect %%hen Architect is in default
under this Agreement, nor steal[ this Article constitute a waiver of art} right, at la%% and at equity. %%hich
City ma) have if Architect is in default, including the right to bring legal action for damages or to force
specific performance of this Agreement.
ARTICLE IX
GENERAL, SUPPLEMENTARY AND SPECIAL CONDITIONS;
CONTRACT ADMINISTRATION
9.01 General, Supplementary and Special Conditions. CitN. of Round Rock - General Conditions.
Supplernentar% Conditions. and Special Conditions. are to be used b% Architect %0hout modification:
ho%%e%er. Cit%' may, upon prior consultation, approve of any changes that may be necessan for specific
cases or instances. Any special conditions pertaining to the Project that are approNed by Cite gill be
included under the Special Conditions portion of the Construction Documents.
9.02 Contract Administration. This Agreement shall be administered on behalf ol' City bN its Cit%
Manager, and Architect shall fully compl% with am and all instructions from m Director. Adispute
arising hereunder shall be submitted to Director. whose decision in the matter shall be final and binding.
ARTICLE X
RESPONSIBILITY FOR WORK INDEMNIFICATION AND INSURANCE
10.01 Architect's Responsibility' for Work. Approval by City shall not constitute nor be deemed a
release of the responsibility and liability of' Architect, its employees. subcontractors, agents and
consultants for the accuracy and competency of their Designs, \ orking Drawings. Specifications or other
documents and work; nor shall such approval be deemed to be an assumption of such responsibility by
City for any defect, error or omission in the Designs. Working Drawings. and Specifications or other
documents prepared by Architect, his employees, subcontractors, agents and consultants.
10.02 Indemnification (Damage Claims). Architect agrees to indemnify and hold City, its officers,
agents and employees, harmless against any and all claims, lawsuits. judgments, costs and expenses for
personal injury (including death), property damage or other harm for which reco%cry of damages is
sought, suffered by any person or persons, that may arise out of or be occasioned by Architect's breach of
any of the terms or provisions of this Agreement, or by any negligent act or omission of Architect, his
officers, agents, associates, employees or subconsultants, in the performance of this Agreement: except
that the indemnity provided for in this paragraph shall not apply, to any liability resulting from the
negligence of City, its officers, agents, employees or separate contractors, and in the event of joint and
concurrent negligence of both Architect and City, responsibility and indemnity, if any. shall be
apportioned comparatively in accordance with the laws of tile State of Texas, without, ho►Never, waiving
any governmental immunity available to City under Texas lay% and without waiving any defenses ofthe
parties under Texas lay,.. The provisions of this paragraph are solely for the benefit of the parties hereto
and not intended to create or grant any rights. contractual or othern ise, to any other person or entity.
10.03 Indemnification (Patent and Copyright Claims). Architect agrees to completely indemnity and
hold harmless City, its officers, agents and employees, against a claim that any of the Designs, Plans or
Specifications prepared by Architect, its employees, associates or subconsultants, pursuant to this
Agreement infringe a U.S, patent or copyright directly, indirectly or contributorily, regardless of whether
or not City is proven to lime actively induced or contributed to the infringement. Architect will pay any
and all resulting costs, damages and attorney's fees finally awarded, provided that:
(1) City promptly notifies Architect in writing of the claim; and
(2) Architect has control of settlement negotiations.
(a) The City. Attorney of City shall be kept inforned of settlement negotiations, and
sliall execute any settlement agreement reached by Architect on City's behalf.
(b) Architect's indemnification under this section is conditioned on Cite's agreement
that if' am of the designs, plans or specifications. become, or in Architect's
opinion are likely to become, the subject of' such a claim. City will permit
Architect. at Architect's option and expense, either to procure the right for City
to continue using the designs, plans or specifications or to replace or modify the
same so that tile,. become non -infringing; and if neither of the foregoing
alternatives is available on terms which are reasonable in Architect's judgment.
City, to the extent City is legally able to do so, %%ill cease using the designs. plans
or specifications on written request of Architect, in which instance City has the
sole option to either require Architect to perform new design work at Architect's
12
sole expense. or to terminate this Agreement.
(c) Architect has no liability under this section for any claim of infringement based
upon the modification or alteration of the designs, plans or specifications
prepared under this Agreement subsequent to the Project b% Cit►, or by am
engineering consultant subsequently emplo} ed by City.
(d) The foregoing states the entire obligation of Architect ►►ith respect to
infringement of patents and cop} rights.
10.04 Insurance. Architect. at Architect's sole cost, shall purchase and maintain during the term of this
Agreement the minimum professional liabilit►, insurance coverage in the amount of One Million Dollars
($1.000.000,00) from a compam authorized to do insurance business in Texas and othen►ise acceptable
to Citk. Failure to maintain the minimum insurance coverage during the term of this Agreement shall be
considered a material breach of this Agreement.
10.05 Subconsultant Insurance. Without limiting any of the other obligations or liabilities of
Architect, Architect sliall require each subconsultant performing work tinder this Agreement to maintain
during the term of the Contract. at the subconsultant's o►►n expense, the same stipulated minimum
insurance required in Section 10.0.4 abo►e, including the required provisions and additional police
conditions as shown belo►► in Section 10.06. unless specificalix ►vaived by the Cit} Manager.
Architect shall obtain and monitor the certificates of insurance from each subconsultant in order
to assure compliance with the insurance requirements. Architect must retain the certilcates of insurance
for the duration of this Agreement, and shall have the responsibility of enforcing these insurance
requirements among its subconsultants. Cite shall be entitled. upon request and ►►ithout expense. to
receive copies of these certificates of insurance.
10.06 Insurance Policy Endorsements. Each insurance polio} under paragraph 10.0.4 shall include the
follo►►ing conditions by endorsement to the policy:
{ I) Each policy shall require that thiit} (30) daN s prior to the expiration. cancellation, or non -
renewal. a notice thereof shall be given to Cit► by certified mail to:
City Manager. Cit} of Round Rock
221 East Main Street
Round Rock. Texas 7866.4
Architect shall also notifj City, ►►ithin 24 hours of receipt. of any notices of expiration.
cancellation. or non-rene►►al it receives from its insurer.
(2) Companies issuing the insurance policies shall lia►e no recourse against City for paytttcnt
of an% premiums or assessments for any deductibles which all are at the sole
responsibility and risk of Architect.
(3) The Term "Citt" or "Cit% of Round Rock" shall include all authorities. Boards.
Commissions. Departments. and officers of Cit► and the individual members, employees
and agents thereof in their ol'ficial capacities, andfor while acting on behalf of the City of
Round Rock.
13
(4) The policy clause "Other Insurance" shall not apph, to any insurance coverage current]%
held by Cit, to any such future coverage. or to City's Self -Insured Retentions of
whatever nature.
10.07 Cost of Insurance. The cost of all insurance required herein to be secured and maintained b►-
Architect shall be borne solely by Architect. ►►ith certificates of insurance evidencing such minimum
coverage in force to be tiled a ith the City.
ARTICLE XI
COMPLIANCE WITH LAWS, CHARTER AND ORDINANCES, ETC.
11.01 Compliance with Laws. Architect. its consultants, agents. emp[oyees and subcontractors shall
comply with all applicable Federal and State La►%s, the Charter and Ordinances of the Cit► of Round
Rock. as amended. and ►►ith all applicable rules and regulations promulgated by all local. State and
National boards, bureaus and agencies. Architect shall further obtain all permits and licenses required in
the performance of the professional services contracted for herein.
11.02 Taxes. Architect will pay all taxes, if any. required by la►► arising by Virtue of the services
perfonned hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the
Texas Limited Sales. Excise. and Use Tax Act.
ARTICLE XII
TERM
12.01 Term. Unless sooner terminated in accordance %%ith the applicable provisions hereof. or extended
by mutual agreement appro►ed by City's Director, the terns of this Agreement shall be from the date
hereof until final completion of the Project and all architeeturaVengineering and construction
administration services in connection therewith. including the final one (I) year ►►arrant} inspection. and
resolution ofany outstanding Project -related claims or disputes.
12.02 Project Performance Schedule. Architect understands that the Project Performance Schedule is
of critical importance, and agrees to undertake all necessary efforts to expedite the performance of
services required herein. so that construction of the Project Hill be commenced as scheduled. In this
regard. Architect shall proceed «ith sufficient qualified personnel and consultants necessary to full- and
timely accomplish all services required under this Agreement in the highest professional manner.
ARTICLE. XIII
FINANCIAL INTEREST PROHIBITED CONFIDENTIALITY
13.01 Financial Interest Prohibited. Architect co►enants and represents that Architect. its officers.
employees, agents, consultants and subcontractors ►►ill ha►e no financial interest, direct or indirect. in the
purchase or safe of any product, materials or equipment that ►►ill be recommended or required for the
construction of the Project.
13.02 Confidentiality. Architect's reports, evaluations, designs, drawings, data, and all other
documentation and work developed by Architect hereunder shall be kept confidential, and sliall not be
disclosed to any third parties without the prior %%ritten consent and appro► al of Cit%'s Director.
14
ARTICLE XIV
GENERAL PROVISIONS
14.01 Time is of the Essence. Architect understands and agrees that time is of the essence and that anv
failure of Architect to complete the services for each phase of this Agreement within the agreed Project
Performance Schedule will constitute a material breach of this Agreement. Architect shall be fully
responsible for its delays or for failures to use his best etlorts in accordance %%ith the terms of this
Contract. Where damage is caused to City due to Architect's failure to perform in these circumstances.
Cit% may i%ithhold, to the extent of such damage. Architect's payments hereunder «ithout kkaiyer of am
of City's additional legal rights or remedies.
14.02 Force Mujeure. Neither Cit% nor Architect shall be deemed in violation ofthis Agreement if it is
prevented from perfonning any of its obligations hereunder by reasons for «hick it is not responsible or
circumstances be% -and its control. HoNwver. notice of such impediment or deiaN in performance must be
time]}- given. and all reasonable efforts undertaken to mitigate its effects.
1.1.03 Assignment. The parties each hereby bind themselves. their successors, assigns and legal
representati%es to each other with respect to the terns ofthis Agreement. Architect shall not assign, sublet
or transfer ani interest in this Agreement without prior %%ritten authorization of City's Director.
14.04 Amendments. This Agreement. representing the entire agreement bet►%cen the parties. maN onh
be amended or supplemented b% mutual agreement of the parties hereto in n riting.
14.05 Enforcement and Venue. I -his Agreement shall be enforceable in Round Rock. Williamson
County, Texas. and if legal action is necessan bN either party «ith respect to the enforcement of any or
all of the terms or conditions herein, exclusive %enue for same shall lie in Williamson County. 'texas.
This Contract shall be governed by and construed in accordance %kith the la« s and court decisions of the
State of Texas.
14.06 Notices. All notices and correspondence to Cih bN Architect shall be mailed or delivered as
fol I ox% s:
Cite Manager. City of Round Rock Stephan L. Sheets. Cite Attorne\
221 East Main Street and to: 309 East Main Street
Round Rock. Texas 78664 Round Rock. Texas 78664
All notices and correspondence from Cit% to Architect shall be mailed or delivered to the
Architect as follons:
R1lad Enterprises, Inc.
dba MODE Design Contpan%
103 Woods Lane
Cedar Park. Texas 78613
l�
IN WITNESS WHEREOF. the City of Round Rock has caused this Agreement to be signed in
its corporate name by its Cit? Manager, dul) authorized to execute the same in its behalf approved and
execrEted by the City Manager on L , 2020. and Rl-lad Enterprises. Inc.. dba
MODE Design Compam signing by and through i s duI% authorized representative, thereby binding the
parties hereto, their successors. assigns and representatives for the faithful and ftill performance of the
terms and provisions of this Contract.
CITY OF ROUND ROCK, TEXAS
R HAD ENTERPRISES, INC.
DBA MODE DESIGN COMPANY
By B
. Cite Manager
Date: ?, . ) +
ATTEST:
BN _
Sara L. White. Citv Clerk
FOR CITY, APP OVEU A5 TO FORM:
[i� : A2 --
Stephan L. heets. Cite Attorney
16
Date: 1 12l 7,07.6
JTEX10�— City of Round Rock
Z Roar Agenda Item Summary
TEXAS
Agenda Number:
Title: Consider executing an Agreement for Architectural Services and
accompanying Supplemental Agreement No. 1 with RHad Enterprises, Inc.
(dba MODE Design Company) for the Prete Main Street Plaza Restroom
Project.
Type: City Manager Item
Governing Body: City Manager Approval
Agenda Date: 2/14/2020
Dept Director: Chad McDowell, General Services Director
Cost: $10,500.00
Indexes: General Self -Financed Construction
Attachments: RHad Enterprise - Supplemental, RHad Enterprise Agreement
Department: General Services Department
Text of Legislative File CM-2020-048
RHad Enterprises, Inc. will provide a freestanding restroom building with two (2) single user
restroom spaces for the Prete Main Street PI_aza Restroom Project.
Cost. $10,500.00
Source of Funds: General Self -Financed Construction
City of Round Rock Page 1 Printed on 21312020