Contract - Nelson Homestead Family Partnership - 9/14/2023 PARCEL NO. 3
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 1 of 9
POSSESSION AND USE AGREEMENT FOR TRANSPORTATION PURPOSES
STATE OF TEXAS §
§ Parcel No.: 3
COUNTY OF WILLIAMSON § Project: CR 112
This Possession and Use Agreement For Transportation Purposes (the "Agreement") between CITY OF
ROUND ROCK, TEXAS ("Grantee"), and NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD.,
a Texas limited partnership (the "Grantor" whether one or more), grants to the Grantee, its contractors,
agents and all others deemed necessary by the Grantee, an irrevocable right to possession and use of the
Grantor's property for the purpose of constructing improvements to CR 112 and related utility
adjustments (the "Project"). The property subject to this Agreement is described more fully in field
notes, plat map or other description (attached as "Exhibit A") and made a part of this Agreement by
reference(the "Property").
I. For the consideration from the Grantee which is set forth in Paragraph 2 below, the receipt and
sufficiency of which is acknowledged, the Grantor grants, bargains, and conveys to Grantee the right
of entry and exclusive possession and use of the Property for the purpose of constructing a roadway,
utility adjustments and ali related appurtenances thereto and the right to remove any improvements
thereon. Authorized activities on the Property include surveying, inspection, environmental studies,
archeological studies, clearing, demolition, construction of permanent improvements, relocating,
replacing, and improving existing utility facilities, locating new utility facilities, and other work
required to be performed in connection with the Project. This Possession and Use Agreement will
extend to the Grantee, its contractors and assigns, providers of any existing utilities on the Property
and those which may be lawfully permitted on the Property by the Grantee in the future, and all
others deemed necessary by the Grantee for the purpose of the Project. This grant will allow the
construction, relocation, replacement, repair, improvement, operation and maintenance of utilities on
the Property only.
2. In consideration for this irrevocable grant of possession and use and other Grantor covenants,
warranties, and obligations under this Agreement, the Grantee will tender to the Grantor the sum of
NINE HUNDRED FIVE THOUSAND SEVEN HUNDRED TWENTY-SEVEN and 00/100 Dollars
($905,727.00). The Grantor agrees that this sum represents 90% of the amount that Grantee has
determined constitutes adequate and full compensation for the possession and use of the Property.
Grantee will be entitled to take possession and use of the Property upon tender of payment as set out
herein, subject to the conditions in Paragraph 14 below, if any. The parties agree that the sum
tendered represents 90% of the Grantee's approved value, which assumes no adverse environmental
conditions affecting the value of the Property. The approved value is the Grantee's determination of
the just compensation owed to the Grantor for the real property interest to be acquired by the
Grantee in the Property, encumbered with the improvements thereon, if any, and damages to the
remainder, if any, save and except all oil, gas and sulphur. The parties agree that the sum tendered to
Grantor will be deducted from any final settlement amount, Special Commissioners' award or court
judgment. In the event the amount of the final settlement or judgment for acquisition of the Property
is less than the amount the Grantee has paid for the possession and use of the Property, then the
{.00080613.5J
II I I II I II I II
* N P U A
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 2 of 9
Grantor agrees that the original amount tendered represents an overpayment for the difference and,
upon written notice from the Grantee, the Grantor will promptly refund the overpayment to the
Grantee. In the event the amount of the final settlement or court judgment for acquisition of the
Property is greater than the amount Grantee has paid for the possession and use of the Property
under this Paragraph 2, Grantee will remit the underpayment to Grantor when required under the
final settlement or court judgment.
3. The effective date of this Agreement will be the date on which payment pursuant to Paragraph 2
above was tendered to the Grantor by the Grantee, or delivered by Grantee to a title company acting
as escrow agent for the transaction, with unconditional instructions to such escrow agent to
immediately release such payment to Grantor upon escrow agent's confirmation that no liens or
other monetary encumbrances affect the Property (the"Effective Date").
4. The Grantor warrants and represents that, to Grantor's actual knowledge, the title to the Property is
free and clear of all monetary liens and encumbrances except as disclosed to Grantee in that certain
title commitment numbered GF#202301512 dated effective June 8, 2023 issued by Heritage Title
Company of Austin Inc., as agent for First American Title Insurance Company, and that proper
releases will be executed for such liens and encumbrances (if any) prior to funds being disbursed
under this Agreement. The Grantor further warrants that no other person or entity owns (or, to
Grantor's knowledge, claims) an interest in the fee title to the Property and further agrees to
indemnify the Grantee from all unrelated or undisclosed liens or other monetary encumbrances
affecting the Property.
5. The parties agree that the valuation date for determining the amount of just compensation for the real
property interest proposed to be acquired by the Grantee in the Property, for negotiation or eminent
domain proceeding purposes,will be the Effective Date of this Agreement.
6. This Agreement is made with the understanding that the Grantee will continue to proceed with
acquisition of a real property interest in the Property. The Grantor reserves all rights of
compensation for the title and other interest in and to the Property which the Grantor holds as of the
time immediately prior to the Effective Date of this Agreement. This Agreement shall in no way
prejudice the Grantor's rights to receive full and just compensation as allowed by law for all of the
Grantor's interests in and to the Property to be acquired by the Grantee, encumbered with the
improvements thereon, if any, and damages, if any, to the remainder of the Grantor's interest in any
larger tract of which the Property is a part (the "Remainder"), if any; all as the Property exists on the
Effective Date of this Agreement. The Grantee's removal or construction of improvements on the
Property shall in no way affect the fair market value of the Property in determining compensation
due to the Grantor in the eminent domain proceedings. This grant will not prejudice the Grantor's
rights to any relocation benefits for which Grantor may be eligible.
7. In the event the Grantee institutes or has instituted eminent domain proceedings, the Grantee will not
be liable to the Grantor for interest upon any award or judgment as a result of such proceedings for
any period of time prior to the date of the award. Payment of any interest may be deferred by the
Grantee until entry of judgment.
8. The purpose of this Agreement is to allow the Grantee to proceed with its Project without delay and
to allow the Grantor to avoid proceeding with condemnation litigation at the current time and
(.00080613.5))
Forth ROW-N-PUA
(12/12)
Replaces Forth ROW-N-7
Page 3 of 9
continue voluntary investigation and negotiation for the proposed Property acquisition. The Grantor
expressly acknowledges that the proposed Project are for a valid public use and voluntarily waives
any right the Grantor has or may have, known or unknown, to contest the jurisdiction of the court in
any condemnation proceeding for acquisition of the Property related to the Project, based upon
claims that the condemning authority has no authority to acquire the Property through eminent
domain, has no valid public use for the Property, or that acquisition of the Property is not necessary
for the public use.
9. The Grantor reserves all of the oil, gas and sulphur in and under the land herein conveyed but waives
all right of ingress and egress to the surface for the purpose of exploring, developing, mining or
drilling. The extraction of oil, gas and minerals may not affect the geological stability of the surface.
Nothing in this reservation will affect the title and rights of the Grantee to take and use all other
minerals and materials thereon, and thereunder.
10. The undersigned Grantor agrees to pay as they become due, all ad valorem property taxes and
special assessments assessed against the Property until the Effective Date, including prorated taxes
until the Effective Date for the year in which the Grantee takes title to the Property. Grantor shall
have no liability for ad valorem property taxes and special assessments assessed against the Property
for any period after recording of a memorandum of this Agreement.
11. Notwithstanding the acquisition of right of possession to the Property by the Grantee in a
condemnation proceeding by depositing the Special Commissioners' award into the registry of the
court, less any amounts tendered to the Grantor pursuant to Paragraph 2 above, this Agreement shall
continue to remain in effect until the Grantee acquires title to the Property either by agreed final
settlement, or final court judgment,whereupon this Agreement shall automatically terminate.
12. This Agreement will also extend to and bind the heirs, devisees, executors, administrators, legal
representatives, successors in interest and assigns of the parties.
13. It is agreed that Grantee will record a memorandum of this Agreement on or about the Effective
Date in the property records of the county in which the Property is located, evidencing the existence
of this Agreement. The Agreement itself will not be recorded. The memorandum will not contain
any information regarding the consideration paid or to be paid to Grantor by Grantee and will
otherwise be in a form mutually acceptable to Grantor and Grantee. The recording of the
memorandum will not modify the terms of this Agreement. Upon termination of this Agreement for
any reason, either Grantor or Grantee may record an affidavit in the county property records
evidencing such termination.
14. Other conditions: See Addendum attached hereto and made a part hereof.
15. By its authorized signature below the following Tenants which have a leasehold interest in the
Property hereby consent in all things to Grantee taking exclusive and sole possession of the Property
pursuant to the terms of this Agreement, and to Grantor receiving the consideration recited herein:
Tenant: Davidson Brothers
(.00080613.5))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 4 of 9
At no time during the possession of the Property by Grantee for the purposes described herein shall
Grantor or Tenant be denied reasonable access and/or ingress to or egress from the Remainder for its
current uses without prior advance agreement between Grantor and Grantee.
To have and to hold the Agreement herein described and conveyed, together with all the rights and
appurtenances belonging to the Grantee and its assigns forever, for the purposes and subject to the
limitations set forth above.
[signature pages follow)
(.00080613.5))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 5 of 9
GRANTOR:
NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD.,
a Texas limited partnership
By: Nelson Homestead Management, L.L.C.,
its general partner
By: C /e�
Name. hn C. Nelson
Title: Manager
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF 7'W2A-V1s
This instrument was acknowledged before me on this the AS day of August, 2023 by John C.
Nelson, Manager of Nelson Homestead Management, L.L.C., the general partner of Nelson Homestead
Family Partnership, Ltd., in the capacity and for the purposes and consideration recited herein.
ot,.F;!PU� Gloria A Veiasquez
_ Notary Public,State of Texas
*' Comm.Expires 01/03/2024
Notary ID 12864109-3 Notary Public, State fff TexasO
Printed Name: Gloria Vel&S&L"e z-
My Commission Expires: 01/03/2,0X f'
(.00080613.5)}
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 6 of 9
TENANT:
Davidson Brothers
By:
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF A t t Ig M5o )
This instrument was acknowledged before me on this the °'tS day of August, 2023 by
D-gitis fA5;g' , in the capacity and for the purposes and consideration recited herein.
Gloria jasq
uez
Notary PuNle,State of Texas �l. V�i�(✓J
` . COMM'Expires 01/03QO24
OF Notary M12m4ipq.3 Notary Public, State of�/exas
Printed Name:610h�VCJkSc-A4AZ
My Commission Expires: O'/03/;LOZL(
1.00080613.5}}
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 7 of 9
GRANTEE:
CITY OF ROUND ROCK, TEXAS
By: �� ft� f
Craig Mor n, Ma jr
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF WILLIAMSON
This instrument was acknowledged before me on this the a.d y of v , 2023 by
Craig Morgan, in the capacity and for the purposes and consideration recited herein.
.........., tir% Notary P c,ataof Tex
Printed Name: Is Y1�CG�
e _ My Commission Ex ''es 9129 I.2
9rF OF
F'O ey0
(.00080613.5)1
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 8 of 9
ADDENDUM TO POSSESSION AND USE AGREEMENT FOR TRANSPORTATION PURPOSES
This Addendum to Possession and Use Agreement For Transportation Purposes (this
"Addendum") is made a part of, and is to be read in conjunction with, the attached Agreement. Unless
otherwise defined in this Addendum, all capitalized terms used shall have the meaning given to them in
the Agreement. In the event of any conflict or inconsistency between the terms and provisions of this
Addendum and those contained in the Agreement, the terms and provisions of this Addendum shall
control and govern.
1. Grantee shall construct the Project substantially in accordance with those certain plans
and specifications dated August 4, 2023 (currently at 95% submission level), prepared by HDR
Engineering, Inc., and any subsequent comments, revisions or updates approved by Grantee for final
project bidding and permitting, and any subsequent change orders approved during construction,
provided that in all events the Project will not change to result in the abandonment of the eastern portion
of existing CR 112 between Ponce De Leon Pass and CR 110 without the prior written consent of
Grantor. Grantee shall use its best efforts to notify Grantor of any subsequent revisions, updates or
change orders to such plans and specifications that could materially affect future use and development of
the Remainder, such as changes related to road alignment, access points, median breaks/turn-in lanes,
drainage and utilities(including stubs and connections).
2. Grantor and Grantee acknowledge that Grantee has made an offer to Grantor for the
acquisition of the Property based on Grantee's approved value and that Grantor intends to submit a
counteroffer to Grantee. If Grantor and Grantee fail to reach a final agreed settlement for Grantee's
acquisition of the Property within 60 days after the date Grantor submits a counteroffer to Grantee,
Grantor may, at its option, at any time thereafter, notify Grantee that it desires that Grantee initiate
condemnation proceedings for the Property. Within 30 days after receipt of such notice from Grantor,
Grantee will undertake to complete any final prerequisites to filing of a condemnation suit as required by
the Texas Property Code, Chapter 21, and as soon as reasonably possible thereafter (and in any event
within 90 days after receipt of such notice from Grantor), shall initiate condemnation proceedings and
will seek to schedule a Special Commissioners' hearing at the earliest possible date. Grantee covenants
that it will take all procedural steps necessary to ensure that the hearing is held in a timely manner and
without any delays caused by Grantee. Grantee agrees to deposit the award of the Special
Commissioners in the registry of the court within 60 days of the date that the Special Commissioners'
award is filed with the court.
3. Grantee agrees to conduct its Project-related activities on the Property in a manner that
avoids or minimizes interference with and interruption of any tenant's operations on the Remainder
(including avoiding loss of or injury to livestock) to the extent reasonably possible. If any such activities
will impact a tenant's operations, Grantee shall coordinate same in advance with such tenant. In no event
shall any existing fence located on the Property be removed, cut, modified, or otherwise damaged by
Grantee or its contractors within thirty (30) days following the Effective Date, by which time Grantor
shall have completed installation of new perimeter fencing for the Remainder at such location. In no
event shall any such new fence be removed, cut, modified, or otherwise intentionally damaged by
Grantee or its contractors without the prior written approval of Grantor and Tenant, which approval shall
not be unreasonably withheld or delayed. In addition, if Grantor or any tenant of Grantor requests that
Grantee, as part of Grantee's acquisition of the Property or the conduct of its Project-related activities on
(.00080613.5))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 9 of 9
the Property, reasonably cooperate with Grantor or such tenant as necessary for carrying out the existing
agricultural and ranching operations on the Remainder and/or continuously maintaining all existing
Agriculture Use ad valorem tax exemptions on Remainder tracts, Grantee agrees to do so.
4. To the extent allowed by law, Grantee will be liable for all damage or injury to persons or
property resulting from the activities of Grantee, its agents, employees, contractors, subcontractors, or
other parties in coming upon or about the Property in connection with Grantee's activities upon the
Property under this Agreement, including but not limited to losses or expenses incurred by Grantor or
Tenant due to unauthorized damage caused by Grantee or its contractors to any fencing, livestock,
growing crops or property of Grantor, Tenant or their respective agents or employees. Grantee will also
promptly discharge any lien claim filed against the Remainder that arises out of the Project. Specifically
without waiving any available governmental immunity, Grantee acknowledges and agrees that Grantor
shall be allowed to seek any existing legally available remedies for any damages incurred by Grantor
due to Grantee's breach of this Agreement.
5. Grantee will obtain, and maintain in full force and effect, at all times during the term of
this Agreement, and will require each of its contractors and assignees to obtain and maintain in effect at
all times during which such contractors or assignees are performing work on or within the Property, a
policy or policies of insurance, in at least the minimum amounts that Grantee typically requires of its
contractors for work similar to the Project. Such liability insurance shall provide that it may not be
canceled without at least 30 days written notice to Grantor. Grantee shall provide a certificate of
insurance evidencing the required coverage to Grantor prior to Grantee or the contractor or assignee in
question entering upon or commencing any construction activity on the Property.
(.00080613.5))
County: Williamson Page 1 of 7
Parcel : 3—Nelson Homestead 08-23-22
Highway: C.R. 112
EXHIBIT ` 1
PROPERTY DESCRIPTION
DESCRIPTION OF A 6.800 ACRE (296,151 SQUARE FOOT) PARCEL OF LAND SITUATED IN THE
THOMAS GLASSCOCK SURVEY, ABSTRACT NO. 255 IN WILLIAMSON COUNTY, TEXAS, BEING A
PORTION OF THE REMAINDER OF THAT CALLED 868.54 ACRE OF LAND IN SPECIAL WARRANTY
DEED TO NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD RECORDED IN DOCUMENT NO.
1998024076 OF THE OFFICIAL RECORDS OF WILLIAMSON COUNTY, TEXAS, AND DESCRIBED IN
VOLUME 1133, PAGE 639 OF THE DEED RECORDS OF WILLIAMSON COUNTY TX., SAID 6,800
ACRE (296,151 SQUARE FOOT) PARCEL OF LAND BEING MORE PARTICULARLY DESCRIBED BY
METES AND BOUNDS AS FOLLOWS:
BEGINNING at an iron rod with aluminum cap stamped "CORR-ROW' set 72.00 feet left of County Road
(C R.) 112 Baseline Station 46+41.23 in (Grid Coordinates determined as N=10,178,211.91
E=3,145,845.29), in the curving proposed northerly right-of-way (ROW) line of C.R. 112 (variable width
ROW), being the westerly boundary line of said remainder of that 868.54 acre tract, same being the
easterly line of that called 97.472 acre (Tract 5) of land described in Trustee's Deed to Marta C. Avery
Exempt Trust recorded in Document No. 2021038922 of the Official Public Records of Williamson County,
Texas, for the northwesterly corner and POINT OF BEGINNING of the herein described parcel,
THENCE, departing the easterly boundary line of said 97.472 acre tract, through the interior of said
remainder of the 868,54 acre tract, with said proposed ROW line the following six(6) courses:
1) with a curve to the right, having a radius of 20,072.00 feet, a delta angle of 00°18'32", an arc
length of 108.22 feet, and a chord which bears N 70°07'09" E, a distance of 108.22 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 72.00 feet left of C.R. 112 Baseline
Station 47+49.06, for a point of tangency;
2) N 70°16'25" E for a distance of 1,902.17 feet to an iron rod with aluminum cap stamped TORR-
ROW' set 72.00 feet left of C.R. 112 Baseline Station 66+51.23, for a point curvature to the left;
3) with said curve to the left, having a radius of 1,428.00 feet, a delta angle of 14°32'24", an arc
length of 362.38 feet, and a chord which bears N 63°00'13" E, a distance of 361.41 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 72.00 feet left of C.R. 112 Baseline
Station 70+31.89, for a point of tangency;
4) N 55°44'01" E for a distance of 150.06 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 72.00 feet left of C.R. 112 Baseline Station 71+81.95;
5) N 40°44'01" E for a distance of 123.64 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 104.00 feet left of C.R. 112 Baseline Station 73+01,37;
6) N 55°44'01" E for a distance of 150.00 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 104.00 feet left of C.R. 112 Baseline Station 74+51.37;
7) N 09°07'44" E for a distance of 32.43 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 127.57 feet left of C.R. 112 Baseline Station 74+73.6.5 in the westerly boundary line of
the remainder of that called 1,162.08 acre tract (Exhibit A, 3) in Special Warranty Deed to Nelson
Homestead Family Partnership, LTD. recorded in Document No. 1998024078 of the Official
Records of Williamson County, Texas, being the easterly line of said remainder of the 868.54
acre tract, for the northeasterly corner of the herein described parcel;
County: Williamson Page 2 of 7
Parcel : 3-Nelson Homestead 08-23-22
Highway: C.R. 112
8) THENCE, departing said proposed ROW line, with the common line of said remainder of the
868.54 acre tract and said remainder of that called 1,162.08 acre tract, N 77006'26" E for a
distance of 396.67 feet to a calculated point in the existing northerly ROW line of C.R. 112
(variable width ROW), being the southerly corner of said remainder of the 1,162.08 acre tract and
the Southeasterly corner of said remainder of the 868.54 acre tract, for the southeasterly corner of
the herein described parcel,
THENCE, departing said remainder of the 1.162.08 acre tract, with the southerly boundary line of said
remainder of the 868.54 acre tract, being said existing northerly ROW line, the following five(5)courses:
9) S 61°59'30"W for a distance of 84.73 feet to a calculated angle point;
10) S 52°35'04"W for a distance of 181.91 feet to a calculated angle point;
11) S 54°53'29" W for a distance of 536.27 feet to a calculated angle point;
12) S 52°48'02" W for a distance of 136.90 feet to a calculated angle point,
13) S 70°06'35" W for a distance of 2,290.98 feet to a calculated point, being the southeasterly
corner of said 97.472 acre tract, same being the southwesterly corner of said remainder of the
868.54 acre tract, for the southwesterly corner of the herein described parcel,
14) THENCE, departing said existing ROW line, with the common line of said 97.474 acre tract and
said remainder of the 868.54 acre tract, N 08°04'42" W for a distance of 95.84 feet to the POINT
OF BEGINNING,containing 6.800 acres (296,151 square feet) of land, more or less.
This property description is accompanied by a separate parcel plat.
All bearings recited herein are based on the Texas State Plane Coordinate Systern, Central Zone No.
4203, NAD 83.
THE STATE OF TEXAS §
§ KNOW ALL MEN BY THESE PRESENTS:
COUNTY OF WILLIAMSON §
That I, M. Stephen Truesdale, a Registered Professional Land Surveyor, do hereby certify that the above
description is true and correct to the best of my knowledge and belief and that the property described
herein was determined by a survey made on the ground under my direct supervision.
WITNESS MY HAND AND SEAL at Round Rock, Williamson County, Texas.
M. Stephen -rruLisdale Date
Registered Professional Land Surveyor No. 4933 OF
Licensed State Land Surveyor lee
Inland Geodetics, LLC
Firm Registration No: 100591-00 ;.,.'...............
LE
1504 Chisholm Trail Road, Suite 103 M.STEPHt.. TROE....
• J
Round Rock, TX 78681 -t a 4933��`�PjlQ
S:1RPS NORTH AMERICA\CR 112\PARCELSIPARCEL 31PARCEL 3-NELSON HOMESTEAD.doc
EXHIBIT A
PLAT TO ACCOMPANY DESCRIPTION
MARTA C. AVERY EXEMPT TRUST
(TRACT 5)
97.472 AC.
DOC. NO. 2021038922
O.R.W.C.T.
- - - - - - --� - - - - - - � K SURVEY
SS000 Z55
ISTA. 46+41.23 NELSON HOMESTEAD FAMILY MAS G�, NO-
72.00' LT PARTNERSHIP, LTD. 1H0 GRID COORDINATES: REMAINDER OF 868.54 ACRES AgST
[ r N=10.178,211.91 DOC. NO. 1998024076
E=3,145,845.29 O.R.W.C.T.
P.O.B. DESCRIBED IN
-� VOL. 1133, PG. 639
STA. 47+49.06 D.R.W.C.T.
72.00' LT
Cl N70'16'25"E 1,902.17'
3 „
(a) PROPOSED R.0-W.
va
d CID
n 6.800 AC.
— Z�' a i 296,151 SQ. FT.
I 50+yo C.R.. 112 ENGINEER'S BASELINE
EXISTING R.O.W. —_T Z o--. - -570"06'35"W 2,290.98' -_- -- ---- - -
- — - +
C.R. _112 _
OSTENSIBLE SURVEY LINE -- —
— — — — — R.O.W. WIDTH VARIES --
_—x_ EXISTING R.,O.W.
— — — — — — — — — — — — —
SURVEY - - - - - - - - - - -
pONANT N0 j73 NUMBER DELTA RADIUS LENGTH CHORD CHORD BEARING
W1��1 B5TRA0 C1 00'1832" 20,072.00' 108.22' 108,22' N70'07'09"E
A
08/23/2022
INLAND
PARCEL PLAT SHOWING PROPERTY OF
_
ISSIO
G I 1.V10 EODETICS= NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. PARCEL 3
AOI SURVEY 6 QM AC.
1 504 CNISMOLM TRAIL RD.STE.103 296,151 SQ. FT.
ROUNO ROCK TX 76691 SCALE
IIL RI A 236-120C,FA%612)23C-12S1 P R OJ ECT
19 FNI RK5TWAM NO.10Os91-ao 1" = 100' WILLIAMSON COUNTY CR 112 PAGE 3 OF 7
S:\RCS NORTH AV_R'CA\CR 112\PARCELS\PARCE_ 3\PARCE,. 3—AVERY—T4JST—PG3.dwg
EXHIBIT
PLAT TO ACCOMPANY DESCRIPTION
S�RvE�
SSc 255NELSON HOMESTEAD FAMILY /
REMAINDER OF 8PARTNEH68.54 D ACRESTNpM Aa5TRAC� Np /
DOC. NO. 1998024076 i
O.R.W.C.T.
DESCRIBED IN APPROXIMATE CEN.VZUNE OF
VOL. 1133, PG. 639 LONE STAR GAS COMPANY /
�
D.R.W.C.T. AScMOL. 2&.36IPG. 18 wAY /
O.R.W.C.-. /
N70'16'25"E 1,902.17' /
oPROPOSED R.O.W.
6.800 AC. ,
C.R. 112 ENGINEER'S BASELINE 296,151 SQ. FT. ,
ZCD
T I
='n 60.00 i I t `'o
S70'06'35"W 2,290.98' - —� z
_ _ _ XI IN .W. -- —+<~ �r
OSTENSIBLE SURVEY LINE - - - - - - -
- -r C.R. 112
(R.O.W. WIDTH VARIES)
- - - - -- - - - - - - - - - - - - - - - - - _ y EXISTING R.O.W.
SURVEY I J, � i - -, - - - - - - - - - - - - - - -
'0_05
A05_
� I /
08 23 2C22
I N LAN D
PARCEL PLAT SHOWING PROPERTY OF
_
GEODETICS NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. 6.8 E AC.
3
v.oaFsI..——wRvav
I Sa CKSHOLM nwL R0.STE 103
KOU�o Rack Tx 78"1 SCALE 296.151 SO. FT.
m.512123 al:oo.vu mn:ne-un P R OJ ECT
RqM nKtS?AA1"Nl I I'llw" �" = IOC' 'MIL'_IAMSCN COUNTY
CR 112 RAGE 4 OF 7
S:\RDS 14ORT-1 AMERICA\CR 112\PARCELS\PARCE_ 3\PARCE_ 3-AVFRl-TR.;S' PC4dwd
EXHIBIT A
PLAT TO ACCOMPANY DESCRIPTION
NUMBER DELTA RADIUS LENGTH CHORD CHORD BEARING
C2 14'32'24" 1,428.00' 362.38' 361.41' N63'0O'13"E NELSON HOMESTEAD FAMILY
PARTNERSHIP, LTD.
REMAINDER OF 868.54 ACRES
SORv�Y NELSON HOMESTEAD FAMILY URVEY DOC. NO. 1998024076
O.R.W.C.T.
GLPS50 Np 255 PARTERSHIP, LT .REMAINDERNOF 868.54DACRES iJ J�S�IC�O 356
�HpMA BS�RAOT DOC. 0 R.W.CO. 8024076 > 30 6s�RAp1
A DESCRIBED IN N P STA. 71+81.95 \.`L
VOL. 1133, PG. 639 W 72.00' LT
J
D.R.W.C.T. �= STA. 70+31.89
w 72.00' LT `1 N
STA. 66+51.23 p
72.00' LT 0 w
N7O'16'25"E 1,902.17' C2 PROPOSED
o
r C.
+ 9.2 W
-I a 29fito Q SQ. Fr.I T0•p0 a -�,- mow.
O
w 65.00 , �r� ��- EX15S11`AG R
Z --fX1STING'R.O.W•
V:3 - - - - S7O'06'35"W 2,290.98'
OSTENSIBLE SURVEY,.LINE --
C.R. 112
(R.O.W. WIDTH VARIES)
EXISTING R.O.W.
(w NO. DIRECTION DISTANCE
Y I�I L1 N55'44'01"E 150.06'
URGE I I = L2 N40'44'01"E 12164'
ppNA�1 No I�1 l 3 1-6 S52'48'02"W 136.90'
w1�t,Pes-�g4O
I
08/23/2022
PARCEL PLAT SHOWING PROPERTY OF
FIN AN D -
DETICS= NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. 6AR EL 3
LM TAAII RD.STE 103
ROCK,7X 78681 SCALE 296,151 SQ. FT.c1m REC5MTMM0.100591-00 1" = 1C0' W!LLIAMSON COJNiY CR 1EC2 PAGE 5 OF 7
S:\RCS NORT-1 AMERICA\CR 112\3ARC__S\3ARCS_ 3\PARCE_ 3-AVERY-TR.IST-PC5.dwg
EXHIBIT A
PLAT TO ACCOMPANY DESCRIPTION
NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. I
REMAINDER PORTION l
1.162.08 ACRES I
\ (EXHIBIT "A", 3)
DOC. NO. 1998024078
URV EY 0.R.W.C.T. S
S ORIGINAL 1,605.03 AC. TRACT
JOS�ICNO. 356 DESCRIBED IN VOL. 305, PG. 219 NELSON
PARTNERSHIP, D LTD.
FAMILY
JpNN , R D.R.W.C.T.5 pG� REMAINDER OF 868.54 ACRES 1
p8 STA. 74+73.65 DOC. NO 1998024076
127.57' LT O.R.W.C.T.
STA. 74+51.37 i
104.00' LT
STA. 73+01.37
104.00' LT `` N77'06'26"E 1
396.67'
SE
PF'OPO "y
STA. 73+01.37 �o cF�S i 6.800 AC. -- L5
104.00 LT ON ��E��$o1go 6 296,151 SQ. FT. N
N� PEER ,9 c� 35 O4
I
U-,� SIBpSEl14E +00 y� N2 RE EE IG l5 --
R
N� 112 EN�1N � N
R.
oZyl� EX51129
ocn O w� S553 <RpW• y _..
r 0
Dorn .. ,-.
_l ` `NG
NO. DIRECTION DISTANCE - - OSTENSIBLE SURVEY LINE
L2 N40'44'01"E 123.64' — —— — — — — — —
L3 N55'44'01"E 150.00'
L4 N09'07'44"E 32.43'
L5 S61'59'30"W 84.73' \
PARCEL PLAT SHOWING PROPERTY OF
08/23/2022
I N LAND .
�G.-- ICS_ NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. PARCEL 3
1C.oveHISHOL�w+o sO.Sn.1tis 296,151 .Su(. �'.
5W CN6NOu1 TgALRD.Sh.103
ROUND ROCK,T)L 78UI
vN.l5in21&-1200.rAXlsln2sa-I:sl SCALE PROJECT
Fl.R[OSTBATION NO.100S91-oo 1" _ l00' WILLIAMSCN COUNTY
CR 112 SAGE 6 OF 7
S:\RPS NORTH AVSRCA\CR 112\PARCFLS\PARCEL 3\PARCE_ 3-AvFRY-TRJST-PG6k7.d—.
EXHIBIT A
LE G E N D PLAT TO ACCOMPANY DESCRIPTION
0 IRON ROD WITH ALUMINUM CAP DENOTES COMMON OWNERSHIP
STAMPED "CORR—ROW" SET P.0.8. POINT OF BEGINNING
p IRON ROD WITH PLASTIC CAP ( ) RECORD INFORMATION
FOUND — AS NOTED P.R.W.C.T. PLAT RECORDS
1/2" IRON ROD FOUND WILLIAMSON COUNTY, TEXAS
TxDOT TYPE II CONCRETE ID.R.W.C.T. DEED RECORDS
MONUMENT FOUND WILLIAMSON COUNTY, TEXAS
O.R.W.C.T. OFFICIAL RECORDS
CALCULATED POINT WILLIAMSON COUNTY, TEXAS
PROPERTY LINE O.P.R.W.C.T. OFFICIAL PUBLIC RECORDS
LINE BREAK WILLIAMSON COUNTY, TEXAS
1) All bearings shown hereon are based on grid bearing. All distances are surface distances. Coordinates are surface values based on the Texas State
Plane Coordinate System, NAD 83, Central Zone.
THE SURVEY SHOWN HEREON WAS PREPARED IN CONJUNCTION WITH THAT COMMITMENT FOR TITLE INSURANCE GF NO. GT2200988, ISSUED BY TEXAN TITLE
INSURANCE COMPANY, EFFECTIVE DATE JULY 22, 2022, ISSUE DATE AUGUST 3, 2022.
10C. PIPELINE EASEMENT GRANTED TO LONE STAR GAS COMPANY AS SET OUT IN VOLUME 238, PAGE 184, OF THE DEED RECORDS OF WILLIAMSON COUNTY
TEXAS, (AS IT PERTAINS TO TRACT 1 ONLY), AFFECTS AS SHOWN.
D. RIGHT—OF—WAY AND PIPELINE EASEMENT GRANTED TO SEMINOLE PIPELINE COMPANY, AS SET OUT IN VOLUME 840, PAGE 699, OF THE DEED RECORDS
OF WILLIAMSON COUNTY, TEXAS; SUPPLEMENTED BY THAT CERTAIN SUPPLEMENTAL PIPELINE RIGHT—OF—WAY AGREEMENT, AS SET OUT IN VOLUME 2169,
PAGE 795, OF THE DEED RECORDS OF WILLIAMSON COUNTY, TEXAS, (AS IT PERTAINS TO TRACT 3 ONLY), DOES NOT AFFECT.
E. NON—EXCLUSIVE PIPELINE EASEMENT AGREEMENT GRANTED TO ENTERPRISE CRUDE PIPELINE, LLC, AS SET IN INSTRUMENT(S) FILED FOR RECORD UNDER
WILLIAMSON CLERK'S FILE NO. 2017003557; FURTHER STIPULATED IN THAT CERTAIN MEMORANDUM OF MERGER, AS SET IN INSTRUMENT(S) FILED FOR
RECORD UNDER WILLIAMSON CLERK'S FILE NO. 2020082921, (AS IT PERTAINS TO TRACT 3 ONLY), DOES NOT AFFECT.
I HEREBY CERTIFY THAT THIS PLAT IS TRUE AND
CORRECT AND THAT THE PROPERTY SHOWN HEREON
WAS DETERMINED BY A SURVEY MADE ON HE
GROUND U ER Y DIRECT UPERVISI +"'~OF
M. ST HEN T UESDALE DATE
'P '.
REGISTERED PROFESSIONAL M.UPH TT1RUESIDI&E
LAND SURVEYOR NO. 4933
LICENSED STATE LAND SURVEYOR
INLAND GEODETICS, LLC ggi /J
FIRM REGISTRATION NO. 100591-00 ✓'
1504 CHISHOLM TRAIL ROAD, SUITE 103 SUR
ROUND ROCK, TEXAS 78681 08/23/2022
PARCEL PLAT SHOWING PROPERTY OF
I N L A ry o _ PARCEL 3
GEODETICS- NELSON HOMESTEAD FAMILY PARTNERSHIP LTD. s.sao AC.
_07ES 1.o — SDRIM10"
I SO4 CN:SMOLai TRAIL RD.M.101 296,151 SO. FT.
RODVD ROCK TX.79"1 SCALE
FILR1Lz38-1200,rum2)ae-1a1 WILLIAMSON COUNTY PROJECT 1 PAGE 7 OF 7
71Rw RtcaTRATIDN No,Toom-ao 1" = 100'
r rr:. •1?\PARCELS\°ARCEL 3\aARCEI 3-AVER,Y-TRVST-0aE&7.cag
PARCEL NO. 4
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 1 of 9
POSSESSION AND USE AGREEMENT FOR TRANSPORTATION PURPOSES
STATE OF TEXAS §
§ Parcel No.: 4
COUNTY OF WILLIAMSON § Project: CR 112
This Possession and Use Agreement For Transportation Purposes (the "Agreement") between CITY OF
ROUND ROCK, TEXAS ("Grantee"), and NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD.,
a Texas limited partnership (the "Grantor" whether one or more), grants to the Grantee, its contractors,
agents and all others deemed necessary by the Grantee, an irrevocable right to possession and use of the
Grantor's property for the purpose of constructing improvements to CR 112 and related utility
adjustments (the "Project"). The property subject to this Agreement is described more fully in field
notes, plat map or other description (attached as "Exhibit A") and made a part of this Agreement by
reference (the"Property").
I. For the consideration from the Grantee which is set forth in Paragraph 2 below, the receipt and
sufficiency of which is acknowledged, the Grantor grants, bargains, and conveys to Grantee the right
of entry and exclusive possession and use of the Property for the purpose of constructing a roadway,
utility adjustments and all related appurtenances thereto and the right to remove any improvements
thereon. Authorized activities on the Property include surveying, inspection, environmental studies,
archeological studies, clearing, demolition, construction of permanent improvements, relocating,
replacing, and improving existing utility facilities, locating new utility facilities, and other work
required to be performed in connection with the Project. This Possession and Use Agreement will
extend to the Grantee, its contractors and assigns, providers of any existing utilities on the Property
and those which may be lawfully permitted on the Property by the Grantee in the future, and all
others deemed necessary by the Grantee for the purpose of the Project. This grant will allow the
construction, relocation, replacement, repair, improvement, operation and maintenance of utilities on
the Property only.
2. In consideration for this irrevocable grant of possession and use and other Grantor covenants,
warranties, and obligations under this Agreement, the Grantee will tender to the Grantor the sum of
TWO MILLION SEVEN HUNDRED TWENTY-TWO THOUSAND THIRTY-SEVEN and 00/100
Dollars ($2,722,037.00). The Grantor agrees that this sum represents 90% of the amount that
Grantee has determined constitutes adequate and full compensation for the possession and use of the
Property. Grantee will be entitled to take possession and use of the Property upon tender of payment
as set out herein, subject to the conditions in Paragraph 14 below, if any. The parties agree that the
sum tendered represents 90% of the Grantee's approved value, which assumes no adverse
environmental conditions affecting the value of the Property. The approved value is the Grantee's
determination of the just compensation owed to the Grantor for the real property interest to be
acquired by the Grantee in the Property, encumbered with the improvements thereon, if any, and
damages to the remainder, if any, save and except all oil, gas and sulphur. The parties agree that the
sum tendered to Grantor will be deducted from any final settlement amount, Special Commissioners'
award or court judgment. In the event the amount of the final settlement or judgment for acquisition
of the Property is less than the amount the Grantee has paid for the possession and use of the
{.00080671.1J
11�1�111111
* N P U A *
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 2 of 9
Property, then the Grantor agrees that the original amount tendered represents an overpayment for
the difference and, upon written notice from the Grantee, the Grantor will promptly refund the
overpayment to the Grantee. In the event the amount of the final settlement or court judgment for
acquisition of the Property is greater than the amount Grantee has paid for the possession and use of
the Property under this Paragraph 2, Grantee will remit the underpayment to Grantor when required
under the final settlement or court judgment.
3. The effective date of this Agreement will be the date on which payment pursuant to Paragraph 2
above was tendered to the Grantor by the Grantee, or delivered by Grantee to a title company acting
as escrow agent for the transaction, with unconditional instructions to such escrow agent to
immediately release such payment to Grantor upon escrow agent's confirmation that no liens or
other monetary encumbrances affect the Property (the "Effective Date").
4. The Grantor warrants and represents that, to Grantor's actual knowledge, the title to the Property is
free and clear of all monetary liens and encumbrances except as disclosed to Grantee in that certain
title commitment numbered GF4202301512 dated effective June 8, 2023 issued by Heritage Title
Company of Austin Inc., as agent for First American Title Insurance Company, and that proper
releases will be executed for such liens and encumbrances (if any) prior to funds being disbursed
under this Agreement. The Grantor further warrants that no other person or entity owns (or, to
Grantor's knowledge, claims) an interest in the fee title to the Property and further agrees to
indemnify the Grantee from all unrelated or undisclosed liens or other monetary encumbrances
affecting the Property.
5. The parties agree that the valuation date for determining the amount of just compensation for the real
property interest proposed to be acquired by the Grantee in the Property, for negotiation or eminent
domain proceeding purposes,will be the Effective Date of this Agreement.
6. This Agreement is made with the understanding that the Grantee will continue to proceed with
acquisition of a real property interest in the Property. The Grantor reserves all rights of
compensation for the title and other interest in and to the Property which the Grantor holds as of the
time immediately prior to the Effective Date of this Agreement. This Agreement shall in no way
prejudice the Grantor's rights to receive full and just compensation as allowed by law for all of the
Grantor's interests in and to the Property to be acquired by the Grantee, encumbered with the
improvements thereon, if any, and damages, if any, to the remainder of the Grantor's interest in any
larger tract of which the Property is a part (the "Remainder"), if any; all as the Property exists on the
Effective Date of this Agreement. The Grantee's removal or construction of improvements on the
Property shall in no way affect the fair market value of the Property in determining compensation
due to the Grantor in the eminent domain proceedings. This grant will not prejudice the Grantor's
rights to any relocation benefits for which Grantor may be eligible.
7. In the event the Grantee institutes or has instituted eminent domain proceedings, the Grantee will not
be liable to the Grantor for interest upon any award or judgment as a result of such proceedings for
any period of time prior to the date of the award. Payment of any interest may be deferred by the
Grantee until entry of judgment.
8. The purpose of this Agreement is to allow the Grantee to proceed with its Project without delay and
to allow the Grantor to avoid proceeding with condemnation litigation at the current time and
1.00080671.1}}
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 3 of 9
continue voluntary investigation and negotiation for the proposed Property acquisition. The Grantor
expressly acknowledges that the proposed Project are for a valid public use and voluntarily waives
any right the Grantor has or may have, known or unknown, to contest the jurisdiction of the court in
any condemnation proceeding for acquisition of the Property related to the Project, based upon
claims that the condemning authority has no authority to acquire the Property through eminent
domain, has no valid public use for the Property, or that acquisition of the Property is not necessary
for the public use.
9. The Grantor reserves all of the oil, gas and sulphur in and under the land herein conveyed but waives
all right of ingress and egress to the surface for the purpose of exploring, developing, mining or
drilling. The extraction of oil, gas and minerals may not affect the geological stability of the surface.
Nothing in this reservation will affect the title and rights of the Grantee to take and use all other
minerals and materials thereon, and thereunder.
10. The undersigned Grantor agrees to pay as they become due, all ad valorem property taxes and
special assessments assessed against the Property until the Effective Date, including prorated taxes
until the Effective Date for the year in which the Grantee takes title to the Property. Grantor shall
have no liability for ad valorem property taxes and special assessments assessed against the Property
for any period after recording of a memorandum of this Agreement.
11. Notwithstanding the acquisition of right of possession to the Property by the Grantee in a
condemnation proceeding by depositing the Special Commissioners' award into the registry of the
court, less any amounts tendered to the Grantor pursuant to Paragraph 2 above, this Agreement shall
continue to remain in effect until the Grantee acquires title to the Property either by agreed final
settlement, or final court judgment, whereupon this Agreement shall automatically terminate.
12. This Agreement will also extend to and bind the heirs, devisees, executors, administrators, legal
representatives, successors in interest and assigns of the parties.
13. It is agreed that Grantee will record a memorandum of this Agreement on or about the Effective
Date in the property records of the county in which the Property is located, evidencing the existence
of this Agreement. The Agreement itself will not be recorded. The memorandum will not contain
any information regarding the consideration paid or to be paid to Grantor by Grantee and will
otherwise be in a form mutually acceptable to Grantor and Grantee. The recording of the
memorandum will not modify the terms of this Agreement. Upon termination of this Agreement for
any reason, either Grantor or Grantee may record an affidavit in the county property records
evidencing such termination.
14. Other conditions: See Addendum attached hereto and made a part hereof.
15. By its authorized signature below the following Tenants which have a leasehold interest in the
Property hereby consent in all things to Grantee taking exclusive and sole possession of the Property
pursuant to the terms of this Agreement, and to Grantor receiving the consideration recited herein:
Tenant: Davidson Brothers
(.00080671.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 4 of 9
At no time during the possession of the Property by Grantee for the purposes described herein shall
Grantor or Tenant be denied reasonable access and/or ingress to or egress from the Remainder for its
current uses without prior advance agreement between Grantor and Grantee.
To have and to hold the Agreement herein described and conveyed, together with all the rights and
appurtenances belonging to the Grantee and its assigns forever, for the purposes and subject to the
limitations set forth above.
[signature pages follow]
(.00080671.1))
Form ROW-N-PUA
(12112)
Replaces Form ROW-N-7
Page 5 of 9
GRANTOR:
NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD.,
a Texas limited partnership
By: Nelson Homestead Management, L.L.C.,
its general partner
By: < . 0 0J�
Name. hn C.Nelson
Title: Manager
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF T►-r*/1 s
This instrument was acknowledged before me on this the Asday of August, 2023 by John C.
Nelson, Manager of Nelson Homestead Management, L.L.C., the general partner of Nelson Homestead
Family Partnership, Ltd., in the capacity and for the purposes and consideration recited herein.
eNotary
Gloria A Velasquez , I Public,Stale of Texas ���' � �CComm.6cpires 01/03/2024 Notary iD+2884+09.3
Notary Public, Stag of TYxas
Printed Name:610 a a, VV45 o-K{
My Commission Expires: 911o3/2oi1
(.00080671.1)}
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 6 of 9
TENANT:
Davidson Brothers
By:
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF wi i t i* 5o#J
This instrument was acknowledged before me on this the A6' day of August, 2023 by
ylh,cs L.1)a.t%rGdsovt, , in the capacity and for the purposes and consideration recited herein.
a. '10da A Velasquez
Notary Public,State of Texas
.. Comm.Expireaol/03/202a Notary Public, State of texas
a Notary ID 1288009-3 �/t�(2�t) �Q
Printed Name:
My Commission Expires: OI103120;zq
{.00080671.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 7 of 9
GRANTEE:
CITY OF ROUND ROCK, TEXAS
By: , M f
Craig Morg n, M I
r
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF WILLIAMSON
This instrument was acknowledged before me on this the ��ay of DkRA1ZQjC, 2023 by
Craig Morgan, in the capacity and for the purposes and consideration recited herein.
N 1 S/P'77j� N ii Notary Pu , Stat of Texas
pGPy•P /N,f%'i'�i Printed NaeftU t(�4�
Ua� My Commission Exr4resG
_/
gFpp ��`:'
1?402g
0p,09i
{.00080671.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 8 of 9
ADDENDUM TO POSSESSION AND USE AGREEMENT FOR TRANSPORTATION PURPOSES
This Addendum to Possession and Use Agreement For Transportation Purposes (this
"Addendum") is made a part of, and is to be read in conjunction with, the attached Agreement. Unless
otherwise defined in this Addendum, all capitalized terms used shall have the meaning given to them in
the Agreement. In the event of any conflict or inconsistency between the terms and provisions of this
Addendum and those contained in the Agreement, the terms and provisions of this Addendum shall
control and govern.
1. Grantee shall construct the Project substantially in accordance with those certain plans
and specifications dated August 4, 2023 (currently at 95% submission level), prepared by HDR
Engineering, Inc., and any subsequent comments, revisions or updates approved by Grantee for final
project bidding and permitting, and any subsequent change orders approved during construction,
provided that in all events the Project will not change to result in the abandonment of the eastern portion
of existing CR 112 between Ponce De Leon Pass and CR 110 without the prior written consent of
Grantor. Grantee shall use its best efforts to notify Grantor of any subsequent revisions, updates or
change orders to such plans and specifications that could materially affect future use and development of
the Remainder, such as changes related to road alignment, access points, median breaks/turn-in lanes,
drainage and utilities (including stubs and connections).
2. Grantor and Grantee acknowledge that Grantee has made an offer to Grantor for the
acquisition of the Property based on Grantee's approved value and that Grantor intends to submit a
counteroffer to Grantee. If Grantor and Grantee fail to reach a final agreed settlement for Grantee's
acquisition of the Property within 60 days after the date Grantor submits a counteroffer to Grantee,
Grantor may, at its option, at any time thereafter, notify Grantee that it desires that Grantee initiate
condemnation proceedings for the Property. Within 30 days after receipt of such notice from Grantor,
Grantee will undertake to complete any final prerequisites to filing of a condemnation suit as required by
the Texas Property Code, Chapter 21, and as soon as reasonably possible thereafter (and in any event
within 90 days after receipt of such notice from Grantor), shall initiate condemnation proceedings and
will seek to schedule a Special Commissioners' hearing at the earliest possible date. Grantee covenants
that it will take all procedural steps necessary to ensure that the hearing is held in a timely manner and
without any delays caused by Grantee. Grantee agrees to deposit the award of the Special
Commissioners in the registry of the court within 60 days of the date that the Special Commissioners'
award is filed with the court.
3. Grantee agrees to conduct its Project-related activities on the Property in a manner that
avoids or minimizes interference with and interruption of any tenant's operations on the Remainder
(including avoiding loss of or injury to livestock) to the extent reasonably possible. If any such activities
will impact a tenant's operations, Grantee shall coordinate same in advance with such tenant. In no event
shall any existing fence located on the Property be removed, cut, modified, or otherwise damaged by
Grantee or its contractors within thirty (30) days following the Effective Date, by which time Grantor
shall have completed installation of new perimeter fencing for the Remainder at such location. In no
event shall any such new fence be removed, cut, modified, or otherwise intentionally damaged by
Grantee or its contractors without the prior written approval of Grantor and Tenant, which approval shall
not be unreasonably withheld or delayed. In addition, if Grantor or any tenant of Grantor requests that
Grantee, as part of Grantee's acquisition of the Property or the conduct of its Project-related activities on
{.00080671.1))
Forth ROW-N-PUA
(12/12)
Replaces Forth ROW-N-7
Page 9 of 9
the Property, reasonably cooperate with Grantor or such tenant as necessary for carrying out the existing
agricultural and ranching operations on the Remainder and/or continuously maintaining all existing
Agriculture Use ad valorem tax exemptions on Remainder tracts, Grantee agrees to do so.
4. To the extent allowed by law, Grantee will be liable for all damage or injury to persons or
property resulting from the activities of Grantee, its agents, employees, contractors, subcontractors, or
other parties in coming upon or about the Property in connection with Grantee's activities upon the
Property under this Agreement, including but not limited to losses or expenses incurred by Grantor or
Tenant due to unauthorized damage caused by Grantee or its contractors to any fencing, livestock,
growing crops or property of Grantor, Tenant or their respective agents or employees. Grantee will also
promptly discharge any lien claim filed against the Remainder that arises out of the Project. Specifically
without waiving any available governmental immunity, Grantee acknowledges and agrees that Grantor
shall be allowed to seek any existing legally available remedies for any damages incurred by Grantor
due to Grantee's breach of this Agreement.
5. Grantee will obtain, and maintain in full force and effect, at all times during the term of
this Agreement, and will require each of its contractors and assignees to obtain and maintain in effect at
all times during which such contractors or assignees are performing work on or within the Property, a
policy or policies of insurance, in at least the minimum amounts that Grantee typically requires of its
contractors for work similar to the Project. Such liability insurance shall provide that it may not be
canceled without at least 30 days written notice to Grantor. Grantee shall provide a certificate of
insurance evidencing the required coverage to Grantor prior to Grantee or the contractor or assignee in
question entering upon or commencing any construction activity on the Property.
(.00080671.1))
County: Williamson Page 1 of 10
Parcel : 4— Nelson Homestead 08-23-22
Highway: C.R. 112
EXHIBIT A
PROPERTY DESCRIPTION
DESCRIPTION OF A 20.586 ACRE (896,713 SQUARE FOOT) PARCEL OF LAND SITUATED IN THE
JOHN L. JUSTICE SURVEY, ABSTRACT NO. 356 IN WILLIAMSON COUNTY, TEXAS, BEING A
PORTION OF A REMAINDER OF THAT CALLED 868.54 ACRES OF LAND IN SPECIAL WARRANTY
DEED TO NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. RECORDED IN DOCUMENT NO.
1998024076 OF THE OFFICIAL RECORDS OF WILLIAMSON COUNTY, TEXAS, AND DESCRIBED IN
VOLUME 1133, PAGE 639 OF THE OFFICAIL RECORDS OF WILLIAMSON COUNTY TEXAS, AND A
PORTION OF THE REMAINDER OF THAT CALLED 1,162.08 ACRE TRACT (EXHIBIT A, 3) TO SAID
NELSON HOMESTEAD FAMILY PARTNERSHIP LTD. RECORDED IN DOCUMENT NO. 1998024078
OF THE OFFICIAL RECORDS OF WILLIAMSON COUNTY, TEXAS, SAID 20.586 ACRE (896,713
SQUARE FOOT) PARCEL OF LAND BEING MORE PARTICULARLY DESCRIBED BY METES AND
BOUNDS AS FOLLOWS:
BEGINNING at an iron rod with aluminum cap stamped "CORR-ROW' set 127.57 feet left of County
Road (C.R.) 112 Baseline Station 74+73.65 (Grid Coordinates determined as N=10,179,349.33
E=3,148,393.14), in the proposed northerly Right-of-Way (ROW) line of C.R. 112 (variable width ROW),
being the common boundary line of said remainder portion of the 868.54 acre tract and said remainder
portion of the 1,162.08 acre, for the POINT OF BEGINNING of the herein described parcel;
THENCE, through the interior of said remainder of the 1,162.08 acre tract and said remainder of the
868.54 acre tract, with said proposed ROW line the following twenty one (21) courses:
1) N 09°07'44" E for a distance of 8.79 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 133.95 feet left of C.R. 112 Baseline Station 74+79.69, for an angle point;
2) N 37°28'32" W for a distance of 7.90 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 141.84 feet left of C.R_ 112 Baseline Station 74+79.25, for an angle point;
3) N 52°31'28" E for a distance of 140.00 feet to an iron rod with aluminum cap stamped "CORR-
ROW" set 150.20 feet left of C.R. 112 Baseline Station 76+15.24, for an angle point;
4) S 37028'32" E for a distance of 18.40 feet to an iron rod with aluminum cap stamped "CORR-
ROW° set 131.86 feet left of C.R. 112 Baseline Station 76+16.61, for an angle point;
5) S 79042'03" E for a distance of 59.24 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 92.00 feet left of C.R. 112 Baseline Station 76+57.40, for a point of curvature to the
right,
6) with said curve to the right, having a radius of 1,592.00 feet, a delta angle of 1°29'03", an arc
length of 41.24 feet, and a chord which bears N 59°32'03" E, a distance of 41.24 feet to an iron
rod with aluminum cap stamped "CORR-ROW' set 92.00 feet :eft of C.R. 112 Baseline Station
76+96.25, for a point of tangency;
7) N 60°16'34" E for a distance of 1,669.66 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 92.00 feet left of C.R. 112 Baseline Station 93+65.90, for an angle point;
8) S 56°58'10" E for a distance of 49.70 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 47.81 feet left of C.R. 112 Baseline Station 93+88.66, for an angle point;
9) N 60°16'34" E for a distance of 95.61 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 47.81 feet left of C.R. 112 Baseline Station 94+84.27, for an angle point,
County: Williamson Page 2 of 10
Parcel : 4—Nelson Homestead 08-23-22
Highway: C.R. 112
10) N 56°58'10" W for a distance of 49.70 feet to an iron rod with aluminum cap stamped TORR-
ROW' set 92.00 feet left of C.R. 112 Baseline Station 94+61.51, for an angle point;
11) N 60°16'34" E for a distance of 1,266.86 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 92.00 feet left of C.R. 112 Baseline Station 107+28,37, for a point of curvature to the
left,
12) with said curve to the left, having a radius of 1,308.00 feet, a delta angle of 04°31'19", an arc
length of 103.23 feet, and a chord which bears N 58°00'55" E, a distance of 103.21 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 92,00 feet left of C.R 112 Baseline
Station 108+38.86, for a point of tangency:
13) N 34°14'45" W for a distance of 20.00 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 112.00 feet left of C.R. 112 Baseline Station 108+38.86, for a point of non-tangency to
the left;
14) with said curve to the left, having a radius of 1,288.00 feet, a delta angle of 14°46'47", an arc
length of 332.25 feet, and a chord which bears N 48°21'52" E, a distance of 331.33 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 112,00 feet left of C.R. 112 Baseline
Station 112+00.00, for a point of non-tangency;
15) S 49°01'32" E for a distance of 22.00 feet to an iron rod with aluminum cap stamped TORR-
ROW' set 90.00 feet left of C.R. 112 Baseline Station 112+00.00, for a point of non-tangency to
the left;
16) with said curve to the left, having a radius of 1,310.00 feet, a delta angle of 16°41'54", an arc
length of 381.79 feet, and a chord which bears N 32037'31" E, a distance of 380.44 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 90.00 feet left of C R 112 Baseline
Station 116+08.02, for a point of tangency;
17) N 24°16'34" E for a distance of 1,044.76 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 90.00 feet left of C.R. 112 Baseline Station 126+52.78, for a point of curvature to the
right,
18) with said curve to the right, having a radius of 1,290.00 feet, a delta angle of 44042'34", an arc
length of 1,006.62 feet, and a chord which bears N 46°37'51" E, a distance of 981.27 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 90.00 feet left of C.R. 112 Baseline
Station 135+89.17, for a point of tangency;
19) N 68°59'08" E for a distance of 162.81 feet to an iron rod with aluminum cap stamped "CORR-
ROW set 90.00 feet left of C.R. 112 Baseline Station 137+51.98, for an angle point;
20) N 23°45'38" E for a distance of 56.35 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 130,00 feet left of C.R. 112 Baseline Station 137+91.66, for an angle point;
21) N 21°27'52" W for a distance of 14.77 feet to an iron rod with aluminum cap stamped "WILCO
ROW' found, in the existing westerly ROW line of C.R. 110 (variable width ROW), for an angle
point,
22) THENCE, with said existing ROW line, being said remainder of the 868.54 acre boundary line,
N 68°32'08" E for a distance of 12.00 feet an iron rod with aluminum cap stamped "WILCO
ROW' found,
County: Williamson Page 3 of 10
Parcel : 4—Nelson Homestead 08-23-22
Highway: C.R. 112
23) THENCE, continuing with said common line, S 21027'52" E for a distance of 294.48 feet an iron
rod with aluminum cap stamped "CORR-ROW' set 149.61 feet right of C.R. 112 Baseline Station
138+05.86, for an angle point;
THENCE, departing said existing ROW line, through the interior of said remainder of the 1,162.08 acre
tract, and said remainder of the 868.54 acre tract, with the proposed southeasterly ROW line of C.R. 112,
the following six (6)courses
24) S 68°32'08" W for a distance of 12.00 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 149.59 feet right of C.R. 112 Baseline Station 137+93.58, for an angle point;
25) N 21°27'52" W for a distance of 19.71 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 130.00 feet right of C.R. 112 Baseline Station 137+93.70, for an angle point,
26) N 66°14'22" W for a distance of 56.79 feet to an iron rod with aluminum cap stamped "CORR-
ROW" set 90,00 feet right of C.R. 112 Baseline Station 137+53.39, for an angle point;
27) S 68°59'08" W for a distance of 164.22 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 90.00 feet right of C.R. 112 Baseline Station 135+89.17, for a point of curvature to the
left,
28) with said curve to the left, having a radius of 1,110.00 feet, a delta angle of 44°42'34", an arc
length of 866.16 feet, and a chord which bears S 46037'51" W, a distance of 844.35 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 90,00 feet right of C.R. 112 Baseline
Station 126+52.78, for a point of tangency;
29) S 24°16'34" W for a distance of 342.37 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 90.00 feet right of C R. 112 Baseline Station 123+10.40, for an angle point, being the
cutback to a proposed spur for C.R. 112,
THENCE, continuing through the interior of said remainder of the 868.54 acre tract, with the proposed
easterly ROW line of said spur, the following four(4) courses:
30) with said cutback, S 20°43'37" E for a distance of 42.42 feet to an iron rod with aluminurn cap
stamped "CORR-ROW' set 120.00 feet right of C.R. 112 Baseline Station 122+80.41, at the end
of said cutback, for an angle point,
31) S 65°43'48" E for a distance of 253.30 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 46.00 feet left of C.R. 112 Spur Baseline Station 14+73.64, for a point of curvature to
the right;
32) with said curve to the right, having a radius of 530.00 feet, a delta angle of 36°49'42", an arc
length of 340.67 feet, and a chord which bears S 46047'52" E, a distance of 334.84 feet to an
iron rod with aluminum cap stamped "CORR-ROW' set 40.00 feet left of C.R. 112 Spur Baseline
Station 17+87.02, for a point of tangency;
33) S 29°49'09" E for a distance of 29.49 feet to an iron rod with aluminum cap stamped "CORR-
ROW" set 40.00 feet left of C.R. 112 Spur Baseline Station 18+16.52, in the existing northerly
ROW line of C.R. 112 (variable width ROW);
34) THENCE, with said existing ROW line, being said remainder of the 868.54 acre boundary line,
S 60°18'18" W for a distance of 80.00 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 40.00 feet right of C.R. 112 Spur Baseline Station 18+16.34, being the proposed
westerly ROW line of said C.R. 112 Spur,
County: Williamson Page 4 of 10
Parcel : 4—Nelson Homestead 08-23-22
Highway: C.R. 112
THENCE, continuing through the interior of said remainder of the 868.54 acre tract, with said proposed
southwesterly Spur ROW line, the following four(4) courses:
35) N 29°49'09" W for a distance of 29.32 feet to an iron rod with aluminum cap starnped "CORR-
ROW" set 40.00 feet right of C.R. 112 Spur PT Baseline Station 17+87.02, for a point of curvature
to the left;
36) with said curve to the left, having a radius of 460.00 feet, a delta angle of 35°54'39", an arc
length of 288.31 feet, and a chord which bears N 47°46'29" W, a distance of 283.61 feet to an
iron rod with aluminum cap stamped "CORR-ROVV' set 40.00 feet right of C.R. 112 Spur Baseline
PC Station 14+73.64, for a point of tangency;
37) N 65°43'48" W for a distance of 253.31 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 120.00 feet right of C.R. 112 Baseline Station 121+94.41, for the beginning of a
cutback for C.R. 112;
38) with said cutback. S 69°16'23" W for a distance of 42.43 feet to an iron rod with aluminum cap
stamped "CORR-ROW" set 90.00 feet right of C.R. 112 Baseline Station 121+64.40, in said
southeasterly proposed ROW line of C.R. 112, at the end of said cutback, for an angle point,
THENCE, continuing through the interior of said remainder of the 868.54 acre tract, with said proposed
southeasterly ROW line of C.R. 112, the following two (2) courses.
39) S 24°16'34" W for a distance of 556.39 feet to an iron rod with aluminum cap stamped "CORR-
ROW' set 90.00 feet right of C.R. 112 Baseline Station 116+08.02, for a point of curvature to the
right;
40) with said curve to the right, having a radius of 1,490.00 feet, a delta angle of 17011'46", an arc
length of 447.19 feet, and a chord which bears S 32052'28" W, a distance of 445.52 feet to an
iron rod with aluminum cap stamped "CORR-ROW" set 90.00 feet right of C.R. 112 Baseline
Station 111+87.83, in the existing northerly ROW line of said C.R. 112, for a point of non-
tangency;
THENCE, with the common line of said existing ROW, and said remainder of the 868.54 acre tract, the
following eight(8)courses:
41) S 60°14'28"W for a distance of 378.47 feet to a calculated angle point;
42) S 59°47'51" W for a distance of 734.98 feet to a calculated angle point,
43) S 59°45'42" W for a distance of 557.94 feet to a calculated angle point;
44) N 17°48'03" W for a distance of 20.48 feet to a calculated angle point;
45) S 59°45'42"W for a distance of 565.90 feet to a calculated angle point;
46) S 61°11'26" W for a distance of 668.35 feet to a calculated angle point;
47) S 60°05'03" W for a distance of 274.21 feet to a calculated angle point,
48) S 59-13'54" W for a distance of 189.54 feet to a calculated angle point, and from which a 112"
iron rod found bears S 19'22'05" E for a distance of 0.37 feet,
County: Williamson Page 5 of 10
Parcel : 4—Nelson Homestead 08-23-22
Highway: C.R. 112
49) THENCE, departing said existing ROW line, with the common line of said remainder of the
1,162,08 acre tract and said remainder of the 868.54 acre tract, S 77°06'26" W for a distance of
396.67 feet to the POINT OF BEGINNING, containing 20.586 acres (896,713 square feet) of
land, more or less.
This property description is accompanied by a separate parcel plat.
All bearings recited herein are based on the Texas State Plane Coordinate System, Central Zone No.
4203, NAD 83.
THE STATE OF TEXAS §
§ KNOW ALL MEN BY THESE PRESENTS
COUNTY OF WILLIAMSON §
That I, M. Stephen Truesdale, a Registered Professional Land Surveyor, do hereby certify that the above
description is true and correct to the best of my knowledge and belief and that the property described
herein was determined by a Survey made on the ground under my direct supervision.
WITNESS MY HAND AND SEAL at Round Rock, Williamson County, Texas.
Z/tA-4
M. Step en Tr esdale Date
Registered Professional Land Surveyor No. 4933
Licensed State Land Surveyor
Inland Geodetics, LLC OF
Firm Registration No: 100591-00 r�.•n1 r'.
1504 Chisholm Trail Road, Suite 103 0 `
Round Rock, TX 78681 ~r��
�µ.STEPHJN TRUESDALE
9 4933 f r
S:\HDR\CR 112\PARCELS\PARCEL MPARCEL 4-NELSON HOMESTEAD.doc / O,Esg`o��O
�"�SU
EXHIBIT
PLAT TO ACCOMPANY DESCRIPTION
DETAIL "A"
N.T.S. DETAIL 'F"
STA. 74+79.25 NELSON HOMESTEAD FAMILY N.T.S.
/ 141'34 LT PARTNERSHIP, LTD.
STA. 74+79.69 t3 REMAINDER PORTION
133.95' LT r 1,162.08 ACRES O
(EXHIBIT "A", 3)
DOC. NO. 199B024078
J O.R.W.C.T.
REMAINDER ORIGINAL 1,605.03 AC. TRACT
DESCRIBED IN VOL. 305, PG. 219 1 S19'22'05"E
68.54 AC. D.R.W.C.T. I C.R. 112 0.37
FP-o-B-l
NELSON HOMESTEAD vE
FAMILY
STA. 74+73.65 PARTNERSHIP, NELSON HOMESTEAD FAMILY 5, LTD. -�icE .356
127.57' LT 1 REMAINDER OF �� N0
GRID COORDINATES: l 868.54 ACRES REMAINDERRPORTIONP868D54 ACRES 3000 S1?
N=10,179,349.33 DOC. NO. 1998024076 pB
E=3,148,393.14 O.R.W.C.T. DOC. NO. 1998024076
` STA. 76+16.61 I O.R.W.C.T.
STA. 76+15.24 131.86' LT DESCRIBED IN
NELSON HOMESTEAD
150.20' LT STA. 76+57.40 VOL. 1133, PG. 639 O
92.00' LT O.R.W.C.T.
FAMILY 20.586 AC.
SEE DETAIL "A' STA 0' LT 25 896.713 S0. FT.
PARTNERSHIP, LTD. L3 —
REMAINDER OF 92.0o LT
� <s N60'16'34"E 1,669.66'
868.54 ACRES 1
DOC. NO. 1998024076 S>>�062g SEE DETAIL
F PROPOSED R.O.W.
TAIL " " ILI o
O.R.W.C.T. Q/ I1' 39 Z o
/� T6•oo 6 6� L31 80-02A 77 L30 A 35.00 +
o
.. ��.--N --
- .-R�1 1 2 (_1-u-R -nF aTH-VAR.-ES -
a
STING U)
- - R-0.W -------------------------- n
c X4STaN6-
al a
N0. DIRECTION DISTANCE _ ` D
L1 N09'07'44"E 8.79' �I -- ° NSIaL Sum
L2 N37'28'32"W 7.90' _LINE n` _ -
L3 N52'31'28"E 140.00' `
L4 S37'28'32"E 18.40'
L5 S79'42'03"E 74.21 NUMBER DELTA RADIUS LENGTH CHORD CHORD BEARING
L31 S60'05'03"W 274.21' Cl 1'29'03" 1592.00' 41.24' 41.24' N59'32'03"E
L31 S59'13'S4"W 189.54'
E(S
A N D
PARCEL PLAT SHOWING PROPERTY OF 08/23/2022
ETICS - NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. PARCEL 4
L LAND SU RVE�'O RS
M TRAIL RD.STE.103 20.586 AC.
OCK,TX.78681 896,713 S0. FT.
200,FAX(512)238-1251 SCALE PROJECT
ATION NO.100591-00 1" = 200' WILLIAMSON COUNT" CR 1 12 PAGE 6 OF 10
S:\-iDR-PROJECTS\CR112\PARCELS\PARCEL a- = SCN\PARCEL 4-NELS0N-PG6.awy
EXHIBIT
PLAT TO ACCOMPANY DESCRIPTION
NELSON HOMESTEAD FAMILY
PARTNERSHIP, LTD.
REMAINDER PORTION 868.54 ACRES R
��STI
DOC. NO. 1998024076 pE SU 56
O.R.W.C.T. Np 3
VOL. ESCRIBED 1133, PG.IN639 jo 455�RApT
O.R.W.C.T.
50'EASEMENT TO
SEMINOLE PIPELINE CO. 50'EASEMENT TO
VOL.640.PG.699 ENTERPRISE
D.R.W.C.T. CRUDE PIPELINE,L.L.C.
ADDITIONAL DOC.NO.2017003557
5'EASEMENT O.PR.W.C.T.
VOL.2169.PG.795 20.5 6 AC.
O.R AVv STA. 94+61.51 896,713 SQ. FT.
STA. 93+65.90 \\ 92.00 LT
00 ��
N60'16'34"E 1,669.66' 92. LT N 60'16'34"E 1,266.86'
cp STA. 94+84.27 PROPOSED R.O.W. O
O
STA. 93+88.66 47.81' LT w O
ZO 47.81 LT \- \ Z
J- 90+00 �� '95+A0 C.R. 112 ENGINEER'S BASELINE 100.00
�I_2=(mow-wt�t �� - - - - - - - - - - - — - - - - - ��
- --- — �- — - ��— EXISIN& R-0-:W.— —
_ - -
�\ o
NO. DIRECTION DISTANCE
L6 S56'58'10"E 49.70' m
L7 N60'16'34"E 95.61'
0
L8 N56'58'10"W 49.70' _ _
L29 N1T48'03'W 20.48' ' � F"slew su--� _Rv��INe _
I N L A N D ,
PARCEL PLAT SHOWING PROPERTY OF 08/23/2022
GEODETICS - NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. PARCEL 4
PROFESSIONAL LAND SURVEYORS ZO.586 AC.
1504 CHISHOLM TRAIL RD.STE.103
ROUND ROCK,TX.78681 896.713 SO. FT.
PH.(512)238-1200,FAX(512)238-1251 SCALE
FIRM REGISTRATION No.100597-00 1�� = 200' WILLIAMSON COUNTY CR PROJECT1 12 PAGE 7 OF 10
S:\-IDR-PROJ=CTS\CR112\PARC=:S\-ARC=, 4-N7_S0\\PARCEL 4-NE;S0\- .,a
EXHIBIT
PLAT TO ACCOMPANY DESCRIPTION
NO. DIRECTION DISTANCE �USTIGE SURVEY
L9 N34'14'45"W 20.00' JOHN L NO. 356
L10 S49'01'32"E 22.00' NELSON HOMESTEAD FAMILY ABSTRACT
XAIL '8" PARTNERSHIP, LTD.
N.T.S.
.r.s. L21 S24'16'34"W 342.37' REMAINDER PORTION 1162.08 ACRES o
L22 S20'43'37"E 42.42' o•° va
vJ• L23 S65'43'48"E 253.30' (EXHIBIT "A", 3)
R 0• DOC. NO. 1998024078
L24 S29'49'09"E 29.49' O.R.W.C.T. 6 ��00
PFt0905 L25 S60'18'18"W 80.00' ORIGINAL 1605.03 AC. TRACT pb, /
OLDr L26 N29-49'09"W 29.32' DESCRIBED IN VOL. 305, PG. 219
j SHED L27 N65'43'48'W 253.31' D.R.W.C.T. � -bb, �21
L28 S69'16'23"W 42.43' N? N. NE s N
�� STA. 123+10.40
%� �• PSE / G9�. 90.00' RT
STA 116+08.02 p� NG1N�2° \� \ STA. 122+80.41
20.586 AC. 90.00 LT ��2 y�F 120.00' RT
STA. 107+28.37 896,713 SQ. FT. o / ?,
STA. 112+00.00
9�OLT STA. 108+38.86 STA. 1' LT C� / � CR 112 SPUR
112.00' LT STA. 112+00.00 / �' ST.4. 121+64.40 < 9 STA. 14+73.64
N6p1G 90.00 LT ` 90.00' RT �� f 46.00 LT
0 1 266.86,E C2 C3 G4 / PRC S(SLk STA. 171+94.41 yc^
120.00' RT
NELSON HOMESTEAD FAMILY a
0= STA. 106+38.86 / PARTNERSHIP, LTD. a'
c2 92.00' LT SEE DETAIL "e" REMAINDER PORTION-868.54 ACRES e \
110.00 ,� DOC. NO. 1998024076 CR 112 SPUR
`-- - -"-- ;__4'-���J>�ig'y SHcO STA. 116+08.02 O.R.W.C.T. ; STA. 14+73.6a
90.00' RT DESCRIBED-IN ao.00' RT
_ 'EX/STING VOL. 1135 PG. 639 CR 112 SPUR
O.R.W.C.T. STA- 17+87.02 F
40.00 RT
Lc STA. 111+87.83 - �$ S60'18'18" PT .87 DETAI E,.E.
DETAIL "E" a - 90.00' RT X!$T W 9,3 p2
�M
CR 112 SPUR
17+e7.o2 NUMBER DELTA RADIUS
4..0 LENGTH CHORD CHORD BEARING
O 40. 0 LT CR 112 SPUR
t4. � C2 04'31'19" 1,308.00' 103.23' 103.21' N58'00'55"E srA- 18+16.34
CR 112 SPUR C3 14'46'47" 1,288.00' 332.25' 331.33' N48'21'52"E f 40.00' RT LLJ c l
N STA 18+16.52 C4 16'41'54" 1,310.00' 381.79' 380.44' N32'37'31"E AREA OF APPARENT R.O.W. qz
-1 40.0o LT C7 36'49'42" 530.00' 340.67' 334.84' S46'47'52"E OCCUPAT1oN FOR DRAINAGE, Qj *-
L25 RECORDAION NOT FOUND U-1Q1
C8 35'54'39" 460.00' 288.31' 283.61' N47'46'29"W Zia
C9 17*11'46" 1,490.00' 1 447.19' 1 445.52' S32"52'28' aC7 POE 20.,59 96-
PARCEL PLAT SHOWING PROPERTY 0- 08/23/2022
F1.1
AN D
DETICS - NELSON HOMESTEAD FAMILY PARTNERSHIP LTD. PARCEL 4
NAL LAND SURVEYORS 2�.586 AC:.
OLM TRAIL RD.STE.103896,713 SQ. FT.
D ROCK,TX.78681-1200,FAX(512)238-12S1 SCALEPROJECT
Fy►77pN:VO.100597-00 11 1" = 200' WILLIAMSON COUNTY CR 112 1 PAGE 8 OF 101
S:\-iDR-PROJECTS\CR112\PARCFLS\PARCF, \FISON\PaPCFL A-NELSON-°C8.awc
EXHIBIT
PLAT TO ACCOMPANY DESCRIPTION
NO. DIRECTION DISTANCE
L11 N24'16734"E 1,044.76'
L12 N68'59'08"E 162.81'
NUMBER DELTA RADIUS LENGTH I CHORD CHORD BEARING L13 N23'45'38"E 56.35'
C5 44'42'34" 1,290.00' 1,006.62' 981.27' N46'37'51"E L14 N21'27'52"W 14.77'
C6 44'42'34" 1,110.00' 866.16' 1 844.35' S46'37'51"W L15 N68'32'08"E 12.00'
L16 S68'32'08"W 12.00'
L17 N21'27'52"W 19.71'
L18 N66'14'22"W 56.79'
STA. 137+91.66 L19 S68'59'08"W 164.22'
Z` \ STA. 135+89.17 130.00' LT L20 S24'16'34"W 342.37'
90.00' LT
C5 PROPOSED R . 0 STA. 1 37+51.98 DETAIL "C"
STA. 126+52.78 W 90.00' LT / STA. 137+91.55 N.T.S.
90.00' L- 44.77' LT
01 N'tE�'130P�E F," -_�,.. .. 02 1� ' DETAIL "C'
v, .C,S
C6 PROPQSED
::R Q' W \ 4,j� ��3 V
STA. 190 009 RT A 09 <i N ^ ~\T': �fRy O N
20.586 AC. 4p•00 NEB
O� DQ N STA. 126+52.75 896,713 SQ. FT. I STA 137+53.39 �cV `, \- S�/V P
o V 90.00' RT 90.00' RT
s? / STA. 137+93.70 DETA L "D' \
130.00' RT
STA. 137+93.58
NELSON HOMESTEAD FAMILY I
PARTNERSHIP, LTD. 149.59' RT
REMAINDER PORTION 868.54 ACRES NELSON HOMESTEAD c N STA. 138+05.86 DETAIL
DOC. N0, 1998024076 FAMILY 149.61' RT N.T.S.
O.R.W.C.T. I PARTNERSHIP, LTD. W rC'V
DESCRIBED IN REMAINDER PORTION �
VOL. 1133, PG. 639 1,162.08 ACRES z Q o cp
O.R.W.C.T. (EXHIBIT "A", 3) `� vCID
DOC. NO. 1998024078 a
SURVEY I O.R.W.C.T. �3 �' cy
ABE J ACT USTICE 356 / ORIGINAL v k
JO N0. 1,605.03 AC. TRACT 3 4 L16
gTR DESCRIBED IN
VOL. 305, PG. 219
D.R.W.C.T.
INLAND
PARCEL PLAT SHOWING PROPERTY OF 08/23/2022
' =
GEODETICS - NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. PARCEL 4
PROFESSIONAL LAND SURVEYORS 20.5
1504 CHISHOLM TRAIL RD.STE.103 86 AC.
896,71320.5 SQ. Ff.
ROUND ROCK,TX.78681
PH.(5'2)238-1200,FAX(512)238-1251 SCAL= PROJECT
FIRM REGISTRATION NO.100591-00 1" _ 200' WILLIAMSON COUNTY CR 1 2 PAGE 9 OF 1 D
...'.>CTS\CR112\3ARC=..S\�ARCF_. 4-N= 4-N=-SO4-"G9k1C.Owc
EXHIBIT
LEGEND PLAT TO ACCOMPANY DESCRIPTION
60D NAIL FOUND LINE BREAK
Q. 1/2 " IRON ROD W/ ALUMINUM CAP —� DENOTES COMMON OWNERSHIP
STAMPED "WILCO—ROW" FOUND P.O.B. POINT OF BEGINNING
O IRON ROD WITH ALUMINUM CAP
STAMPED "CORR—ROW" SET ( } RECORD INFORMATION
IRON ROD WITH PLASTIC CAP P.R.W.C.T. PLAT RECORDS
WILLIAMSON COUNTY, TEXAS
FOUND -- AS NOTED D.R.W.C.T. DEED RECORDS
1/2" IRON ROD FOUND WILLIAMSON COUNTY, TEXAS
IE TxDOT TYPE II CONCRETE O.R.W.C.T. OFFICIAL RECORDS
MONUMENT FOUND WILLIAMSON COUNTY, TEXAS
0 CALCULATED POINT O.P.R.W.C.T. OFFICIAL PUBLIC RECORDS
PROPERTY LINE WILLIAMSON COUNTY, TEXAS
1) All bearings shown hereon ore based on grid bearing. All distances are surface distances. Coordinates are surface values based on the Texas State Plane
Coordinate System, NAD 83, Central Zone.
THE SURVEY SHOWN HEREON WAS PREPARED IN CONJUNCTION WITH THAT COMMITMENT FOR TITLE INSURANCE GF NO. GT2200988, ISSUED BY TEXAN TITLE INSURANCE
COMPANY, EFFECTIVE DATE JULY 22, 2022, ISSUE DATE AUGUST 3, 2022.
10C. PIPELINE EASEMENT GRANTED TO LONE STAR GAS COMPANY AS SET OUT IN VOLUME 238, PAGE 184, OF THE DEED RECORDS OF WILLIAMSON COUNTY TEXAS,
(AS IT PERTAINS TO TRACT 1 ONLY), DOES NOT AFFECT.
D. RIGHT—OF—WAY AND PIPELINE EASEMENT GRANTED TO SEMINOLE PIPELINE COMPANY, AS SET OUT IN VOLUME 840, PAGE 699, OF THE DEED RECORDS OF WILLIAMSON
COUNTY, TEXAS; SUPPLEMENTED BY THAT CERTAIN SUPPLEMENTAL PIPELINE RIGHT—OF—WAY AGREEMENT, AS SET OUT IN VOLUME 2169, PAGE 795, OF THE DEED
RECORDS OF WILLIAMSON COUNTY, TEXAS, (AS IT PERTAINS TO TRACT 3 ONLY), AFFECTS AS SHOWN.
E. NON—EXCLUSIVE PIPELINE EASEMENT AGREEMENT GRANTED TO ENTERPRISE CRUDE PIPELINE, LLC, AS SET IN INSTRUMENT(S) FILED FOR RECORD UNDER WILLIAMSON
CLERK'S FILE NO. 2017003557; FURTHER STIPULATED IN THAT CERTAIN MEMORANDUM OF MERGER, AS SET IN INSTRUMENT(S) FILED FOR RECORD UNDER WILLIAMSON
CLERK'S FILE NO. 2020082921, (AS IT PERTAINS TO TRACT 3 ONLY), AFFECTS AS SHOWN.
I HEREBY CERTIFY THAT THIS PLAT IS TRUE AND
CORRECT AND THAT THE PROPERTY SHOWN HEREON
WAS DET INE4 BY A SURVEY MAD 0 THE
G Z DER MY DJ SUPERVI I OF
M. ST16PTFIEN fRUESDALF DATE .� ��"�•"'
REGISTERED PROFESSIONAL a"M.STEPHENT'!Lt �
LAND SURVEYOR NO. 4933 `�:o••g f
LICENSED STATE LAND SURVEYOR 90 dr�
INLAND GEODETICS, LLC iy °E49� �-�
FIRM REGISTRATION NO. 100591-00 !77!ll���������, Q s+u�
1504 CHISHOLM TRAIL ROAD, SUITE 103
ROUND ROCK, TEXAS 78681
I N LAN D ..
PARCEL PLAT SHOWING PROPERTY OF 08/23/2022
GEODETICS = NELSON HOMESTEAD FAMILY PARTNERSHIP LTD. PARCEL 4
PROFESSIONAL LAND SURVEYORS 2�..
1 504 CHISHOLM TRAIL RD.STE. 103 6 AC.89 20.5 SQ. FT.
ROUND ROCK,TX.78681
PH.(512)238-1200,FAX(512)238-1251 SCALE
FIRM REGIS7RAT1ON NO.100591 00 1" _ 200' WILLIAMSON COUNTY �OJ1E 2 PAGE 10 OF 10
PARCEL NO. 5
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 1 of 9
POSSESSION AND USE AGREEMENT FOR TRANSPORTATION PURPOSES
STATE OF TEXAS §
§ Parcel No.: 5
COUNTY OF WILLIAMSON § Project: CR 112
This Possession and Use Agreement For Transportation Purposes (the "Agreement") between CITY OF
ROUND ROCK, TEXAS ("Grantee"), and NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD.,
a Texas limited partnership (the "Grantor" whether one or more), grants to the Grantee, its contractors,
agents and all others deemed necessary by the Grantee, an irrevocable right to possession and use of the
Grantor's property for the purpose of constructing improvements to CR 112 and related utility
adjustments (the "Project"). The property subject to this Agreement is described more fully in field
notes, plat map or other description (attached as "Exhibit A") and made a part of this Agreement by
reference (the"Property").
1. For the consideration from the Grantee which is set forth in Paragraph 2 below, the receipt and
sufficiency of which is acknowledged, the Grantor grants, bargains, and conveys to Grantee the right
of entry and exclusive possession and use of the Property for the purpose of constructing a roadway,
utility adjustments and all related appurtenances thereto and the right to remove any improvements
thereon. Authorized activities on the Property include surveying, inspection, environmental studies,
archeological studies, clearing, demolition, construction of permanent improvements, relocating,
replacing, and improving existing utility facilities, locating new utility facilities, and other work
required to be performed in connection with the Project. This Possession and Use Agreement will
extend to the Grantee, its contractors and assigns, providers of any existing utilities on the Property
and those which may be lawfully permitted on the Property by the Grantee in the future, and all
others deemed necessary by the Grantee for the purpose of the Project. This grant will allow the
construction, relocation, replacement, repair, improvement, operation and maintenance of utilities on
the Property only.
2. In consideration for this irrevocable grant of possession and use and other Grantor covenants,
warranties, and obligations under this Agreement, the Grantee will tender to the Grantor the sum of
ONE HUNDRED TWENTY-FIVE THOUSAND THREE HUNDRED NINETY-THREE and
00/100 Dollars ($125,393.00). The Grantor agrees that this sum represents 90% of the amount that
Grantee has determined constitutes adequate and full compensation for the possession and use of the
Property. Grantee will be entitled to take possession and use of the Property upon tender of payment
as set out herein, subject to the conditions in Paragraph 14 below, if any. The parties agree that the
sum tendered represents 90% of the Grantee's approved value, which assumes no adverse
environmental conditions affecting the value of the Property. The approved value is the Grantee's
determination of the just compensation owed to the Grantor for the real property interest to be
acquired by the Grantee in the Property, encumbered with the improvements thereon, if any, and
damages to the remainder, if any, save and except all oil, gas and sulphur. The parties agree that the
sum tendered to Grantor will be deducted from any final settlement amount, Special Commissioners'
award or court judgment. In the event the amount of the final settlement or judgment for acquisition
of the Property is less than the amount the Grantee has paid for the possession and use of the
{.00080672.1J
II I I II I II I II
* N P U A
Forth ROW-N-PUA
(12/12)
Replaces Forth ROW-N-7
Page 2 of 9
Property, then the Grantor agrees that the original amount tendered represents an overpayment for
the difference and, upon written notice from the Grantee, the Grantor will promptly refund the
overpayment to the Grantee. In the event the amount of the final settlement or court judgment for
acquisition of the Property is greater than the amount Grantee has paid for the possession and use of
the Property under this Paragraph 2, Grantee will remit the underpayment to Grantor when required
under the final settlement or court judgment.
3. The effective date of this Agreement will be the date on which payment pursuant to Paragraph 2
above was tendered to the Grantor by the Grantee, or delivered by Grantee to a title company acting
as escrow agent for the transaction, with unconditional instructions to such escrow agent to
immediately release such payment to Grantor upon escrow agent's confirmation that no liens or
other monetary encumbrances affect the Property (the"Effective Date").
4. The Grantor warrants and represents that, to Grantor's actual knowledge, the title to the Property is
free and clear of all monetary liens and encumbrances except as disclosed to Grantee in that certain
title commitment numbered GF#202301512 dated effective June 8, 2023 issued by Heritage Title
Company of Austin Inc., as agent for First American Title Insurance Company, and that proper
releases will be executed for such liens and encumbrances (if any) prior to funds being disbursed
under this Agreement. The Grantor further warrants that no other person or entity owns (or, to
Grantor's knowledge, claims) an interest in the fee title to the Property and further agrees to
indemnify the Grantee from all unrelated or undisclosed liens or other monetary encumbrances
affecting the Property.
5. The parties agree that the valuation date for determining the amount of just compensation for the real
property interest proposed to be acquired by the Grantee in the Property, for negotiation or eminent
domain proceeding purposes, will be the Effective Date of this Agreement.
6. This Agreement is made with the understanding that the Grantee will continue to proceed with
acquisition of a real property interest in the Property. The Grantor reserves all rights of
compensation for the title and other interest in and to the Property which the Grantor holds as of the
time immediately prior to the Effective Date of this Agreement. This Agreement shall in no way
prejudice the Grantor's rights to receive full and just compensation as allowed by law for all of the
Grantor's interests in and to the Property to be acquired by the Grantee, encumbered with the
improvements thereon, if any, and damages, if any, to the remainder of the Grantor's interest in any
larger tract of which the Property is a part (the "Remainder"), if any; all as the Property exists on the
Effective Date of this Agreement. The Grantee's removal or construction of improvements on the
Property shall in no way affect the fair market value of the Property in determining compensation
due to the Grantor in the eminent domain proceedings. This grant will not prejudice the Grantor's
rights to any relocation benefits for which Grantor may be eligible.
7. In the event the Grantee institutes or has instituted eminent domain proceedings, the Grantee will not
be liable to the Grantor for interest upon any award or judgment as a result of such proceedings for
any period of time prior to the date of the award. Payment of any interest may be deferred by the
Grantee until entry of judgment.
8. The purpose of this Agreement is to allow the Grantee to proceed with its Project without delay and
to allow the Grantor to avoid proceeding with condemnation litigation at the current time and
(.00080672.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 3 of 9
continue voluntary investigation and negotiation for the proposed Property acquisition. The Grantor
expressly acknowledges that the proposed Project are for a valid public use and voluntarily waives
any right the Grantor has or may have, known or unknown, to contest the jurisdiction of the court in
any condemnation proceeding for acquisition of the Property related to the Project, based upon
claims that the condemning authority has no authority to acquire- the Property through eminent
domain, has no valid public use for the Property, or that acquisition of the Property is not necessary
for the public use.
9. The Grantor reserves all of the oil, gas and sulphur in and under the land herein conveyed but waives
all right of ingress and egress to the surface for the purpose of exploring, developing, mining or
drilling. The extraction of oil, gas and minerals may not affect the geological stability of the surface.
Nothing in this reservation will affect the title and rights of the Grantee to take and use all other
minerals and materials thereon, and thereunder.
10. The undersigned Grantor agrees to pay as they become due, all ad valorem property taxes and
special assessments assessed against the Property until the Effective Date, including prorated taxes
until the Effective Date for the year in which the Grantee takes title to the Property. Grantor shall
have no liability for ad valorem property taxes and special assessments assessed against the Property
for any period after recording of a memorandum of this Agreement.
11. Notwithstanding the acquisition of right of possession to the Property by the Grantee in a
condemnation proceeding by depositing the Special Commissioners' award into the registry of the
court, less any amounts tendered to the Grantor pursuant to Paragraph 2 above, this Agreement shall
continue to remain in effect until the Grantee acquires title to the Property either by agreed final
settlement, or final court judgment, whereupon this Agreement shall automatically terminate.
12. This Agreement will also extend to and bind the heirs, devisees, executors, administrators, legal
representatives, successors in interest and assigns of the parties.
13. It is agreed that Grantee will record a memorandum of this Agreement on or about the Effective
Date in the property records of the county in which the Property is located, evidencing the existence
of this Agreement. The Agreement itself will not be recorded. The memorandum will not contain
any information regarding the consideration paid or to be paid to Grantor by Grantee and will
otherwise be in a form mutually acceptable to Grantor and Grantee. The recording of the
memorandum will not modify the terms of this Agreement. Upon termination of this Agreement for
any reason, either Grantor or Grantee may record an affidavit in the county property records
evidencing such termination.
14. Other conditions: See Addendum attached hereto and made a part hereof.
15. By its authorized signature below the following Tenants which have a leasehold interest in the
Property hereby consent in all things to Grantee taking exclusive and sole possession of the Property
pursuant to the terms of this Agreement, and to Grantor receiving the consideration recited herein:
Tenant: Davidson Brothers
(.00080672.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 4 of 9
At no time during the possession of the Property by Grantee for the purposes described herein shall
Grantor or Tenant be denied reasonable access and/or ingress to or egress from the Remainder for its
current uses without prior advance agreement between Grantor and Grantee.
To have and to hold the Agreement herein described and conveyed, together with all the rights and
appurtenances belonging to the Grantee and its assigns forever, for the purposes and subject to the
limitations set forth above.
[signature pages follow]
{.00080672.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 5 of 9
GRANTOR:
NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD.,
a Texas limited partnership
By: Nelson Homestead Management, L.L.C.,
its general partner
By: G
Name: C. Nelson
Title: Manager
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF TK-AViS
This instrument was acknowledged before me on this the 2-6-day of August, 2023 by John C.
Nelson, Manager of Nelson Homestead Management, L.L.C., the general partner of Nelson Homestead
Family Partnership, Ltd., in the capacity and for the purposes and consideration recited herein.
Gloria A Velasquez � 9
O
*; Notary Public,State of Texas
con.EXOm 01/03/2024 Notary Public, State of texas
Notary ID UWiow Printed Name-A IDrt•.— Vtlws&-(Atz
oa-•
My Commission Expires: o 1/0 3`Aas Y
(.00080672.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 6 of 9
TENANT:
Davidson Brothers
By:
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OFIA/iwwA usooJ
This instrument was acknowledged before me on this the A5- day of August, 2023 by
DExK is L • Db yr p So,), in the capacity and for the purposes and consideration recited herein.
o� Y P�BG Gloria A VElasquez 1/!�l✓�
2, c+
•: * Notary Public,State of Texas
c.«rH,,.Expires 01/03/2024 T s
Notary ID+28e4to9.3 Notary Public, State f ,
Printed Name:6z�oKic, Y06.504A-&L
My Commission Expires: a!/031V2-q'
.00080672.t}}
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 7 of 9
GRANTEE:
CITY OF ROUND ROCK, TEXAS
By: �4 M I
Craig Mdgan, M r
ACKNOWLEDGMENT
STATE OF TEXAS
COUNTY OF WILLIAMSON
LL
This instrument was acknowledged before me on this the f day o , 2023 by
Craig Morgan, in the capacity and for the purposes and consideration recited herein.
PG A N Sp%,�
Notary P 'c, Sta of Tex •
Printed Name:
My Commission Ex res p /29/24pOF !
1.00080672.1))
Forth ROW-N-PUA
(12/12)
Replaces Forth ROW-N-7
Page 8 of 9
ADDENDUM TO POSSESSION AND USE AGREEMENT FOR TRANSPORTATION PURPOSES
This Addendum to Possession and Use Agreement For Transportation Purposes (this
"Addendum") is made a part of, and is to be read in conjunction with, the attached Agreement. Unless
otherwise defined in this Addendum, all capitalized terms used shall have the meaning given to them in
the Agreement. In the event of any conflict or inconsistency between the terms and provisions of this
Addendum and those contained in the Agreement, the terms and provisions of this Addendum shall
control and govern.
1. Grantee shall construct the Project substantially in accordance with those certain plans
and specifications dated August 4, 2023 (currently at 95% submission level), prepared by HDR
Engineering, Inc., and any subsequent comments, revisions or updates approved by Grantee for final
project bidding and permitting, and any subsequent change orders approved during construction,
provided that in all events the Project will not change to result in the abandonment of the eastern portion
of existing CR 112 between Ponce De Leon Pass and CR 110 without the prior written consent of
Grantor. Grantee shall use its best efforts to notify Grantor of any subsequent revisions, updates or
change orders to such plans and specifications that could materially affect future use and development of
the Remainder, such as changes related to road alignment, access points, median breaks/turn-in lanes,
drainage and utilities(including stubs and connections).
2. Grantor and Grantee acknowledge that Grantee has made an offer to Grantor for the
acquisition of the Property based on Grantee's approved value and that Grantor intends to submit a
counteroffer to Grantee. If Grantor and Grantee fail to reach a final agreed settlement for Grantee's
acquisition of the Property within 60 days after the date Grantor submits a counteroffer to Grantee,
Grantor may, at its option, at any time thereafter, notify Grantee that it desires that Grantee initiate
condemnation proceedings for the Property. Within 30 days after receipt of such notice from Grantor,
Grantee will undertake to complete any final prerequisites to filing of a condemnation suit as required by
the Texas Property Code, Chapter 21, and as soon as reasonably possible thereafter (and in any event
within 90 days after receipt of such notice from Grantor), shall initiate condemnation proceedings and
will seek to schedule a Special Commissioners' hearing at the earliest possible date. Grantee covenants
that it will take all procedural steps necessary to ensure that the hearing is held in a timely manner and
without any delays caused by Grantee. Grantee agrees to deposit the award of the Special
Commissioners in the registry of the court within 60 days of the date that the Special Commissioners'
award is filed with the court.
3. Grantee agrees to conduct its Project-related activities on the Property in a manner that
avoids or minimizes interference with and interruption of any tenant's operations on the Remainder
(including avoiding loss of or injury to livestock) to the extent reasonably possible. If any such activities
will impact a tenant's operations, Grantee shall coordinate same in advance with such tenant. In no event
shall any existing fence located on the Property be removed, cut, modified, or otherwise damaged by
Grantee or its contractors within thirty (30) days following the Effective Date, by which time Grantor
shall have completed installation of new perimeter fencing for the Remainder at such location. In no
event shall any such new fence be removed, cut, modified, or otherwise intentionally damaged by
Grantee or its contractors without the prior written approval of Grantor and Tenant,which approval shall
not be unreasonably withheld or delayed. In addition, if Grantor or any tenant of Grantor requests that
Grantee, as part of Grantee's acquisition of the Property or the conduct of its Project-related activities on
(.00080672.1))
Form ROW-N-PUA
(12/12)
Replaces Form ROW-N-7
Page 9 of 9
the Property, reasonably cooperate with Grantor or such tenant as necessary for carrying out the existing
agricultural and ranching operations on the Remainder and/or continuously maintaining all existing
Agriculture Use ad valorem tax exemptions on Remainder tracts, Grantee agrees to do so.
4. To the extent allowed by law, Grantee will be liable for all damage or injury to persons or
property resulting from the activities of Grantee, its agents, employees, contractors, subcontractors, or
other parties in coming upon or about the Property in connection with Grantee's activities upon the
Property under this Agreement, including but not limited to losses or expenses incurred by Grantor or
Tenant due to unauthorized damage caused by Grantee or its contractors to any fencing, livestock,
growing crops or property of Grantor, Tenant or their respective agents or employees. Grantee will also
promptly discharge any lien claim filed against the Remainder that arises out of the Project. Specifically
without waiving any available governmental immunity, Grantee acknowledges and agrees that Grantor
shall be allowed to seek any existing legally available remedies for any damages incurred by Grantor
due to Grantee's breach of this Agreement.
5. Grantee will obtain, and maintain in full force and effect, at all times during the term of
this Agreement, and will require each of its contractors and assignees to obtain and maintain in effect at
all times during which such contractors or assignees are performing work on or within the Property, a
policy or policies of insurance, in at least the minimum amounts that Grantee typically requires of its
contractors for work similar to the Project. Such liability insurance shall provide that it may not be
canceled without at least 30 days written notice to Grantor. Grantee shall provide a certificate of
insurance evidencing the required coverage to Grantor prior to Grantee or the contractor or assignee in
question entering upon or commencing any construction activity on the Property.
{.00080672.1})
County: Williamson Page 1 of 4
Parcel : 5— Nelson Homestead 08-23-22
Highway: C.R. 112
EXHIBIT A
PROPERTY DESCRIPTION
DESCRIPTION OF A 0.305 ACRE (13,269 SQUARE FOOT) PARCEL OF LAND SITUATED IN THE
JOHN L. JUSTICE SURVEY, ABSTRACT NO. 356 AND THE WILLIS DONAHOE SURVEY, ABSTRACT
NO 173 IN WILLIAMSON COUNTY, TEXAS, BEING A PORTION OF A REMAINDER OF THAT
CALLED 868.54 ACRES OF LAND IN SPECIAL WARRANTY DEED TO NELSON HOMESTEAD
FAMILY PARTNERSHIP, LTD. RECORDED IN DOCUMENT NO. 1998024076 OF THE OFFICIAL
RECORDS OF WILLIAMSON COUNTY, TEXAS, AND DESCRIBED IN VOLUME 1133, PAGE 639 OF
THE DEED RECORDS OF WILLIAMSON COUNTY TEXAS., SAID 0.305 ACRE (13,269 SQUARE
FOOT) PARCEL OF LAND BEING MORE PARTICULARLY DESCRIBED BY METES AND BOUNDS AS
FOLLOWS:
BEGINNING at an iron rod with aluminum cap stamped "CORK-ROW" set 82.58 feet right of County
Road (C.R.) 112 Baseline Station 72+50.00 (Grid Coordinates determined as N=10,179,049.77
E=3,148,326.63), in the existing southerly Right-of-Way (ROW) line of C.R. 112 (variable width ROW),
same being the common boundary line of said remainder portion of the 868.54 acre tract, for the most
northwesterly corner and POINT OF BEGINNING of the herein described parcel, and frorn which a 1/2"
capped iron rod found at the southeasterly intersection of C.R. 117 (variable width ROW) and said C.R.
112, being the northwesterly corner of the remainder of that called 27.03 acre tract described in Special
Warranty Deed to Nelson Homestead Family Partnership, LTD, recorded in Document No. 9828296 of
the Deed Records of Williamson County Texas, bears, S 54°53'55" W at a distance of 207.13 feet to a
calculated angle point, thence S 52°57'09"W at a distance of 183.23 feet,
1) THENCE, with said common line, N 54°53'55" E for a distance of 261.11 feet to calculated point,
being the northwesterly corner of a remainder portion of that called 92.18 acre tract described in a
Special Warranty Deed to North Paloma Lake Development, Inc. recorded in Document No.
2014004361 of the Official Public Records of Williamson County, Texas, for the northeasterly
corner of the herein described parcel,
2) THENCE, with the common line of said remainder portion of that called 92.18 acre tract and of
said remainder portion of the 868.54 acre tract, S 37°25'23" E for a distance of 176.39 feet to an
iron rod with aluminum cap stamped "CORR-ROW" set 254.90 feet right of C.R. 112 Baseline
Station 75+20.78, in the proposed ROW line of said C.R. 112 (variable width ROW), for the
southeasterly corner of the herein described parcel;
THENCE, departing said remainder portion of that called 92.18 acre tract, through the interior of said
remainder of the 868.54 acre tract, with the proposed southerly ROW line of C.R. 112, the following five
(5) courses:
3) S 52°31'28" W for a distance of 19.27 feet to an iron rod with aluminum cap stamped "CORR-
ROW° set 255.98 feet right of C.R 112 Baseline Station 75+01.55, for an angle point;
4) N 37°28'32" W for a distance of 82.20 feet to an iron rod with aluminum cap stamped "CORR-
ROW" set 173.91 feet right of C.R. 112 Baseline Station 74+96.95, for an angle point;
5) N 80°52'16" W for a distance of 87.20 feet to an iron rod with aluminum cap stamped "CORR-
ROW° set 114.00 feet right of C.R. 112 Baseline Station 74+33.59, for an angle point;
6) S 55°44'01" W for a distance of 183.59 feet to an iron rod with aluminum cap stamped "CORR-
ROW° set, 114.00 feet right of C.R. 112 Baseline Station 72+50.00, for an angle point:
County: Williamson Page 2 of 4
Parcel : 5—Nelson Homestead 08-23-22
Highway: C.R. 112
7) N 34015'59" W for a distance of 31.42 feet to the POINT OF BEGINNING.containing 0.305 acres
(13,269 square feet)of land, more or less.
This property description is accompanied by a separate parcel plat.
All bearings recited herein are based on the Texas State Plane Coordinate System, Central Zone No.
4203, NAD 83,
THE STATE OF TEXAS §
§ KNOW ALL MEN BY THESE PRESENTS:
COUNTY OF WILLIAMSON §
That I. M. Stephen Truesdale, a Registered Professional Land Surveyor, do hereby certify that the above
description is true and correct to the best of my knowledge and belief and that the property described
herein was determined by a survey made on the ground under my direct supervision.
WITNESS MY HAND AND SEAL at Round Rock, Williamson County, Texas.
M. Stephen Truesdale Date
Registered Professional Land Surveyor No 4933
Licensed State Land Surveyor OF
Inland Geodetics, LLC f .•�6 re*
11Z
Firm Registration No: 100591-00 fi t•° .A„ ge..
1504 Chisholm Trail Road, Suite 103 ............................
Round Rock, TX 78681 M.STEPHEN myFsN
•493•3•• P 3Q'
'o
°%'-'0
.��`t
S:\HDRICR 112\PARCELS\PARCEL 5\PARCEL 5-NELSON HOMESTEAD.doc �y� r.....•'
sua
EXHIBIT
PLAT TO ACCOMPANY DESCRIPTION
NO. DIRECTION i DISTANCE
L1 S52'31'28"W 19.27' _`-
L2 N37'28'32"W 82.20'
L3 N80'52'16"W 87.20'
L4 S55'44'01"W 183.59'
L5 N34'15'59"W 31.42' �-
JUST�C�O 356
HN L AC� / SIBASELINE,5+00 iW_
sO C.
R• 11tNEEa' \NG RO.R•-.���pR\ESA I
P.O.B. -R.0 w
STA. 72+50.00 _
EX
1'
_r 5
RIDoCOORII9 TES. �54753'55°E
70 E=3,,48,326.63 E� �
4
STA. 74+33.59
LTE19eLE SURVEY LINE 554 53 55�1.. --= - Lr - 114.00' RT. <3 c�
STA. 72+50.00 5
Q9 114.00 STA. 74+96.95 -1
557.5�, \ 0.30 AC. 173.91' RT N .LA
13,269 SQ. FT. do
• DOC.N0, g828296� -� �_ NELSON HOMESTEAD FAMILY STA. 75+20.78
PARTNERSHIP, LTD. L 254.90' RT
w REMAINDER OF 868.54 ACRES STA. 75+01.5s
o \ DOC. NO. 1998024076 255.98" Rr 1
c NELSON HOMESTEAD FAMILY O.R.W.C.T.
�= DESCRIBED IN
o PARTNERSHIP, LTD \VOL. 1133, PG. 639
3 ? (REMAINDER OF 27.03 AC.) NORTH PALOMA LAKE
U N D.R.W.C.T.
DOC. NO. 9828296 Y � 1 DEVELOPMENT, INC.
p w O.R.W.C.T. UP, 1.52 AC.
ON
\S 001,A-pN0 j13 ' OF CALLEEDR92.18 AC.)
�IL�A�STR DOC. . W 2014004361
0
C8/23 2022
I N AN ID PARCEL PLAT SHOWING PROPERTY 07
L .
GEODETICS NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. P030c5AC.
7 SO4 CNEWIOLN TRAR RD.SrL 103
ROUND Roar,TX.70601 SCALE 13,269 SQ. FT.
FIRM't RE@STRATION No.,00591 1-00 1" = 100' WIL'JAMSON COUNTY ni PROJECT
cR •12 PAGE 3 OF 4
S:\H7)R—PROJECTS\CR112\PARCELS\PARCEL 5—\ELSON\PARCEL 5—NELSON.dwg
EXHIBIT
LEGEND PLAT TO ACCOMPANY DESCRIPTION
IRON ROD WITH ALUMINUM CAP DENOTES COMMON OWNERSHIP
STAMPED "CORR—ROW" SET P.O.B. POINT OF BEGINNING
p IRON ROD WITH PLASTIC CAP ( ) RECORD INFORMATION
FOUND — AS NOTED P.R.W.C.T. PLAT RECORDS
• 1/2" IRON ROD FOUND WILLIAMSON COUNTY, TEXAS
p TxDOT TYPE II CONCRETE D.R.W.C.T. DEED RECORDS
MONUMENT FOUND WILLIAMSON COUNTY, TEXAS
O.R.W.C.T. OFFICIAL RECORDS
CALCULATED POINT WILLIAMSON COUNTY, TEXAS
F� PROPERTY LINE O.P.R.W.C.T. OFFICIAL PUBLIC RECORDS
r LINE BREAK WILLIAMSON COUNTY, TEXAS
1) All bearings shown hereon are based on grid bearing. All distances are surface distances. Coordinates are surface values based on the Texas State
Plane Coordinate System, NAD 83, Central Zone.
THE SURVEY SHOWN HEREON WAS PREPARED IN CONJUNCTION WITH THAT COMMITMENT FOR TITLE INSURANCE GF NO. GT2200988, ISSUED BY TEXAN TITLE
INSURANCE COMPANY, EFFECTIVE DATE JULY 22, 2022, ISSUE DATE AUGUST 3, 2022.
10C. PIPELINE EASEMENT GRANTED TO LONE STAR GAS COMPANY AS SET OUT IN VOLUME 238, PAGE 184, OF THE DEED RECORDS OF WILLIAMSON COUNTY
TEXAS, (AS IT PERTAINS TO TRACT 1 ONLY), DOES NOT AFFECT.
D. RIGHT—OF—WAY AND PIPELINE EASEMENT GRANTED TO SEMINOLE PIPELINE COMPANY, AS SET OUT IN VOLUME 840, PAGE 699, OF THE DEED RECORDS
OF WILLIAMSON COUNTY, TEXAS; SUPPLEMENTED BY THAT CERTAIN SUPPLEMENTAL PIPELINE RIGHT—OF—WAY AGREEMENT, AS SET OUT IN VOLUME 2169,
PAGE 795, OF THE DEED RECORDS OF WILLIAMSON COUNTY, TEXAS, (AS IT PERTAINS TO TRACT 3 ONLY), DOES NOT AFFECT.
E. NON—EXCLUSIVE PIPELINE EASEMENT AGREEMENT GRANTED TO ENTERPRISE CRUDE PIPELINE, LLC, AS SET IN INSTRUMENT(S) FILED FOR RECORD UNDER
WILLIAMSON CLERK'S FILE NO. 2017003557; FURTHER STIPULATED IN THAT CERTAIN MEMORANDUM OF MERGER, AS SET IN INSTRUMENT(S) FILED FOR
RECORD UNDER WILLIAMSON CLERK'S FILE NO. 2020082921, (AS IT PERTAINS TO TRACT 3 ONLY), DOES NOT AFFECT.
I HEREBY CERTIFY THAT THIS PLAT IS TRUE AND
CORRECT AND THAT THE PROPERTY SHOWN HEREON
WAS DET INED BY A SURVEY MADE 0 THE y
GR D D MY C SUPE ISI �'0+S T E
M. ST•PN N TRUESDALE DATE 1 M.STEPMENTAU'ESMA
REGISTERED PROFESSIONAL
LAND SURVEYOR NO. 4933
LICENSED STATE LAND SURVEYOR �i� "ESSNO
INLAND GEODETICS, LLC O S',1R
FIRM REGISTRATION NO. 100591-00
1504 CHISHOLM TRAIL ROAD, SUITE 103
ROUND ROCK TEXAS 7AA 1 08/23/2022
39 I N LAND
PARCEL PLAT SHOWING PROPERTY OF GEOID PARCEL 5ETICS_ NELSON HOMESTEAD FAMILY PARTNERSHIP, LTD. 0.305 AC.
�Ro.�loOM UM.0 RD ST 10 13,269 $Q. .
ISOa CHISHOIM TRAIL RD STC.103
ROUND ROCK.TX.76661 SCALE PROJECT
vl.Rlz:ne-Izoo,ru(sl:):3a-Izsl WILLIAMSON COUNTY
FIRM RkimnoN No-i6osv:-oo 1" = 100' CR 112 PAGE 4 OF 4
S:\HDR—PROJECTS\CR1'.2\PARCELS\PARCEL 5—NELS0N\PARCEL 5—NELSONA.9