Loading...
R-2024-346 - 12/19/2024 RESOLUTION NO. R-2024-346 WHEREAS, the City of Round Rock entered into a contract on December 21, 2023 with SpawGlass Contractors, Inc., entitled "Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of Work Plus a Fee with a Guaranteed Maximum Price"("Agreement"),and such contract is for the Old Settlers Park Buildout Project—Harrell Parkway (Package 3A.2); and WHEREAS, the terms of said Agreement require the submission of an Exhibit "A" to the Agreement titled, "Guaranteed Maximum Price Amendment" ("Amendment"); and WHEREAS,the City Council wishes to accept and execute said Amendment to the Agreement, Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK,TEXAS, That the Mayor is hereby authorized and directed to execute, on behalf of the City, Guaranteed Maximum Price Amendment to the Agreement with SpawGlass Contractors, Inc. for the Old Settlers Park Buildout Project — Harrell Parkway (Package 3A.2), a copy of said Amendment being attached hereto as Exhibit"A" and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date,hour,place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. RESOLVED this 19th day of December, 2024. CRXIA MOR N, Mayor City f Roun ock, Texas ATT T: (�,Akw- i-- ANN FRANKLIN, City Clerk 0112.20242:4918-9651-9429 EXHIBIT "A„ a� Document A133 2019 Exhibit A Guaranteed Maximum Price Amendment This Amendment dated the Nineteenth day of Voveniber in the year Two Thousand Twenty-Four, Is incorporated into the accompanying AIA Document A:33"1-2019. Standard Forst of Agreement Between Owner and Construction Manager as C'onstnletor where the basis of payment is the Cost of the Work Plus a Fee with a ADDITIONS AND DELETIONS: Guaranteed ;Nlaximum Price dated the day of w the year(the"Agreement") The author of this document may (bi n'o1'(t`i, i1Nllrate r1+m', mow li, an(l i PCU' have revised the text of the original AIA slandard form An Additions for the following PROJECT: and Deletions Resat that notes tN(ime and a&h'ess or lorwiolr) revisions to the standard form text Old Settlers Park Bluldout -Package 3A 2-Harrell Parkway is available from the author and C'oRR-Old Settler's Park should be reviewed A vertical Ione 3300 E. Palm Valley Blvd in the left margin of this document Round Rock,TX 78665 indicates where the author has added to or deleted from the THE OWNER: original AIA text (Nome, legal status, aur!cid&ess) This document has important legal consequences Consultation with City of Rotund Rock an attorney is encouraged with 221 East Nfai n Street, Round Rock,TX 78644 respect to Its completion or modification THE CONSTRUCTION MANAGER. (Nonce, leg(d stouts,au(ia("'eis) AIA Document A201'M-2017, General Conditions of the Contract SpawGlass Cont3actors,nuc for Construction is adopted in this I I l I Snlith Road.Austin TX 78721 document by reference Do not use with other general conditions TABLE OF ARTICLES unless this document is modified A.1 GUARANTEED MAXIMUM PRICE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION A.3 INFORMATION UPON WHICH AMENDMENT IS BASED AA CONSTRUCTION MANAGER'S CONSULTANTS,CONTRACTORS,DESIGN PROFESSIONALS,AND SUPPLIERS ARTICLE A.1 GUARANTEED MAXIMUM PRICE §A.1.1 Guaranteed Maximum Price Pursuant to Section 3.2.6 of the Agreement.the Owner and C'onsirtiction Manager hereby amend the Agreement to establish a Guaranteed Nilaxinulnt Price. As agreed by the Owner and ConstnTction Manager,the Guaranteed Nlaxinnun Price is all amount that the Contract Suul shall not exceed.Tl:e Contract Soul consists of the Construction Manager's Fee plus the Cost of the Work, as that term is defined ill Article 6 of the Agreement. §A.1.1.1 The Contract Sunt is guaranteed by the C'onstnlcnon Manager not to exceed (58,477,199),subject to additions and deductions by Change Order as provided in the Contract Documents. §A.1.1.2 Itemized Statement of the Guaranteed Maximum Price Provided below is an itemized statement of[lie Guaranteed Maximum Price organized by trade categories. AIA Daunnent A133 -20t9Exhibit A Copyright C,1991 2003,2009 and 2019 Alt rights reserved 'The American Institute of Architects' American Inst tute of Architects' 'AIA the AIA Logo and AIA Contract Documents'are trademarks of The American Institute of Architects This document was produced at 10 it 32 CST on 1111912024 under Subscrnpuon No 20240040942 vduch expires on 0110512025,is not for resale is licensed for ane time use only and may only be used in accordance with the AIA Contract Documerits°Terms of Service To report copyright violations e-mail docmfo@aiaconiracts Com Lisor Notss (673030257573cc341eac231) including allov,ances,the Construction Manager's contingency:alternates:rlie Constnlction Manager's Fee.and other items that comprise the Guaranteed Nlaxilnum Price as defined in Section 3.2 1 of the Agreement. (Provide itemr--ed staremew belott or reference an arrrtchmetrt 1 $8,477,199 §A.1.1.3 The Construction Manager's Fee is set forth In Section 6 1 2 of the Agreement. §A.1.1A The method of adjustment of the Construction%tanager's Fee for changes u1 the Work is set forth in Section 6.1.3 of the Agreement §A1.1.5 Alternates §A.1.1.5.1 Alternates,if any, included in the Guaranteed Nlaxuuunt Price: Item Price §A.1.1.5.2 Subject to tine conditions noted below.the following alternates may be accepted by tine Uwuter following execution of this Exhibit A.Upon acceptance.the ON%net-shall issue a Modification to the Agreement. (Insert below each alternate mid the conditions that must be met for the tit ner to accept the alternate t Rem Price Conditions for Acceptance §A.1.1.6 Unit prices, if any. (Ide►rti -the item and state the unit price mid quantity Innitntrom if aur, to which the unit price a ill be applicable 1 Rem Units and Limitations Price per Unit($0.00) ARTICLE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION §A.2.1 The date of conl:nteucemeut of the Work shall be: (Check one of rhe following boxes.) [ J The date of execution of this Aruendment. (X j Established as follows: (Insert a date or a memis to derermrm the dare of romnmencement of the FVork Febnlary Sth, 2025 If a date of commencement of the Work is not selected. then the date of conunencettnent shall be the date of execution of this Amendment. §A.2.2 Unless other-wise provided. the Contract Time is the period of time. including authorized adjustments,allotted ill the Contract Documents for Substantial Completion of the Work. The Contract Time shall be measured front the date of conunencentent of the Work §A.2.3 Substantial Completion §A.2.3.1 Subject to adjustments of(lie Contract Time as provided in the Cbutract Documents. the Construction Manager shall achie,.e Substantial Completion of the entire «cork: (Check ane of tl►e follonvttg bo.s-es nrrd complete the tiecesscrn�iti/onuation.l ( J Not later than l )calendar days from the date of conuuencenient of the Work [X J By the folloss ing date. August 24. 2025 §A.2.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents. if portions of the Work are AIA Document At 33-2019 Exhibit A CopyrgM'D 1991 2003 2009 and 2019 All rights reserved 'The Amencan Institute or Arch tects Amencan Institute of Architects AIA the AIA Logo and AIA Contract Documents are Irademarks of The American Institute of 2 Architects This document was produced at 10 11 32 CST on 11 1912024 under Subscription No 20240043942 which expires on 07 052025 s not for resale is licensed for onetime use only and may only be used-n accordance wrlh Ire AIA Contract Documents' Terms of Service To report copyright violations email docmfoaataconlracts cam User Notes: (673cb30257573cc34leac231 to be completed prior to Substantial Completion of the entire Work.the C'onstnlction Manager shall achieve Substantial Completion of such portions by the folio%%ing dates: Portion of Work Substantial Completion Date §A.2.3.3 If the Construction Sianager flails to achieve Substantial Completion as provided in this Section A.2.3. liquidated damages, if any.shall be assessed as set forth in Section 6.1.6 of the Agreement. ARTICLE A.3 INFORMATION UPON WHICH AMENDMENT IS BASED §A.3.1 The Guaranteed IVIaxuluuu Price and Contract Time set forth in this Amendment are based on the Contract Documents and the following. §A.3.1.1 The follocs•utg Supplementary and other Conditions of the C'ontr'act: Document Title Date Pages §A.3.1.2 The following Specifications. (Either list rite Spec fca►ions here.or refer to an exhibit atached to this.1u►endme►►t.t Harrell Parkway Phase A.2 Roadway and utilities Specifications as issued by Kinney-Horn on September 13,1. 2024 Section Title Date Pages §A.3.1.3 The following Dra-wings. tEither list the Drm1•ings here, o►•refer to an exhibit attached to this.lntenrlutent.) i Harrell Parkway Phase A.2 1000o Submittal as issued by Kinney Horn ort September 131h. 2024 Number Title Date §A.3.1.4 The Sustainability Plan.if any: (if the Owner identified a Sustainable Objective in the Owner's ('riterin, ielerrr f•the docrarre»t or documents that comprise the Stuumrabilin Plan br title, date and►uunber ofpages.and include other idem f•hrg it)attttio►. The Stnstainabilitu Plan identifies and describes the Sustainable Objective; the targeted Sustainable:bleasra•es. implententatioa strategies selected to achieve the Sits irrinable:Aleasta•es; the acner's and Carisn•uction,vAnKiger's roles and responsibilities associated 1rt►h achieving the Sustainable 11easures;the specific details about design reviews resting or metrics to ver f•achievement of each sustainable.-Ifeasure;and the S►istahtabili{n'Documentation requil"ed fir tine Project, as those terms ar-e defined in Exhibit Cto the.dgr•eement i Title Date Pages Other identifying information: §A.3.1.5 Allosvances,if an}.. included in the Guaranteed.1-faxnnunn Price: (Idetu f-each allowance.r Item Price j Access and Event Flagmen S75.000.00 §A.3.1.6 Assumptions and clarifications.if an.. upon which the Guaranteed Maxinnlru Pi ce is based ((dent fir each asswu►ptiorr and ciarfc atioa x Reference attached GULP Package-TAB 05 §A.3.1.7 The Guaranteed Maxrtnunt Price is based upon the following other do unnents and information. tLis►ait'v other documerus or•information he)-e, or refi-r to an exhibit tutached to this.♦meadmeni.r AIA Document A133-2019 Exhibit A.Copyright Z 1991 2003 2009 and 2019 All rights reserved The American Institute of Arcndects American Institute of Architects AIA the AIA Logo and AIA Contract Documents are trademarks of The ArTwrcan Institute of 3 Aichdects This document was produced at 10 11 32 CST on 11 19.2024 under Subscription No 20240040942 whrcn expires oar 07 05x2025 is not(of resale is licensed for one-time use only and may only le used n accordance vAh the AIA Contract DocurnentO remrs of Service ro reoort co,;rght wolatrau email docrnforlaraco track rom User Notes: .0 7 3cb30257573cc 14 leac23r, ARTICLE A.4 CONSTRUCTION MANAGER'S CONSULTANTS, CONTRACTORS, DESIGN PROFESSIONALS, AND SUPPLIERS §A.4.1 The Constnlction Manager shall retain the consultants,contractors,design professionals,and suppliers,identified below- (List name discipline address, arid other ittfonnatiou.) This Amendment to the Agreement entered into as of the day and year first written above. j If 192024 c OWNER(Signature) CTiON NAGER(Signature) BY: Craig Morgan,Mayor BY: Paden.Austin Di%Iston President (Printed name and title) (Printed name and title) AIA Document At 33 2019 Exhibit A Copynght a 1991 2003 2009 and 2019 Ad rights reserved The Amerxan Institute of Architects American Institute of Architects AIA the AIA Logo and'AIA Contract Documents are trademarks of The American Institute of 4 Architects This document was produced at 1C 11 32 CST on 11 197024 under Subscription No 20240040942 which expires an 07 05(2025 is not for resale s licensed tot one-time use only and may only be used�n accordance Mh the AIA Contract Documents' Terms of Service To report ropy ight v olatu:ns e-mail ft info@?aiacontracts corn User Nous: 1673030257573cc34leac23f ACC)RUa E(11Y,00 YYYY) CERTIFICATE OF LIABILITY INSURANCE DATE THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW, THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER CONTACT NAJAMirta Tamez Adams Risk Management Services, LLC PHONE FAX — -- Adams Insurance Service, nc. (AVC.No.Ext).(713)869-8346 (Aic,No);.(713)869-9144 1111 North Loop W, Suite 600 A�DDRRESS mtamez@adamsins com _ Houston TX 77008 NOURER(S)AFFORDING COVERAGE _i NAIC•_ INSURER A:American Contractors Insurance Co.RRG 12300 INSURED +;ADMIN 01 INSURER B:ACIG Insurance Company 19984 SpawGlass Contractors, Inc. 1 1 1 1 Smith Road INsuRER c:Travelers Lloyds Insurance Company 41262 Austin TX 78721 INSURENo:Valley Forge Insurance Company_ 20508 INsuwn E;The Continental Insurance mpany 35289 INSURER f Co COVERAGES CERTIFICATE NUMBER:788730579 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSRITYPE OF INSURANCE _ --�ADOL S BR -- POLICY EFF POLICY EXP LIMITS LTR I POLICY NUMBER MMiDD/YYYY MM/DDIYYY A X COMMERCIAL GENERAL LIABILITY Y Y GL24AIl000146 6/112024 611!2025 EACH OCCURRENCE s 10,000,000 DAMAGE TO RENTED CLAIMS MADE X OCCUR i PREMISESlEa occurrence/—,.$100.000 1 _ _ MED EXP(An one person $5.000 _ PERSONAL b ADV INJURY s 10,000,000 [OF',LAGGREGATELIMITAPPLIESPER' GENERAL AGGREGATE 1510,000,000 POLICY X JECTPRO -I I �LOC ! PRODUCTS COMPIOP AGG I s lo,000,000 OTHER _. _ _. 5 D AUTOMOBILE LIABILITY Y Y BUA7033775896 6/112024 611/2025 COMBINED SINGLE LIMIT S 5,000,000 a accgem) _ X ANY AUTO I BODILY INJURY(Per person) S OWNEDSCHEDULED AUTOS ONLY AUTOS BODILY INJURY(Per accideMl 5 _ X HIRED X NON-OWNED �PROPERTY 1)AMAGE s AUTOS ONLY AUTOS ONLY i IPer gttidenil S E UMBRELLA LIAB I OCCUR Y Y CUE7034067095 6/112024 i 611/2025 EACH OCCURRENCE i s_10,0W,000 EXCESS X rLIAR I CLA_IMS.MADE III AGGREGATE 610.000_,000 _ OED I I RETENTION$ f i f B �WORKERS COMPENSATION Y WCA000008324 6/1/2024 6/1/2025 X PER OTH AND EMPLOYERS'LIABILITY STATUTE ER YIN IANVPROPRIETORrPARTNER/EXECUTIVEN EL EACH ACCIDENT $1,000000 IOFFICE RMEMBEREXCLUCE01 NIA - ---------- (Mandatory In NH) l I 3 E L DISEASE EA EMPLOYEE I $1,000,000 if yes,describe Ur,der l{ !DESCRIPTION OF OPERATIONS below i ( E L DISEASE POLICY LIMIT S 1,000,000 C EQUIPMENT FLOATER OT-630-76258350-TLC-24 I 611/2024 61112025 PER ITEM 1,500,000 LEASEDIRENTED AGGREGATE 3,000,000 i DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached If more space Is required) The Automobile policy includes the following endorsements. 1)CNA63359-Blanket Additional Insured as required by written contract executed pr or to the bodily injury or property damage.2)CNA63359-Blanket Wa ver of Subrogation as required by written contract executed prior to the bodily injury or property damage.3)CNA63359&CNA71527 -Primary Non-Contnbutory basis only when required by a written contract prior to Accident or Loss 4)CNA68021 -Notice of Cancellation-30 days blanket as required by wr)ten contract. The General Liability policy includes the following endorsements: 1)1170-Additional Insured-Automatic Status as required by Contract-Blanket-Who is an insured is amended to include as Additional Insured any person or organization when you have agreed In a written contract that such person or organization be added as an additional insured on your policy.The endorsement also provides for the coverage to apply on a primary and non-contributory basis for ongoing See Attached... CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Round Rock 221 East Main Street AUTHORIZED REPRESENTATIVE Round Rock TX 78644 ©1988-2015 ACORD CORPORATION All rights reserved. ACORD 25(2016103) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: SGADMIN•01 LOC A: -- -_ _. ACORO® ADDITIONAL REMARKS SCHEDULE Page 1 of 1 AGENCY NAMEDINSURED Adams Risk Management Services,LLC SpawGlass Contractors, Inc. 1111 Smith Road POLICY NUMBER Austin,TX 78721 CARRIER NA1C CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: CERTIFICATE OF LIABILITY INSURANCE and completed operations when required by written contract.2)205-Blanket Waiver of Subrogation when required in a written contract or agreement-3)336- Notice of Cancellation,Nonrenewal or Material Change-30 days blanket as required by wntten contract 4)9-Aggregate Limits of insurance Per Project. The Workers'Compensation policy includes the following endorsements. 1)WC990304-Waiver of Subrogation-Blanket waiver for any person or organization for whom the named insured has agreed in a wntten contract to furnish the waiver.2)WC420601-Notice of Cancellation-30 days blanket as required by wntten contract. The Umbrella/Excess Liability policy applies in excess and follows form of the underlying General Liability,Automobile Liability and Employers Liability policies above including the terms of any additional insured,waiver of subrogation and 30 day notice of cancellation endorsements.The policy follows the terms and conditions of such underlying policies unless they are inconsistent with the terms of the policy. The Equipment Floater policy includes a Blanket Automatic Loss Payee Endorsement CMU618 that provides Loss Payee status to the Certificate Holder only when there is a wntten contract between the Named Insured and the Certificate Holder that requires such status Re.Project:Old Settlers Park Buildout-Package 3A 2-Harrell Parkway,Old Settler's Park,3300 E.Palm Valley Blvd.,Round Rock,TX 78665. ACORD 101 (2008101) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD ADDITIONAL INSURED - AUTOMATIC STATUS 7170 AS REQUIRED BY CONTRACT - BLANKET This endorsement modifies insurance provided under the following COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Any person or organization that you are required by written contract to include as an additional insured on[his policy if the contract is executed prior to the loss. A Section II,Who Is An Insured is amended to include as an addiMnal insured any person or organization shown in the above SCHEDULE (called additional insured),but only with respect to liability for'bodily injury" "property damage"of"personal and advertising injury"arising out of your premises or your operations for the additional insured,and only to the extent and for the minimum limits required in the written contract. B The insurance provided to the additional insured is subject to the following limitations I. Unless a written contract specifically requires additional insured coverage for your completed operations,this insurance does not apply to"bodily injury"or"property damage"occurring after"your work"for the additional insured has been completed or after that portion of .your work"out of which the"bod ly injury"or"property damage"arises has been put to Its intended use by any person or organization, whichever occurs first. 2 Unless specifically required by written contract,this insurance provides additional insured coverage only for liability for"bodily injury", "property damage"or"personal and advertising injury"to the extent caused by the named insured's acts or omissions or the acts or omissions of those acting on the named insured's behalf 3. This insurance does not apply to"bodily injury","property damage"or"personal and advertising injury"for which the additional insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement except to the extent that the additional insured would have been obligated to pay such damages in the absence of the contract or agreement. 4 This insurance does not apply to"bodily injury","property damage"or"personal and advertising injury"ansing out of the rendering or failure to render any professional services by any insured or on any insured's behalf,including: a) The preparing, approving or failing to prepare or approve maps,shop drawings,opinions, reports, surveys, field orders,change orders,drawings or specifications,or b) Supervisory,inspection,architectural,or engineering services Th s exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, h ring,employment,training or monitoring of others by that insured,if the"occurrence"which caused the"bodily injury" or"property damage", or the offense which caused the"personal and advertising injury", involved the rendering of,or the failure to render,any professional architectural,engineering or surveying services 5 Th s endorsement shal not apply to a person or organization if any other additional insured endorsement attached to this policy specifica ly applies to that person or organization 6. The insurance afforded herein only applies to the extent permitted by applicable state law, including statutes governing additional insured coverage in the construction industry. 7 The insurance afforded to the additional insured shall not exceed the minimum limits required in the written contract C In no event shall the nsurance provided to the additional insured exceed the minimum coverage required by the written contract, including but not limited to minimum limits,minimum scope of coverage or minimum duration of coverage It a written contract or agreement requires that additional insured status be provided by the use of specified edition dales of the ISO CG2010 and/or CG2037,then the terms of that endorsement are incorporated into this endorsement as respects such additional insured and shall supersede the coverage grant and limitations in Sections A. and B of this endorsement In the event that CG2010 and/or CG2037 are required but no edition dales are specified,the 04!13 editions shall apply D This insurance is excess to any other insurance, whether primary, excess, contingent or on any other basis, available to the additional insured unless a written contract requires that this insurance be primary or primary and non-contributing.However,this insurance is always excess to other insurance,whether primary,excess,contingent or on any other basis,when the additional insured has been added to the other nsurance as an additional nsured Nothing herein contained shall be held to vary,alter,waive or extend any of the terms,conditions provisions,agreements or limitations of the mentioned Policy other than as above slated This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective 6112024 Policy No GL24ABC00046 Insured: SpawGlass Contractors Inc , SpawGlass Construction Corp SpawGlass Civil Construction, Inc.,Westland Equipment and Supplies, LLC Insurance Company. American Contractors Insurance Company Risk Retention Group WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies Insurance provided under the following COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Persons or Organization(s): Any person or organization for whom you have agreed by written contract to furnish this waiver. Section IV—Commercial General Liability Conditions, 14. Transfer of Rights of Recovery Against Others to Us Condition is amended by the addition of the following. We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or"your work"done under a contract with that person or organization and included in the"products-completed operations hazard This waiver applies only to the person or organization shown in the Schedule above Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it;s attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective 6/1/2024 Policy No GL24ABC00046 Insured. SpawGlass Contractors, In: ,SpawGlass Construct on Corp., SpawGlass Civil Construction Inc,Westland Equipment and Supplies, LLC Insurance Company Amercan Contractors Insurance Company Risk Retention Group !f! NOTICE OF CANCELLATION, NONRENEWAL OR MATERIAL CHANGE - CERTIFICATE HOLDERS This endorsement modifies insurance provided under the following. COMMERCIAL GENERAL LIABILITY COVERAGE PART The certificate of insurance holders shown in the schedule below have requested that they receive written notice of cancellation, nonrenewal or material change with respect to this policy. If we decide to cancel, nonrenew or make a material change to this policy, we agree to mail or deliver sixty(60) days advance written notice to the certificate of insurance holders shown in the schedule below. However, if we are cancelling or nonrenewing due to nonpayment of premium, we will only provide the certificate of insurance holders shown in the schedule below with ten (10) days advance written notice. The notice of cancellation, nonrenewal or material change will be mailed to the addresses provided to us by the certificate of insurance issuer. Proof of mailing will be considered sufficient proof of our good faith attempt to provide notice of cancellation, nonrenewal or material change to the certificate of insurance holders shown in the schedule below SCHEDULE All certificate of insurance holders where written notice of cancellation, nonrenewal or material change to this policy is required by written contract, permit or agreement with the Named Insured. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective 611/2024 Policy No.: GL24ABC00046 Insured SpawGlass Contractors, Inc., SpawGlass Construction Corp, SpawGlass Civil Construction, Inc., Westland Equi pment and Supplies, LLC Insurance Company American Contractors Insurance Company Risk Retention Group y AGGREGATE LIMITS OF INSURANCE (PER PROJECT) 1 his endorsement modifies insurance provided under the following COMMERCIAL GENERAL LIABILITY COVERAGE PART It is hereby understood and agreed the General Aggregate Limit under Section 111, Limits of Insurance of the Coverage Form applies separately to each of your projects away from premtses owned by or rented to you. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective. 6/1/2024 Policy No.: GL24ABC00046 Insured; SpawGlass Contractors, Inc , SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Insurance Company. American Contractors Insurance Company Risk Retention Group CNAusiness Auto Policy SpawGlass Contractors,Inc.,lnc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc ,Westland Equipment and Supplies,LLC CONTRACTORS EXTENDED COVERAGE ENDORSEMENT -BUSINESS AUTO THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies onsurance provided under the fo'lowing: BUSINESS AUTO COVERAGE FORM I. LIABILITY COVERAGE A. Who Is An Insured The following is added to Section II, Paragraph A.1., Who Is An Insured: 1. a. Any incorporated entity of which the Named Insured owns a majority of the voting stock on the date of inception of this Coverage Form; provided that, b. The insurance afforded by this provision A.1. does not apply to any such entity that is an insured under any other liability "policy" providing auto coverage. 2. Any organization you newly acquire or form, other than a limited liability company, partnership or joint venture, and over which you maintain majority ownership interest. The insurance afforded by this provision A.2.: a. Is effective on the acquisition or formation date, and is afforded only until the end of the policy period of this Coverage Form, or the next anniversary of its inception date, whichever is earlier. b. Does not apply to: (1) Bodily injury or property damage caused by an accident that occurred before you acquired or formed the organization; or (2) Any such organization that is an insured under any other liability "policy" providing auto coverage. K�sured ny person or organization that you are required by a written contract to name as an additional is an insured but only with respect to their legal liability for acts or omissions of a person, who qualifies as an insured under SECTION II - WHO IS AN INSURED and for whom Liability Coverage is afforded under this policy If required by written contract, this insurance will be primary and non-contributory to insurance on which the additional insured is a Named Insured. 4. An employee of yours is an insured while operating an auto hired or rented under a contract or agreement in that employee's name, with your permission, while performing duties related to the conduct of your business. "Policy", as used in this provision A. Who Is An Insured, Includes those policies that were in force on the inception date of this Coverage Form but: 1. Which are no longer In force; or 2. Whose limits have been exhausted. B. Bail Bonds and Loss of Earnings Section II, Paragraphs A.2. (2) and A.2. (4) are revised as follows 1. In a.(2), the limit for the cost of bail bonds is changed from $2,000 to $5,000; and 2. In a.(4), the limit for the loss of earnings is changed from $250 to $500 a day. Form No CNA63359XX (04 20121 Policy No. BUA 7033775896 Underwriting Company Va ley Forge Insurance Company Policy Effect ve Date 06 01'2024 ` Copyr ght CNA Al;Rights Reserved. Includes copyrighted materia of the CNA Business Auto Policy -Iorsenient C. Fellow Employee Section 11, Paragraph B.5 does not apply. Such coverage as is afforded by this provision C. is excess over any other collectible insurance. II. PHYSICAL DAMAGE COVERAGE A. Glass Breakage - Hitting A Bird Or Animal - Falling Objects Or Missiles The following is added to Section III, Paragraph A.3.: With respect to any covered auto, any deductible shown in the Declarations will not apply to glass breakage if such glass is repaired, in a manner acceptable to us, rather than replaced. B. Transportation Expenses Section III, Paragraph A.4.a. is revised, with respect to transportation expense incurred by you, to provide: a. $60 per day, in lieu of $20; subject to b. $1,800 maximum, in lieu of $600. C. Loss of Use Expenses Section 111, Paragraph A.4.b. is revised, with respect to loss of use expenses incurred by you, to provide: a. $1,000 maximum, in lieu of $600. D. Hired "Autos" The following is added to Section Ill. Paragraph A.: 5. Hired "Autos" If Physical Damage coverage is provided under this policy, and such coverage does not extend to Hired Autos, then Physical Damage coverage is extended to: a. Any covered auto you lease, hire, rent or borrow without a driver; and b. Any covered auto hired or rented by your employee without a driver, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. The most we will pay for any one accident or loss is the actual cash value, cost of repair, cost of replacement or $75,000, whichever is less, minus a $500 deductible for each covered auto. No deductible applies to loss caused by fire or lightning. d. The physical damage coverage as is provided by this provision is equal to the physical damage coverage(s) provided on your owned autos. e. Such physical damage coverage for hired autos will: (1) Include loss of use, provided it is the consequence of an accident for which the Named Insured is legally liable, and as a result of which a monetary loss is sustained by the leasing or rental concern. (2) Such coverage as is provided by this provision will be subject to a limit of $750 per accident. E. Airbag Coverage The following is added to Section III, Paragraph 8.3.: The accidental discharge of an airbag shall not be considered mechanical breakdown. Form No: CNA63359XX (04-20121 Po icy No:BUA 7033775896 underwriting Company. Valley Forge Insurance Company Policy Effective Date 0601'2024 Copyr ght CNA Ai' R ghts Reserved. Includes copyrighted matenal of the CNA Business Auto Policy 'vlicy lorsemen, F. Electronic Equipment Section III, Paragraphs B.4.c and B.4.d. are deleted and replaced by the following: c. Physical Damage Coverage on a covered auto also applies to loss to any permanently installed electronic equipment including its antennas and other accessories d. A $100 per occurrence deductible applies to the coverage provided by this provision. G. Diminution In Value The following is added to Section III, Paragraph B.6.: Subject to the following, the diminution in value exclusion does not apply to: a. Any covered auto of the private passenger type you lease, hire, rent or borrow, without a driver for a period of 30 days or less, while performing duties related to the conduct of your business; and b. Any covered auto of the private passenger type hired or rented by your employee without a driver for a period of 30 days or less, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. Such coverage as is provided by this provision is limited to a diminution in value loss arising directly out of accidental damage and not as a result of the failure to make repairs; faulty or incomplete maintenance or repairs; or the installation of substandard parts. d. The most we will pay for loss to a covered auto in any one accident is the lesser of: (1) $5,000; or (2) 20% of the auto's actual cash value (ACV). III. Drive Other Car Coverage - Executive Officers The following is added to Sections II and III: 1. Any auto you don't own, hire or borrow is a covered auto for Liability Coverage while being used by, and for Physical Damage Coverage while in the care, custody or control of, any of your "executive officers", except: a. An auto owned by that "executive officer" or a member of that person's household; or b. An auto used by that "executive officer" while working in a business of selling, servicing, repairing or parking autos. Such Liability and/or Physical Damage Coverage as is afforded by this provision. (1) Equal to the greatest of those coverages afforded any covered auto; and (2) Excess over any other collectible insurance 2. For purposes of this provision, "execut;ve officer" means a person holding any of the officer positions created by your charter, constitution, by laws or any other similar governing document, and, while a resident of the same household, includes that person's spouse. Such "executive officers" are insureds white using a covered auto described In this provision. IV. BUSINESS AUTO CONDITIONS A. Duties In The Event Of Accident, Claim, Suit Or loss The fol'owing is added to Section IV, Paragraph A.2.a Form No CNA63359XX (04 201 2) Policy No.BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date 06/01 2024 Copyr ght CNA A i Rights Reserved. Includes copyrighted mater at of the CNA Business Auto Policy Endo (4) Your employees may know of an accident or loss. This will not mean that you have such knowledge, unless such accident or loss is known to you or if you are not an individual, to any of your executive officers or partners or your insurance manager. The following is added to Section IV, Paragraph A.2.b.: (6) Your employees may know of documents received concerning a claim or suit. This will not mean that you have such knowledge, unless receipt of such documents is known to you or if you are cutive officers or partners or your insurance manager. B. Transfer Of Rights Of Recovery Against Others To Us e ap A.5. Transfer Of Rights Of Recovery Against Others To Us: We waive any right of recovery we may have, because of payments we make for injury or damage, against any person or organization for whom or which you are required by written contract or agreement to obtain this waiver from us. This injury or damage must arise out of your activities under a contract with that person or organization. You must agree to that requirement prior to an accident or loss C. Concealment, Misrepresentation or Fraud The following is added to Section IV, Paragraph B.2.: Your failure to disclose all hazards existing on the date of inception of this Coverage Form shall not spect to the coverage afforded provided such failure or omission is not intentional. D. Other Insurance ed to Section IV, Paragraph B.5.: Regardless of the provisions of Paragraphs 5.a. and 5.d. above, the coverage provided by this policy shall be on a primary non-contributory basis. This provision is applicable only when required by a written contract. That written contract must have been entered into prior to Accident or Loss. E. Policy Period, Coverage Territory Section IV, Paragraph B. 7.(5).(a). is revised to provide: a. 45 days of coverage in lieu of 30 days. V. DEFINITIONS Section V. paragraph C. is deleted and replaced by the following: Bodily injury means bodily injury, sickness or disease sustained by a person, including mental anguish, mental injury or death resulting from any of these. Form No: CNA63359XX (04 20121 Policy No BUA 7033775896 Underwriting Company Valley Forge Insurance Company Policy Effective Date 0601'2024 s'Copyright CNA A!I Rights Reserved Includes copyrighted mater al of the CNA Business Auto Policy NOTICE OF CANCELLATION TO CERTIFICATEHOLDERS ,' It is understood and agreed that: If you have agreed under written contract to provide notice of cancellation to a party to whom the Agent of Record has issued a Certificate of Insurance, and if we cancel a policy term described on that Certificate of Insurance for any reason other than nonpayment of premium, then notice of cancellation will be provided to such Cert=ficateholders at least 30 days in advance of the date cancellation is effective. If notice is mailed, then proof of mailing to the last known mailing address of the Certiflcateholder on file with the Agent of Record will be sufficient to prove notice. Any failure by us to notify such persons or organizations will not extend or invalidate such cancellation, or impose any liability or obligation upon us or the Agent of Record. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy. SpawGlass Contractors,Inc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,I.I.0 Form No: CNA68021XX (02.20131 Policy No BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date 06,01 2024 1 Copyright CNA Ail Rights Reserved CNABusiness Auto Policy ADDITIONAL INSURED PRIMARY , NON-CONTRIBUTORY, . . It is understood and agreed that this endorsement amends the BUSINESS AUTO COVERAGE FORM as follows: SCHEDULE Name of Additional Insured Person Or Organization ANY PERSON OR ORGANIZATION THAT YOU ARE REQUIRED BY WRITTEN CONTRACT OR WRITTEN AGREEMENT TO NAME AS AN ADDITIONAL INSURED 1. In conformance with paragraph A.1.c. of Who Is An Insured of Section II LIABILITY COVERAGE, the person or organization scheduled above is an insured under this policy. 2. The insurance afforded to the additional insured under this policy will apply on a primary and non-contributory basis if you have committed it to be so in a written contract or written agreement executed prior to the date of the "accident" for which the additional insured seeks coverage under this policy. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and Is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy. Form No: CNA71527XX (10-2012) Policy No BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date 06:01 2024 Insured:Spaw0ass Contractors,Inc.,Spaw(ilass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Fyuipment and Supplies,I.LC Copyright CNA All R ghts Reserved TEXAS WORKERS COMPENSATION AND EMPLOYERS LIABILITY POLICY WC 99 03 04 (Ed. 04-07) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3.A. of the Information Page. We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule, but this waiver applies only with respect to bodily injury arising out of the operations described in the Schedule where you are required by a written contract to obtain this waiver. This waiver does not extend to the statutory right of reimbursement from a claimant who recovers any amount under Section 417.002 of the Texas Labor Code. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule. The premium for this endorsement is shown in the Schedule. Schedule 1 ( ) Specific Waiver Name of person organization ( X ) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. This waiver does not extend to the statutory right of reimbursement under Section 417.002 of the Texas Labor Code, 2. Operations: CONSTRUCTION AND RELATED CONSTRUCTION RELATED WORK ALL TEXAS OPERATIONS 3. Premium: The premium charge of this endorsement shall be 2 percent of the premium developed on payroll in connection with work performed for the above person(s)or organization(s)arising out of the operations described. 4. Minimum Premium. $0 5 Advance Premium. $0 This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise slated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective. Same as Policy Effective Date unless otherwise indicated above. Policy Effective Date 6/1/2024 Policy No. WCA000008324 Insured SpawG'ass Contractors, Inc SpawGlass Construction Corp , SpawGlass C vil Construction Inc . Westland Equipment and Supplies LLC Carrier Name/Code ACIG Insurance Company WC 99 03 04 (Ed. 04-07) WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 42 06 01 (Ed 03-13) TEXAS NOTICE OF MATERIAL CHANGE ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3 A of the Information Page. In the event of cancelation or other material change of the policy, we will mail advance notice to the person or organization named in the Schedule The number of days advance notice is shown in the Schedule This endorsement shal' not operate directly or indirectly to benefit anyone not named in the Schedule Schedule 1 . Number of days advance notice: 60 days. However, in the case of cancellation or nonrenewal due to nonpayment of premium, only 10 days advance notice will be provided. 2. Notice will be mailed to: All certificate holders where written notice of cancellation, nonrenewal or material change to this policy is required by written contract, permit or agreement with the Named Insured. The notice will be mailed to the addresses provided to us by the certificate of insurance issuer. Proof of mailing will be considered sufficient proof of our good faith attempt to provide written notice. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below Is required only when this endorsement Is Issued subsequent to preparation of the policy.) Endorsement Effective 06/0-' /2.24 Policy No. WCA000008324 Insured SpawGlass Contractors,Inc. , SpawGlass Construction Corp. , Premium$ SpawGlass Civil Construction, Inc. , Westland Equipment and Supplies, LL: Insurance Company ACtG Insurance Company WC 42 06 01 Wolters Kluwer Financial Services I Uniform Forms Page 1 Of 1 (Ed 03.13) TM COMMERCIAL INLAND MARINE THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET LOSS PAYEES This endorsement modifies insurance provided under the COMMERCIAL INLAND MARINE COVERAGE PART The following is added to Section E — ADDITIONAL b. Pay any claim for loss or damage jointly to you COVERAGE CONDITIONS: and the Loss Payee as your interests may Loss Payable Provision appear. In the event of a Covered Cause of Loss to Covered This endorsement applies to all Covered Property for Property in which both you and a Loss Payee share which a Loss Payee is on file with us or your an insurable interest, we will: insurance agent or insurance broker. a. Adjust the loss or damage with you; and SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc.,Westland Equipment and Supplies, LLC Travelers Property 8 Casualty Co. Policy No. OT-630-7625835-0-TLC-24 CM U6 18 05 21 O 2021 The Travelers Indemnity Company Page 1 of t Includes copyrighted material of Insurance Services Office,Inc.w th its permission I C H U B B surety o + 908 903 3485 202B l lalls Mill Road,PO Box 1650 h +908 903 3656 W'hnclxwe Station.NJ 08889-1650 Federal Insurance Companv Liberty Mutual Insurance Company AIA Document A312 Performance Bond K41875525(Federal) 58S218516(Liberty Mutual) Any singular reference to Conimaor.Surety.O%ner or other park shall be considered plural where applicable CONTRACTOR(Vance oral Address). SURETY(Nana caul Principal Place orBtrsaressl SpawGlass Contractors. Inc. Federal Insurance Company(IN) 1 I I I Smith Road Liberty Mutual Insurance Company(MA) Austin.Texas 78721 OWNER(h"ante arrdAddrets). City of Round Rock 221 East Main Street Round Rock,TX 78644 CONSTRUCTION CONTRACT Date: lI day of �o (,2024 Amount:$8,477,199.00 Eight Million Four Hundred Seventy Seven Thousand One Hundred Ninety Nine& 00/100 Dollars Description (Varve oncl Location) Old Settlers Park Buildout-Package 3A.2-Harrell Parkway BOND Dale(Vat earlier than Calsirtt(tlnn Contract Dare): I day of F�PYl�.�r,2024 AMOUNT: $8,477,199.00 Eight Million Four Hundred Seventy Seven Thousand One Hundred Ninety Nine& 00/100 Dollars Modifications to this Bond: ® None ❑ See Page 3 CONTRACTORSAS PRINCIPAL Company: (Corporate Seal) SURETY SpawGlass Contractors Company: (Corporate Seal) Federal Insurance om y Liberty Multi nsur c p y Sig urt, _ — Signature: Na a and Y-' avid Paden Name and i John A.Prince ' �_� President -Austin Division Attorney-in-Fact (Any additional signatures appear on page 3) (10R 1 N'1--0Rd4,1-/'10,1'ONIA' :Name.adc/ress an(l T elephrme) AGENT or BROKER: Adams Inswance Service OWNER'S REPRESENTATIVE(Architect.Engineer or ntlterlxrr•A) 427 W 20th.Suite 500 Houston,TX 77008 713-869-8346 Pr•urred rn cooperation a-ith the America(lista to ojArcheects(AL-0 ht•Chubb The language ra this ductinoern cogf mars exacta 10 the language used or AU Dnetrnrent,1312 December 1984 editrem.Thnd Priming,.%krr-ch 1937. Form IS-02-0219-F FU IR- 11 IN A312-1984 I I The Contractor and the Surety,jointly and severally, performance and payment bonds executed by a bind themselves, their heirs, executors, administrators, qualified surety equivalent to the bonds issued on the successors and assigns to the Owner for the performance of Construction Contract,and pay to the Owner the amount the Construction Contract,which is incorporated herein by of damages as described in Paragraph 6 in excess of the reference. Balance of the Contract Price incurred by the Owner 2 If the Contractor performs the Construction Contract, resulting from the Contractor's default.or the Surety and the Contractor shall have no obligation Linder 4.4 Waive its right to perform and complete, arrange this Bond,except to participate in conferences as provided for completion, or obtain a new contractor and with in Sub-paragraph 3.1. reasonable promptness under the circumstances: 3 If there is no Owner Default, the Surety's obligation .1 After investigation,determine the amount for tinder this Bond shall arise after: which it may be liable to the Owner and,as soon 3.1 The Owner has notified the Contractor and the as practicable after the amount is determined, Surety at its address described in Paragraph 10 below tender payment therefor to the Owner;or that the Owner is considering declaring a Contractor .2 Deny liability in whole or in part and notify the Default and has requested and attempted to arrange a Owner citing reasons therefor. conference with the Contractor and the Surety to be held 5 If the Surety does not proceed as provided in Paragraph not later than fifteen days after receipt of such notice 4 with reasonable promptness,the Surety shall be deemed to discuss methods of performing the Construction to be in default on this Bond fifteen days after receipt of Contract. If the Owner,the Contractor and the Surety an additional written notice from the Owner to the Surety agree, the Contractor shall be allowed a reasonable demanding that the Surety perform its obligations under this time to perform the Construction Contract, but such Bond,and the Owner shall be entitled to enforce any remedy an agreement shall not waive the Owner's right,if any, available to the Owner.If the Surety proceeds as provided subsequently to declare a Contractor Default;and in Subparagraph 4.4,and the Owner refuses the payment 3.2 The Owner has declared a Contractor Default and tendered or the Surety has denied liability, in whole or in formally terminated the Contractor's right to complete part,without further notice the Owner shall be entitled to the contract. Such Contractor Default shall not be enforce any remedy available to the Owner. declared earlier than twenty days after the Contractor 6 After the Owner has terminated the Contractor's right and the Surety have received notice as provided in to complete the Construction Contract, and if the Surety Subparagraph 3.1;and elects to act under Subparagraph 4.1, 4.2, or 4.3 above, 3.3 The Owner has agreed to pay the Balance of the then the responsibilities of the Surety to the Owner shall Contract Price to the Surety in accordance with the terms not be greater than those of the Contractor under the of the Construction Contract or to a contractor selected Construction Contract,and the responsibilities of the Owner to perform the Construction Contract in accordance with to the Surety shall not be greater than those of the Owner the terms of the contract with the Owner. under the Construction Contract. To the limit of the amount 4 When the Owner has satisfied the conditions of of this Bond, but subject to commitment by the Owner Paragraph 3, the Surety shall promptly and at the Surety's of the Balance of the Contract Price to mitigation of costs expense take one of the following actions: and damages on the Construction Contract, the Surety is obligated without duplication for: 4.1 Arrange for the Contractor, with consent of the 6.1 The responsibilities of the Contractor for correction Owner, to perform and complete the Construction of defective work and completion of the Construction Contract;or Contract; 4.2 Undertake to perform and complete the 6.2 Additional legal,design professional and delay costs Construction Contract itself, through its agents or resulting from the Contractor's Default,and resulting through independent contractors;or from the actions or failure to act of the Surety under 4.3 Obtain bids or negotiated proposals from qualified Paragraph 4;and contractors acceptable to the Owner for a contract 6.3 Liquidated damages,or if no liquidated damages are for performance and completion of the Construction specified Contract, arrange for a contract to be prepared for fied in the Construction Contract,actual damages execution by the Owner and the contractor selected caused by delayed performance or non-performance of with the Owner's concurrence,to be secured with the Contractor. Printed in cooperation with the American Institute ojArchitects(A[A)by Chubb.The language in titis docutrretu conjorrtrs eractiv to the language used in A 1 Document A312 Deeernber 1984 editiort,Third printing,Alarch 1987. r«on ts.r_.orQ t4ea(kc�11%) A312-19842 I 7 The Surety shall not be liable to the Owner or others be deemed deleted herefrom and provisions conforming to for obligations of the Contractor that are unrelated to the such statutory or other legal requirement shall be deemed Construction Contract, and the Balance of the Contract incorporated herein. The intent is that this Bond shall be Price shall not be reduced or set off on account of any such construed as a statutorybond and not as a common law bond. unrelated obligations. No right of action shall accrue on this 12 DEFINITIONS Bond to any person or entity other than the Owner or its heirs,executors,administrators or successors. 12.1 Balance of the Contract Price:The total amount 8 The surety hereby waives notice of any change,including payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have changes of time,to the Construction Contract or to related been made, including allowance to the Contractor of subcontractors,purchase orders and other obligations. any amounts received or to be received by the Owner in 9 Any proceeding,legal or equitable,under this Bond may settlement of insurance or other claims for damages to be instituted in any court of competent jurisdiction in the which the Contractor is entitled,reduced by all valid and location in which the work or part of the work is located and proper payments made to or on behalf of the Contractor shall be instituted within two years after Contractor Default under the Construction Contract. or within two years after the Contractor ceased working or 12,2 Construction Contract: The agreement between within two years after the Surety refuses or fails to perform theOwner and the Contractor identified on the signature its obligations under this Bond,whichever occurs first.if the page, including all Contract Documents and changes provisions of this Paragraph are void or prohibited by law, thereto. the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to 10 Notice to the Surety,the Owner or the Contractor shall perform or otherwise to comply with the terms of the be mailed or delivered to the address shown on the signature Construction Contract. page. 12.4 Owner Default: Failure of the Owner,which has 11 When this Bond has been furnished to comply with a neither been remedied nor waived,to pay the Contractor statutory or other legal requirement in the location where as required by the Construction Contract or to perform the construction was to be performed,any provision in this and complete or comply with the other terms thereof. Bond conflicting with said statutory or legal requirement shall MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (CorporareSeah Federal Insurance Company Signature: Signature:_ Name and Title: Name and Title: Address: Address: Primed in cooperation with the Arnerican Institute of Architects(AIA)by Chubb.The language in this docuneent conforms exactly to the language used in AIA Docennent A312 Decenrher 198.1 edition,Third printing,Alarch 1987. Furm1S-02-02M-FFJ11Nev 11,10 A312-19843 CHUBS Power of Attorney Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents,that FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY a New York corporation,PACIFIC INDEMNITY COMPANY,a Wisconsin corporation.WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations of the Commonwealth of Pennsylvania, do each hereby constitute and appoint Andrew A.Adams,Norman E.Adams,Michael Macomber,John A.Prince and Larry D.Snider of Houston,Texas---- each as their true and lawful Attorney-in Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise,bonds and undertakings and other writings obligatory In the nature thereof(other than hallbonds)given or executed In th^course of business,and any Instruments amending or altering the same,and consents to the modification or alteration of any Instrument referred to In said bonds or obligations In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have each executed and attested these presents and aMxed their corporate seals on this lou day of April 2024. N RuptrtHDSx•indflls,AssistantSecrit" 1l3rrinFichhl+rn.1Oct:NrR--)dent _60000 *14)"0 STATE OF NEW IERSEY County ofliunterdon Ss On this l0d,day of April,2024 before me,a Notary Public of New Jersey,personally came Rupert IID Swindells and Warren F.ichhorn,tome known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Rupert HD Swindells and Warren Eichhorn,being by me duly sworn, severally and each for himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL-INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY.WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of said Companies,and that their signatures as such officers were duly affixed and subscribed by like authority Notarial Seal AlbeCorsexarsf NOTAX rt OU61LIC of facw xfRSEY �saa' No S0202369 Let�c Commission Fxpirout Aaatait 22,21727 weary tubttr CERTIFICATION Rrsolutions adopted by the Boards of Directors of FEDERAL.INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016; WESTCHESTER FIRE INSURANCE COMPANY on December 11,2006;and ACE AMERICAN INSURANCE.COMPANY on March 20,2009: 'RESOLVED that the following authorizations relate to the execution,for and on behalf of the Company,of bonds,undertakings,rtcognizances.contracts and other written commitments of the Company entered int,In the ordinary snursr of business(eaIt a'Wrmen Commitment-) (11 Each of the ChalrmaR the President and the Via Presidents of the Company is hereby authorized to execute any Written Commitment for and on behalfo(lhe Company.under the seal of the Company or otherwise (21 Each duly appointed anarrxy-In•facl of the Company Is hereby authorized to execute any Written Commitmrm for and on behalf of the Company under the seal of the Company or otherwise to the extent that such action Is authorized by the grant of powers provided for In such person s written appointment as such attorneydrrfact (3; Each of the Chairman.the President and the Vice Presidents of the Company is hereby authorired for and on behalf of the Company,to appoint In writing any person the attorney dm fact of the Company with full power and authority to execute,for and on behalfof the Company under the seal ofthe Company or otherwise such written Commitments of the Company as may be specified In such written appointment,which specification maybe by general type or class of Written Commitments or by specification of one or more partimlx Written Commitments (4) Each of the Chairman. the President and the vice Presidents of the Company is hr reby authorized for and on behalfof the Company,to delegate in writing to any other officer of the Companylheauthuritytoexecule,.forandonbehalf of the Company,under the Company's seal ir-dherwise,such Written Commitments of the Company as are specified in such written delegatton,whichspeclfkUllon may be by general"or classo(Written Commitments or by s ped nation of o no or more particular Written Commitments (S) The signatum of any officer or other person executing any written Commitment or apj, mment or delegalbm pursuant to this Resolution.and the seal of the Company may be affixed by fxslmlle on such written rommllment or written appointment or delegation. FURTHER RESOLVED,that the formgoing Resokitlon shall not be deemed to be an exclusive statement of the powers and authority of offlctrs.employees and other persons to act for and on behalf of the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or aulharityotherwue validly granted or vested.' I Rupert HD Swindells,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the"Companies-)do hereby certify that (1) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and in full force and effect, (f)) the foregoing Power of Attorney is true correct and in full force and effect. (.Iven under my hand and seals of said Compan les at Whltebnuse Station,NJ,this /4 Of , 2024 ----z Rupert HD Swindells.Assist-art Secrittary IN THF.EVENT YOU WISH TO VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER PLEASE CONTACT US AT Telephone(906)903.3493 Fax 1908)903.3656 -ail:suretyO hubbcum Combined.FEO-VIG-Pi-WFIC-AAIC(rev 11.19) This Power of Attorney limb the ads of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. I Liberty Liberty Mutual Insurance Company ML1tLid�. The Ohio Casualty Insurance Company Certificate No 8205857.974105 X5 West American Insurance Company SURETY POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duty organized under the laws of the State of New Hampshire.that Liberty Mutual Insurance Company is a oorporabon duly organized under the laws d the State of Massachusetts and West American Insurance Company is a corporation du y organ zed under the laws of the State of Indiana(herein collectively called the'Comparues'),pursuant to and by authority herein set forth.does hereby name.constitute and appoint, Andrew A Adams;John A.Prince,Larry D.Sni&r,Michael Macomber;Norman I Adams all of the city of Ilouston stale of TX each individually if there be more than one named,its he and lawful attorney-in-lad to make, execute,seal,acknowledge and deliver,for and on its behalf as surety and as its ad and deed,any and all undertakings bonds,reeognizances and ober surety oblgabons,in pursuance of these presents and shalt be as binding upon the Companies as if they have been duty signed by the president and attested by the sauetary of the Companies in their atm proper persons IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the copo,ale seals of the Companies have been affixed thereto this 29th day of Junc 2021 Liberty Mutual Insurance Company "Al INS& INSbq, The Ohio Casualty Insurance Company tiJ 4°aro�r �O J 1`0�rR9t :'o1 0 West American Insurance Company 1912 c 1919 *w 1991 s o 0 1 O Vf N .rcHQ$ .�D ZO�ti�rr%`'�D� ra xot�Hr ,D! a) OU C 8j1 ��► til + >`� dk r �� By: — m David til.Carey,Assistant Secretary ra o c`o State of PENNSYLVANIA ss m =i County of MONTGOMERY o E U .L j On Ihis 28th day of June 2021 before me personalty appeared David M Carey who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance ori o Company,The Ohio Casualty Company,and West American Insurance Company,and that he,as such being authorized so to do,execute the foregoing instrument for the purposes`€ N duty auofficer therein contained by signing on behalf of the corporations by himself as a dthorized — IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at Kug of Prussia.Pennsylvania,on the day and year first above written Q7 O 00 O Q�'��oNw 3rd` Conn on unh of pw"WA ne Notary Sed T 41ti�� ��i➢ Ta+sa MfEW.NotWy Ptbk y.— OR1 C o f Monlea wy CwTty My oytntiawn npM Match?s.2025 By; y ` �t corm"31on nwnbw 11200" P"'pPat4a. d) LvW" M*nW PM rk*u ru bttn of Ha... sNotary Public Q O co d 4qy O IT This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company Liberty Mutual 3:°Np E G Insurance Company.and West American Insurance Company which resolutions are now in full force and effect reading as follows: O C14 d M t_6 ARTICLE IV-OFFICERS:Section 12 Power of Altomey o 0 o Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the 0 co President may prescribe shall appoint such aftomeys4n-fad,as may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety M_ tu C any and all undertakings,bonds,raoognizances and other surety obligations.Such attomeys-in-fad-subject to the limitations set forth in their respective powers of attorney shall v t have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation.When so executed,such c m Zv instruments shall be as binding as if signed by the President and attested to by the Secretary Any power or authority granted to any representative or aftomey-m-fad under the m provisions of this article may be revoked at any time by the Board,the Chairman the President or by the officer or officers granting such power or authority ti CL2 ARTICLE XIII-Execution of Contracts:Section 5 Surety Bonds and Undertakings Any officer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such imitations as the chairman or the president may prescribe, shall appoint such attorneys-in-fact,as may be necessary to ad in behalf of the Company to make,execute seal.acknowledge and deliver as surety any and all undertaldnigs, bands,recognizances and other suety obligations.Such attorneys-in-fact subject to the limitations set forth in their respective powers of attorney,shall have fun power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company When so executed such instrixments shall be as binding as ri signed by the president and attested by the secretary Certificate of Designation-The President of the Company,acting pursuant to the Bylaws of the Company authorizes David M Carey,Assistant Secretary to appoint such attomeys4n- fad as may be necessary to ad on behalf of the Company to make,execute,seal acknowledge and dekver as surety any and all undertakings,bonds,recognizanlces and other surety obligations Authorization-By unan mous consent of the Company's Board of Directors,the Company oonsenls that facsimile or mechanically reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power M attorney issued by the Company n connection with surety bonds,shall be valid and binding upon the Company with the same force and effect as though manually affixed I,Renee C.Llewellyn,the undersigned,Assistant Secretary,The Ohio Casualty Insurance Company.Liberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the original power of attomey of which the foregoing is a full true and correct copy of the Power of Attorney executed by said Companies 1s in fuT force and effect and has not been revoked IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this�_day of 11tKgU[f 2024 \Nsu r��r INS& %148tr �J `oRro4r ti J Prov v' °r coy + 1e919�! 1991 c By: rd��eecHv� D O a ,�t4 � e *"''*�+a rod °�•*��D Renee C Llewellyn,Assistant Secretary LMS 12813 LMIC C)CIC WAIC Muni Co 72121 C H U B B surer 0 + 908 903 3485 202B flails Mill Road.PO Box 1650 F +908 903 3656 Whitehouse Statism NJ 08889-1650 Federal Insurance Company Liberty Mutual Insurance Company AIA Document A3121"I- 2010 Payment Bond K4187S525(Federal) 58S218516(Uberty Mutual) Am %tngular reference to Contractor.Surct3.O%vncr or tdher part%shell be considered plural.%here appltcahlc CONTRACTOR SURETY (.Name, legal slants and address) (Varve, legul slalus and principal place of liusuves ) SpawGlass Contractors,Inc. Federal Insurance Company(IN) 1111 Smith Road Austin,Texas 78721 Liberty Mutual Insurance Company(MA) OWNER (Nan►e. legal slalrts and address) City of Round Rock 221 East Main Street Round Rock,TX 78644 CONSTRUCTION CONTRACT Date: 6— day of he 1,- ,2024 Amount: $8,477,199.000 Eight Million Four Hundred Seventy Seven Thousand One Hundred Ninety Nine& 00%100 Dollars Description(Nance and Location): Old Settlers Park Buildout-Package 3A.2-Harrell Parkway BOND Date(Not earlier than Consrruclion Conliad Date) A day of 17Mja&r 2024 Amount: $8,477,199.00 Eight Million Four Hundred Seventy Seven Thousand One Hundred Ninety Nine& 00/100 Dollars Modifications to this Bond: El None O See Page 4 CONTRACTORS AS PRINCIPAL SURETY Company: SpawGlass ,Inc. (Cu-pnvreSealt Company: WorporareSeah Federallnsuran Co p ibcrty Mutual Insur ce C a Signal e!_ N e andD Paden Signature resident -Austin Division Attorney-i act Na e: John A.Prince Signed and Sealed this If day of 17*?, her ,2024 (.In)'utldilional.signaltn•es appear on the lust page ofthis Peel/rtpwnce Bond) (FOR 1VFOR.%t ITIOV ONIA' Vante. .Iddi-ess rnvd T elepholle) AGENT or BROKER: OWNER'S REPRESENTATIVE(Archttect.largttteeror atltmtxs1t) Adams Insurance Service 427 W loth.Suite Soo Houston,TX 77oo8 713-869-8346 Printed in cm1wratinn lath the tntrrican Instmne of Architects(41.4)hvChubb 7'he lungtutge in this document conforms to the language used rn AL1 Psicutnettt AJ12"-2010. Fw 15.02-0574.FY0(Re 11 16) l L The Contractor and the Surety,jointly and severally,bind themselves,their heirs,executors,administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. 2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. 3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13)of claims,demands,liens or suits against the owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. 4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. 5. The Surety's obligations to a Claimant under this Bond shall arise after the following: 5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was, furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). 52 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety (at the address described in Section 13). 6. If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment tinder Section 5.1.1. 7. When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: 7.1 Send an answer to the Claimant,with a copy to the Owner, within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and 72 Pay or arrange for payment of any undisputed amounts. 73 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing theClaimant. & The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. R Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any,under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. Printed iti cooperation with the AmeHcrut lrtstitute of Architects(AIA)by Chubb. The language in this d"unnent conforms to the language used in A1 Document A312 r"•2010. Form 15410574-FEU Wvv.]VIO 7 IR The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant tinder this Bond,and shall have under this Bond no obligations to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. IL The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is subject of the Construction Contract is located or after the expiration of one year from the date (t) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs. If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 13. Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page which their signature appears. Actual receipt of notice or Claims, however accomplished,shall be sufficient compliance as of the date received. kl When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. L5. Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. 16 DEFINITIONS 16.1 Claim.A written statement by the Claimant including at a minimum; .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4a brief description of the labor,materials or equipment furnished; .S the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6the total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and, .8the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. 162 Claimant:An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials,or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim tinder an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water,gas power, light, heat, oil gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor Printed ill cooperation with the American Institute of Architects(AM)bt-Chubb. The language in this docmnent conforms to the language used in AIA Doeumetet A312*"-2010. Porus 1,02(157 I-M)IR"11'161 3 and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. 163 Construction Contract: The agreement between the Owner and the Contractor identified on the cover page,including all Contract Documents and all changes made to the agreement and the Contract Documents. 16AOwner Default:Failure of the Owner,which has neither been remedied nor waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 165 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. O. If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. I& MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: I&I "Claim notices for FEDERAL.INSURANCE COMPANY must be sent to the following address: Chubb,PO Box 2191, Chesapeake,Virginia 23327,Attention:Surety SupportTeam." (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporateseal) Federal Insurance Company Signature:6 _ Signature: Name and Title: Name and Title: Address: Address: Printed ill cooperation with fire American brstitute ojArchitects(AW by Chubb. Tire language in this document carI orrrrs to the language used in AIA Voctt►nent A312'4•2010. hwln 1"201,71".D(Re, 1111.: ,i CHUBB Power of Attorney Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents,that FEDERAL INSURANCE COMPANY,an Indiana corporation VIGILANT INSURANCE COMPANY,a New York corporation,PACIFIC INDEMNITY COMPANY,a Wisconsin corporation,WESTCHESTER FIRE.INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations of the Commonwealth of Pennsylvania, do each hereby constitute and appoint Andrew A.Adams,Norman E.Adams,Michael Macomber,John A.Prince and Larry D.Snider of Houston,Texas---- each as their true and lawful Attorney-tn-Fact to execute under such designation in their names and to affix their corporate seals to and del Wer for and on their hehalf as surety thereon or otherwise,bonds and undertakings and other writings obligatory In the nature thereof(other than ball bonds)given or executed In the course of business,and any instruments amending or altering the same,and consents to the modification or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have each executed and attested these presents and affixed their corporate seals on this 100i day of April 2024. Rupert HD Swindells.Assistaint Seeretary 113rrin Eichhr rn l kc 11n-�4dou STATE OF NEW IF-RSEY County of Hunterdon ss On this IOth day of April,2024 before me,a Notary Public of New Jersey,personally came Rupert HO Swindells and Warren Efchhorn,to me known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY.VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,W ESTCHESTER FIRE INSURANCE COMPANY and ACF. AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Rupert HD Swindells and Warren Eichhorn.being by me duly sworn, severally and each for himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FiRE.INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of said Companies:and that their signatures as such officers were duly affixed and subscribed by like authority. Notarial Seal Ain."east+W NOTARY PMK OF NNW JERSEY �taa' No S02M69 titcic C—rtalsrslon Eagsires Aug-122,M? Notary F wk CERTIFICATION Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016; WESTCHESTER FIRE INSURANCE COMPANY on December 11,2006;and ACE AMERICAN INSURANCE COMPANY on March 20,2009: 'RESOI VED that the roll raving authorizations relate to the execution,for and on behalf of the Company,of bonds,undertakings,in cogrsfzances,mnlncts and other written commitments of the Company entered Into In the ordinary ccume of business leach a-Wrinen commitment') (1) Each of the Chairman,the President and the Vl,e Pres dents of the C:mpany is hereby authorized In execute any Written Commitment forandon behalfofthe Company.under the seal orthe Company or otherwise (2) Each dulyappolnled attorney in fact of the Company is herebyauthulzed to execute any Written Commitment for and onbehal(ofthe Company,under the seal oflhe Company or otherwise, to the extent that such action Is authorized by the grant of powers provided for n su,h person's wrlllcn appointment as suck auorney-in-fact 13) Each of the Chairman,the President and the Vice Presidents of the f:ompany is hembyauth.-Axed,for and on behalfofthe Company,to appoint In writing any person the attorney-in- fact of the Company with full power and authority to execute,for and on behalfofthe Company,under the seat ofthe Company or otherwise,such Written Commnmentsofthe Company as may be specified in such written appointment which specification may be by general type or class of Written Commitments or by specification of one or more particular Written Commitments (4) Each of the Chairman, the President and the Vice Presidents of the C—pany Is hereby authorized,I,and on behalf orthe Company.to delegate In writing to any other officer of the Company the authority to execute.for and on behalf of the Company under the Company*s seal cr otherwise,such Written Commitments o(lhs Company as art specified In such written delegation,which specincaucn may be by general type or class if written fcmmilmeru or by specificau mofoneor more particular Written Commitments (S) The signature of any officer or other pers•:o executing any Written Commitment or appointment or delegatWn pursuant to this Resolution.and the seal of the Company,may he affixed by f—Irrille on such Written Commitment or wr nen appointment or delegation. FURTHER RESOLVED,that the foregoing Resolution shall not be deemed to be an exclusive statement of the powers and authority of afficers,employees and other persons to act for and on behalf of the Companyand such Resolution shalt not limit or itherwise affect the exercise of any u-h power or authority otherwise validly granted"vested' I,Rupert IID Swindells.Asslstant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY.WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the'Companies-)do hereby certify that (I) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and In full force and effect, (it) the foregoing Power of Attorney is true,correct and In full force and effect. G von under my hand and seals of said Companies at Whitehouse Station,NL this Of 2024 ®� Rupert HD Swindells.Assistant Secrent}, IN TUF FVFNT YOU WISH TO VERIFY TIIE AUTHENTICITY OFTHIS BOND OR NOTIFY US OF ANY 017I4ER MATTER PLEASECONTACr US AT Tekphone(906)903-3493 Fax(908)903.3656 e-mail:surety@ichubbcom Combined:FED-VIGPI-WFIC•AAIC(rev 11.191 This Power of Attorney limits the ads of those named herein,and they have no authority to bind the Company except in the manner and to the extent haroln stated. Liberty Liberty Mutual Insurance Company mutum. The Ohio Casualty Insurance Company Certificate No $205857-974105 SURETY West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the Slate of New Hampshire,that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts,and West American Insurance Company is a corporation duly organized under the laws of the Stale of Indiana(herein col actively called the*Companies*),pursuant to and by authority herein set forth,does hereby name,constitute and appoint, Andrew A. Adams;John A.Princc;Larry D.Snider;Michael Macomber;Nonnan fi.Adams all of the city of Houston state of TX each individually if there be more than one named,its true and lawful atiomey-in-fact to make, execute,seal,acknowledge and deliver,for and on its behalf as surety and as its ad and deed.any and all undertakings,bonds,rec ognaances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 28th day of June 2021 Liberty Mutual Insurance Company tNill *qtr INS& tNSUq, The Ohio Casualty Insurance Company of °yr6O� J pjfOt*r� 0 �4r�oc otir fO West American Insurance Company ui 1912 o cQ3 1919, a i 1991 y rd� c*���D OhxaND rMa�+'N+D! By: C o C 1 ♦ M ♦ ti -- ta David M Carey,Assistant Secretary 3 f0 cit State of PENNSYLVANIA c , N D County of MONTGOMERY ss o E U w j On this 28th day of June 2021 before me personally appeared David M Carey who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance cur ro Company,The Ohio Casualty Company,and West American Insurance Company and that he,as such being authorized so to do,execute the foregoing instrument for the purposes`E Cotherein contained by signing on behalf d the corporations by himself as a duty authorized officer W g —v IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at King of Prussia,Pennsylvania on the day and year first above written M y eP PasT a= o�yotiw�r F�9 Cannnnrsarm of uvw sa,l�Ypr�i n' �� ti M« aqw c«�r l E y xa Lo My o7mesm MMU 29.2025 By: � C W v'�� M„„r».oma,,, A4306~of erase Pastella,Notary Public Q o Of a) Rv 1 v t d This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty nsurance Company Liberty Mutual 3 0-S Insurance Company,and West American Insurance Company which resolutions are now in full face and effect reading as blows 0 M cur ARTICLE IV-OFFICERS:Section 12 PowerofAttorney ods 0 T An officer a other official of the Corporation authorized for that a Any Corpor purpose in writing by the Chairman a the President and subject to such km talion as the Chairman a the�coPresident may prescribe,shall appoint such atiomeys-n-fad,as may be necessary to ad in behalf of the Corporation to make,execute seal,acknowledge and deliver as surety —_ C any and all undertakings,bonds,recognizances and other surety obligations Such attorneys-in-fad,subject to the limitations set forth in their respective powers of attorney,shat a s t have full paver to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed such g cur Zu instruments shall be as binding as if signed by the President and attested to by the Secretary Any power or authority granted to any representative or attorney-in-fad under the cc provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer or officers granting such power or authority ti m ARTICLE XIII-Execution of Contracts:Section 5.Surety Bonds and Undertakings. Any officer of the Company authorized fa that purpose in writing by the chairman or the president,and subject to such limitations as the cabman or the president may prescribe. shall appoint such attomeys4-fad as may be necessary to act in behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings bonds,recognizances and other surety obligations Such attorneys-in-fad subject to the limitations set forth n their respective powers of attorney shall have full power to bind the Company by their signahxe and execution of any such instruments and to attach thereto the seal of the Company When so executed such instruments shall be as binding as of signed by the president and attested by the secretary. Certificate of Designation-The Resident of the Company,acting pursuant to the Bylaws of the Company,authorizes David M Carey Assistant Secretary to appoint such attomeysan- fad as may be necessary to ad on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings bonds reoognizances and other surety obligations Authorization-By unanimous consent of the Company's Board of Directors,the Company consents that facsimile or mechanic8#y reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power of anomey issued by the Company in connection with surety bonds,shall be val d and binding upon the Company with the same face and effect as though manually affixed. I,Renee C.Llewellyn,the undersigned,Assistant Secretary,The Ohio Casualty Insurance Company,Liberty Mutual Insurance Company and West American Insurance Company do hereby car*that the original power of attorney of which the foregoing is a full,true and cared copy of the Power of Attorney executed by sa d Compan es is in fu-force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this day of /2024 '`INSIx,p- '`tY INaU �tNSU� J 3°�r�r6��i� c3J3�oNo�r''° c+ 4r oFro�r q. = 1912 Q 1919 a 3`19916 By 4 Q �,�•, lit, x* D y0 h•"'' s �4�sou"r��a� Renee C Llewellyn,Assistant Secretary 1 a S M • � LMS-12973 LMIC oCIC WAIC Mun,Co 02121 Have a complaint or need help? Tiene una queja o necesita ayuda? IMPORTANTNOTICF. AWSO IMPORTANTh If you have a problem with a claim or your premiums,call Si tiene un problema con un reclamo o las primas,llame your insurance company first. If you can't work out the primero a la empress de seguros.Si no puede resolver el issue, the Texas Department of Insurance may be able to problema,el Departamento de Seguros del estado de Tejas help. puede ayudar. Even if you file a complaint with the Texas Department of Si registra una queja con el Departamento de Seguros del Insurance, you should also file a complaint or appeal estado de tejas,tambien debe presentar una queja o through your insurance company. If you don't, you may apelacion a traves de su compania de seguros.Si no to hace lose your right to appeal. puede perder su derecho de apelar. To get information or file a complaint with CHUBB: Para obtener informacion o registro de una queja con CHUBB: Call Toll-free:i-Soo-36-CHUBB Llame al:i-Soo-36-CHUBB Mail: Eastern Claim Service Center Correo: Eastern Claim Service Center 600 Independence Parkway 600 Independence Parkway Chesapeake,VA 23320 Chesapeake,VA 23320 Attn: Surety Support Attn: Surety Support Phone: 800-252-4670 Fax:800-664-5358 Telefono: 800-252-467o Fax: 800-664-5358 Email: ecse.claims@chubb.com Correo electronico: ecsc.claims@chubb.com To get help with an insurance question or file a complaint Para ayuda con una pregunta de seguros o registrar una with the state: queja con el estado: The Texas Department of Insurance El Departamento de Seguros del Estado de Tejas Call with a question: 1-800-252-3439 Preguntas: 1-800-252-3439 File a complaint: www.tdi.texas.gov Quejas: www.tdi.texas.gov E-mail: ConsumerProtectionC tdi.texas.gov Correo electronico: ConsumerProtectionC'tdi.texas.gov Mail: MC-111-1A,P.O. Box 149091 Correo: MC-111-1A,P.O.Box 149091 Austin,TX 78714-9091 Austin,TX 78714-9091 Fbrni15•10-01a7(Rev t,23) Libe utualrty M . SURETY TEXAS TEXAS IMPORTANT NOTICE AVISO IMPORTANTE To obtain information or make a complaint: Para obtener informacion o para someter una queja: You may call toll-free for information or to Usted puede Ilamar al numero de telefono gratis make a complaint at para informacion o para someter una queja al 1-877-751-2640 1-877-751-2640 You may also write to: Usted tambien puede escribir a: 2200 Renaissance Blvd., Ste. 400 2200 Renaissance Blvd., Ste. 400 King of Prussia, PA 19406-2755 King of Prussia.. PA 19406-2755 You may contact the Texas Department of Puede comunicarse con el Departamento de Insurance to obtain information on companies, Seguros de Texas para obtener informacion coverages, rights or complaints at acerca de companias, coberturas, derechos o 1-800-252-3439 quejas al 1-800-252-3439 You may write the Texas Department of Insurance Puede escribir al Departamento de Seguros Consumer Protection (l 1 1-I A) de Texas Consumer Protection(1 1 1-I A) P. 0. Box 149091 P. 0. Box 149091 Austin, TX 78714-9091 Austin, TX 78714-9091 FAX: (512)490-1007 FAX # (512)490-1007 Web: http://www.tdi.texas.gov_ Web. h"p://www.tdi.tr,2sas.vo E-mail: ConsumerProtectionntdi.texas.gov E-mail: ConsumerProtectionna tdi.texas.gov PREMIUM OR CLAIM DISPUTES: DISPUTAS SOBRE PRIMAS 0 RECLAMOS: Should you have a dispute concerning your Si tiena Una disputa concemiente a su prima o a premium or about a claim you should first un reclamo, debe comunicarse con el agente o contact the agent or call 1-800-843-6446. primero. Si no se resuelve la disputa, puede If the dispute is not resolved, you may contact the entonces comunicarse con el departamento(TDI) Texas Department of Insurance. ATTACH THIS NOTICE TO YOUR UNA ESTE AVISO A SU POLIZA: POLICY: This notice is for information only and does not Este aviso es solo para proposito de informacion become a part or condition of the attached y no se convierte en parte o condicion del document. documento adjunto. NP 70 69 09 01 1 M 5-15792 I W 15 SpawGlass +._ Providing the Absolute B' / / Experience r- OFF 90% GMP R1 b , CITY OF ROUND ROCK OLD SETTLER'S PARK BUILDOUT PROJECT Harrell Parkway Package 3A.2 };+' November 6th, 2024 "Im' ,RI ,.4�0 TABLE OF CONTENTS TAB 1 TAB 6 GUARANTEED MAXIMUM PRICE PROPOSED GMP BREAKDOWN PROPOSAL FORM TAB TAB EXECUTIVE PROJECT SUMMARY MASTER PROJECT SCHEDULE TAB 3 TAB 8 PROJECT TEAM PROCUREMENT PACKAGE STRATEGY TAB 4 TAB 9 LIST OF DOCUMENTS TAB 5 TAB 10 ASSUMPTIONS & CLARIFICATIONS AB1 GUARANTEED MAXIMUM PRICE PROPOSAL FORM i t J" `may i F it SpawGlass 1 . Project Cost Summary 90% CD ESTIMATE OVERVIEW SpawGlass Contractors, Inc. hereby submits to the City of Round Rock for the use and benefit of the new Old Settler's Park Buildout - Package 3A.2 Harrell Parkway Realignment, a CMAR price based on the 90% CD Drawings, as follows: 1. The proposed amount for the Direct Cost of the Work: $ 7,232,510 2. General Conditions $ 221.758 3. General Liability Insurance (.78%) $ 66,122 4. Payment & Performance Bonds $ 71,102 5. Subcontractor Default Insurance (1.25% of C.o.W.) $ 90,406 6. Contractors Contingency (3%) $ 254,316 7. Construction Phase Fee (3.50%) $ 286,669 8. Owner/Design Progression Contingency (3.00%) $ 254.316 9. TOTAL: LINE ITEMS 1 THROUGH 8: $ 8,477,199 TuLef- Wewtet, Tyler Wenzel, Project Executive 1 ' t �Eo_0 I�U Providing the Absolute Best Construction Experience 1 Executive Summary City of Round Rock - Old Settler's Park Build Out Package 3A.2- Harrell Parkway Realignment 90% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 Scope of Work Package 3A.2 - Harrell Parkway Realignment is the modification of the existing road. This includes demo, road base, asphalt, striping, site utilities relocation, traffic control, new trails, new sidewalks, and landscaping. Overview The new Harrell Parkway Re-alignment modifies the existing road going through the middle of the Old Settler's Park. This work is planned to be completed in three main stages: 3A.1 - The road in front of the Lakeview project and the connection to Kenny Fort is the first phase, which allows the Lakeview package to be completed and allows a bypass by this connection. This phase also includes installation of the Lakeview parking lot and two new grass fields, of which these must be completed prior to the Multipurpose Complex commencing work. It is assumed that the entirety of the 3A.1 Harrell Parkway will be shutdown. 3A.2 - This phase is the rest of the road, minus the vehicular bridge. This phase will require the road to be re-built, while maintaining public access via pedestrians and vehicles. It is assumed that this section of Harrell Parkway must be partially open to the public during this construction phase. 3A.3 - This phase is the Chandler Branch vehicular bridge. The phasing of this road is crucial to allow for the construction to be completed, while keeping the park open and active to the public. This road also ties into all the other packages, which leads this package to be coordinated with the other packages schedule and logistics plan. i A/ TAB PROJECT TEAM 4 ti •.A S -P f � r r N1/M� SpawGIass Providing the Absolute Best Construction Experience ORGANIZATION CHART LEGEND Management Support Team Lead/Single Point-of-Conlact On sde Team Safety CITY OF ROUND ROCK Preconstruction/EstimatingSupport DAVID PADEN ' =-"' TOM MCCLANAHAN JOEY GEORGE ADAM WARDEN OPERATIONS MANAGER JUAN MARQUEZ BRIAN CLAXTON SAFETY COORDINATOR BIMNDC COORDINATOR JTYLER WENZEL PROJECT EXECUTIVE/ PRECONSTRUCTION SERVICES MANAGER PER BLASCHKE _ HARRISON HOLLEY SENIOR PROTECT MANAGER CHRIS SOTOJECTMANAGER © ASSISTANT SUPERINTENDENTS ASSISANT PRr DAYLON DYESS 0 ASSISTANT PROJECT MANAGER OUALITY CONTROL COORDINATOR TAB 4 LLIST OF DOCUMENTS 21z �i r1 � + a `1y -w t � Providing the Absolute Best Construction Experience 0 List of Documents City of Round Rock-Old Settler's Park Build Out Package 3A.2-Harrell Parkway Realignment 90%CD Drawings 3300 E Palm Valley Blvd Round Rock,TX 78665 PAGE# SHEET DESCRIPTION REVISION DATE Page 1 R-1-COVER PAGE 9/13/2024 Page 2 R-2-INDEX OF SHEETS 9/13/2024 Page 3 R-3-PROJECT LAYOUT 9/13/2024 Page 4 R-4-SURVEY CONTROL 9/13/2024 Page 5 R-5-SURVEY CONTROL 9/13/2024 Page 6 R-6-SURVEY CONTROL 9/13/2024 Page 7 R-7-SURVEY CONTROL 9/13/2024 Page R-8-SURVEY CONTROL 9/13/2024 Page 9 R-9-SECTIONS EXISTING TYPICAL 9/13/2024 Page 10 R-10-SECTIONS PROPOSED TYPICAL 9/13/2024 Page 11 R-11-SECTIONS PROPOSED TYPICAL 9/13/2024 Page 12 R-12-GENERAL NOTES 9/13/2024 Page 13 R-13-SUMMARY OFTRAFFIC CONTROL PLAN QUANTITIES 9/13/2024 Page 14 R-14-REMOVAL QUANTITIES SUMMARY OF 9/13/2024 Page 15 R-15-SUMMARY OFROADWAY QUANTITIES 9/13/2024 Page 16 R-16-ROADWAY QUANTITIES SUMMARY OF 9/13/2024 Page 17 R-17-DRAINAGE QUANTITIES SUMMARY OF 9/13/2024 Page 18 R-18-ILLUMINATION QUANTITIES SUMMARY OF 9/13/2024 Page 19 R-19-AND PAVEMENT MARKINGS SUMMARY OF SIGNING 9/13/2024 Page 20 R-20-CONTROL QUANTITIES SUMMARY OF EROSION 9/13/2024 Page 21 R-21-NARRATIVE TRAFFIC CONTROL PLAN 9/13/2024 Page 22 R-22-STEP A DETOUR PLAN LAYOUT TRAFFIC CONTROL 9/13/2024 Page 23 R-23-STEP B DETOUR PLAN LAYOUT TRAFFIC CONTROL 9/13/2024 Page 24 R-24-STEP B TYPICAL SECTIONS TRAFFIC CONTROL PLAN 9/13/2024 Page 25 R-25-STEP B TRAFFIC CONTROL PLAN 9/13/2024 Page 26 R-26-STEP C DETOUR PLAN LAYOUT TRAFFIC CONTROL 9/13/2024 Page 27 R-27-STEP C TYPICAL SECTIONS TRAFFIC CONTROL PLAN 9/13/2024 Page 28 R-28-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 29 R-29-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 30 R-30-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 31 R-31-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 32 R-32-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 33 R-33-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 34 R-34-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 35 R-35-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 36 R-36-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 37 R-37-STEP C TRAFFIC CONTROL PLAN 9/13/2024 Page 38 R-38-STEP D DETOUR PLAN LAYOUT TRAFFIC CONTROL 9/13/2024 Page 39 R-39-STEP D TYPICAL SECTIONS TRAFFIC CONTROL PLAN 9/13/2024 Page 40 R-40-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 41 R-41-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 42 R-42-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 43 R-43-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 44 R-44-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 45 R-45-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 46 R-46-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 47 R-47-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 48 R-48-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 49 R-49-STEP D TRAFFIC CONTROL PLAN 9/13/2024 Page 50 R-50-STEP E DETOUR PLAN LAYOUT TRAFFIC CONTROL 9/13/2024 Page 51 R-51-STEP E TYPICAL SECTIONS TRAFFIC CONTROL PLAN 9/13/2024 Page 52 R-52-STEP E TRAFFIC CONTROL PLAN 9/13/2024 Page 53 R-53-DETAILS CITY STANDARD 9/13/2024 Page S4 R-54-AND REQUIREMENTS GENERAL NOTES BARRICADE AND CONSTRUCTION 9/13/2024 Page 55 R-55-PROJECT LIMIT BARRICADE AND CONSTRUCTION 9/13/2024 Page 56 R-56-WORK ZONE SPEED LIMIT BARRICADE AND CONSTRUCTION 9/13/2024 Page 57 R-57-TEMPORARY SIGN NOTES BARRICADE AND CONSTRUCTION 9/13/2024 Page 58 R-58-TYPICAL SIGN SUPPORT BARRICADE AND CONSTRUCTION 9/13/2024 Page 59 R-59-MESSAGE SIGN(PCMS)PORTABLE CHANGEABLE BARRICADE AND CONSTRUCTION 9/13/2024 Page 60 R-60-WARNING LIGHTS&ATTENUATOR ARROW PANEL,REFLECTORS, BARRICADE AND CONSTRUCTION 9/13/2024 Page 61 R-61-CHANNELIZING DEVICES BARRICADE AND CONSTRUCTION 9/13/2024 Page 62 R-62-CHANNELIZING DEVICES BARRICADE AND CONSTRUCTION 9/13/2024 Page 63 R-63-CHANNELIZING DEVICES BARRICADE AND CONSTRUCTION 9/13/2024 Page 64 R-64-PAVEMENT MARKINGS BARRICADE AND CONSTRUCTION 9/13/2024 Page 65 R-65-PAVEMENT MARKING PATTERNS BARRICADE AND CONSTRUCTION 9/13/2024 Page 66 R-66-LOW PROFILE CONCRETE BARRIER PRECAST BARRIER (TYPE 1) 9/13/2024 Page 67 R-67-LOW PROFILE CONCRETE BARRIER PRECAST BARRIER (TYPE 2) 9/13/2024 Page 68 R-68-DETAILS ROAD CLOSURE WORK ZONE 9/13/2024 Page 69 R-69-PAVEMENT MARKINGS WORK ZONE SHORT TERM 9/13/2024 Page 70 R-70-SHOULDER WORK CONVENTIONAL ROAD TRAFFIC CONTROL PLAN 9/13/2024 Page 71 R-71-TRAFFIC CONTROL ONE-LANE TWO-WAY TRAFFIC CONTROL PLAN 9/13/2024 Page 72 R 72-UNDIVIDED HIGHWAYS MOBILE OPERATIONS TRAFFIC CONTROL PLAN 9/13/2024 Page 73 R-73-DIVIDED HIGHWAYS MOBILE OPERATIONS TRAFFIC CONTROL PLAN 9/13/2024 Page 74 R-74 TREATMNET FOR VARIOUS EDGE CONDITIONS 9/13/2024 Page 75 R-75-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page76 R-76-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page77 R-77-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 78 R-78-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 79 R-79-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 80 R 80-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 81 R-81-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 82 R-82-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 83 R-83-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 84 R-84-DATA SHEET HORIZONTAL ALIGNMENT 9/13/2024 Page 85 R-85-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 86 R-86-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 87 R-87-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 88 R-88-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 89 R-89-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 90 R-90-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 91 R-91-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 92 R-92-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 93 R-93-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 94 R-94-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 95 R-95-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 96 R-96-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 97 R-97-HARRELL PARKWAY PLAN&PROFILE ROADWAY 9/13/2024 Page 98 R-98-HERITAGE CROSSING PLAN&PROFILE ROADWAY 9/13/2024 Page 99 R-99.HARRELL PARKWAY PLAN&PROFILE SHARED-USE PATH 9/13/2024 Page 100 R-100-HARRELL PARKWAY PLAN&PROFILE SHARED-USE PATH 9/13/2024 Page 101 R-101-HARRELL PARKWAY PLAN&PROFILE SHARED-USE PATH 9/13/2024 Page 102 R-102-HARRELL PARKWAY PLAN&PROFILE SHARED-USE PATH 9/13/2024 Page 103 R-103-HARRELL PARKWAY PLAN&PROFILE SHARED-USE PATH 9/13/2024 Page 104 R-104-HARRELL PARKWAY PLAN&PROFILE SHARED-USE PATH 9!1312024 Page 105 R-105-HARRELL PARKWAY PLAN&PROFILE SHARED-USE PATH 9/13/2024 Page 106 R-106-HARRELL PARKWAY CONNECTION SHARED-USE PATH 9/13/2024 Page 107 R-107-HARRELL PARKWAY CONNECTION SIDEWALK 9/13/2024 Page 108 R-108-DETAIL PARKING LOT 9/13/2024 Page 109 R-109-DETAILS ROADWAY MISCELLANEOUS 9/13/2024 Page 110 R-110-DETAILS ROADWAY MISCELLANEOUS 9/13/2024 Page 111 R-111-DRIVEWAY DETAILS 9/13/2024 Page 112 R-112-FOOTING DETAILS MONUMENT SIGN OLD SETTLERS PARK 9113/2024 Page 113 R-113-FOOTING DETAILS MONUMENT SIGN OLD SETTLERS PARK 9/13/2024 Page 114 R-114-DETAILS CITY STANDARD 9/13/2024 Page 115 R-115-DETAILS CITY STANDARD 9/13/2024 Page 116 R-116-DETAILS CITY STANDARD 9/13/2024 Page 117 R-117-DETAILS CITY STANDARD 9/13/2024 Page 118 R-118-DETAILS CITY STANDARD 9/13/2024 Page 119 R-119 N HPW SHEET NO.-GF(31)-19 TL-3 MASH COMPLIANT 9/13/2024 Page 120 R-120 N HPW SHEET NO.-OWNSTREAM ANCHOR TERMINAL)GF(31)DAT-19 TL-3 MASH COMPLIANT 9/13/2024 Page 121 R-121-TL-3 MASH COMPLIANT METAL BEAM GUARD FENCE(MOW STRIP) 9/13/2024 Page 122 R-122-MEDIAN DETAILS PATH,SIDEWALK,AND MISCELLANEOUS CURB, 9/13/2024 Page 123 R-123-POST&CABLE FENCE 9/13/2024 Page 124 R-124-CURB RAMPS PEDESTRIAN FACILITIES 9/13/2024 Page 125 R-125-CURB RAMPS PEDESTRIAN FACILITIES 9/13/2024 Page 126 R-126-CURB RAMPS PEDESTRIAN FACILITIES 9/13/2024 Page 127 R-127-CURB RAMPS PEDESTRIAN FACILITIES 9/13/2024 Page 128 R-128-DETAILS PEDESTRIAN HANDRAIL 9/13/2024 Page 129 R-129-DETAILS PEDESTRIAN HANDRAIL 9/13/2024 Page 130 R-130-DETAILS PEDESTRIAN HANDRAIL 9/13/2024 Page 131 R-131-MASH-TL-3 SOFTSTOP END TERMINAL TRINITY HIGHWAY 9/13/2024 Page 132 R-132-MASH-TL-3 MAX-TENSION END TERMINAL 9/13/2024 Page 133 R-133-MSKT-MASH-TL-3 SINGLE GUARDRAIL TERMINAL 9/13/2024 Page 134 R-134-MAP DRAINAGE AREA 9/13/2024 Page 135 R-135-HARRELL PARKWAY SUMMARY DITCH TABLE 9/13/2024 Page 136 R-136-HYDRAULIC SUMMARY CULVERT HYDROLOGIC AND 9/13/2024 Page 137 R-137-CC-1 CULVERT LAYOUT 9/13/2024 Page 138 R-138-CC-2 CULVERT LAYOUT 9/13/2024 Page 139 R-139-DETAILS DRAINAGE MISCELLANEOUS 9/13/2024 Page 140 R-140-DETAILS CITY STANDARD 9/13/2024 Page 141 R-141-SAFETY END TREATMENT PIPE CULVERTS TYPE II-CROSS DRAINAGE FOR 12"DIA TO 60"DIA 9/13/2024 Page 142 R-142-SAFETY END TREATMENT PIPE CULVERTS TYPE II--CROSS DRAINAGE FOR 12"DIA TO 60"DIA 9/13/2024 Page 143 R-143-SAFETY END TREATMENT PIPE CULVERTS TYPE II-PARALLEL DRAINAGE FOR 12"DIA TO 72"DIA 9/13/2024 Page 144 R-144-STONE RIPRAP 9/13/2024 Page 145 R-145-STONE RIPRAP 9/13/2024 Page 146 R-146-ILLUMINATION LAYOUT 9/13/2024 Page 147 R-147-ILLUMINATION LAYOUT 9113/2024 Page 148 R-148-ILLUMINATION LAYOUT 9/13/2024 Page 149 R-149-ILLUMINATION LAYOUT 9/1312024 Page 150 R-150-ILLUMINATION LAYOUT 9/13/2024 Page 151 R-151-ILLUMINATION LAYOUT 9/13/2024 Page 152 R-152-ILLUMINATION LAYOUT 9/13/2024 Page 153 R-153-ILLUMINATION LAYOUT 9/13/2024 Page 154 IR-154-1 LU MI NATION LAYOUT 9/13/2024 Page 155 R-155-ILLUMINATION LAYOUT 9113/2024 Page 156 R-156-ILLUMINATION LAYOUT 9/13/2024 Page 157 R-157-DATA SUMMARY ELECTRICAL SERVICE 9/13/2024 Page 158 R-158-MARKING LAYOUT SIGNING&PAVEMENT 9/13/2024 Page 159 R-159-MARKING LAYOUT SIGNING&PAVEMENT 9/13/2024 Page 160 R-160-MARKING LAYOUT SIGNING&PAVEMENT 9/13/2024 Page 161 R-161-MARKING LAYOUT SIGNING&PAVEMENT 9/13/2024 Page 162 R-162-MARKING LAYOUT SIGNING&PAVEMENT 9/13/2024 Page 163 R-163-MARKING LAYOUT SIGNING&PAVEMENT 9/13/2024 Page 164 R-164-MARKING LAYOUT SIGNING&PAVEMENT 9/13/2024 Page 165 R-165-SIGN DETAILS EDGE LIT PEDESTRIAN 9/13/2024 Page 166 R-166-PAVEMENT MARKINGS TYPICAL STANDARD 9/13/2024 Page 167 R-167-MARKINGS REFLECTORIZED PROFILE RAISED MARKERS OSITION GUIDANCE USING 9/13/2024 Page 168 R-16-PAVEMENT MARKINGS AND LANE REDUCTION RURAL LEFT TURN BAYS, WO-WAY LEFT TURN LANES 9/13/2024 Page 169 R-169-DEVICE PLACEMENT SIGNING,STRIPING,AND DETAILS RAILROAD CROSSING 9/13/2024 Page 170 R-170-SIGNING&STRIPING DETAILS RAILROAD CROSSING 9/13/2024 Page 171 R-171-DESCRIPTION MATERIAL OBJECT MARKER DELINEATOR& 9/13/2024 Page 172 R-172-INSTALLATION OBJECT MARKER DELINEATOR& 9/13/2024 Page 173 R-173-PLACEMENT DETAILS OBJECT MARKER DELINEATOR& 9/13/2024 Page 174 R-174-PLACEMENT DETAILS OBJECT MARKER DELINEATOR& 9/13/2024 Page 175 R-175-PLACEMENT DETAILS OBJECT MARKER DELINEATOR& 9/13/2024 Page 176 R-176-PLACEMENT DETAILS OBJECT MARKER DELINEATOR& 9/13/2024 Page 177 R-177-ATTENUATORS FOR VEHICLE IMPACT OBJECT MARKER DELINEATOR& 9/13/2024 Page 178 R-178-CONDUITS&NOTES ELECTRICAL DETAILS 9/13/2024 Page 179 R-179-CONDUCTORS ELECTRICAL DETAILS 9/13/2024 Page 180 R-180-GROUND BOXES ELECTRICAL DETAILS 9/13/2024 Page 181 R-181-SERVICE NOTES&DATA ELECTRICAL DETAILS 9/13/2024 Page 182 R-182-AND NOTES SERVICE ENCLOSURE ELECTRICAL DETAILS 9/13/2024 Page 183 R-183 PEDESTAL SERVICE TYPE PS LECTRICAL SERVICE SUPPORT ELECTRICAL DETAILS 9/13/2024 Page 184 R-184 DETAILS ILLUMINATION ROADWAY 9/13/2024 Page 185 R-185-(RDWY ILLUM FOUNDATIONS)DETAILS ILLUMINATION ROADWAY 9/13/2024 Page 186 R-186-POLES ILLUMINATION ROADWAY 9/13/2024 Page 187 R-187-POLES ILLUMINATION ROADWAY 9/13/2024 Page 188 R-168-POLES ILLUMINATION ROADWAY 9/13/2024 Page 189 R-189-POLES ILLUMINATION ROADWAY 9/13/2024 Page 190 R-190-GENERAL NOTES&DETAILS SMALL ROADSIDE SIGNS SIGN MOUNTING DETAILS 9/13/2024 Page 191 R-191-TRIANGULAR SLIPBASE SYSTEM SMALL ROADSIDE SIGNS SIGN MOUNTING DETAILS 9/13/2024 Page 192 R-192-TRIANGULAR SLIPBASE SYSTEM SMALL ROADSIDE SIGNS SIGN MOUNTING DETAILS 9/13/2024 Page 193 R-193-TRIANGULAR SUPBASE SYSTEM SMALL ROADSIDE SIGNS SIGN MOUNTING DETAILS 9/13/2024 Page 194 R-194-REQUIREMENTS TYPICAL SIGN 9/13/2024 Page 195 R-195-REQUIREMENTS TYPICAL SIGN 9/13/2024 Page 196 R-196-REQUIREMENTS TYPICAL SIGN 9/13/2024 Page 197 R-197 TRAFFIC SIGNAL POLE FOUNDATIONS 9/13/2024 Page 198 R-198 N HPW SHEET NO.-SPRFBA(1)-13 DETAILS ASHING BEACON ASSEMBLY 9/13/2024 Page 199 R-199-CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 200 R-200-CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 201 R-201-CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 202 R-202-CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 203 R-203-CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 204 R-204-CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 205 R-205-SHARED USE PATH CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 206 R-206-SIDEWALK PLAN CONTROL PLAN SEDIMENTATION EROSION AND 9/13/2024 Page 207 R-207-DETAILS CITY STANDARD 9/13/2024 Page 208 R-208-DETAILS CITY STANDARD 9/13/2024 Page 209 R-209-DETAILS CITY STANDARD 9/13/2024 Page 210 R-210-REMOVAL PLAN 9/13/2024 Page 211 R-211-REMOVAL PLAN 9/13/2024 Page 212 R-212-REMOVAL PLAN 9/13/2024 Page 213 R-213-REMOVAL PLAN 9/13/2024 Page 214 R-214-REMOVAL PLAN 9/13/2024 Page 215 R-215-REMOVAL PLAN 9/13/2024 Page 216 W-1 -WATER,REUSE,AND WASTEWATER G ENERAL NOTES 9/13/2024 Page 217 W-2 -WATER,REUSE,AND WASTEWATER OVERALL LAYOUT 9/13/2024 Page 218 W-3 -STA 10+00 TO 14+00 8INCH WATER LINE"A"PLAN AND PROFILE(1 OF 2) 9/13/2024 Page 219 W-4 -STA 14+00 TO END 8 INCH WATER LINE"A"PLAN AND PROFILE(2 OF 2) 9/13/2024 Page 220 W-5 -STA 10+00 TO 14+00 B INCH WATER LINE"B"PLAN AND PROFILE(1 OF 5) 9/13/2024 Page 221 W-6 -STA 14+00 T018+008INCH WATER LINE"B"PLAN AND PROFILE(2 OF 5) 9/13/2024 Page 222 W-7 -STA 18+00 TO 22+00 8 INCH WATER LINE"B"PLAN AND PROFILE(3 OF 5) 9/13/2024 Page 223 W-8 -STA 22+00 TO 26+00 8 INCH WATER LINE"B"PLAN AND PROFILE(4 OF 5) 9/13/2024 Page 224 W-9 -STA 26+00 TO END 8 INCH WATER LINE"B"PLAN AND PROFILE IS OF 5) 9/13/2024 Page 225 W-10 -STA 10+00 TO END B INCH WATER LINE"C"PLAN AND PROFILE 9/13/2024 Page 226 W-11 -STA 10+00 TO 14+00 B INCH WATER LINE"D"PLAN AND PROFILE(1 OF 2) 9/13/2024 Page 227 W--12 -STA 14+00 TO END 8INCH WATER LINE"0"PLAN AND PROFILE(2 OF 2) 9/13/2024 Page 228 W-13 -STA 10+00 TO END 6INCH WATER LINE"A"PLAN LAYOUT 9/13/2024 Page 229 W-14-STA 10+00 TO END 6 INCH WATER LINE"B"PLAN LAYOUT 9/13/2024 Page 230 W-15 -STA 10+00 TO END 24 INCH REUSE LINE"A"PLAN AND PROFILE 9/13/2024 Page 231 W-16-STA 10+00 TO END 4INCH REUSE LINE"A"PLAN LAYOUT 9/13/2024 Page 232 W-17-STA 50+00 TO END 4INCH REUSE LINE"B"PLAN LAYOUT 9/13/2024 Page 233 W-18-STA 10+00 TO END 10 INCH WASTEWATER LINE"A"PLAN AND PROFILE 9/13/2024 Page 234 W-19-WATER,REUSE,WASTEWATER DETAILS(1 OF 4) 9/13/2024 Page 235 W-20 -WATER,REUSE,WASTEWATER DETAILS(2 OF 4) 9/13/2024 Page 236 W-21 -WATER,REUSE,WASTEWATER DETAILS(3 OF 4) 9/13/2024 Page 237 W-22-WATER,REUSE,WASTEWATER DETAIL(4 OF 4) 9/13/2024 Page 238 L-5.0-SITE DETAILS 9/13/2024 Page 239 L-5.1-SITE DETAILS 9/13/2024 Page 240 L-5.2-SITE DETAILS 9/13/2024 Page 241 L-5.3-SITE DETAILS 9/13/2024 Page 242 L-7.0-OVERALL KEYMAP 9/13/2024 Page 243 L-7.1-ROADWAY LANDSCAPE PLAN 9/13/2024 Page 244 L-7.2-ROADWAY LANDSCAPE PLAN 9/13/2024 Page 245 L-7.3-ROADWAY LANDSCAPE PLAN 9113/2024 Page 246 L-7.4-ROADWAY LANDSCAPE PLAN 9/13/2024 Page 247 L-7.5-ROADWAY LANDSCAPE PLAN 9/13/2024 Page 248 L-7.6-ROADWAY LANDSCAPE PLAN 9/13/2024 Page 249 L-7.7-ROADWAY LANDSCAPE SCHEDULE 9/13/2024 Page250 L 8.0-LANDSCAPE DETAILS 9/13/2024 Page251 L8.1-LANDSCAPE SPECIFICATIONS 9/13/2024 Page 252 L-9.0-OVERALL KEYMAP 9/13/2024 Page 253 L-9.1-ROADWAY IRRIGATION PLAN 9/13/2024 Page 254 L-9.2-ROADWAY IRRIGATION PLAN 9/13/2024 Page 255 L-9.3-ROADWAY IRRIGATION PLAN 9/13/2024 Page 256 L-9.4-ROADWAY IRRIGATION PLAN 9113/2024 Page 257 L-9.5-ROADWAY IRRIGATION PLAN 9/13/2024 Page 258 L-9.6-ROADWAY IRRIGATION PLAN 9/13/2024 Page 259 L-9.7-ROADWAY IRRIGATION SCHEDULE 9/13/2024 Page 260 L-10.1-IRRIGATION SPECIFICATIONS 9/13/2024 Page 261 L-10.0-IRRIGATION DETAILS 9/13/2024 AB 5 ASSUMPTIONS & CLARIFICATIONS ' > - ylt M3 v � tea •• �j��%rY!: r,� C�1 rr. t t I S awGlass r!'7 �{j�., • Assumptions and Clarifications City of Round Rock — Old Settler's Park Build Out Package 3A.2 - Harrell Parkway Realignment 90% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 GENERAL QUALIFICATIONS 1. Kimley Horn is the civil engineer of record. 2. Roadway, and Utilities specifications have been provided to SpawGlass. 3. Based on an anticipated NTP of January 2025 and SC of August 2026 for a total duration of 355 working days. 4. The baseline schedule is based on a 5-day work week. 5. Normal working hours have been included from 7:00 AM to 5:30 PM unless otherwise noted, with the exception of early concrete operations as deemed necessary. It is also assumed that work can occur on a 7 day a week schedule if required. Notify City Transportation Department on Wednesday before weekend work is scheduled for approval. 6. In order to subcontract scopes of work in a timely manner to meet the construction schedule it is assumed that buyout packages will be reviewed within 5 business days of their submission. 7. LEED Certifications or Green Building Programs are not incorporated into the project. 8. No Builders Risk Insurance is to be provided by SpawGlass as requested by CoRR at 7/15/2024 meeting. 9. Performance &Payment Bonds are provided by SpawGlass. 10. General Liability is provided by SpawGlass and included in this proposal. 11. The proposal assumes that the specified material and equipment are available as required to meet the schedule. If they are not available as required, we assume the Owner/Architect will authorize alternate material or equipment selections. If specified material is not available, SpawGlass will submit to the City for approval. 12. The owner must accept GMP within 60 calendar days, at which time pricing will expire. 13. General conditions were originally based on one overall project and GMP during the RFP/RFQ time, and as later outlined by the City. Any general conditions savings or losses from this package are to be rolled onto the other GMP packages as deemed necessary by SpawGlass. 14. SpawGlass budget pricing includes removal of the existing road in its entirety,This includes curbs, pavement, base, and lime stabilized base (if present). The proposed road will be built back with all new materials. 15. The quantities and unit rates of this proposal are based on the 90% CD Documents. Assumptions and Clarifications SPECIFIC QUALIFICATIONS Division 01 — General Reguirements and GenerMl Conditions 1. SpawGlass general conditions are included in the cost reports. 2. Construction photos will be taken on a regular basis by SpawGlass. Digital files will be turned in monthly. Aerial photos will also be taken. 3. Drone footage to be provided. 4. As-Built drawings, record drawings and record submittals will be kept in electronic format. These files will be accessible to all on the jobsite. 5. Reasonable repairs or damage caused by unknown factors will be funded from the CM Contingency, if funds remain AND approved by Owner. 6. Dimensional Control for the Project is included. 7. Individual non-photographic hard hat stickers for workers will be utilized. 8. On-site construction facilities have been included in this proposal. 9. Temporary barriers and enclosures are included to delineate construction zone from the public. 10. Construction cleaning and waste management have been included. 11. City fees related to tree mitigation to be by Owner. 12. No sound/vibration monitoring. 13. Dust control included in GR's. 14. No arborist included, city to use their own arborist.This city arborist includes tree trimming for construction activities and monthly reports that will be provided to SpawGlass on the tree health. Division 02 — Existing Conditions 1. The extent of demolition includes but limited too, removal of all existing asphaltic pavement, curbs, base material, piping, RCP, guard rails, handrails, and signage. Division 03 — Concrete 1. Includes valley gutters, sidewalk, ribbon gutters, and ramps. Division 04 — Masonry Division 05 — Metals Division 06 — Wood, Plastics, and Composites None included. Division 07 — Thermal and Moisture Protection Assumptions and Clarifications Division 08 - Openings Division 09 - Finishes Division 10 - Specialties 1. An allowance of$100,000 for the two monument signs is included. Division 11 - Eguipment 1. None included. Division 12 - Furnishings 2. None included. Division 13 - Special Construction 1. None included. Division 14 - Conveying Eauipment 1. None included. Division 21 - Fire Suppression 1. None included. Division 22 - Plumbina 1. None included. Division 23 - HVAC and Controls 1. None included. Division 26 - Electrical 1. Includes conduit, wiring, and site light fixtures. Division 27 - Communications Division 28 - Electronic Safety & Security 1. None included. Division 31 - Earthwork 1. Clear&Grub as required is included. t . Assumptions and Clarifications 2. SWPPP measures as required has been included. 3. SpawGlass assumes that all water can be taken from existing City of Round Rock water utilities on-site, and no water will need to be trucked in from other cities due to water restrictions. 4. Existing road profile being removed is assumed to be 4" of asphalt, 10" of base, and 8" of lime stabilized subgrade. 5. General fill assumed to be used behind road curbs, but not under shared use paths and not in the 3' road overbuild. Division 32 - Exterior Improvements 1. Pavement Markings included. 2. Includes Access & Flagmen Allowance of$75,000 for SG or other entities (such as police or other event staff) to maintain proper traffic flow during events and road closures. 3. Includes $150,000 allowance for temp roads to help traffic during lane closures. 4. Includes $25,000 irrigation repair allowance. Division 33 - Utilities 1. Includes piping for storm and water as shown. EXCLUSIONS 1. Permits, by Owner. 2. LEED documentation and Submittals. 3. We have not included the following items as we assume, they will be provided in a timely manner by the Owner at no cost to SpawGlass: a. Materials Testing Services b. Excludes all local electrical utility fees for permanent power 4. Preconstruction costs for the Project are not included in this budget. 5. Contaminated soils - hauling or disposal. 6. Gas line installation - by others. AB 6 PROPOSED GMP BREAKDOWN �'- I' r SpawGlass r Summary Report Harrell Parkway 3A.2 100 % GMP 3023148 Estimate Date: 11/06/2024 Documents Date: 09/13/2024 Project Size (SF): 332,820 Project #: 3023121 Project Location: Round Rock Lead Estimator: Kristofer Rodriguez ITEM COST COST I SF % OF TOTAL Direct Costs 7,232,510 21.73 85.32 Indirect Costs 1,244,689 3.74 14.68 % Tota!Cost $ 8,477,199 $ 25.47 100.000/0 Harrell Parkway 3A.2 100%GMP Estimate Date: 11106/2024 3023148 Page 1 of 1 Documents Date:0 911 312 02 4 Recap Report Harrell Parkway 3A.2 100 % GMP 3023148 Estimate Date: 11/06/2024 Documents Date: 09/13/2024 Project Size (SF): 332,820 Project #: 3023121 Project Location: Round Rock Lead Estimator: Kristofer Rodriguez ITEM COST COST I SF % OF TOTAL Direct Costs 7,232,510 21.73 85.32 Div. 01 - General Requirements 1,114,458 3.35 13.15% Div. 02 - Existing Conditions 273,897 0 82 3.23 % Div. 03 - Concrete 1,013,160 3.04 11.95% Div. 04 - Masonry 1,125 0.00 0.01 0/0 Div. 05 - Metals 164,207 0.49 1.94 Div. 26 - Electrical 714,891 2.15 8.43 % Div. 31 - Earthwork 1,894,878 5.69 22.35 % Div. 32 - Exterior Improvements 1,183,450 3.56 13.96 % Div. 33 - Utilities 872,445 2.62 10.29 % Harrell Parkway 3A.2 100%GMP Estimate Date: 11/06/2024 3023148 Pagel of 2 Documents Date:09/13/2024 ITEM COST COST I SF %OF TOTAL Indirect Costs • :• 3.74 14.68 ' . General Conditions 221,758 0.67 2.62 % General Liability Insurance 66,122 0.20 0.78 % Payment and Performance Bonds I 71,102_1 0.21 0.84 Subcontractor Default Insurance (SDI): I 90,406 0.27 1.07 % Escalation 0 ! 0.00 ` 0.00 % i Contractor's Contingency 254,316 0.76 3.00 % Overhead and Profit 286,669 0.86 3.38 Owner's Design Contingency 254,316 0.76 3.00 Total Cost $ 8,477,199 $ 25.47 100.000/0 Harrell Parkway 3A.2 100% GMP Estimate Date:1 110 612 02 4 3023148 Page 2 of 2 Documents Date:0 911 312 02 4 Detail Report (Direct Costs Only) Harrell Parkway 3A.2 100 % CAMP 3023148 Estimate Date: 11/06/2024 Documents Date: 09/13/2024 Project Size (SF): 332,820 Project #: 3023121 Project Location: Round Rock Lead Estimator: Kristofer Rodriguez ITEM QUANTITY I UM UNIT COST TOTAL COST 7,232,510 Div. 01 - General Requirements 1,114,458 , General Requirements 1,039,458 As-Builts/ Drawings 6.0 Sets 378.88 2,273 First Aid Kits 4.0 Each 324.75 1,299 General Safety Supplies 7.0 Mos 216.50 1,516 Fire Extinguishers 1.0 LS 2,000.00 . 2,000 Temp. Water Meter 4.0 Each 433.00 1,732 CUT AND RESTORING PAV 300.0 SY 105.00 31,500 MOBILIZATION 1.0 LS 6,000.00 6,000 PREPARING ROW 47.9 STATI 2,425.00 116,158 PIPE (PVC)(SCH 80)(10 IN) 165.0 LF 120.00 19,800 MOBILIZATION 1.0 LS 500,515.00 500,515 BARRICADES, SIGNS AND TRAFFIC HANDLING 10.0 MONTH 12,200.00 122,000 PORT CTB (FUR&INST)(LOW PROF)(TY 1) 220.0 LF 22.00 4,840 PORT CTB(FUR & INST)(LOW PROF)(TY 2) 60.0 LF 2.00 120 PORT CTB (MOVE)(LOW PROF)(TY 1) 200.0 LF 14.00 2,800 PORT CTB (MOVE)(LOW PROF)(TY 2) 40.0 LF 14.00 ! 560 PORT CTB(REMOVE)(LOW PROF)(TY 2) 280.0 LF 22.00 6,160 WK ZN PAV MRK REMOV (W)4"(BRK) 40.0 LF 11.00 440 WK ZN PAV MRK REMOV (W)4"(SLD) 7,106.0 LF 1.00 7,106 WK ZN PAV MRK REMOV (W)8"(DOT) 45.0 LF 11.00 495 WK ZN PAV MRK REMOV (W)(ARROW) 1.0 Each 250.00 250 WK ZN PAV MRK REMOV (W)(DBL ARROW) 1.0 Each 385.00 385 Harrell Parkway 3A.2 100%GMP Estimate Date:1110612024 3023148 Page 1 of 7 Documents Date:0911312024 ITEM QUANTITY I UM UNIT COST TOTAL COST WK ZN PAV MRK REMOV(Y)4"(SLD) 12,144.0 LF 1.00 12,144 WK ZN PAV MARK SHT TERM (TAB)TY W 350.0 Each 10.00 3,500 WK ZN PAV MRK SHT TERM (TAB)TY Y-2 475.0 Each 11.00 5,225 WK ZN PAV MRK REMOV(Y)8"(DOT) 42.0 LF 11.00 462 EUM EXT PAV MRK&MRKS (4") 3,920.0 LF 0.50 1,960 ELIM EXT PAV MRK &MRKS (8") 96.0 LF 6.00 576 ELIM EXT PAV MAK&MRKS (ARROW) 1.0 Each 110.00 110 ELIM EXT PAV MAK& MRKS (WORD) 1.0 Each 220.00 220 PORTABLE CHANGEABLE MESSAGE SIGN 293.0 DAY1 78.00 22,854 TMA (STATIONARY) 6.0 DAY1 380.00 2,280 Temp. Fencing - Rental (6' h Chain Link Fence w/ 7,500.0 LF 12.00 90,000 Driven Posts) Project Signs (SpawGlass) 4.0 Each 1,267.95 5,072 OSHA Required Signs 1.0 Each 1,182.78 1,183 Licensed Professional Certified Survey (Initial) 1.0 Each 3,000.00 3,000 Licensed Professional Certified Survey (Final) 1.0 Each 3,000.00 3,000 Licensed Professional Certified Survey (Intial 1.0 LS 4,500.00 4,500 Control Points) Street Cleaning 32.0 Wks 1,732.00 55,424 Allowances 75,000 ACCESS &EVENT FLAGMEN (ALLOWANCE) 1.0 LS 75,000.00 75,000 Div. 02 - Existing Conditions 273,897 ! Demolition 273,897 PREPARING ROW(TREE)(4"TO 12" DIA) 39.0 Each 220.00 8,580 PREPARING ROW(TREE)(12"TO 24" DIA) 25.0 Each 240.00 6,000 REMOVING CONC (PAV) _ 885.0 SY 21.00 18,585 REMOVING CONC (RIPRAP) 67.0 SY 20.00 1,340 REMOVING CONC (CURB) 6,686.0 LF 6.00 40,116 REMOVING CONC (CURB AND GUTTER) 456.0 LF 6.00 2,736 EXCAVATION (ROADWAY) 7,664.0 CY 13.00 99,632 REMOV STR (PIPE) 567.0 LF 28.00 15,876 REMOV STR(SMALL FENCE) 8,673.0 LF 4.00 34,692 REMOVE STR (BARRIER GATE) 6.0 Each 500.00 3,000 REMOVE METAL BEAM GUARD FENCE 424.0 LF 10.00 4,240 REMOVE TERMINAL ANCHOR SECTION 8.0 Each 200.00 1,600 REMOVE RD IL ASM (SHOE-BASE) 21.0 Each 1,000.00 21,000 Harrell Parkway 3A.2 100%GMP Estimate Date: 1110612024 3023148 Paye 2 of Documents Date:0911312024 ITEM QUANTITY I UM UNIT COST TOTAL COST REMOVE GROUND BOX 6.0 Each 550.00 3,300 RELOCATE ELECTRICAL SERVICES 2.0 Each 6,600.00 i 13,200 Div. 03 - Concrete .0 Cast-In-Place Concrete(Site) 1,013,160 P.C. VALLEY GUTTERS 232.0 SY 165.00 38,280 CL C CONC (MISC) 1.0 CY 2,140.00 2,140 RIPRAP (MOW STRIP)(4 IN) 9.5 CY 1,350.00 12,825 CONC CURB&GUTTER(TY II) 811.0 LF 38.00 30,818 CONC CURB (TY F3) 20.0 LF 165.00 3,300 CONC CURB (RIBBON) 7,715.0 LF 25.00 192,875 DRIVEWAYS (CONC) 2,471.0 SY 122.00 301,462 -------------- CONC SIDEWALKS (5") 4,008.0 SY 105.00 420,840 CURB RAMPS (TY 7) 2.0 Each 4,860.00 , 9,720 CONC MEDIAN 12.0 SY 75.00 900 Div. 0• - Masonry 1,1251 Masonry/Stone 1,125 RIPRAP (STONE PROTECTION)(18 IN) 1.5 CY 750.00 �^ 1,125 Div. 05 - Metals 164,2071 Structural/Miscellaneous Steel- Erection 164,207 RAIL(HANDRAIL)(TY F) 62.0 LF 285.00 17,670 MTL W-BEAM GD FEN (TIM POST) 225.0 LF 40.00 9,000 DOWNSTREAM ANCHOR TERMINAL SECTION 1.0 Each 1,815.00 1,815- GUARDRAIL END TREATMENT (INSTALL) 1.0 Each 4,510.00 4,510 BARRIER PIPE GATE (DOUBLE) 5.0 Each 4,150.00 20,750 BARRIER PIPE GATE (SINGLE) 1.0 Each 1,850.00 1,850 POST AND CABLE FENCE 3,879.0 LF 28.00 108,612 Div. 26 - Electrical 714,891 Electrical 714,891 CONDT (PVC) (SCH 80) (4") 787.0 LF 40.00 31,480 DRILL SHAFT (RDWY ILL POLE) (30 IN) 264.0 LF 413.00 109,032 IN RD IL (TY SA) 40S-8 (250W EQ) LED 33.0 Each 7,150.00 235,950 CONDT(PVC) (SCH 80) (2") 5,510.0 LF 43.00 236,930 ELEC CONDR (NO.8) BARE 1,255.0 LF 2.20 2,761 ELEC CONDR (NO.8) INSULATED 2,510.0 LF 3.30 8,283 Harrell Parkway 3A.2 100%GMP Estimate Date:1 110612 02 4 3023148 Page 3 of 7 Documents Date:0 911 312 02 4 ITEM QUANTITY I UM UNIT COST TOTAL COST ELEC CONDR (N0.6) BARE 4,265.0 LF 3.00 12,795 ELEC CONDR (NO.6) INSULATED 8,530.0 LF 4.00 34,120 GROUND BOX TY A (122311) W/APRON 11.0 Each 1,980.00 21,780 ELC SRV TY A 120/240 060(NS)AL(E)PS(U) 2.0 Each 8,580.00 17,160 CONDUIT(PREPARE) 10.0 LF 30.00 300 GROUND BOX (PREPARE) 1,0 Each 1,000.00 1,000 MODIFY EXISTING ELECTRICAL SERVICE 1.0 Each 3,300.00 3,300 Div. Earthwork 1,757,582 EXCAVATION (ROADWAY) 12,600.0 CY 27.00 340,200 EMBANKMENT (FINAL)(DENS CONT)(TY C) 6,780.0 LS 33.00 223,740 FL BS (CMP IN PLC)(TYA GRI&2)(FNAL POS) 11,987.0 CY 59.00 707,233 LIME (HYDRATED LIME (SLURRY)) 701.0 TON/D 330.00 231,330 LIME TRT (EXST MATL)(10") 861.0 SY 14.50 12,484 LIME TRT(EXST MATL)(8") 26,132.0 SY 4.50 117,594 TEMPORARY ACCESS ROADS 1.0 LS 125,000.00 125,000 Erosion Control 137,296 FURNISHING AND PLACING TOPSOIL (4") 17,414.0 SY 3.30 57,466 DRILL SEEDING (PERM) (RURAL) (CLAY) 17,414.0 SY 0.35 6,095 DRILL SEEDING (TEMP) (WARM) 17,414.0 SY 0.30 5,224 ROCK FILTER DAMS (INSTALL) (TY 2) 161.0 LF 26.00 4,186 ROCK FILTER DAMS (REMOVE) 161.0 LF 11.00 1,771 CONSTRUCTION EXITS (INSTALL) (TY 1) 1.0 SY 2,000.00 2,000 CONSTRUCTION EXITS (REMOVE) 1.0 SY 879.20 879 TEMP SEDMT CONT FENCE (INSTALL) 4,499.0 LF 4.30 19,346 TEMP SEDMT CONT FENCE (REMOVE) 4,499.0 LF 0.70 3,149 TREE PROTECTION 65.0 Each 572.00 37,180 Div. 32 - Exterior Improvements 1,183,450 Asphalt Paving 600,361 D-GR HMA TY-B PG64-22 4,371.0 TON/D 125.00 546,375 D-GR HMA TY-C PG64 22 95.0 TON/D 150.00 14,250 D-GR HMA TY-C PG70-22 71.0 TON/D 168.00 11,928 PRIME COAT(MC-30 OR AE-P) 5,056.0 Gal. 5.50 27,808 Traffic Markings/Signage 154,180 Harrell Parkway 3A.2 100%GMP Estimate Date:1 110 612 02 4 3023148 Page 4 of 7 Documents Date:0 911 312 02 4 ITEM QUANTITY I UM UNIT COST TOTAL COST IN SM RD SN SUP&AM TYI0BWG(1)SA(P) 5.0 Each 1,210.00 6,050 RELOCATE SM RD SN SUP&AM TY 1OBWG 62.0 Each 715.00 44,330 REMOVE SM RD SN SUP&AM 12.0 Each 140.00 1,680 INSTL DEL ASSM (D-SW)SZ (BR)GFI (BI) 6.0 Each 83.00 498 INSTL OM ASSM (OM-2Y)(WC)GND 8.0 Each 180.00 1,440 REFL PAV MRK TY I (W)8"(DOT)(090MIL) 345.0 LF 3.00 1,035 REFL PAV MRK TY I (W)8"(SLD)(090MIL) 1,383.0 LF 2.50 3,458 REFL, PAV MRK TY I (W)12"(SLD)(090MIL) 48.0 LF 5.50 264 REFL PAV MRK TY I (W)24"(SLD)(090MIL) 367.0 LF 11.00 4,037 REFL PAV MRK TY I(W)(ARROW)(090MIL) 15.0 Each 280.00 4,200 REFL PAV MRK TY I (W)(DBL ARROW)(090MIL) 2.0 Each 360.00 720 REFL PAV MRK TY I (W)(WORD)(090MIL) 15.0 Each 330.00 4,950 REFL PAV MRK TY I (W)(RR XING)(090MIL) 1.0 Each 1,320.00 1,320 REFL PAV MRK TY I (Y)12"(SLD)(090MIL) 400.0 LF 4.00 1,600 REFL PAV MRK TY II (Y) 6" (SLD) 782.0 LF 3.00 2,346 REFL PAV MRK TY II (Y) 12" (SLD) 75.0 LF 16.00 1,200 RE PM W/RET REQ TY I (W)4"(SLD)(090MIL) 17.0 LF 57.00 969 RE PM W/RET REQ TY I (W)6"(BRK)(090MIL) 430.0 LF 2.50 1,075 RE PM W/RET REQ TY I (Y)6"(SLD)(090MIL) 12,068.0 LF 1.00 12,068 INSTL RDSD FLSH BCN ASSM (SOLAR PWRD) 2.0 Each 15,400.00 M 30,800 PED DETECT PUSH BUTTON (STANDARD) 2.0 Each 5,720.00 11,440 LED ROADSIDE SIGN 2.0 Each 9,350.00 y 18,700 Landscaping/Irrigation 428,909 HARDWOOD MULCH 29.0 CY 110.00 3,190 IRRIGATION REPAIRS 1.0 LS 3,920.00 3,920 IRRIGATION REPAIRS 1.0 LS 25,000.00 25,000 IRRIGATION SYSTEM 1.0 LS 48,389.00 48,389 MONUMENT SIGN (ALLOWANCE) 2.0 Each 113,500.00 227,000 SHADE TREE - 3" CALIPER 114.0 Each 1,065.00 121,410 Div. Site Utilities 872,445 CEM STABIL BKFL 3.0 CY 330.00 990 TRENCH EXCAVATION PROTECTION 14.0 LF 115.00 1,610 CL C CONC(COLLAR) 3.0 Each 1,630.00 4,890 RIPRAP (STONE PROTECTION)(18 IN) 5.0 CY 750.00 3,750 Harrell Parkway 3A.2 100%GMP Estimate Date:11106/2024 3023148 Page 5 of 7 Documents Date:0911312024 ITEM QUANTITY I UM UNIT COST TOTAL COST RC PIPE (CL III)(21 IN) 150.0 LF 172.00 25,800 RC PIPE (CL III)(24 IN) 231.0 LF 145.00 33,495 SET(TY II) (21 IN) (RCP) (4: 1) 3.0 Each 2,855.00 . 8,565 SET(TY II) (24 IN) (RCP) (4: 1) (C) 6.0 Each 2,840.00 : 17,040 RC PIPE (CL III)(21 IN) 163.0 LF 90.00 14,670 RC PIPE (CL III)(24 IN) 161.0 LF 105.00 16,905 SET(TY II) (18 IN) (RCP) (6: 1) (P) 6.0 2,700.00 16,200 GRATE AND FRAME 3.0 2,300.00 6,900 SET(TY II) (24 IN) (RCP) (6: 1) (P) 4.0 3,550.00 14,200 ENCASEMENT PIPE 16" DIA., STEEL, (3/8" 214.0 LF 270.00 57,780 THICKNESS) MOBILIZATION 1.0 LS 26,000.00 26,000 ENCASEMENT PIPE 16" DIA., STEEL, (1/4" 130.0 LF 186.00 24,180 THICKNESS) ENCASEMENT PIPE 18" DIA., STEEL, (1/4" 90.0 LF 175.00 15,750 THICKNESS) TRENCH EXCAVATION SAFETY PROTECTIVE 3,685.0 LF 6.00 22,110 SYSTEMS (ALL DEPTHS) PIPE, 4" DIA., DI CL 350, (ALL DEPTHS) WITH RESTRAINED JOINTS, INCLUDES EXCAVATION 185.0 LF 125.00 23,125 AND BACKFILL. PIPE, 6" DIA., DI CL 350, (ALL DEPTHS) WITH RESTRAINED JOINTS, INCLUDES EXCAVATION 340.0 LF 98.00 33,320 AND BACKFILL. PIPE, 8" DIA., DI CL 350, (ALL DEPTHS) 1,330.0 LF 95.00 126,350 INCLUDES EXCAVATION AND BACKFILL. PIPE, 8" DIA., DI CL 350, (ALL DEPTHS) WITH RESTRAINED JOINTS, INCLUDES EXCAVATION 1,800.0 LF 101.00 181,800 AND BACKFILL. WET CONNECTIONS, 4" DIA. X 4" DIA. 4.0 Each 1,950.00 7,800 WET CONNECTIONS, 6" DIA, X 6" DIA. 2.0 Each 1,950.00 3,900 WET CONNECTIONS, 8" DIA. X 8" DIA. 7.0 Each 2,800.00 19,600 DUCTILE IRON FITTINGS 4 INCH THROUGH 24 2.0 TON/D 8,630.00 17,260 INCH CONCRETE TRENCH CAP, (4FT WIDTH, RED 45.0 LF 421.00 18,945 COLOR) CONCRETE TRENCH CAP, (6FT WIDTH) 20.0 LF 205.00 4,100 VALVES, GATE, 6" DIAMETER 10.0 2,400.00 24,000 VALVES,GATE, 8" DIAMETER 5.0 Each 3,400.00 17,000 FIRE HYDRANTS 6.0 Each 6,400.00 38,400 DRAIN VALVE 1.0 Each 4,025.00 4,025 AUTOMATIC COMBINATION AIR/VACUUM 1.0 Each 5,950.00 5,950 RELEASE VALVE ASSEMBLY, 1" DIA Harrell Parkway 3A.2 100%GMP Estimate Date:1110612024 3023148 Page 6 or Documents Date:09,/1312024 ITEM QUANTITY I UM UNIT COST TOTAL COST SPLIT ENCASEMENT PIPE 20" DIA., STEEL, (5/16' 10.0 LF 2,700.00 27,000 THICKNESS) RESTRAIN EXISTING PIPE. 10" DIAMETER 1.0 Each 630.00 630 RESTRAIN EXISTING PIPE. 24" DIAMETER 1.0 Each 8,405.00 8,405 Total- Direct Costs $ 7,232,510 Harrell Parkway 3A.2 100%GMP Estimate Date: 11/06/2024 3023148 Page 7 of 7 Documents Date:09/13/2024 x i I i I i - I I " fl88+8 80l �a s'as ig8s�ssag',e �$ i '88 e- I I i IT ;A 3 88888 8 8 8 8 88;888;88 8 8 8888 99 yynn ynaapplyypp pp nnpppp�} I ' I R� l i .I I I i 3 a Ila lai7Z� � � '�¢u I • 3 Vi �I� SQi�S3� '� 3�Y iiusa 2 ►r:Z �� 2JJ8f'ui4gdl� �.� a 44 � , g,s; ss,aseoaa�'sssss�ssaassisass'sa I ss$ �s?se�; i i i II I — 97 a a� a�l `,` ,� t S�;�Si� � �`5 s sus TAB MASTER PROJECT SCHEDULE 3 i - rrrrp., 1 li Providing the Absolute Best Construction Experience a g � R � y ^ e$ r, .� � fl �� 2 � l b � • � i p m � � � 9. m � a � c u � • • ® S � e � `r y n c1 v {� U U ♦ F L S � � � .� ei C 4 � � T a � n • 3 � � E+ � E g a N o U xg � � l2g �g 2 n n s s x s !C t 3 R o o e o 0 0 0 0 o a o 0 0 0 0 0 0 0 0 0 o a a o a o 0 0 r R I S Joao - - - - - - - - - - - - 0000a ^ - - - - - - - a f� 9 ¢ • � �m � cam, i i i � � i � io iL � 5 S S � u u 3 3 4g lg ££ fifi 4 2 D 3 u 299 u u u u u u u a n R a n n < < cc oc t; r tr; t;- � r;rr;r16- t; roi t; rhr t; N N N N N N N V, N N . . 7 7 7 O t z G p • o e B s # g s g st I a — g g � Q � j N N O O ' INA O ' S N - �OA� � � N N O O N °u tJ - • u� N - � vN l� - � - S loin O O O O O O O O O o - O . 0 0 0 0 O O O o 0 0 0 0 0 0 0 0 O O O E D D > > D > > > > D A D > > D D D > > > D D > > > D D D D D D ) D D D > N „ N : ; 1� NNNN N N NNNNN NNNN D > > > > D D D > D •I N 1 D D > D > D D > D D > > > > > p p p p p p p o_ 2 o_ o_ _o O_ o_ o_ o_ o_ 12 13 2o_ o_ o_ _o o_ O O O O O o f - • • � ll t • ......................-.... ...... g $ e ....... .................c......... Eq d � yp pit CL - a 3 S 9 p 6 t X 3 M n � g .. w ---------. . € ry i 3 e ... L d a ......�. ^ o � a �. s s Ab fj U • A A i i • "+ i < a a = a a a < < < < < < < a < a < a < < a a < < < < < < < • • t #' tgeed7$•t tt thea z < a a < < < < < 91 a a a a a a a a < < a < a a < < a < a < < a a < < < < < < < 9 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 8 o 0 0 0 0 a 0 0 0 0 0 0 0 c ' -. d . N N � � • � t � N .. f R 0 N N O � ` � � � T n N � • -- N p 9 5 • I a � r J a n ZN IE - f id 22pAAff • � � � i_ � � � � c a e �� � � � � $ a � - � a ul ((R�� (8� d� e� $ ] B 3 Ja S� 8] �� rc Uvv V) (vvlf) �Upp1 N t 171 17) VI N VI f��7pO1 V VU+ 0 0 0 0 0 8 N N P N N N ry �i y n �3 59 % A • - N s 1+1 Til LL a K N n r 3 O • E Cc V � 2 n o 5 a U � F� s O K g ti NNNNNlp gA R g RRRi� � AANN � s N N N N ry N N tV tV .N N R N N R I Zvi s . Ma d ! TV tig sa Rsaeeggo � o a � F � gg � a � xg � � AsaF � � . . c yiLL O¢ x F � " s � U � R fl ° � ° � � • g � � � � u y a 2i " • g EE U g, 2a - & • o MR cn U N N n Y V ♦ N N (v IV l��V{{ �Y{1 ♦ . N . . . h (�v (�V N N g tV N N N n o$f ttYY s < < < < < < < < • R R 5R R o 0 0 o 0 o m - 0 0 0 0 0 0 0 0 0 0 0 0 0 . ^ . n r $ fi w y E f � � " ° g a & d € ; & a � " E � a a � � s ; � � • 0 5 � g° � d a r• t3 t 8 ALLos'' e o E it � a m JI a y - o o 0 0 u O O o 0 0 0 0 0 0 n < • • < • . • • • • • • A '" � � hR IQ R R RRig RRRR R r o W p R r R r R R R R R R R R < < N I . . . . . . . o . . . . � F 7.1 s € 0 � � � � � � 53 � _ � � g $ � .5u " 7 � d i� � 85? � S8 ~ � uf � 5� d � t ^ • t2t2t277777Za � Zx7 ON a LF ' � a � � 5 � � � 000 : jr �.�..�. �' a a g � �0 ° p o I I I ,a € O t d u N - p 0 O U 0 N N 1V � f N N ' I 00000 00000000000 ,-� R � � r � $ X88 9. $ 53SRR9 �i R � g m r g K U t3S � m t P E 1 mmmPssa � E � 6 s 30 tT s I S u9 7 LM1 Y _ t P OS A� t g& _ ..................... .. _ . ..... . -........- . __...... ............ ._. ............ �.-. . gg .... .g a o I ; 5 $ r - 053 53 in .. 1 .. c � U xx � xx � xxx $ 3? xs N gg S < < < < < < < < < < < < < < < < < < < < < < < 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 - _ • - r + - ++ ,9, " I IQ U e m a 8 F E a X, OIL, �te p s g z a a p 8 a p 8 gg e e d � $ 8 � 88 � � 538 � 5i � S385i � � 5� � 5? 5Z � � � 53S3 � d � 53 � 5t $ 3&� 2 N2 2 2 T 2 2 t o l=l A5720 CORR PrOrW approval for recOMOM a SMOOMwCors 5 5 17-FeD25 21FeD25 16-May-2S 60 4 COR pfoti0e approval for wmmnln0e4 supcorawon pwCorlabuctbrl BufOut end CofltraUAdrmf9lotbir 55 55 17Jar425 03Apr-25 23Jra425 58 tINalleala7"-CXA 9"Corr 0 MmnmyWn A3270 SG conduct buyout mWngs for preYneury scopes of work for Poc age 38-Mantk 20 20 17-ta,25 13-Feb-25 0e-May-25 60 CM S4)candua WrW m qvp br PreWrt ry.epee otwont for Pacaige 38 Mar4— A3280 SG ad—sler—trade 10 subcontrwor%for Package 38-Me"-- 10 10 2bFetf25 13Mar-25 02-IL-25 56 0 SG sa"alr11er comraas towlbdorllndps con Paduge 30-Manlewrloe Area A3290 S.Dcontrw.rs revxw SG subcontract for Package 38-M.".-rlca Area 5 5 14-Mar-25 204Aaa25 09Jun2558 i o Submmawda"New SG euocorttrea Ion Paauge 78 Mahlenance Area A3300 SG Matra and execute sutwoxdmds for Package 3B-MWderism"Nes 5 5 21-Mor-25 274Aa,25 16.An25 56 111 a.SG avtre aro o."O suboWl as Cor Pck aage 38.Mant"nm Neo A3310 MobftrMn of preirnnary submmraaors for Package 38-Ms"artance Area 5 5 26-Mar-25 0314pr-25 23425 56 - e Mooiut.on of preanenary subconbadors for Package 38 Mamenanca Nes S11SRilmk 40 40 04-Apr-25 3"ay-25 064)ea26 386 9ubmrob A3320 --Suomnab-Long lead nuler■Is for Package 3e-%40~arcN a es(E*-- M CAMP 40 40 04-Apr-25 30- eV-25 054)01,245368 o � ma.ts Tony rad rryler{su(or Pactape}B-Marnerunoe Nee IIx. Promwer lent 100 100 02Jun25 21-00-25 2"W-27 3811 /Rbasemeslt . -3330 --Pkowrerrora-Long Med nutenab for Package 38-Ma.a---Arae(EWc,Can 100 100 02Jun25 21 CO-25 29-Apr.27 366Ilium :'•PfOdaMlMfe=LOnp Mad mweaalt[br PaOdge]B 4 ._ .. ..-..:..:-._. ..:............ .. _... - ---- - - - - . CaMnsditn' A5630 , Eannwork i Baking Pads 40 40 04-Apr-25 30-M rt-25 19AUg-25 56 EanDwak I Building Rads A5840 Undergrouno tnwrear MEP Rough-In 60 60 024Aa)-25 25-ALV-25 12-Now25 56 Uno4rywr10(AUl s1 MEPRough4n A5660 Concrete Foundation 40 40 164Aa)r25 I"P25 01.Od-25 56 Concrete Foorean . A5870 SVVct I Steel 30 30 15Ju425 25,4.g.25 1244-25 56 5lnpura151eet A5W MEP eusdokn 40 40 12,-LV-25 07-00.25 304).1-25 56 o MEP 6uidout A5920 FnNses so eo tOSep-25 044)41-25 25Feo-26 56 I � Fnk■lea A59DO Impsuon 20 20 06-0d 25 0444ov25 26Jan-28 56 I o "Pta A5930 Inslatom of Mac.Metab and Sne FumnWgs 20 20 OSNov-25 044)eo25 254AM-26 76 o Installation of Mm Meati and Slur FumWmgs A5910 LaMscapng 20 20 OSNo.25 O&Dea25 25-Feb-25 56 o LanowlWR g ASW Ptndees and eldwo 20 20 0513ea25 06.111"-26 254Aar-26 56 d Punalfst and Cbseou 36•RoC1fN Ricer 53S 355 12-FeD24 A Tatfr 76 24A� JR 3C-Rock RAer ♦I seises 6 Cons m"s FA.3370 �AwR-RodcN River need s to be complele try 04.01.2026 0 0 27-M..26' 01-Apr-26 3 0Per CORR-Rock'N Riser needs to be: Oellgn Devebpnwa of Pac age 3C-RockN RAer 30%Dmwelgs 25 0 12FeD24 A 21-Mar.-A O5NOQ4 r� DevebpentofP&OMpa3C•ROMNRher30%Drawargs SG"Itil of Package 3C-RockT4 Rrwr 30%Drawings(largch Date W 15 24) 1 0 21-Mar•24 A 2t.Me,24 A D5-1,1 -24 .se.'scups dPackage 3C-RoWN-Rww3D%Dm*"s(raga Owe 0315.24) Cry RvewofPackage 3C-RockN Ryer 30%Drwwtgs 10 0 21-Mar-24A 05-Ap-24 A OS440v-24 . CywNewdPecage3C-Ro"Rnar30%D—rIgs Oeeebpmem of Package 3C-RotlM Rher 60%Drawings 27 0 06Apr-24 A 12,AA24 A 0"0v-24 OewlW-M d P.0k"&3C.RockN Riser 60%pm"s A3390 SG RecW of Package 3C-ROdcN R"(60%Drakwlgs(Tager Dale 05 31.24) 1 0 124.1624 A 1244.24 A 05N-24 %G Retest ofPwkage 3C-RodeN Rivar W%Dials(Ta"Date 06 31341 A3390 Crymawcf PscsW3C-RodkNRiser60%Dmwngs 10 0 12,A24A 17.AA24A 0"9.24 a Ctyu MPsckage3G RockNRNn601s D■welgs A3400 Devebpmem of Package 3C-RodkN Rover 90%Drawngs 35 0 01Aug-24A 201Sep24A 0"-24 w Devabprnem O(Package 3C-R.OWN Rner 90%Drawetgs A3430 Dewldpmem of Paauge 3C RoakN Riser 130%Dmwegs 19 0 02Se9-24 A 01-00-24 A 24-Feld-25 to Dev wog t pf Package 3C-fRocKN RNer f00%0rew.)gs A34AO SG receipt of Package 3C Rock74Rhe.100%Drawings(rarget Owe 1004.24' 1 0 01-00-24 A 0143d-24 A 24-Feb-25 r SG recspt cif Vackage 3C-RocKN Rlvei 100%DnrmF s(Targe(Dale 10 04 24) s Drawg9 Package 3C-RodfN Riker 30% 53 0 214Aar-24 A O3#tayd4 A OSNov-21 �F Aatlrags 3C-RockN Rker30K Drawings A347C `Ai provide o Mudabily my ew wmments on 3O1 Package 3C RodkN Rtrer On 5 0 214ar-24 A 02.Apr-24 A 0SN0v-24 ■ SG pmv.M wnftfudabray mMw Oanmems m 30%Pwkags 3C-RoCKN R"r drwgs A3490 SG wlct 30%Paduge 3C Ro"Riser drawings for budgetxg 15 0 0340-24A 30-Apr-24 A 05Nov24 M SG so"30%Package 3C•RD"River dr-Ings for WOgetng A3480 C O(Idncl page lip"wetmg muwng 30%Package 3C RocKN Rner dwgs 5 0 03AW-24 A 0344..24 A OS-N4v-24 I Oonouct pope RP meetng mvewang 30%Pv ckm"3C-ROOM Riser dmgs A3500 SG compo prig for 1T Package 3C-Rerk'N Rhw drawings 4 0 30,-4x-24 A 034Asy-24 A 05N0v-24 • $G compse Mmg for 3D%P&"O 3C-ROCKN Roar drpvwge A3511 SG subrtn budgetary pdvg for 30%Package X-RocKN Riser drwvngs 1 0 034Ary-24A 03-aAM24 A OSNov-24 511 wbms budgetarypdmg for 30%Package 3C-ROckN Riser dmwngs Package 3C-RockW Riser 60%Dmovilgs 46 0 15JA24A 30.Wg-24A 05NOv24 VeaeW Paoage 3C-RoWN Rker 60%Dcawngs Stan Dale 1542124 w Aauw won. • ♦M4eftone aaaaaaaaa Actual Level of Effort CoRR OSP-Preconstructlon Schedule FinishDale 26-Apr.27 — Remen^ Vwm �►Smmau9 ry WBS Layout.HH NI AdrMres Dna Dare 31.Ocl-24 w Caul Rema.rrg Work Level o(Ellod Page 9 of 15 Run Ogle J1.Oa-24 -::Iw ik: .. $-�i e. � • � Q .g � �..�.�,... � � to rs O .. OC 0 v 3bokkp 4 � t44Rlesv N s � >eg � >e >e >e � R $ z ttr7}7i tV �i 1fyN�e �i 1� � tri t(Ayps N f� � }N� RI N NA N IPI STN SN N N LL ffNVV ttVV F 2251 L W n n 0 0 . . . . . . n p b u • g � ' a zON Pg ji ir � � E i fi � o rc e: Deaq A3780 Develogrrlent of Package 3C-Rec Center Complex•SAO 30%Drawingf 46 0 25,Y124A 13•May24A Ot Nov-24 amp� Development of PaCWge x•RecCemercomplex-Ste 30%Drow" A3790 SG rang of Package 3C-Roc Canter Comple.-See 30%Dmsrgs(Target Date 1 0 13AAay74 A 13-May-24 A 014ov-24 SG reap of Package 3C•Roc CoMer Complex-$ee 30%Orwrga(rorgel Dile a 15 24) "210 Ch mwew of Package 3C-Rec Comer Complex-SAO 30%Drswngs 10 0 13Map24A 26Map24A 01 Nov-24 ae CN rewmof Package 3C Rec Center Complex-Ste 30%Orawngs A38DO Dewwwrierlt of Package 3C-Rec Cemer Complex-SM 60%Drewngs 47 0 15JIA-24 A 16-S•P24 A 01No 24 •ansesee, Da•.ebpnbre d Paaage 3C-Rec Canter Complex Sae 60%Dravnlgs A3810 SG Reap of Package 3C-Rec Curler Complex-Ste W%DM.gs(Tergal Date 1 D I&SsF44A 16-Sop-24A 01440v-24 r.SG Reapof Psckag■3C-Rae CanerCamplmi-Ste 80%OmK+gs(Tw"Dale%2D24). A3670 De.ebpmem of Pedage 3C-Rx Cama Complex.St•90%Drawngs 38 36 14Nov24 101a125 13,0125 1 o DeselopMre r PaO"o 3C I Rec Cemr Compo.f See 9D%Dnxergt A3840 SG reap of Package 3C-RecCemer Complex-Sae 90%Draweg3(Tager Date 1 1 134an25 13Ja125 1AJa125 1 f -SO ragoe i1 ofPickige 3C_-Ric�s01er CCmple.;•$til W%0newings(Taiget Date 0627 24} A3S50 Cryrevrew of Paw x-Rec Comer Com _....j..j..�.:................ ................................-........_........_... _. .............. 4e plex•Sfa 9D%Dmngs 10 10 14,0125 27-Jan-25 01-Apr•25 46 a Coy wNw of Package 3C-Rec Center C ompYx-Sae 90%Orm"s --,No De.ebpmam of Package SC-Rec Coma Compf•x-See 100%Dn•Asg3 t8 1s 26Ja12S 20-Fab-25 25-Ap-25 46 Dow". Package.3C-Rec C.MV Complex-St.100%Drawags !3870 SG reap of Package 3C-Rat Cemex Complex-Ste 100%Dm•1gs(Target Dan 1 1 21 F0 4S 21 FaA25 26Apr-25 46 r.e0 Memo of Package 3C-Rec Carear CwTios•Sae 100%DrMgs(Taegr Date 10 A3880 Cry mAew of Package 3C•Rec Center Complex-Sao IOD%Orowgs 10 10 24Feb-25 0716461-25 12w1ay25 46 o Coy nvw Of P.O."3C.ROC CMrCompYx•Sb 1q0%Ofawngs A38W F"Iplenreua two Padage3C•Rec CareerCwVie.-Ste 10 10 10•Mw.25 21 JNar-25 274ap25 46 ,e;FItW glen rellsans briadtapa l0>Rad CarprCompinfSM; ; ...................... .... _ ..... .... ....... . .... . .... _. PackjW 3C-ROC Censer Cortplex-SCC 30960MwngS 25 0 1Wep24A 16Jun24A O1NOr24 �VOW Packago3CRec Calver Complex-Ste 30%Dneings A3900 SG provo.wnswcWbiry mwew anmenla on 3D%Pawge 3C-Rac Comer Cor 5 0 13#asy24A 144A4ry-24 A 01Nov24 a SG mvide anstnraabdyreww ONMOMsoh 30%Paiirap0 7C•Rec CeMerComplex-Sie dwgs A3920 SG soled 30%Package x-Rec Cemer Complex•Ste dravegs for budgereg 15 0 14.Mry-24 A 12Ju 24 A 011-24 One SG soks 30%Pac ago 3C•Ree Comer Complex-Sae:drose"s for bud"" A3930 SG rn+riPee Pncn9 for 30%aAdrsge K-Rec Carmar Comptax-Sea dmvgs A 0 124u124 A 18Ju124 A 01NOv24 a SG compes plcrV for 30%Pacate"3C-Rad Carr ClOrr"I 51e:dnlowga A3940 SG wbme budgetary prkdllg for 30%Package X-Rec Cemer Complex-Ste dm 1 0 16.Ak124 A t 5,1u124 A 01Nov24 r SG wbmt budgetary priatg#ar 30%PaeAapa x-ReCCaeNi carr q •Ste ara4ag• Package 3C-RBC CenW Cwplex.Ste 60%Drawngs 20 10 184;W24 A 13Nop24 1444 v 24 1 V—vidPadage DC-ROC DeIKR,Otkllpwi Sb AO%i0liwl•1g>i A3970 SG proe cvnwm ubaty mvanr owments on 60%Package 3C-Rec Centel50p Cor 5 0 1624A 253ep-24A 01No,24 • SG provide corlyclabily mwr mrm10 0"PiOiegi 3C-Rea Gear Complai-Safdaigs; A39W Conduct page fop meetrrg ireyeeng60%Paw9e 3C-Rac Cemr Complex-See 1 0 25Sef1.24A 25SeP24A 0140v24 Conduct pays lllp.Ma rig AxsWaetg 601LPidaya JC_pjap C4aifar COlfpMl�Sts rings ^3990 SG wbA 60%Pacage k3C-Rec Cotler Conkplex-Ste drawTg s lr oudgetalg 15 0 26SW24A 24-00.24A 01Nov24 also SG MM rgpe4 Package 3C�Rec,Collier 6rall SM ObnYpibrbudg�tng ... --._..............:.:. .. .. .... A4000 SG compile pmRg for 60%Package 3C-Rec Cemar COrroarx Sae dneelps 4 0 2400-24 A 3000-24 A 01Nov-2A a gG mntpae pam0 for 60%Padoge 3C:Roc Clavier.C omp................. e.•Star dmaNgs A4010 SG wbm t w0gnary P—Ig for 60%Package 3C•Rec Comer Complex-See arra. 1 0 310024 A 3100-24 A 01NOv2A r SIG wbort buUgelary,pncwlp for 60%fos"ga X-Rec Cemr Crrplex•Sae daaelgs A4020 Oa r Provide ammams w 60%package,3C•Rec Carver Complex-See OrM br 5 5 3100.24 06-N0•.24 07Nov24 1 • Doew prcrwde cq mems w 60%Package qC-Rec Cemex Crepe.-St."b.0gA&ryrsnroe A4030 SG ewe W%Package 3C-Rec Cw"rComplex-Sea prlong sccordnq to owner 5 5 07Nov24 13No•.24 14Nov-24 1 0 SG mKse W%Package 3C.RaC Cemr Conpbx Sae pfivug decoking tag uwerr odnlnleras .11'ssawassleaw GMP: _.: ....... _..: .:..:..:..J...: . ..... .... ... ................__._............ "r).0 SG prowda mmstrumbtry,review mmnYms on 90%Package 3C-Rec Center Cor 3 3 1AJs125 16Jan-25 17-Art-25 1 ._... r:SG prwf7a pangnxl�bRy+ewewoovowt an9MPadlAp3C-Roc GMr Cdrrpa:. A4050 Conduct page flp meetrg wolpwng 90%Package 3C-Rec Comer Complex-So* 1 1 17Ja125 17,1an-25 20,lan-25 1 .'COMUO page M1p maetnq nwMng 9g%PiGapO 3C•Rac Canlaf CtrflpMa-9M dasp ^4060 SG w1m 90%PsOage 3C-Rac Center Conpla.•SA0 for GMP t5 15 20,18125 07-Feb-25 10Feb•25 1 v SG:wldt 90%Psokage 3C-ROC Center Complex-BAo fr qlP M070 SG ampM GMP torPackage 3C-Rec Cemr Complex Sar•from 110%dMreVIgs 4 4 10-Feb-25 13Fw25 14FelQ5 1 • SQ rx Mph GMP for Package 3C Rep Comer Cpmplea•$tabun 901f:tlrasgs "O60 SG wbma GMP fr Padrage 3C-Rx CarverC=pkx-S4e 1 1 14Feb25 14Fe425 17Fe0-25 1 'SG kk"GMP kr PSOago 3C-R.ec Cemr,Conpk.-Ste AA090 01—r Deargn Toam mAwGMPfor Padage 3C-Rec Centel Complex Shand S 5 17FsD25 21 Fs1•25 24-Feb-25 1 x DwArl Design Team nNewGMPIMPsaage3C-R6'CC~Compox-SIO andp "100 SG revamv,commems for Package 3C-Rec Center Complex-See GMP and mvsa 4 4 24-Feb-25 27FW25 28FeO_25 1 e SG my mmmreres for Peak"3C:Rec termer Compal:Sia GMP and rewa Ml f(f SG rewbma Package 3C-Rec Comer Complex Sae GMP 1 1 28-Feb25 28-Feb-25 03-M-25 1 ' SG naerret Padage 3C-Rec Comer Cn.wkg-Saa GMP AA 120 0w1er fo,.wa package 3C.Roc C•maf Complex-Site GMP to CnRR Cry Caro 5 5 03-Maa25 07•Mar•25 16Mr-25 1 s pAfyr ws 3 lcmMrp PagG-Hoc cainec Cgmpfex•Ste GW 10 CORR Cry Couna A5760 CORR Cy Cwrd appoval process fr Package 3C.Rec Cemr Complex-Sae 30 30 1PMar.25 16-Apr-25 21-Apr-25 1 �+ CoRR Cy Coadappp w per fdr Phkage 3C-Rx Camr Corrybx-$M A5770 SG provl0e CoRR l9 of mpdmmenpal ed Orly wma bcoclon(OrC7-Apr-ZS 14•Apr-25 5 approval 1 1 07apf.2S ..:..:....__ r SG provide CORK lot of reammemaa pnrey aubartu0tlaa for approval A5750 CORR prowde approval for recommended wm bnlngpn 5 5 D&Apr-25 14-Apr-25 21-Apr-25 5 a CORR pa)Nde appwl IOr mamnlefww tubcomn0or Pre-Contnr0gn -BUyOLA and ConaactA6 estrabon 55 55 10#Ar-25 23•M y.25 27J.My25 1 �g BuyQa And COntOa AdaMlftratUn "130 SG mmu0 ovyomnfor vt eeings for preemary scopes of work Package 3C-Rec: 20 20 10-M-25 04•Apr•25 1 k.Apr 25 5 as SG orCua bryost praetrpa for praMMary sOePas Of wok 1r PaOags>C-Rx 84RDaa: is,laa$6 ale—osse Actual Work ♦ ♦Mll"One mar Actual Levet of e8a1 CoRR OSP-Preconstruction Schedule Fidel Doe:211AW-27 4 Rwm.g W ark Vo---7 Sammaly WBS Layout-HFI All AgrvdYs Oft Was: 214XH-28 — Cmral Remat"Work assesseass Level of Effort Page 11 of 15 Run CM; 31.Ot1.24 I M140 SG admaysor cols to submmrsdora for Packager 3C-Rec Censer Complex-: 10 10 21.W.25 024.1y-25 05-M"25 1 o ll".—Werooetrausloaracatraaors la Pvcmge3C-Roc Center Compbxc A4150 subcontractors re—SG,ubmmraa lu Pockne 3C•Roc Center Complex-Sae 5 5 054asy-25 09-May-25 12WI,yy25 1 • 6uomntndas rjMaw 9G aMatrad for Package 30•Rw Comer Complex- A4160 SG litre and execute subcontracts for Package 3C-Rec Curler Complex-Ste 5 5 12-a�ty25 16-May-25 19-May-25 1 r SG Iw1ze and execute subcomraae for Package 3C.Rw Center Complu- AA 170 Mobilyton of Preliminary,ubbamredw,W Package 3C-Rec Center Complex•S 5 5 19AW75 234Aay25 27-M.I,25 1 a Mobiutiw of pr.nhmN sabmnusd"br Pacaga 3C-Rw Csr1Mr C SubrystlIals 75 75 274eay25 10-Bap•26 25 SeF 16 265 �a�SuDmNb "'w -' Omatab-L bad materab for a 3C-Rw Career Cam PackADo brag Package plex�Sae Tele 75 75 27Jaay25 7p5eP25 25Sa1s26 2G5 0 ^Submaab.lorp bed moltuMle/or x-Rw ClrnerC Rwureffll 150 150 11S4P25 15.Apr.2e 2SApr-27 265 ��Prowlemem M190 '-Prodawnam-Long bad mat.."lar Pawge 3C.Ret Comer Complex.Sae CE 150 150 11 SeD25 t 5.Apr-26 29 Apr27 265 '9rorplxrerl+.nl Lonq red mof—1 for voloolooloolool"raraq Conmwion A60e0 Esrtnwork f Bkddoq Pao, 100 100 27-May-25 t 5-0025 1600.25 1 ­=M—1 E1Mnww% Bwdnq Paas Ab090 Underground U1wors f MEP Rougn.n 100 too 234►25 124)-25 02-Apr•26 76 O lJnd"round VNes, MFP RougRln 3C Rec Center ConTiox Biddngs Fi66 506 25Jan-24 A 30.00.26 2944 21 125 3C•Rec Confer C ♦ISI.xn 6 Canlnnts A6630 �AECwto be tumed dk.r by 10 01.26 b show Ica do iarg for Opennq 01.207, 0 0 3000.26' 0244or26 1 •R EC Corker to be full Oaagn A 3390 Devriopmera of Parlage 3C-Roc Center Complex-Bull 30%Ow"s 46 0 25.bt•24A 13-May21Fob25 seaarass^a DeNlopnanlWPwlu6a 5C:Rac CattMrConpMx•BulOitgc30%Doetrlgs . A6310 SG raoW of Package 3C-Rw Comer Canpez 30%Drawings(Target Date 04.15 1 0 13-May24A 134day24A 1 so recap of package 3C yRwc Comer Complex 30%oiMirga(target oat*04.1524) A6670 Cy ravlew of Pea&"3C-Rot Center Complex 30%Drawngs 10 0 13•May24A 28May24A 21-Feb-25 •. coy tre*.o1 Padage 3t;-I1K Como(Complex 30%Drawi Drawings A6320 Dowtopmem of Package 3C•Rec Center Complex 60%Dn g, 47 0 15,ia24A 2500-24A rx�r DexelOpm•f1t of PeuagoX•Rw Cerear Complex fi0%Qrai age AA280 SGReceplof Package3C Rw Canter Cwnpbx60%DMn )gs(Target Det.092 1 0 250d-24A 2500-24A 21 Fsb25 r SG Rodptol Package 3C-Rat ..:..:..:..:..: ......................C~Cnpx 60%00"(TAW WN 09.20:24) ............:........ . -----.. . - _---- -- A6290 -.._.. Dawkipmem al Package 3C-Rec Corder Complex 90%Dr qs 36 38 160e624 11Fao25 3044ay25 77 o.Da9olpprnoM o1 Pa kpp X%Rw C W..Co q Mx 90%Droodogs Ad= SG mall or Package 3C-Also:Comer Complex 90%Drawegs(Target Date N 2' 1 t 12Fob-25 12F002S 02,Aws26 77 1:SO new of Psifupa 3C:-9Eaccer"Cgrlplexp0%D awnp(la"Db 0827.24) -ASW CN ravleeof Package 3C-Roc Center Complex 90%0-91 10 10 13F.D25 2r1Fob-25 21du825 124 as;coy W.P.of pwkagw 3c-IIsi CMM coagbpr 90%onail8a AM Devrtropme4 of Package 3C-Rec Cener Complex 100%Dr-91 18 is 27Fe425 24Mw-25 17Se0.25 124 b Divebpmom d PNM*3C•Fee Cirwai Cgmplox 100%D—r p A6360 SG r.cep of Package 3C-Rec Comer Complex l00%Dr gs(Target DMe 10.2 1 1 25A4am25 25Mw25 16Sep.25 124 1 SG necklet of Paaa94 X-Red Certer Compo.100%OMwrrgs(Rxgat Dato 70.22' A6370 Cy now of Package 3C-Aft Center Complex 100%Dgw"s 10 10 26Mar•25 05,W25 024)a-25 124 o Cy fevww d fnackayo X•Rec Carver Complex 100%Drawmgs A6380 Foal plan reNs m for Package 3C.Roc Comer Complex 10 10 D%Apr-25 22.4pr-25 1606.25 124 o Fns pap rawon7 tat PwxaOe x-Rec Career Cwnq.x _ foloolool1 DjogevW Pedrage3C-Rec CQfW Col.pICx-X330%D'&AVS 25 0 1NMay24A 18.kn,24A 21-Feb-25 loaWPadsge3C•Roc Center ComMex Buildings W%Orawngs A6400 SG pro,Me wnmuctaboy mr ow eomn+ants on 30%Package 3C•Rec Comer Cor 5 0 13-May-24 A 1"ay.24 A 21-F t,25 1 SG proves mnstnxOaNty relic«wrnmems oP 30%PaQ98a SC•RK C4alfwComplex lYwga AGA 10 SG,moat W%Parka9e 3C•Rec Comer Complex dMwngs Ica aWgMng 15 0 14-May24 A 12Jun24 A 21-Feb-25 elea SG lk:k4 30%Pswge 3C Red CamwCompbxd#vAngs for oudgMrg A6420 SG wmpse pnmg tow 30%Package 3C-Rec Center Complex dmwrgs 4 0 12Jun24 A 16Jurs24 A 21-Feb-25 a SG oompM pnkdng for 30%Pscage 3C•Rec C4t4dr Cwrlple,drawhgs Aa430 SG subma budgetary prxrg lar 30%Package 3C.Rec Center Complex ar oqs 1 0 t6Jun-24 A 18,k n24 A 21Fob-25 {;auoma budgetary pma for 30%Poekago 3C RedCwnw Complex drowegs PaduW 3C-Rec Center Carq*x-Buildings 60%Dt111pngs 32 32 25-00.24 A 17.4) ,2{' 07,W25 77 V—B Package 7CmpM . R-Center Coz-Buiinmg,60%Dg, A6440 SG pf 4je adowuaabww y rf wrnmonts on 60%package 3C-Rx Center Cor 5 1 25-00-24 A 3104,24 7 21F.D25 77 a SG provda conses4abwy rswew comrrwvson W%Package 3C-Rec Comer Complex dregs A6460 Conduct pope ep mleelxl9 rale 9 60%PIOU"3C-Rw Center Complex dpgr 1 1 01JJm.24 01-N-24 24Fe?25 77 1 Conduct pope lop meewg mvwwq 60%Psc vga 3C Roc:CwnerComplex bergs A6450 SG sdsts 60%Padage 3C•Rw Center Complex dravr gs fw budgeting 15 15 04H ov-24 22-Nor24 1741Mr-25 77 o SG soots 60%P.cage 3C-Rw Confer Complex draaelg,for budge g A6460 SG—pie pricing for 60%Packaget 3C.Rw Center Complex drawegs A 4 25-1,1ov-24 020eD24 214U,25 77 s SG wmpdo prlOrg ler 60%Package 3C•Rw Comer Complex drawings A6470 SG,ubmt budgetery prong 1er60%PK age X.Rot C.mer Complex dkawrgs 1 1 034D-24 030e<,24 24-Mar-25 77 1 SG wbma.bu"aw y pA=g fw 60%Po&a"3C•Rw Comer Complex dm"s A6490 Cwtef proWe mmmems on e0%Package X.Rx Carder Complex 0r.Y bud9eu 5 5 044).624 100e 24 31 Mar 25 77 o punerprd,,ids rommwms m 60M Padaga 3C-Rec Cotler Compri anq DudpMary numbers A6500 SG rows 60%Package 3C-Rw Cemw Complex prxmg scwMng to owller oomn 5 5 11-00624 17-0e624 07.Apr-25 77 o SO reNho 80%PaCAage X Rx cocoon CbmPlex ppv19 wWrdal9 la caner mrm+ents volooloolow GMP A6510 SG proud.mnslnr0altoly review commerns on W%Package X-Rec Center Car 5 5 13Fo625 19Fen25 09,kw25 77 a SG pmwdo mn4vueablry wAow w ms on 90%Pwkage X Rw Cemer CompMi A6550 Conduct page lip meetay row og 90%Package X-Rec Center Complex drwg; 1 1 20F.625 20Fea25 10,ist125 77 1 ConO,d page ap meeletg nseawlrq 90%Patlkage 3C.Rw Cenw Complex lift," SW OM 15,soo-24 - Actual M11, • •Well » Actual Lawlef E90R CoRR OSP-Preconstruction Schedule Finish Dole:26-Apr.27 m Remaining Work r-oloor Slmimary WBS Layout-HH All Aarvnles Data Data 31.00-24 — Cmcak P.—dung Won — Level W Effon Psge 12 o1 15 Run cab 31 W-24 �_- __= 7A:8570SGmm� d 90%Package 3C-Ret Cams(Complex for GRIP 15 15 21 Feb25 13Mar•25 01 Ju425 77 ea SD sole/90%PoOkage 3C-Ree Center Complex for GMP compile GMP for Package 3C-Rec Comer Complex hom 90%drawargs 4 4 14•MIu4s 19Mar-25 0"L 25 77 a SCC CdnpM OMP P"' P/,Cllage 3C•Rec Comer Complex horn 90%orav ngs ng GMP for Package 3C-Rec Center Complex 1 1 20•Mar•25 20Mar--25 09,1UL25 77 SG sAml GMP for Packs"3C-Roe Center Complex :Dougn Team wvsew GMP for Package 3C Rec CemerCDnrpaxwgpovs 5 5 21-Mar-25 27 Mar•25 IGJul.25 77 s:Otsoor:Deagn team nNaWGMPfw Podag►3C Rat Comer Compla.and fommeres for Package 3C Rec Center Complex GMP and revise acceR 4 4 26-MV-25 02•Apr•25 7.2 -25 77 s SG nr w comments fof Psoceye 7C.-Rac Center Comps.GMP and mwa.acconil A6583 SG rewbme Padage 3C Rec Center Complex GMP 1 i 03-APr-25 03-Ay25 23.1425 77 SG Iesubme Package 3C ReC Cemef Compkr GMP A6590 0ener foN/ira Package 3C-Rec Cerner Complex GMP to CORR Cy Cwnol S 5 04-Ayr-25 16A4r-25 30Ju425 77 ? bk nu fo"ro Poc""3(3•Re Comq Complex GMPto CoRR Cry Counp A6660 CORR Cry Cwrrra appmval pmass for P&Oub"3C•Rec Career Complex 30 30 11 Apr-25 22-My-25 11Sop25 77 CORR Cty Cow"appwal process for Package 3C-Rec Corea Conplex A6690 SG provda CORR kg of recommended pdoAy SUDCOMMCEM for appmval 1 1 094M 25 09Me)25 04Sep-25 61 fiG provlds CORK f4 Of fapdmlmMtletl PfoftY sulknmr90oa far appoW A6700 CORR pronto approval for recommended wboundraCIM S 5 12My-25 16A1y-25 11 Sej�25 6t • CORR p%10e appoW for recommended suRartracton PM-CO.tmcf" Bert-Out and CorlYafYAdrllnstratipn - 55 $5 I l Apr-25 27 n n 25 iGoa 25 77 Vanneenell'Rrrc4DLa are erontraaAon+vmasxm A46M SG conduct ouyou]mbafngs for preanalary copes of%cork for Package 3C Rac' 20 20 11 Apr-25 06-My25 0.1SaP25 61 4 SG mndua Wyag maMslgs foryisYnnary sc»pes of sulk for pa(Xago 3C-R A6610 SG admtwot cantmps to subcontractors for Padage x-Rec Cerner Complex 10 10 23-May-25 06,A -25 25-Sep-25 77 Co SG odmnigerconbectsso prgodpnpon for Packpgo 3C•Rec Comer Com A6620 Subeorltrs0ors nt—r SG subcontract for Package 3C Ret Comer C ornple. 5 5 094un-25 t3Jun-25 024)C•25 77 s SuboonbaCom levyw SG au000nlnC for Package 3C-Roe CemM C AM30 SG fnalme and exactas submmnstls tar Package 3C Rac Cenler Complex 5 5 16.lun•25 20,).,2S 09.Od-25 77 s SG fnasxe and ex6oA9 wbWlhatts for Packag►3C Reck Cwtw C 76540 Mobton of preliminary wboomractors for Package 3C-Rec Cerner Complex 5 5 23.1,,25 27-A-25 16-0a-25 77 s MObrtraUMOf prof mnary subcontn0ors for Package •Ree Center C • ba SubmMs 75 75 30.1,,•25 14-00.25 2560p," 241 ♦entleanneenew Submittals A05650 -'Suomttsts-long 11a0-1—k.I.Package 3C-Rx Comer Complex(Ebc.Qn 75 75 30Ju,25 14-0025 25Sep-26 241 n� -5lubmnab Long bad malnleb lu Psaege>C-Rec PrpMMnent 150 150 1510c1.25 19May26 29-Apr-Z7 241 tea♦Procurement A6660 --p1mrem orb long lead mateeab for Pelage 3C RecCerner Complex(Esc E 150 150 154e-25 19-My-26 29-Ap,27 241 0 -P-M-em ent Long bad matMlab ro COngnxtbn A6740 Conan7e Foundations 100 100 16-00-25 114Aw-26 12 Mar 26 1 Cona4leFoundan— A6730 Conpws Pang 60 60 15Dea25 O&Agr-26 24JUL26 76 C*dcrore Pahg A6750 Shucturat Steer 60 60 os-ret-25 26-My-26 29.MW26 1 Structure]Steel A6760 Flaanor Facade 60 60 02Ab-26 23J426 24.x126 1 o EA.doc Facade A6620 MEP Midout 120 120 02,W-26 IBSep•26 21 Sep-26 1 - -^ MEPBuboul . A677. Fnnhas 100 100 144.Iy-26 02400.26 05-Oct261 o Fnryes A6790 Imge4ior+ 40 40 14dsay26 09,1426 07Aug-26 21 r'-y Imgarwl A6790 Imnalafion of Mac.Malats and Sde Fumrsnalgs 40 40 10JUL26 01Sep-26 02Nor•26 41 c=o Inslabpor.of MeC Me44 A6000 LSM--Wg 40 40 1114426 035eP26 05x0-26 21 O LanOscepOq A6610 Pmd*il and Closeout 20 20 05-00.25 30016-26 02-Nov-245 1 o Puntnig and C 3D MubPurpow Center Etpertsun 610 630 25.1,24 A 26,W.27 29Apr-27 3 66210- RFP S hedule gwe6o p comclaw by 042027 0 0 26.Apr•27 29Ap':11 3 a- Donn A4250 Developmam of Package 3D-Muw%rpose Comer Fxpanson 30%Drawings 46 0 25Ja,24 A 19JuF24 A 03Ap,25 Deve"mem el PaOWga:3D-MLAW%Apow Ceme(EvpaMwn 30%Onseelgs AA260 D#�obpmecM of Package 3D-MuUPurpose Center Expansion 60%Dra"s 43 20 10Sep•24 A 27-NOv24 3040,2$ 106 ers.ao Dsvoognes a l abaga 3D•MusePurpoee:Carner 6parlston 60%DOsratgt A4290 SG Reapt of Package 3D-MuaFPrapow Center E pansxIn 60%Dra A gs(Tar" t 1 02-Oer;24 024ea24 01401ay25 105 1 SG Reap of Package 30-Mul.Purpow CenterExpansbn W%0mvengs(Target Dale 06 24 A4300 Cry resew of Package 30•Mul.Purposs Cerner Fxosrr on W%Dwwvs 10 10 03.0ea24 115-04,24 23Jr,25 132 - e CIy gwew of Psdu9e 3D MueiP,rppss CMle(Erpan>nn BOK Onawgs AA310 Devebprnertt of Package 3D,Mul.Purpuss Center Expansion 90%Dm sgs 43 43 24Js,25 25Mw-25 22Aug-25 105 d==2 Development of Package 3D•Mu(Pwpaw Center Ealowsbn 90%parngs A4320 SG recept of Package 3D-MukLOurpose Canter Evanson W%Omwngs(Tar" 1 f 26-Mm-25 26.Mw-25 25Aug•25 106 - - r 5G rocep Of Pac"3D-Mus.Ptnpbse Corner Elpanwn 90%Doswgs(Torg, AAM Cy renew of Package 30.MulrPurpow Cerner Fxpansbn 9D%Drawogs 10 10 27-Mw.25 09Apr-25 0340-2S 124 o Csy rowew of Package 30 MutWurpow Calver Expanaon 90%Drawings A4340 Development of Package 3D•Muli%pose Center Expanson 100%Draatngs 47 47 10Ap-25 16Ju,25 11Oec25 124 C:7= Desebprr*M M Peclu"3D MuWPurposo Cerner Epww"top%Urowr A4350 SG reaps of Package 30-Muk Pu]gose Cemw Fxponsbn t00%DraAsngs(Targr 1 1 17,M,25 17Ju,25 124)eO25 124 SG Mono Of Psckage:3D-Mutokorpose CentwEque w 10M]nAng Start Date 15-Jan-24 A0usi Work ♦ ♦Milestone r.eeneen Actual Lswt of Enol CoRR OSP-Preconstruction Schedule Fwsn Date 2&Apf-27 ane Rwnanng Work 1^p Summary 1A8S Layout HM At ActrAWS Date Date 31-00.24 w Critical Remaining Work Levef M Effort Page 13 of Is 4 Run Date 314ct-24 D M360 Cly review of Package 30-Mul.Plapose Cella Epafwon 100%Drawngs 10 10 1 B.M-25 01 Ja 25 7PUec25 124 o Cry coraco nr Packa�0D-MubPurpose Cerner E-p•n>on 1 o0x D AA370 Fstsl plan!&mons for Padape 30-MubPapom Cerner E tanson 10 10 02JJ-25 16.,ed.25 14.iarv26 124 Frei part revoons(or papage 30-MuU Purpose Center F VWW 111111&11Q�Wj I, budgetng Padrage3D-WO-PurposeCerderFiV9nsi0n30%Drawngs 37 0 OSAL*24A 10uep24A OSAp-25 VMW Package SO-Mu W1 urpowGenter Evwwn300ADrwvngs A (X) SG w"30%Pedag.JD MulfPurpow Cerner E Vwwn eawngs for wd9•fn 15 0 OSAp24 A 30-Aug-24A 03-Ayr-25 me SG sora 30%:Padage 30-Mu4Pt,rposa Carter Errant dritwrps for ouogelng Mw SG prwde c Wuaabity T mm is on 30%P@Okor 3D Muaf-PL,gp e C 5 0 02Sso-24 A 06-Sep24 A 03-Ap,25 r 5G promde mnWudabary mv%w commartf on 30%Padaye 30_MubPuryose Comer Expanson drwgs A4410 SG compoe pncn0 for 30%Package 30-MulfPupOM Center Epanw dawngs 4 0 03Sep24 A 04-Sep-24A 03Apr-25 • Sr,compie prratg fit,30%Paoage 3[)*- dawegs Aa420 SG wbrra budgetary prtvtg for 3C^ Package 3D Mut,%rposs Canter EVwwn 1 0 03-Se024 A 10Sep24 A 03.Ap,25 a SG wbml budgetary Pace for 30%Paduge 3D:-WI PLNpose Cerner Emanaon drawitgs Package 30-WO-Pufpose Ce bvaresbn 60%Drew gs 36 36 03-Oap24 21.aR25 2340Lx.25 106 1110"T PM4g4 SO-Mufi,%rposa C.Aw ErPan-w 60%D MwMs . A4450 SG prove consbuesbfy renew mnments on 60%Package 30,Mua,Purpos•C 5 5 030e 24 09-0ec24 06-May-25 106 a 6Gprgwder cpnynesao4ry reVew•coTmems orj 60%Pot7ago 3D M.b-'-w-Carta F-10 A4460 Conduct page lipmeeung renewstq Bev Package 30-MubPurp..Center Etpa' 1 1 10D-24 10-0aP24 04-aMr25 tae r conaua pager ro^reotrl9 rewi+n9 60K Pa9rge 30 MubFLrpose cM.r Eignaon dopa A4/71- SG wad EC-package 30 Mu1.Purpose Cerner Egan—a—V.for budgtbn 15 15 11-CW 24 02.Nn-25 02Jun25 106 to,Moge" - A4460 SG mope p• g for 50+.Package 3D-MLA.N pow Center Expansion da-Ig. 4 4 03Ja-25 06J4-25 06Ju-25 106 r SGmmpae prta'tg for W%Package 30:-MaO Lopow Cans Epanaon dawstgs M490 SG werM Wogetary pang for�Package 3D-MubPurposs Center Epanston 1 1 09Ja-25 09Ja-25 09.Aur25 106 SG:submt budgetary prat;for 60%Package 3D:f4A Pttpow Ceres Erparaton drawetgs A4500 Owner prove comments on tf,.,Package 30-Mut.Purpose Center Emanwn a 5 5 1 a Aa 25 1"n-25 18Jurv25 106 • P+ner powde porn—s on 60%ParJgge 3D Lwaw aposs Center E.aPwwn sing t-.dgm AA510 SG fe.tas 60%Pack.age 3D Muar.Pwpo a Cerner EvaA pnonq acccrdstg to 0 5 5 17,W.25 23,4-25 23-1,125 106 - . S0 cowls 60%PWaga 30 MlsiFpup0.e Caner P paror0n prtpnq acoognp to owner m GMP M520 SG provide mrtstrudabaty ren►w comments on 90%Package 3D MuUPurpose C 5 5 27-Mar25 02Jtpfd5 02Sap25 106 o SG ped tle consifuWDaiy r%%-*w porfanarsaon 90%Package 30 Mul.PwPOW C M 530 Conduct page Ap nteebrtg revevntg 90%Package 30-MuttPurpose Center E*w 1 1 03-Apr2503-Apr-25 033ep25 106 1 Cortaa Page lap net"ravewng 90%Package 30-MuNPumoae Comer EV40 AAS40 SG wka 9C%Pocage 3D MulfPurPow Cafear Erpsnwn for GMP 15 15 04,10--25 24-Apr-25 24Sep25 106 SG mid 90%Package 30,MabPntpose Center Expan"WGMP M550 SG oo Vd*GMP for Peeage 3D MWtPttpose C•mer P penton,rant 9p%draw. 4 4 25,10-25 30-Ap-25 3054025 106 . SG corttpaa GMP for Pauaq.3D-M11afPupOse Comer E�panson from 90% _ ..........s.........I.......i.•i.., M560 so cob"GMP for Package 30-Mus.Pupow Center E;panaon 1 1 0141Ary-25 01JMsy25 014e-25 106 t W wbmt GMP for ParLge 3p-MubP,0gpw Cerra Eapamon A4570 Owner 5 5 02-Mio,25 Obaaap25 06.Od-25 106 : - • Omer,Desgn ham M~(aMP W P4dAge 30-ktubFVpola Came M500 SG renew comments br Package 30 Mub.FL w e Caner Eparlstm GMP and n 4 4 09.Mry-25 144Asy-25 14.Od-25 106 - • SG nww m rds br Paowge 3D.Mul.PuMp C.rtwExpwsionGMPiW A45W SG Awbmd P3OAge 3D ML9W%MOW Caner EPWn GRIP 1 1 154Aay25 1 SMay25 15-0c-25 106- SG fflwtaN Pfaoaq•3D•MultPapafe Gema Fipanaon GMP AA600 Owrtar IowwO PKkage 3O MW.Purpom Comer Etgw=n CLAP ro CoRR Cry C 5 5 '"W25 224Aay-25 22-0H-25 106 : - • Owfttr Nrward Patlaq.3D MuttPtxpose Comw Expansbn GMP to CoRR _ .....i..t..x..1..1..4...t.3....i..:..(..(..{.. A5790 CoRR Cry COurca appmW pontis for Pad lge 3D MJbPurpase Center Egan 30 30 23-My.25 07,1uF25 0.Sae.25 106 - CoRR Cey Courld appfwM p ods for Padoge)p MWWuMp*e A5600 SG provide CORR isi of tsmmmerdW ed PM(ty wbcordrars for epprowl 1 1 23-J-25 IJ.lun-25 26No 25 110 ' %pwo O.CoRR►M of fomm y*gM prorry u owWso n far appow A5613 -ORR pm tle approval fp reoxrtmen0eo wbmnlactm 5 5 24Ju-25 30Ju-25 050•o-25 110 a CORK pre4desppmvM Iw recommended woaerttackora 1 Ph-ConatnKitln buy-Otsi And Contad Admatation .. 5s 55 23Qvt25 Il Auq-25 14,U-28 106 - - ^I 6uy-00 and Coausib Admnrmalfon ' nab 1 C SG mrdud buyout meetings for praimrtary scopes d work for Package 30 Mub1 20 20 23-May-25 204et-25 2"o,-25 110 a SG condw Duyaa meeovs for grew.ary scopes M work for Package 30 A4620 CG admnmer contracts 10 wbconiradom for Package 3D-MubPupoa•Cerner F,, 10 10 06-%,L25 21JuL25 190D-25 106 o SG admnu0er c)nbads 10 sutxmladon for Paeage SD-Mut-P A4630 Subm troom renew SG wbcomrad for Padage 3D.Mul.Purpow Cemar Evw 5 5 22-td25 26Ja.25 500ap25 106 • SuomnVWas awtw SG subconad far Padage 30.MubPupose C A4640 SG Main all aa•6ea wbm19124s for Package 30-Mub-Ptapoae Center Etp•n 5 5 294,625 04-Atr025 07-An-26 106 o SG fngce and stuwns attOoltutda for Package 30-M.m-P tp..C AA650 Mobaratbn of prAwnmry wbwntrac10rs for Package 30-MultPurpose Career Eq 5 5 05Aug-25 114.;.25 14-4-26 106 a Mobianon of preamnary wbcontractors for Padag•30-MLLPun" SUS"Wal5 75 75 12-A4-25 25Now25 25Se026 211 I r "subm4tals - A46W "Submtaa-Long ysd rmarob fpr Package 30-Mus-Pupow Center EAP-sor 75 75 12.rw025 2"J 25 25Sap26 211 - --Subrnaaa.Lmg aW mMeMM for Padaga 3D-Mut Proaxernierit 150 150 26Nor25 01JLk26 29.Apr-27 211 i ��Prowrerrlent A4670 "Prt-Mrteft-Long lead n,,AsAM for Parluge 30-MutfPapofr CMer 6pana 150 150 26N0 25 01 Ju426 2911pr-27 211 c========= -Ptowament-t-oN bad Cc 3D.1-For Eastern Fields 110 110 12Jart M 1&4M 2e 27Aug-26 53 g'ae �3D 1-F.EaMem FWds 3n I-162 De-k-or exmnq Me elements 10 10 12Je- Jer 26 21 -26 26.H-26 3 o Demoon Wof tRsing sae elements ® 3P.1-172 Underyrwnd Oat- 20 20 12Ja-26 O6-Feb26 i1Feb-28 J Underground LAMAS... gunOah 15Ja-24 « Adua1 Work ♦ ♦M9batons Act"LeM of endn CORR OSP•Preeonstructlon Schedule F"ah Data 2&Apr-27 — Remannq W.n weateaf/Summary W9S Layout Wi AI Ad1vtAtS 1 as Data 31-Oct-24 r C rout Rernanng Work — Levsi of EffW! Page 14 of IS Rut OM 31-Oct 24 gQA LL wR � � � . u oD 3 � m 3 i u M , oc125o u � n : a - x r ooh, IL N V RW,. I:il� l6iP, R1� F, lC7CRRFJl2HARAF ^ s e e e e r a e e t o d e t d a p I SSR � R � � � SS� St '� 4 $ zS � ggSSRR = o r5 • f I fp 5 � ¢ g � 3 � 32 F n Q O pp r g� N fi fi 5 s w Q a B jr "r 71SLLOK � A.. k i ti •r. Mfr --j SpawGIass Providing the Absolute Best Construction Experience ,fl 1 . Pr Bid Proposal Package Strategy City of Round Rock - Old Settler's Park Build Out Package 3A.2 - Harrell Parkway Realignment 90% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 Long Lead Time Equipment and Material There are no expected long lead items associated with package 3A.2. Construction Document Packages It is tentatively anticipated that multiple packages will be required to satisfy material procurement and drawings development. This includes: • Bid Package I - Package 3A.1 portion (already awarded) • Bid Package II - Package 3A.2 portion (this package) • Bid Package III - Package 3A.3 portion (future package) Proposal Package Strategy The project will be advertised for proposals from suppliers, subcontractors, and vendors for all major features of work. Proposals shall be received via mail, email, courier, or hand delivered from subcontractors and suppliers. Any addendums that may be required will be issued one week prior to receiving proposals. The respondents will be evaluated on the subcontractors' ability to perform the work. Subcontractors will be recommended based on their company's personnel and corporate qualifications. SpawGlass will recommend the best value supplier and/or subcontractor to the Owner for concurrence prior to negotiating their contract. SpawGlass Providing the Absolute Construction I ' 00 0 010 0 00 00 0000 SpawGlass Contractors, Inc. 1111 Smith Road Austin, TX 78785 512-719-5251 www.SpawGlass.com Connect with us today.