Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
R-2025-042 - 2/13/2025
RESOLUTION NO. R-2025-042 WHEREAS, the City of Round Rock entered into a contract on December 21, 2023 with SpawGlass Contractors, Inc., entitled "Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of Work Plus a Fee with a Guaranteed Maximum Price" ("Agreement"), and such contract is for the Old Settlers Park Buildout Project — Recreation Center-Earthwork(Package 3C); and WHEREAS, the terms of said Agreement require the submission of an Exhibit "A" to the Agreement titled, "Guaranteed Maximum Price Amendment" ("Amendment"); and WHEREAS, the City Council wishes to accept and execute said Amendment to the Agreement, Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK,TEXAS, That the Mayor is hereby authorized and directed to execute, on behalf of the City, Guaranteed Maximum Price Amendment to the Agreement with SpawGlass Contractors, Inc. for the Old Settlers Park Buildout Project—Recreation Center- Earthwork(Package 3C), a copy of said Amendment being attached hereto as Exhibit "A" and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date,hour,place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. RESOLVED this 13th day of February, 2025. 9/9/ CRA14 MO AN, Mayor City of Rou Rock, Texas AST: m ' 4l,,ho , FRANKLIN, City Clerk 0112.20252:4935-0680-6549 EXHIBIT „A„ ` = Document A133" - 2019 Exhibit A Guaranteed Maximum Price Amendment This Amendment dated the Twentieth day of January in the year Two Thousand Twenty-Fisc,is Incorporated Into the accompanying AIA Document A I33T'" 2019, Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Plus a Fee with a ADDITIONS AND DELETIONS: Guaranteed Maximum Price dated the day of in the year(the"Agreement") The author of this document may (/n it orris, indicate day, morNh, and icor.) have revised the text of the original AIA standard form.An Additions for the following PROJECT: and Deletions Report that notes (Name and address or location) revisions to the standard form text Old Settlers Park Buildout-Packai'e_3.('_ _Rec Center-Earthwork- is available from the author and Old Settlers Park should be reviewed.A vertical line 3300 E. Palm Valley Blvd in the left margin of this document Round Rock,TX 79665 indicates where the author has added to or deleted from the THE OWNER: original AIA text. (Name, legal status, and address) This document has important legal consequences.Consultation with City of Round Rock an attorney is encouraged with 221 East Main Street,Round Rock,'I'X 78644 respect to its completion or modification. THE CONSTRUCTION MANAGER: (Nano. legal.status, and addr•cs.$) AIA Document A2011-2017, General Conditions of the Contract SpawGlass Contractors,Inc. for Construction,is adopted in this I I I I Smith Road, Austin TX 78721 document by reference.Do not use with other general conditions TABLE OF ARTICLES unless this document is modified. A.1 GUARANTEED MAXIMUM PRICE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION A.3 INFORMATION UPON WHICH AMENDMENT IS BASED A.4 CONSTRUCTION MANAGER'S CONSULTANTS,CONTRACTORS,DESIGN PROFESSIONALS,AND SUPPLIERS ARTICLE A,1 GUARANTEED MAXIMUM PRICE §A.1.1 Guaranteed Maximum Price Pursuant to Section 3.2.6 of the Agreement,the Owner and Construction Manager hereby amend the Agreement to establish a Guaranteed Maximum Price-As agreed by the Owner and Construction Manager,the Guaranteed Maximum Price is an amount that the Contract Sum shall not exceed.The Contract Sum consists of the Construction Manager's Fee plus the Cost of the Work,as that term is defined in Article 6 of the Agreement. §A.1.1.1 The Contract Sum is guaranteed b} the Construction Manager not to exceed Five Million Two Hundred and Eighty-Seven Thousand One Hundred Twenty-One Dollars and Zero Cents(S 5.287,121 00),subject to additions and deductions by Change Order as pros ided fit the Contract Documents §A.1.1.2 Itemized Statement of the Guaranteed Maximum Price. Provided below is an AIA Document A133-2019 Exhibit A.Copyright®1991,2003.2009,and 2019 AN rights reserved The American Institute of Architects. 'Amencan Institute of Architects,' AIA'the AIA Logo,and'AIA Contract Documents-are trademarks of The American Institute of Architects This document was produced at 15,29 16 1 CST on 01/20/2025 under Subscription No 20240040942 which expires on 07/0512025.is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents Terms of Service To report copyright violations e-mail docmfo@aiacontracis corn User Notes: (673cb30257573cc341eac23f) itemized statement of the Guaranteed Maximum Price organized by trade categories,including allowances;the Construction Manager's contingency;alternates;the Construction Manager's Fee;and other items that comprise the Guaranteed Maximum Price as defined in Section 3.2.1 of the Agreement. (Provide itemized statement below or reference an attachment.) «Reference attached GMP package-TAB 06 §A.1.1.3 The Construction Manager's Fee is set forth in Section 6.1,2 of the Agreement. §A.1.1.4 The method of adjustment of the Construction Manager's Fee for changes in the Work is set forth in Section 6.1.3 of the Agreement. §A.1.1.5 Alternates §A.1.1.5.1 Alternates,if any, included in the Guaranteed Maximum Price: hem Price §A.1.1.5.2 Subject to the conditions noted below,the following alternates may be accepted by the Owner following execution of this Exhibit A.Upon acceptance,the Owner shall issue a Modification to the Agreement. (Insert below each alternate and the conditions that must he met for the Owner to accept the alternate.) item Price Conditions for Acceptance §A.1.1.6 Unit prices,if any: (Identify the item and state the unit price and quantity limitations, i/any, to which the sin it price will he applicable.) Item Units and Limitations Price per Unit($0.00) ARTICLE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION §A.2.1 The date of commencement of the Work shall be: (Cheek one ojthe following boxes.) ( ] The date of execution of this Amendment. (X] Established as follows: (Insert a date or a means to determine the date r f eonnnencement(?/'rhe (York) April 16th,2025 If a date of commencement of the Work is not selected,then the date of commencement shall be the date of execution of this Amendment. §A.2.2 Unless otherwise provided,the Contract Time is the period of time,including authorized adjustments,allotted in the Contract Documents for Substantial Completion of the Work.The Contract Time shall be measured from the date of commencement of the Work. §A.2.3 Substantial Completion §A.2.3.1 Subject to adjustments of the Contract Time as provided in the Contract Documents.the Construction Manager shall achieve Substantial Completion of the entire Work: (Check one oJ'1he 1611ot4ing boxes and complete the ne cessart information.) ( ] Not later than( )calendar days from the date of commencement of the Work. (X] By the following date: November 02,2026 AIA Document A133—2019 Exhibit A.Copyright®1991,2003.2009,and 2019.AN rights reserved.'The American Institute of Architects;-American Institute of Architects"-AIA,'the AIA Logo.and'AIA Contract Documents'are trademarks of The Amerlcan Institute of Architects.This document was produced at 1529:16 2 CST on 01/2012025 under Subscription No.20240040942 which expires on 07105/2025,is not for resale.is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents-'Terms of Service.To report copyright violations,e-mail docunfo@alacontracts.com. User Notes: (673cb30257573cc341eac23f) §A.2.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents,if portions of the Work are to be completed prior to Substantial Completion of the entire Work,the Construction Manager shall achieve Substantial Completion of such portions by the following dates: Portion of Work Substantial Completion Date §A.2,3.3 If the Construction Manager fails to achieve Substantial Completion as provided in this Section A.2.3,liquidated damages, if any,shall be assessed as set forth in Section 6.1.6 of the Agreement. ARTICLE A.3 INFORMATION UPON WHICH AMENDMENT IS BASED §A.3.1 The Guaranteed Maximum Price and Contract Time set forth in this Amendment are based on the Contract Documents and the following: §A.3.1 A The following Supplementary and other Conditions of the Contract: Document Title Date Pages §A.3.1.2 The following Specifications: (Either list the Specifications here. or ruler to an exhibit attached to this Amendment) Old Settler 's Park Buildout—Rec Center Complex 100° Construction Documents Technical Specifications issued August 2024 Proposed Old Settlers Park Improvements Rec Center Complex —Soccer and Practice Fields as issued by UE S on November 20,2024 Proposed Old Settlers Park improvements Rec Center Complex as issued by UES on November 4,2024 Section Title Date Pages §A.3,1.3 The following Drawings: (Either list the Dran,ings here, or refer to an exhibit attached to this Amendment.) Old Settlers Park Improvements-Rock N River Expansion 90%Construction Documents as issued by Kimley-Flom in September 2024 Number Title Date §A.3.1.4 The Sustainability Plan,if any: (If the Owner identified u Sustainable Ol jeciiii a in the 0ivner's Crile ria, identify the document or documents that comprise the Sustainabili!t^Plun by title.date and number g1'pages, and include other identifying information. The Sustainubilio,Plan identifies and describes the Sustainable Ohjective:the targeted Strstainuhle Measures: intplententatiort strategies selected to achieve the Sustainable pleasures:the Owner's and Construction Manager's roles and responsibilities associated with achieving the Sitvtainable pleasures,the specrlic details about design revielcs, testing or metrics to yerifj•achievement ofeach Sus7ainable Measure:and tits Susluinahilit)�Documentation required.161.the Project, as those terms are delined in Exhibit C to the Agreement.) Title Date Pages Other identifying information. AIA Document A133—2019 Exhibit A.Copyright®1991,2003.2009,and 2019-An rights reserved."The American Institute of Architects.* American Institute of Archilects."'AIA'the AIA Logo.and-AIA Contract Documents'are trademarks of The American Institute of Architects.This document was produced at 15:29 16 3 CST on 01120/2025 under Subscription No.20240040942 which expires on 07!05/2025,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents*Terms of Service.To report copyright violations,e-mail docinfo@aiacwntrecls.com. User Notes: (673cb30257573cc34leac23f) §A.3.1.5 Allowances,if any,included in the Guaranteed Maximum Price; (Identio,each allowance) Storm Drain Piping for Roof and Landscape $225,000.00 Reclaimed Water Extension to Irrigation Meeter S24,000.00 Drinking Fountains and Hose Bibbs S55,000.00 §A.3.1.6 Assumptions and clarifications,if any,upon which the Guaranteed Maximum Price is based: (Identify each assumption and clarification.) Reference attached GMP Package-TAB 05 §A.3.1.7 The Guaranteed Maximum Price is based upon the following other documents and information: (List any other documents or infot•mation here,or refer to an exhibit attached to this Amendment.) ARTICLE AA CONSTRUCTION MANAGER'S CONSULTANTS, CONTRACTORS, DESIGN PROFESSIONALS, AND SUPPLIERS §A,4.1 The Construction Manager shall retain the consultants,contractors,design professionals,and suppliers, identified below: (List name, discipline,address, and other information.) This Amendment to the Agreement entered into as of the day and year first written above. 11/19/2024 OWNER(Signature) 4y: 4Paden, GER(Signature) BY:Craig Morgan,Mayor Austin Division President (Printed name and tide) (Prin(ed name and title) AIA Document A133—2019 Exhibit A Copyright®1991,2003.2009,and 2019.All rights reserved.'The American Institute of Architects,""American Institute of Architects."'AIA,"the AIA Logo,and AIA Contract Documents'are trademarks of The American Institute of Architects.This document was produced at 15:29:16 4 CST on 01/20/2025 under Subscription No 20240040942 which expires on 07105/2025,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents!Terms of Service To report copyright violations.e-mail docinfo@aiacontracts.com. User Notes: (673cb30257573cc34leac23q i Sp awGlass ' Providing the Absolute Best Construction Experience Aft t .c 1 4 _ b TABLE OF CONTENTS TAB 1 TAB 6 BUDGET ESTIMATE OVERVIEW BUDGET PROPOSAL COST BREAKDOWN TAB 2 TAB l EXECUTIVE PROJECT SUMMARY MASTER PROJECT SCHEDULE TAB 3 TAB 8 PROJECT TEAM BID/PROPOSAL PACKAGE STRATEGY TAB 4 TAB 9 LIST OF DOCUMENTS TAB 5 ASSUMPTIONS & CLARIFICATIONS TAB1 BUDGET ESTIMATE OVERVIEW Providing the Absolute Best Construction Experience 9 I� I Project Cost Summary 60% DD GMP OVERVIEW SpawGlass Contractors, Inc. hereby submits to the City of Round Rock for the use and benefit of the new Old Settler's Park Buildout - Package 3C Rec Center - EARTHWORK, based on the 60% DD Drawings, as follows: 1. The proposed amount for the Direct Cost of the Work: $ 4,464,511 2. General Conditions (see ARCH budget): $ 0 3. Builder's Risk Insurance: $ 61873_ 4. General Liability Insurance: $ 39,865 5. Payment & Performance Bonds: $ 52.215 6. Subcontractor Default Insurance (1.25%): $ 55,806 7. Warranty: $ 13,218 8. Construction Manager's Contingency (3.0%): $ 158,614 9. Design Progression Contingency (60/6): $ 317,227 10.Construction Phase Fee (3.50%): $ 178,792 11.Price Forecasting: $ 0 12.TOTAL: LINE ITEMS 1 THROUGH 11: $ 5,267,121 TuLtr WewrtL Tyler Wenzel, Project Executive B 2 EXECUTIVE PROJECT SUMMARY �r , i X It SpawGlass i; Executive Summary City of Round Rock - Old Settler's Park Build Out Package 3C -Rec Center - EARTHWORK 60% DD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 Scope of Work Package 3C - Rec Center - EARTHWORK includes the earthwork and site wet utilities construction of the Rec Center and Admin site. This includes mass grading of the site, clear and grubbing, demo, asphalt paving, all weather access road for AH], SWPPP, building pads, site wet utilities, and allowances for: 1. Connections to Drinking Fountains 2. Reclaimed Water Connections 3. Storm Drain Piping to Building Roof Drains Overview The new Rec Center and Admin building is now being tracked in 3 GMP packages. This is: 1. Rec Center - EARTHWORK 2. Rec Center - SITE IMPROVEMENTS 3. Rec Center - BUILDINGS The Rec Center - EARTHWORK package was broken out separately for shared efficiencies in performing the earthwork for Rock 'N River at the same time as the Rec Center. Depending on the timing of the rest of the Rec Center drawings, it may be an option to now combine the Rec Center BUILDING with the Rec Center SITE IMPROVEMENTS, and make this one GMP. i 3 PROJECT TEAM PAP NN r .rte.♦ �-. pS awGlass �� ORGANIZATION CHART LEGEND uj, Management Support Team Lead/Single Point of Contact On site Team Safety CITY OF ROUND ROCK 0 Preconstruction/EstimatngSupport DAVID PADEN TOM MCCLANAHAN DIVISION PRESIDENT _3TIMATOR JOEY GEORGE ADAM WARDEN OPERATIONS MANAGER t;3; JUAN MARQUEZ BRIAN CLAXTON SAFETY COORDINATOR COORDINATOR TYLER WENZEL PROJECT EXEC.j PRECONSTRUCiION SERVICES MANAGER PARKER BLASCHARRISON HOLLEY SENIOR PROIEC; !'. SLN OR SUPERINIENDENT 2CHRIS SOTO © ASSISTANT SUPERINTENDENTS SI ASSTANT PROJECT MANAGER O ASSISTANT PROJECT MANAGER DAnON DYESS QUALITY CONTROL COORDINATOR TAB 4 r :� 1., L LIST OF DOCUMENTS Ilk SpawGlass � w T _ • a Y } 'y& Providing the Absolute Best Construction Experience A" ` List of Documents 1-1. ErTS --� City of Round Rock-Old Settler's Park Build Out Package 3C-Rec Center-EARTHWORK-60%Drawings 3300 E Palm Valley Blvd Round Rock,TX 78665 PAGE# SHEET DESCRIPTION REVISION DATE Page 1 L-0.0 COVER SHEET AUGUST 2024 Page 2 L-0.1 KEY SHEET AUGUST 2024 Page 3 L-1.0 GENERAL NOTES AUGUST 2024 Page 4 L-2.0 EXISTING CONDITIONS AUGUST 2024 Page 5 L-3.0 DEMOLITION PLAN AUGUST 2024 Page fi L-3.1 DEMOLITION PLAN AUGUST 2024 Page 7 L-3.2 DEMOLITION PLAN AUGUST 2024 Page 8 L-3.3 DEMOLITION PLAN AUGUST 2024 Page 9 L-3.4 DEMOLITION PLAN AUGUST 2024 Page 10 L-4.0 SITE PLAN AUGUST 2024 Page 11 L-5.0 JOINTING PLAN&DETAIL KEY AUGUST 2024 Page 12 L-6.0 SITE DETAILS AUGUST 2024 Page 13 L-7.0 LANDSCAPE PLAN AUGUST 2024 Page 14 L-7.1 LANDSCAPE PLAN AUGUST 2024 Page 15 L-7.2 LANDSCAPE PLAN AUGUST 2024 Page 16 L-7.3 LANDSCAPE PLAN AUGUST 2024 Page 17 L-7.4 LANDSCAPE PLAN AUGUST 2024 Page 18 L-7.5 LANDSCAPE PLAN AUGUST 2024 Page 19 L-7.6 PLANT SCHEDULE AUGUST 2024 Page 20 L-8.0 LANDSCAPE DETAILS AUGUST 2024 Page 21 L-9.0 IRRIGATION PLAN AUGUST 2024 Page 22 L-9.1 IRRIGATION PLAN AUGUST 2024 Page 23 L-9.2 IRRIGATION PLAN AUGUST 2024 Page 24 L-9.3 IRRIGATION PLAN AUGUST 2024 Page 25 L-9.4 IRRIGATION PLAN AUGUST 2024 Page 26 L-9.5 IRRIGATION PLAN AUGUST 2024 Page 27 L-10.0 IRRIGATION DETAILS AUGUST 2024 Page 28 L-10.1 IRRIGATION SPECIFICATIONS AUGUST 2024 Page 29 PF-1.0 PLAYING FIELD AUGUST 2024 Page 30 PF-1.1 PLAYING FIELD AUGUST 2024 Page 31 PF-1.2 PLAYING FIELD AUGUST 2024 Page 32 PF-1.3 PLAYING FIELD AUGUST 2024 Page 33 PF-2.0 PLAYING FIELD DETAILS AUGUST 2024 Page 34 PF-2.1 PLAYING FIELD DETAILS AUGUST 2024 Page 35 PF-2.2 PLAYING FIELD DETAILS AUGUST 2024 Page 36 PF-2.3 PLAYING FIELD DETAILS AUGUST 2024 Page 37 PF-2.4 PLAYING FIELD DETAILS AUGUST 2024 Page 38 PF-2.5 PLAYING FIELD DETAILS AUGUST 2024 Page 39 PF-2.6 PLAYING FIELD DETAILS AUGUST 2024 Page 40 PF-2.7 PLAYING FIELD DETAILS AUGUST 2024 Page 41 PF-2.8 PLAYING FIELD DETAILS AUGUST 2024 Page 42 PF-2.9 PLAYING FIELD DETAILS AUGUST 2024 Page 43 PF-2.10 PLAYING FIELD DETAILS AUGUST 2024 Page 44 PF-2.11 PLAYING FIELD DETAILS AUGUST 2024 Page 45 PF-3.0 PLAYING FIELD GRADING AUGUST 2024 Page 46 PF-3.1 PLAYING FIELD GRADING AUGUST 2024 Page 47 PF-3.2 PLAYING FIELD GRADING AUGUST 2024 Page 48 PF-3.3 PLAYING FIELD GRADING AUGUST 2024 Page 49 PF-4.0 PLAYING FIELD SUB-DRAINAGE AUGUST 2024 Page 50 PF-4.1 PLAYING FIELD SUB-DRAINAGE AUGUST 2024 Page 51 PF-4.2 PLAYING FIELD SUB-DRAINAGE AUGUST2024 Page 52 PF-4.3 PLAYING FIELD SUB-DRAINAGE AUGUST 2024 Page 53 PF-5.0 PLAYING FIELD SUB-DRAINAGE DETAILS AUGUST 2024 Page 54 PF-5.1 PLAYING FIELD SUB-DRAINAGE DETAILS AUGUST 2024 Page 55 C-1.0 EROSION CONTROL PLAN AUGUST 2024 Page 56 C-1.1 EROSION CONTROL PLAN AUGUST 2024 Page 57 C-1.2 EROSION CONTROL PLAN AUGUST 2024 Page 58 C-1.3 EROSION CONTROL PLAN AUGUST 2024 Page 59 C-2.0 GRADING PLAN AUGUST 2024 Page 60 C-2.1 GRADING PLAN AUGUST 2024 Page 61 C-3.0 PAVING PLAN AUGUST 2024 Page 62 C-3.1 PAVING PLAN AUGUST 2024 Page 63 C-4.0 STORM PLAN AUGUST 2024 Page 64 C-4.1 STORM PLAN AUGUST 2024 Page 65 C-5.0 UTILITY PLAN AUGUST 2024 Page 66 C-5.1 UTILITY PLAN AUGUST 2024 Page 67 C-6.0 CONSTRUCTION DETAILS AUGUST2024 Page 68 C-6.1 CONSTRUCTION DETAILS AUGUST 2024 Page 69 A.101-RECREATION CENTER COMPLEX RESTROOM FLOOR PLAN AUGUST 2024 Page 70 A.102-RECREATION CENTER COMPLEX RESTROOM REFLECTED PLAN AUGUST 2024 Page 71 A.103-RECREATION CENTER COMPLEX RESTROOM ROOF PLAN AUGUST 2024 Page 72 A.201-RECREATION CENTER COMPLEX RESTROOM EXTERIOR ELEVATIONS AUGUST 2024 Page 73 A.301-RECREATION CENTER COMPLEX RESTROOM BUILDING CROSS SECTIONS AUGUST 2024 Page 74 A.401-RECREATION CENTER COMPLEX RESTROOM INTERIOR ELEVATIONS AUGUST 2024 Page 75 5A.501-RECREATION CENTER COMPLEX RESTROOM WALL SECTIONS AUGUST 2024 Page 76 A.502-ROCKIN'RIVER PUMP FILTRATION/RESTROOM BUILDING DOOR DETAILS AUGUST 2024 Page 77 A.601-ROCKIN'RIVER PUMP FILTRATION/RESTROOM BUILDING SCHEDULES AUGUST 2024 Page 78 5A.701-ROCKIN'RIVER PUMP FILTRATION/RESTROOM BUILDING SCHEDULES AUGUST 2024 Page 79 AS-1 -RECREATION CENTER COMPLEX RESTROOM GENERAL NOTES AUGUST 2024 Page 80 AS-2 -RECREATION CENTER COMPLEX RESTROOM FOUNDATION PLAN AUGUST 2024 Page 81 AS-3 -RECREATION CENTER COMPLEX RESTROOM ROOF FRAMING PLAN AUGUST2024 Page 82 AS-4 -RECREATION CENTER COMPLEX RESTROOM FOUNDATION DETAILS AUGUST 2024 Page 83 AS-5 -RECREATION CENTER COMPLEX RESTROOM ROOF FRAMING DETAILS AUGUST 2024 Page 84 M-1-RECREATION CENTER COMPLEX RESTROOM-HVAC AUGUST 2024 Page 85 M-2-DETAILS-HVAC AUGUST 2024 Page 86 P-1-FILTRATION& RESTROOM BUILDING-PLUMBING AUGUST 2024 Page 87 P-2-NOTES&DETAILS- PLUMBING AUGUST 2024 Page 88 E-0-ELECTRICAL SYMBOL LEGEND AUGUST 2024 Page 89 E-1-OVERALL SITE PLAN-ELECTRICAL AUGUST 2024 Page 90 E-2-TRACK&FIELD COMPLEX PLAN-ELECTRICAL AUGUST 2024 Page 91 E-3-NORTH SOCCER FIELDS PLAN-ELECTRICAL AUGUST 2024 Page 92 E-4-PARKING LOT PLAN-ELECTRICAL AUGUST 2024 Page 93 E-5-RESTROOM BUILDING PLANS-ELECTRICAL AUGUST 2024 Page 94 E-6-ELECTRICAL RISER DIAGRAM AUGUST 2024 Page 95 JE.7.ELECTRICAL DETAILS AUGUST 2024 TAB ASSUMPTIONS & CLARIFICATIONS 4 ITT SpawGlass I J i�i I• Ir l Providing the Absolute Best Construction Experience 1 . Assumptions and Clarifications City of Round Rock - Old Settler's Park Build Out Package 3C - Rec Center EARTHWORK 60% DO Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 GENERAL QUALIFICATIONS 1. Kimley Horn and Associates, Inc. is the civil engineer/prime consultant of record. 2. Based on an anticipated NTP of February 2025. 3. No specifications provided. Structural and MEP narratives provided. 4. The baseline schedule is based on a 5-day work week. 5. Normal working hours have been included from 7:00 AM to 5:30 PM unless otherwise noted, with exception to early concrete operations as deemed necessary. It is also assumed that work can occur on a 7 day a week schedule if required. 6 In order to subcontract scopes of work in a timely manner to meet the construction schedule it is assumed that buyout packages will be reviewed within 5 business days of their submission. 7. LEED Certifications or Green Building Programs are not incorporated into the project. S. Builders Risk Insurance is provided by SpawGlass. Builder's Risk deductible to be paid from construction contingency. 9. Performance & Payment Bonds are provided by SpawGlass. 10. General Liability is provided by SpawGlass. 11. Proposal assumes that the specified material and equipment are available as required to meet the schedule. If they are not available as required, we assume the Owner/Architect will authorize alternate material or equipment selections. 12. Owner must accept GMP within 30 calendar days, at which time pricing may expire. 13. General conditions were included in Rec Center - SITE IMPROVEMENTS package. Any general conditions savings or losses from that package are to be rolled into the other GMP packages. SPECIFIC QUALIFICATIONS Division 01 - General Requirements and General Conditions 1. SpawGlass general requirements assume a 16 month project construction schedule. 2. Construction photos will be taken on a regular basis by SpawGlass. Digital files will be turned in monthly. 3. As-Built drawings, record drawings and record submittals will be kept in electronic format. These files will be accessible to all on the jobsite. 4. Reasonable repairs or damage caused by contractor(s) will be funded from the CM Contingency if funds remain and approved by CoRR. 5. Dimensional Control for the Project is included. 6. Individual non-photographic hard hat stickers for workers will be utilized. row Assumptions and Clarifications 7. Temporary barriers and enclosures are included to delineate construction zone from the public. 8. No sound/vibration monitoring included. 9. Balance of General Requirements to be included in Rec Center- SITE IMPROVEMENTS package. Division 02 - Existing Conditions 1. Site demolition and clearing is included. Division 03 - Concrete 1. NA Division 04 - Masonry 1. NA Division 05 - Metals 1. NA Division 06 - Wood. Plastics, and Composites 1. NA Division 07 - Thermal and Moisture Protection 1. NA Division 08 - Openings 1. NA Division 09 - Finishes 1. NA Division IQ - Specialties 1. NA Division 11 - Equipment 1. NA Division 12 - Furnishings 1. NA Division 13 - Special Construction 1. NA Division 14 - Conveying Equipment 1 . Assumptions and Clarifications 1. NA Division 21 - Fire Su- l. NA Division 22 - Plumbing 1. NA Division 23 - HVAC and Controls 1. NA Division 26 - Electrical 1. NA Division 27 - Communications I. NA Division 28 - Electronic Safety & Security 1. NA Division 31 - Earthwork 1. Includes all clear and grub and earthwork. 2. SWPPP setup included. 3. SpawGlass assumes that all water can be taken from existing City of Round Rock water utilities on-site, and no water will need to be trucked in from other cities due to water restrictions. 4. Includes 1.5" - 2" PVR at playing fields, as outlined in draft Playing Fields Geotech Report. 5. Includes removal of fat clays and minimum 12"of select fill at building pads for 3/4" PVR. 6. Includes a 3/4" PVR at track. Includes leaving subgrade at middle of track down 2'for infill by others in future GMP. 7. Includes stockpiling of existing onsite material for respread later at planters. 8. Includes asphalt paving. 9. Includes temp road for AHJ. 10. Potential $263,000 credit can be provided to CoRR if onsite material can be mined at Rock `N River detention pond and used at Rec Center. Division 32 - Exterior Improvements 1. NA Division 33 - Utilities Assumptions and Clarifications 1. Site utilities are included. 2. $225,000 allowance for storm drain piping for roof drains and landscape drains. 3. $24,000 allowance for reclaimed water extension to irrigation meter. 4. $55,000 allowance for drinking fountains and hose bibs throughout site. EXCLUSIONS 1. All building work. This estimate only includes site work. 2. Permits, by Owner. 3. LEED documentation and Submittals. 4. We have not included the following items as we assume, they will be provided in a timely manner by the Owner at no cost to SpawGlass: a. Materials Testing Services b. Excludes all local electrical utility fees for permanent power 5. Preconstruction costs for the Project are not included in this budget. b. Contaminated soils - hauling or disposal !�1'1 ,�� BUDGET PROPOSAL COST � °a � � BREAKDOWN ,f An SpawGlass i i Absolute +� Construction Experience it �_ Summary Report Recreation Center Earthwork and Site Wet Utilities 60% Earthwork and Site Utilities GMP Rev 01 Estimate Date: 01/15/2025 Documents Date: 08/23/2024 Project Size (SF): 1,621,737 Project #: 3023121.03C Project Location: Round Rock Lead Estimator: Tom McClanahan ITEM COST COST I SF % OF TOTAL General Requirements (1,621,737 SF) 59,043 0.04 1.12 % Site - Earthwork, Utilities, Parking, and Site 2,974,194 1.83 56.25 % Building Pads - Administration, Recreation, and 855,700 9.51 16.18 % Track and Field (239,842 SF) 155,575 0.65 2.94 % Practice Field (204,105 SF) 85,800 0.42 1.62 % Four Pack - Soccer Artificial Turf Fields (656,094 315,000 0.48 5.96 % Restroom Building (1,680 SF) 19,200 11.43 0.36 % Indirect Costs 822,610 0.51 15.56 % Total Cost $ 5,287,121 $ 3.26 100.000/0 Recreation Center Earthwork and Site Wet Utilities 60% Estimate Date:0111512025 Earthwork and Site Utilities GMP Rev 01 Page 1 of 1 Documents Date:0812312024 Recap Report Recreation Center Earthwork and Site Wet Utilities 60% Earthwork and Site Utilities GMP Rev 01 Estimate Date: 01/15/2025 Documents Date: 08/23/2024 Project Size (SF): 1,621,737 Project #: 3023121.03C Project Location: Round Rock Lead Estimator: Tom McClanahan ITEM COST COST I SF % OF TOTAL General Requirements (1,621,737 SF) 59,043 0.04 1.12 % Div. 01 - General Requirements 59,043 0.04 100.00 % Site - Earthwork, Utilities, Parking, and Site 2,974,194 1.83 56.25 Improvements (1,621,737 SF) Div. 02 - Existing Conditions 81,306 0.05 2.73 Div. 31 - Earthwork 1,510,808 0.93 50.80 Div. 33 - Utilities 1,382,080 0.85 46.47 % Building Pads -Administration, Recreation, 855,700 9.51 16.18 % and Airnasium (90,000 SF) Div. 31 - Earthwork 855,700 9.51 100.00 % Track and Field (239,842 SF) 155,575 0.65 2.94 Div. 31 - Earthwork 132,500 0.55 85.17 % Div. 33 - Utilities 23,075 0.10 14.83 % Practice Field (204,105 SF) 85,800 0.42 1.6201b Div. 31 - Earthwork 85,800 0.42 100.00 % Four Pack - Soccer Artificial Turf Fields 315,000 0,48 5.96 (656,094 SF) Div. 31 - Earthwork 315,000 0.48 100.00 % Restroom Building (1,680 SF) 19,200 11.43 0.36 Div. 31 - Earthwork 19,200 11.43 100.00 % Recreation Center Earthwork and Site Wet Utilities 60010 Estimate Date:0111512025 Earthwork and Site Utilities GMP Rev 01 Page 1 of 2 Documents Date:08/23/2024 ITEM COST COST I SF % OF TOTAL Indirect Costs S22,610 0.51 15-56 010 Builder's Risk Insurance 6,873 0.00 0.13 % General Liability Insurance 39,865 0.02 0.75 % Payment and Performance Bonds 52,215 0.03 0.99 % Subcontractor Default Insurance (SDI): 55,806 0.03 1.06 % Warranty 13,218 0.01 0.25 % Contractor's Contingency 158,614 0.10 3.00 Owner's Design Progression Contingency 317,227 0.20 6.00 Overhead and Profit 178,792 0.11 3.38 % Total Cost $ 5,287,121 $ 3.26 100.000/0 Recreation Center Earthwork and Site Wet Utilities 60% Estimate Date:0111512025 Earthwork and Site Utilities GMP Rev 01 Page 2 of 2 Documents Date:0812312024 Detail Report (Direct Costs Only) Recreation Center Earthwork and Site Wet Utilities 60% Earthwork and Site Utilities GMP Rev 01 Estimate Date: 01/15/2025 Documents Date: 08/23/2024 Project Size (SF): 1,621,737 Project #: 3023121.03C Project Location: Round Rock Lead Estimator: Tom McClanahan ITEM QUANTITY I UM UNIT COST TOTAL COST General Requirements 59,043 General Requirements 59,043 Temp. Fencing - Rental (6' h Chain Link Fence w/ 5,218.2 LF 10.16 53,043 Driven Posts) Licensed Professional Certified Survey (Intial 1.0 LS 3,000.00 3,000 Control Points) Licensed Professional Certified Survey (Final) 1.0 Each 3,000.00 3,000 Site -Earthwork, Utilities, Parking, and Site Improvements 2,974,194 Div. I . Conditions f Demolition 81,306 Remove Rock Road 362,090.0 SF 0.05 18,104 Remove T-Post and Rope Fencing 35,922.0 LF 0.50 17,961 Signs to Remove 64.0 Each 10.00 640 Trees to Remove 446.0 Each 100.00 44,600 Div. 31 - Earthwork : • : Earthwork 1,486,948 Clear and Grub Site, Grading, Subgrade 1.0 LS 1,248,000.00 1,248,000 Preparation, and Asphalt Paving Finish Grading / Spreading Stock Piled Top Soil - General Site Area Buildings, Airnasium, Parking, 1.0 LS 13,500.00 13,500 and Plaza Areas Grading For Site Improvements Between the 1.0 LS 31,000.00 31,000 Building Foundations Temporary All Weather Road For Fire and EMS 52,036.3 SF 3.55 184,729 Around the Buildings Clay Cap Around Perimeter of Buildings W thout 694.3 CY 14.00 9,720 Abutting Paved Surface Erosion Control 23,860 SWPPP Narrative 1.0 Each 1,300.00 1,300 Recreation Center Earthwork and Site Wet Utilities 60% Estimate Date: 0111512025 Earthwork and Site Utilities GMP Rev 01 Page 1 of 3 Documents Date:0812312024 ITEM QUANTITY I UM UNIT COST TOTAL COST SWPPP Inspections 18.0 Mos 425.00 7,650 SWPPP Signage 1.0 Each 175.00 175 -- 4 Stabilized Construction Entrance 1.0 Each 3,000.00 3,000 Silt Fencing 2,033.1 LF 3.85 7,827 OSHA Safety Caps on T Posts - Silt Fencing 339.0 Each 2.60 881 Mulch Sock 274.9 LF 3.85 1,058 Tree Protection - Allowance 268.5 LF 5.00 1,343 Inlet Protection 5.0 Each 125.00 625 Div. 1,382,080 Site Utilities 1,382,080 Sanitary Sewer Scope of Work - Per Drawings 1.0 LS 219,570.00 219,570 Storm Sewer Scope of Work - Per Drawings 1.0 LS 444,410.00 444,410 Water Service Scope of Work - Per Drawings 1.0 Each 389,500.00 389,500 Fire Risers 5' Out to 12" AFF Flange 3.0 Each 6,500.00 19,500 Connect Sanitary Sewer and Water Service Lines 6.0 Each 850.00 5,100 to Buildings Drinking Fountains and Hose Connections - Piping, 1.0 Allow. 55,000.00 55,000 Fountains, and Dry Wells Reclaimed Water Service Line - Extension, 1.0 Allow. 24,000.00 24,000 Connections, BFP, & Metering Storm Drain System For Landscaping and Buildings - Piping, Inlets, and Roof Drain &Downspout 1.0 Allow. 225,000.00 225,000 Connections Building Pads -Administration, Recreation, and Airnasium 855,700 Earthwork 855,700 Admin • Building Pad - Excavate, Subgrade Prep, 1.0 LS 215,300.00 215,300 Select Fill and Haul Off Expansive Clay Airnasium -Building Pad - Excavate, Subgrade 1.0 LS 337,400.00 337,400 Prep, Select Fill and Haul Off Expansive Clay Recreation Center -Building Pad - Excavate, Subgrade Prep, Select Fill and Haul Off Expansive 1.0 LS 303,000.00 303,000 Clay Track and Field 155,575 Div. Earthwork 132,500 Grade and Backfill With Low PI On-Site Material for 1.0 LS 122,000.00 122,000 1 1/2" to 2" PVR Finish Grading / Respreading Stock Piled Top Soil - 1.0 LS 10,500.00 10,500 Track and Seating Area Recreation Center Earthwork and Site Wet Utilities 60% Estimate Date:0111512025 Earthwork and Site Utilities GMP Rev 01 Page 2 of 3 Documents Date: 0812312024 ITEM QUANTITY I UM UNIT COST TOTAL COST Div. 33 - Utilities 23,075' Site Utilities 23,075 18" HDPE Storm Drain Piping From Track & Field to 192.3 LF 120.00 23,075 Storm System Practice Field 85,800 Div. 31 - Earthwork : •0 Earthwork 85,800 Excavate Fat Clay Soils, Backfill With Low PI Soils 1.0 LS 76,000-00 76,000 For 1 1/2" to 2" RVR ' Finish Grading / Respreading Stock Piled Top Soil - 4 1.0 LS ^ 9,800.00 9,800 Practice Field Area Four Pack - Soccer Artificial Turf Fields 315,000 Div. 31 - Earthwork 315,000 , Earthwork 315,000 Excavate Fat Clay Soils and Grade to Subgrade With On-Site Select Fill - 4 Pack Soccer Fields - 1.0 LS 303,000.00 303,000 PVR 1 1/2" to 2" Finish Grading / Respreading Stock Piled Top Soil - 1.0 LS 12,000.00 12,000 4 Pack Soccer Fields Restroom Building 19,200 Div. 31 - Earthwork 19,200 Earthwork 19,200 Restroom - Building Pad - Excavate, Subgrade 1.0 LS 19,200.00 19,200 Prep, Site Select Fill and Haul Off Expansive Clay Total - Direct Costs $ 4,464,511 Recreation Center Earthwork and Site Wet Utilities 60% Estimate Date:0111512025 Earthwork and Site Utilities GMP Rev 01 Page 3 of 3 Documents Date:0812312024 AB 7 MASTER PROJECT SCHEDULE +;J 0 D, + F ri ti� t _t t 1 SpawGlass i CAR OSPr (v9bSUM— 000 SGO 23FeD24A 25AW-27 29•Apr27 3 MSTONE-10 -NTP for Pmcoreauclbn Acrteeb4 0 0 23Fsb24 A : -w kF Ppoene"AdlOA M MSTONE•10 GMPAm,-,W 2 LWWvlew 0 0 OBA.9.24 A 01-No 24 l*GMP/OpIOVgI_R•�.e� MSTONE-10 GMP Approval 3AHanel Pkwy lalteNaw Panda 6 Apex Flelda ROWcaWn 0 0 D9-AW-24 A 05NO 24 A GMP ALp,p�l`p'•b'l_3AA-74eeeeP d y.Lakevlbw Poll"6 ADex Floods R•"IlOn- MSTONE-10 Conemsbon Sun 2 lalewew 0 0 14400.24A - - ....f dldn Sibrt'2:lalmlew MSTONE-10 Cmsouoon Strt 3A7 Hanan Pkwy.LAkexew'Panora 6 Apel Frain Rebowal 0 0 21400$4 A : f:CMILAKIan Start 30,1 Harrell Plow/,Lekrxoe PwWq 6 ADO PlydtRe XOM M570NE 10 GMPAgaoW 3B Tama+Pdkleeell 0 0 24-0ft-24A 11000,24 f L,IAPApproyal_30 �Orrs/Pwoebe) MSTONE-10 DMPAppmAvl_3A2-Hanel Pkwy0 0 po30000,24 04-Febd5 25 ♦GMP Allodvol_3A2-Harts P" . MSTONE-11 GMPApvN 3C-RodCNea Rr 0 0 14.ken25 17,tan25 3 f:GMPAppwal 3C-RatYN Rear ' MSTONE-10 Can0-b-Sun_36•11oma:Pcklabel 0 0 10,4n.25 , :f:ca+cwemn:surt.3d- nbal PKklrbel� MSTONE-11 Cmubuclbl Stan 3A2-1-lsrrel Pbw 0 0 OSFeb26 25 �Comwww+0ta1 ;3A? Hwrel�Irey. MSTONE-11 CorocnMlon Sun_3C-R.WN RKer 0 0 19Feb43 3 f C+nalndnA Stan_3C-RodfN Rive MSTONE-11 GMP A.pprovw_3A 3-HsnM Pkwy WOl;s) O 0 25-Feb 25 19-Sw25 145 f GMR A#pa"l, 3143.Haft P"(B") MSTONE-10 GMPApp—al 38-Melnterla—Area 0 0 27-Feb-25 164.tar25 56 ♦GMP Approve!. 3B-Marleruno Wel MSTDNE•10 Constn.Wpn Stwl_3&Mentenflna Plea0 0 04Ap,25 56 -.... ....... ,a�apLodipn 3urt_78✓.kAainterotAlaa fa . MSTONE-11 GMPApproval_3C-Ret Canter Complex O 0 1"4.-25 21•Aw,25 1 - ♦GfOP�IlpproNI_3C fteo C tmw Cony W MSTONE-11 Conaoucbon Sten 3C-Rec Center Complex 0 0 274Itr25 78 r Cort W.*rt 30-Rec Cenbr Cyajrplax MSTCNE-11 GMPApwovW_3D-MdtGP xpoae Center Expenwrl 0 0 07,7u1,25 D543eo25 105 _ r GMPAplrbedl JD-Nan:Pu+Dooe Career F.�antaA MSTONE-11 Conatn.abl Stet 3A3-Hartel Pkwy MAdpsl 0 O 22 SW25 2$ •C rw,.dnn SUM-3743:-HamN Pkwy 5Ww: MSTONE-12 Subwnml Corrp4uon 2-Larmvuw 0 0 265.1.25- 29Seo•25 t .-....... ...... ...• 4)SulxnardW tompletlen_2.Laiasew MSTONE-12 S.Ix"nol Compatbn_38-Tw N.7 Rd0ao1 0 0 1744 -25 22-Apr,26 107 - ♦SUertanipl CorflHeOnn_•3B•Ten np'F3dWrp7 MSTONE-12 Substaraal ConpMlun 38-Marrteronoa Mea 0 0 OB-Jan-26 25-Mer-26 56 Cpmpletjon_3-Msrtanarm'1ra} k4STONE-11 SrM7fnbN Canplsmn 3A1-HWW Ploy Lalw~Parlonp i Apex F+eab Rebt 0 0 09Jan-26- 14.6r26 3 - *Subvjnb6,CwnpIwW. 31L1 HaAM Pkwy L MS71ONE-11 Conatn,dbn Start_30-Wb-Purpose Center Erparabn 0 0 12,12r 26 3 :f COrutn.won Sulrt 30 Mkdlb OMM CsMw ..............,.... . ., .; MSTONE-12 SrneaNul Corrpabm_3C•RocVN R7w 0 O 27*W-26- 01,W26 J x f S"wMrv*lCw pblldn.3C-RodM..RKw. MSTONE-12 SubsurAal Conpalwt_3A-2-Hanel Pkwy 0 0 29-A n-26' 24Aup-28 40 ' b1tarllYlCg7pl•OOn_ Ltj MSTONE-12 SuMW7W Canplobpn 3A3-HrrV Ps1Ay(Tirdps) 0 0 271MR6, 31Auq-26 25 $ilbatwllbl;Ceirplae}n_3A3 M5TONE-12 Svesuntlu Completion_3C-RK Center Complex 0 0 30-oa-26- 02Nw26 1 5ub#Lw tel MSTONE-12 SubatersW Completion_30-MWOPuDoee Center Emarvxr+ 0 0 2BAW-27 29,W27 3 E81fy P100lf6ff1B7N 290 35 23Fi1:44A 200w24 29Apr27 599 . .Eany Pma%Mmwe: 'AS= ••SG compile and tum h early p•dtepa for lora add Rema 1 S 0 23-FOO-24A 2"n-24A A 12JAaN27 �leel�p . -v4iJ and tum In ewM poplaggle 1.long bbd Lean A5210 C.RR W.pedtepe and re".SG to Wooed WM Wq WM ft., 15 0 264Uu 24A 1246,24A 12-MoN27 • OoRRreAlevtpaUmpe entl Ieb•M 940 m pbb•e1 WI,Wnp land 4pms I., ' M ®® --.-.. ♦�suatnx7FFjtoa AS= 30.1-Howell May Condo Padntlr+UnderpassUnderpassSL&,.bel 40 0 03,A7n24 A 3146-24A 124427 .... -ss� 34.'(-vle+rel Pkwy Cprrtpo;Pede6tngn if nderpase Subml4af A5240 3A7•Moro Ploy Pedesdbn BAdpe DetaRq and%AcrwA ADD" 40 0 03,K -24 A 17.kA.24A 1211427 bMM 3,11:H Ilme�PwwyreoedrM.Bilepe Dauir+�and�,bmlthl,4pgw}I t A5230 3A7-Hero Ptwy Ctarat111 Pwkl7abbn UrMrpbla Poem 0 160 38 17.1124 A 200eo24 25-W-27 596 -9==, 3A+•HO"PW#Cdrdddr PedsNvrt Jeddpets Roturrmer. A52SO 3r11-Harled Pl ey PedMMIw Odd98 PloOtwner7l 160 3S 31,bQ4A 20-Oso21 29-Apr27 596 �a.�-a x+.HMrV PIrJtPVMe4on®1dQ.Pro6nantFt ; 2 Lakeypay 496 230 26,bn24A 2Moo-25 29Sep25 1 2-Lakwa Delrpn LKVWIOO SGRWWOflakev8w60%DM*V9 t 0 26Jan24A 26Jan24A 01 Jvov-24 r SGRvcWoi Labn.sw607b DtsaI'gs start Dain. 15-Jan-24 Arb,Wok f •Mbllbro Acetel Leel of Ef t CoRR OSP-Preconstructlon Schedule F{nleN Date'. 26Ap-27 0.0, Rerrrea7rlp 11Wr% VM-1 s,anmay .WBS Lryoul-HH MI ACNvitNs � r Dau Dain. 31-00-24 aaa�r Cffial Rsmank%l Work saaane Lmel otEffort Page 1 of 15 J Run Dab: 31-0a-24 ..................................Y..........._ 0 .... ... .......... .. ....... _ ... i ..s . . .... air- gg ....... .... r 5? z �.; .......... Ir0 10 t ♦ ry n ♦ • ♦ ♦ ♦ ♦ ♦ v a ♦ n v �¢i d e ♦ ♦ ♦ ♦ o a < < < < < < < a a < < < < c < < < < < k< < < < < < < < < < a < < N ♦ ♦ � ♦ n n n n h 7 ♦ ♦ . N ti n < < 115 LTi ♦ ry n n H N N ry n {y N f♦V ♦ r 1♦V ♦ a••♦ H H r n N o e e e e e e e o 0 x P y P V� � N } 4 � • M � -� � } V N SL �� � Vu � N V '.�15 udOuLN®�� 78VNV OO J�N • V u ♦ � V + > �. � VN u ♦ �. M n - - 0 - o O n n - c 13 aa , � Y4 § IL i y C'1 O i ppT IL _q g�5 ' �j .i • C i ix � ul 0 at 0 v _ 66 � 4 t p N t t e < < s < t ry x T A a A " A A a ti n A R AH u 15 r. r. `J � • �'�" • - � - nQ � .n�IQ �' � s ,n ., $ 28R Jrl f�' $ �' � Rt' � � P.. .i � R : S. ''" �' i '� s h k s e . a d i y a i ` z721 r _ _.. _ m L nX ogle iIIA �' y����yy� � jj11 ppr� yy1 ' pq� ((•.Y� (4fqq � � � � {1 M � ,. �' , Y; i� `•1 = � ' � `� 'j_ 11 . a _ . a � uu _ . � � � a a - T A azo;g sosx �' J - • •� ♦ M W®0 9 0 0 0 0 0 0 0 P 9 b ! C 5 + 4 G •J G�� ej O ? O 5 k 1 E 2i Tas x z � L . Y z> v r > y > f > > > r > > ? � T T > � gY � N ►• sc". � � i � � b �? � i. sssss � ssss 0 A f y 6 ¢ 1 ' a p -! 3 � ., � :$ : it 16 acral P � € _ • ILi CK it �a' X x � 4z4 n Fa o n n n ,- r. se e Q91"R 5 919SR RR a woe n n �- ennw . r i F E � � fig ➢ � F � € F � � � � � � � 8 � x Y r t a� 0 v w; ca IL B DID a < < A 4 < < < < < < < < < J • c o 0 o a o 0 0 0 0 0 o a �; o o - 6 K � n .n a g `j g g�y � k Y fa Fd Y kS `.�. Y FI Id Y = n - N • - n • - n k - w' F. n a N Q A !R®" Y A S St ? A 3j 9 A P. V a OR it At a� n a 4 A 5� yy z � zz is s _ < If s i IF ` 13 Jl is IL t n t A x 1 $ A It � e •3 0 0 0 0 0 - !' . - a. . . . ' / {u OR a 3� `c � � m m 0 r : 14 1 $ p is ua tn Fig i U < a < < H N N N I N N r j ` $ R � u+ •�+ v+ $ g g 8 $ $ < R S $ R R R R "� � o 0 0 0 0 0 o u o o - o 0 o a o u e I A R I $ R R R R 6 a H - o r - ' p _ .P r r + - = P r c U 7 Q : r 9 .2 1 � 1 � € 9 Fe r ja ' _ 1irN M w jrto IL s � I r - K U 1p • n v a 0 0 0 o a o - o a o • - h . - w " n " FT7 f � z - sasa R ss � Ra � � saa '5 6 • rr • � d, � � � a N � cT� cQ, Sri � � n G u n � � v. d •r. } � � u � u � 7 � � S 6 � 1 Ij �j I a: : .. . x: 90, 5 i s Cc 0 u _ _ _ _ - - . _ _ m - -, n n . r $ $ � sR d E L4 1 < i K c = ma c :- it � � � � ? ��a c+ o 0 o g o n a o o r. w w � '' . - a • � w R - r � � /t r o � .. � o a o a � �i +� . - �1. r n + a o - w � � � . a • r. � � k � �i 6 � s ,� � ac r� a � � a � � � � i � � 6 f � • a � x � AOWV In A.%�O N— Ow Ria" am Asian Late Finish -761W FlOW 0 0 a a 0 0 0 0 a U Q 0 a M140 SG adnwrter mnbacObsubmreraxon for Padape 3C•Rec Center Complex-! 10 10 21apr-25 02-Mai25 054tw25 1 o sennsw:co.tradafo sutr0oferaobre fo Peek4pe3O• ecC•nw Complex A4150 9uEmrtr•mor.m—SG ofboontrad for Peaage 3C Rec C.nnr Complex-Sfw 5 5 054 IV,25 09AMy.2s 12#1•y25 1 • 6upoor'trepota rr vN1.9G auMnrrtirap by PfxlPpq 7Q-HeCC4rnr CMr7•R•9 A4160 SG*dkM rtd execute wbrnnencb for Padwge 3C Ree Center COMPMx Sae 5 5 1241ay25 18.Mey,25 194Mw25 1 .-SG fvWine and exearta arOcanPeai Lor P{ta4pe 7Cf Red Cfrmr cumPex A4170 MoblftponofproWeranysitbmnbsMmbr Pa4age3C Rec COMWComplex-S 5 5 1944ey2s 21Atey25 27"wt.25 1 - . MWbI�al4nd p�afm.fary aoaantraadra ter Rsda�+3C-Rete GnlbrCat•.t Subn*ab 75 7s 27418yz 106OP45 2554p-28 265 Plnnalonolf/SubRlanle .:......................:..:..:.. 1..:-.L--:.-: , A4180 "Submittals -onrp lead nxttrtel.for%dogs 3C-Roc Cerxer Contplax Sin(Eke 75 75 27Awr2S 10-Sep-25 25Sw26 285 "StbrtMts4,Lop teatl nt.swrle lot fAWopc3C-RWX~Ca Pmlatrerr•1m 150 ISO 11Sep25 15A" 26Aph27 285 !9•6•(•wm"wmumwI Proaameent M190 "Proaeamsnt-Long Med mater"for Paaage 3C-Rea Cerdw Complex-Sb(E ISO 150 II-SOP-25 15,W-26 29Apr-27 255 ..•,--r�r..- "Prawrarneni .00fiNud rt.twemain fix; OMEM �.reeleer—�,ColnbAw9Dn. ANN E&VWAA r eued+t9 Pada .. 100 100 2744sy25 15-00.25 160ot-25 1._... . I I � � � EKfrtjortjl9uks5 P,d+: . AS090 Underground Utilities r MEP Rough4n 100 100 23,)ut25 124)ax25 02AO,28 78 Lmaerlifoynd UtDlea MEP Ijou+nln 3C RSO C6n*r CorM"-BuldwW SW 506 25van24 A 304clial1•26 29•Apr47 125 7C-!rat C•n►r can �llauie 8 CMRn%rn AUX REC Unfair to be Nmed Dar by 10,0126 b alawfdr obddrp for OW"01.202; 0 0 300rt-M' 0244ov-26 1 REC Clew m W N �EF.MrS-F Do in _..: .......' A6390 DwnteprbrtM PrbW 3C-Ree Center Crmrptex da •&irps 30%Draearps 46 0 25Jr.24 A 1341sy41A 21-Feb-25 .eaa�r DevelbpneM of I�'etlap 3C✓'Wo Csroer Complx•80idlpt30%Drewrgs A5310 SG rack d PKkWe 3C Rw Center Complex 3O%Dawgs(TargetDab W.15 1 0 134%,,24A 1344ay 24A 21-Feb-25 SG nlDelpl ot,PoJGupe 3C;Rae tMnr:CaMplex 901E DyeNrrg7(ibgst llaM D�t�2, A6670 CDy wArmv of Padrape 3C Rec Canter Complex 30%DrwnYpe 10 0 134&y,24A 284Aey24A 21-Fob-25 Qty leV1p4•Pf P.� 3C jt•G Center Qomfdgr 30%;O"V.. A6320 De.eloontentof P•r+a9.3C-Rec Cenw Comptexrl0%DraWngs 47 0 154,1-24A 2SQ1,24A 21-Feb-25 Dw6bMat(R 4f PPd gq3;-Req Center Complex eq%Qrwrgs _ A9280 SG RvoW l Pedwge 3C Rec Center Complex 60%Dnv4ngs frarpet Date 09.2 1 0 25,0a-24 A 254Dx•24 A 21-Feb-25 SG R•aeipl:et Pad{npe 3C.Rdc Center CortpMx 80%DOwirpt(rargat ClEI :20;241 A6290 Development of Padage 3C-Rec Center Complex 90%Dray.Yp4 38 38 18-De»24 11-Feb-25 30"•y-25 Ti ..o De4ebWn..t of-P.0 pe 3C-Rec Carrier:Cornpbx 90%DMrY9s A63DO SG scall t of Pndnpe 3C Rec center Complex DO%Dnveps(TOW Dae.08 27 1 1 12-Feb-25 12Fe1:05 024,.25 77 r .SO memo of Packa 3C:-flat GnterComdax9DIA Dretwtga(&W bate 06 0,24) AB340 Cay wAswol Pe""3C Rec Carrier Complex 90%DrownP 10 10 134eb45 26•Fe15-25 21Aug-25 124 a• C`flyfevpwpf Peppgp3C step CM+vM C`yorprNeK 9p1G;0rtwygs A8350 Devebpment of Package 3C.Rw Conw CanDlax 100%Drwing. 18 is 27-Feb-26 24-Ma.25 17Sep-25 124 d.DwebpirgM d PPxpga 3G•RaoC�nter Cpmplaa 1U0'I�UTwng► A8360 SG ferafpt of Podm"3C-Rao Canter Complex 100%DfNA6pW(Target Dan t0 2 1 1 2544or45 254Aar.25 1BSey25 124 - ..SG rd000t df PbddmO 3C-Red Cents Cbnlplrr 100%D�YrIrp1 RMprlt pets i 0:22, A9370 Cry rwAw of Paaage 3C-Ree C4tmar Complex 100%Oraeaps to 10 26-M x25 Ofl•Apr-25 020x,25 124 C ClyiMrew of PaNapa SC-Roe CanbrCal.pYx 7g0%Dfal�Ytpa Ai F"pian wAvio ra for Pactrapa 3C Rec Ceraw Complex 10 10 09dpr45 22-AM-25 1604.25 124 e.phal plsp MAW" lot Prooli 9C: Rec GDurCo fe": raw" Buog"ng PbOkepe3C-PAC C.arlbrCMI)bx-Btdd Vs30%Drrwhlps 25 0 134tay24A t6JuQ4A 21FeW25 px'-WPedoo•3CI-RecCMalCa„0x..Nftl0 tp♦30%Dw1+w• A6400 sG pwo de oonatrtrcbbRy review tp w"tir on 3D%Pooke"3C-Rec Center Cdr 5 0 134My-24A 144ArjQ4A 21-Feb-2S M7rrde paC4t)!�.YeN mf^^lemla of 3�%'PapkWe pCN Ree�•rlterCoRrpl•x dnv8+ ............... - --. A6410 SG aofot 30%Pecbpe 3C Rec Center Canplax dravtrps for NK480V is 0 144/ay24A 12,6 24A 21•Feb•25 _ aide, :SG so4yl, Red C w .. ...... .•..•...•..:... PAd1.94 xG M r•^Pl•!t d awY pe bi bubp4trr e A6420 SG cDmpte plop ter 30%Podape 3C RocCanty Complex dreaerps 4 0 12,Am.24 A 18Jun24 A 21 Feb25 _ • SG Nfridb x1dry Tor 30%PbdOgd 3C Red C~Cpmple7l OOVMO+ A8430 SG-W)A NAgewy limong for 30%Poduw 3C Rec Cerrtar Comple.dnsrmg+ 1 0 18,A),24 A 184un24 A 21 Feb25 SO submit ary pr"for 30%Podtspa 3C.ROCCsiw C Phex orw,rogs. Pbclapa3C-ROCCetlterCarpbx-Bulditgs60%Drewngs 32 32 250x24A 17-0ax24 DTAW-25 TT Pactgp•aC.•RecCeotetGllmpfex.8u10hp+60%DrawwM AOW SG provoo oonrAnmtaWily revtew corn emo on BO%Package 3C•Rec Center Cor 5 1 25-0x44 A 314ct•24 21 Feb-2577 -----SG D�oede mnswaebRty fawaw mrturnnaon-W1A Prsape 3C Rec Crar domlplex d!M0 .. .... .- -- -.. .._:.... -... . .... AB180 Conduct page Ilio moo"revewerp 60%P•dCenter age 3C-Rec Cer Complex*v4p 1 1 0141oM24 01aJov-24 24-Feb-25 77 Qorldup Dupe sa mNetc 9 PvWoXV ck784 30 Fj.:.0 yrler CempteN drygt A645C SG aoedt 60%Peaage 3C-Rec Canter Complex*av*w for txxfgo" is 15 04Nov24 22a40v24 17-Mr-25 77 a SG.Pd 60%P.daBa IC-Rec Carrier Cor pl}x dravkp•to,b,dQ" . A6460 SGmnpb prong ter 80%Package 3C-Rec Center Caroex dr.ekpe 4 4 2544ov-24 0243ov.24 21 AW-25 77 a sG opmpW pr"fdr 60%Pabia"3C.Roc Center Complex pnvurps A6470 SG sufrrNl budgetary pfFyp YOI BO%Pdape 3C•Rec Cemr Complex dravepa 1 t 030w24 03dex24 264Mr25 77 i SG woim:butgetry pftirtq fair f1C%Peoage JC:RfiC. . . .P�sx do iNpe A6490 0.wer provide connente on 80%Padaps 3C-Ree Center Complex dnvg btdgob 5 5 04)w24 10434x24 31-Mai 77 : P veetprwidb combents on b0l(P�dtapa(3C•R4«;Ceitter COmp4N drip bWpatfrynumpefa; AM SG fwAm 60%Pei. ge 3C-Rec Gluten Complex amr6q b x p0OWW 00011,11s 5 11-0ex24 17-0•x24 07-Apr-25 77 n's(1 rayeq fiQ%Patlape�'Rope q:rri.'EdrprDl}rc p•d09 japnl�q b�dpnprejrts• GMP A6510 SO Provide c mgtx2WMy 1wMw dommerite on 90%Pacoap 3C•Rec Carter Cor 5 5 134;06-2s 19F046 0941111•25 n I e s6 uiDvtp.pxremiaapeti•r:Na(Y a}fmri'»rib jm pO1i Pid4g::3G f}.c?caitoej C}mgMx ASM Condopt nape tYp mostli nAWM 90%P•dage 3C.Rec Cantor Complex Attar 1 1 20Feb•25 20•Feb25 10,A.t•25 77 • Cendta:p.gs/p Alares+b rrwMftP 90%i'aCtaOa 3C-Roe CanEar L:dMpMx ilrvgs Start Date: 15-Jan24 AfAau Work ♦ •Mumma Actual Of effort Cci OSP.Preconstruction Schedule Finish Date:2&Apr-27 ria RmraYdp Work peii Sarong WOS Data Dew: 31.Od-24 ayoul- Ali Actrvio■a �� Critical Rmenktg Work so LevN of EBbR Page t 2 2 o of -5 Run Date: 31.00.24 L pp n ; { � c ♦ .. Y p r � u v $ - - OR ip ..... ..............._ ... :5.. .. O_ .,._. .t ... .................... I , O 1 8 .. �. Aj �. n � Air is cc rn 0 u b 'e w F 3 I a � F u A 4 e 2 � t = 1 0 a " O r, .a n � .. � r . � .n � n . _ v - .r. ♦ ., 9. � Ip 3n' �' � ,� r � C � $ F o � � ss � E 00 � � . _ � .. - .nm ,n �+ . ., g .. � k . ., •, n .. SSR R y � � � b w � � � 43 2 K L r N V o � m ; c = � o _.. ..._.-....._ ..................._. . a h 0 V N N N N N N � Cf N D N N N A r` r N � ry ti • N N � 18 N� N N A N � ry$d 7 r7 N � � f. N N N ^ N N N �I rryytpq 5 rW . 8S � � RSRS � 49553 § 888888 gSSRR � � � 3 g u a PAD g � 181 g �, VR YY C C PACKAGETAB 8 71 STRATEGY 1 40 } 7 yyyy j '5 s f�: � C F Providing the Absolute Best Construction Experience i r � '�-rte+• � .- SpawGlass Contractors, Inc. 1111 Smith Road Austin, TX 78721 � . 512-719-5251 SpawGlass.com AcoREP CERTIFICATE OF LIABILITY INSURANCE OATS(MM'DOrVVVV) ,11612025 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the pollcy(les)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). MOO CER CONTACT Adams Risk Management Services,LLC PMS Mina Tamez FAx Adams Insurance Service, Inc. (A1C,No,Ext):(713;869 8346 (A/C,No)-(713)869 9144 1111 North Loop W. Suite 600 ADMDRESS: miamez@adamsins.com Houston TX 77008 INSURER(SI AFFORDING COVERAGE NAIL Y INSURER A:American Contractors Insurance Co.RRG 12300 INSURED N-01 INSURER 8:ACIG Insurance Company _ 19984 SpaSmith Nth Road Contractors, Inc. 1111 INSURER c Valley Forge Insurance Company 20508 1111 S Austin,TX 78721 INSURER D The Continental Insurance Company 35289 INSURER E Travelers Lloyds Insurance Company 41262 INSURER F: XL Insurance America,Inc. 24.554 COVERAGES CERTIFICATE NUMBER:1257883251 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NO-WITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISS.jED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POL`CIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE AODL SUER POLICY EFF POLICY EXP R POLICYNUMBER r LIMITS A X COMMERCIAL GENERAL LIABILITY " " GL24ABC00046 61112024 6/1/2025 EACH OCCURRENCE $10.000,000 CLAIMS MADE X OCCUR DAMA09-TO AENTE•O PREMISES(Ea occwrencg_) $100,000 MED EXP IAny One rscn) $5.000 PERSONAL 8 ADV INJURY $10,000.000 ;E WL A:,GREGATE LIMIT APPLIES PER GENERAL AGGREGATE $10.000.000 PO ICY X PRO ,OL PRODUCTS COMPrOP AGG $10.000.000 OTHER: $ C AUTOMOBILE LIABILITY Y Y BUA70337?)896 6/112024 6/1/2025 COMBINED SINGLE LIMIT $5,000,000 IED acRoqu X ANY AUTO BODILY INJURY(Per persons S OWNED SCHEDULED BODILY INJURY(Per accident) S AUTOS ON Y AUTOS X HIRED X NON OWNED PROPERTYDAMAGE $ AUTOS ONLY AUTOS ON-Y (P�r aooi4enl) S D UMBRELLALIAB X OCCUR Y Y CUE7034067095 6/1/2024 6/1/2025 EACH OCCURRENCE $10.000,000 X EXCESS LIAR CLA MS MADE AGGREGATE S 10,000.000 DED RETENTION $ B WORKERS COMPENSATION Y WCA000008324 61112024 6/112025 XEREH AND EMPLOYERS'LIA8ILITY Y N 'S'-__TU7E__ ER ANYPROPRIt-TOR PARTNER,EXE UTIVE NE.L.EACH ACCIDENT $1,000,000 OFF CER MEMSEREXCLUDED? N A (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E L.DISEASE POLICY LIMIT S 1,000.000 E CONTRA::TORS EQUIPMENT OT-630-7625835-0-TLC-24 6/112024 611/2025 LEASED/RENTED SEE BELOW F BUILDERS RISK iBROAD FORM. US00116369CA24A 6/112024 611/2025 PROJECT AMOUNT <510,000 000 SEE PAGE 2 DESCRIPTION OF OPERATIONS LOCATIONS VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached it more space Is required) Contractors Equipment Continued Per Item $1.500,000 Aggregate $3.000,000 The Automobi a policy includes the following endorsements. 1)CNA63359-Blanket Additional Insured as required by written contract executed prior to the bodily injury or property damage 2)CNA63359-Blanket Waiver of Subrogation a5 required by written contract execaled prior to the bod'Iy injury or property damage.3)CNA63359 8 CNA71527-Primary Non-Contributory basis only when required by a written contract prior to Accident or Loss.4)GNA68021 -Notice of Cancellation-30 days blanket as required by written contract See Attached CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Round Rock 221 East Main Street RUTH IZED REPRESENTATIVE Round Rock TX 78644 r y /r� ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: SGADMIN-01 LOC#: ACORO ADDITIONAL REMARKS SCHEDULE Page 1 of 1 AGENCY NAMED INSURED Adams Risk Management Seances, LLC SpawGlass Contractors,Inc. 1111 Sm th Road POLICY NUM IER Austin,TX 78721 CARRIER MAIC CODE EFFECTIVE DATE ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: - _25 FORM TITLE: CERTIFICATE OF LABILITY INSURANCE The General Liability policy Includes the following endorsements 1)1 170-Add tional Insured-Automatic Status as required by Contract-Blanket-Who is an insured is amended to include as Add tional Insured any person or organization when you have agreed in a written contract that such person or organization be added as an additional Insured on your policy The endorsement also provides for the coverage to apply on a primary and non-contributory basis for ongoing and completed operations when required by written contract 2)205-Blanket Waiver of Subrogation when required in a written contract or agreement.3)336- Notice of Cancellation,Nonrenewal or Material Change-30 days blanket as required by wrtten contract 4)9-Aggregate Limits of insurance Per Project. The Workers'Compensation policy includes the following endorsements 1)WC990304-Waiver of Subrogation-Blanket waiver for any person or organ zation for whom the named insured has agreed in a written contract to furnish the waiver 2)WG420601 -Notice of Cancellation-30 days blanket as required by written contract The UmbreilalExcess Liability policy applies in excess and follows form of the underlying General Liability,Automobile Liability and Employers Liability pol cies above including the terms of any additional insured waiver of subrogation and 30 day notice of cancellation endorsements The policy follows the terms and conditions of such underlying policies unless they are Inconsistent with the terms of the policy The Equipment Floater policy includes a Blanket Automatic Loss Payee Endorsement CMU618 that provides Loss Payee status to the Certificate Holder only when there Is a written contract between the Named Insured and the Certificate Holder that requires such status. Re.Project Old Settlers Park Bui clout,Package 3C-Rec Center EARTHWORK 60'.DD Draw ngs,3300 E Palm Valley Blvd Round Rock,TX 78665 Project Amount$5,287,121 ACORD 101 (2008101) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD ADDI. ._NAL INSURED - AUTOMATIC %'- __ JUS AS REQUIRED BY CONTRACT - BLANKET This endorsement modifies insurance provided under the following COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Any person or organization that you are required by written contract to include as an additional insured on this policy if the contract is executed prior to the loss. A. Section II,Who Is An Insured is amended to include as an additional insured any person or organization shown in the above SCHEDULE (cai ed add'tional insured),but only with respect to hab fly for"bodily injury" 'property damage"or'personal and advertising injury'ar sing out of your premises or your operations for the additional insured,and only to the extent and for the minimum limits requ.red in the written contract. B. The insurance provided to the additional insured is subject to the following limitations t. Unless a written contract specifically requires additional nsured coverage for your completed operations,this insurance does not apply to'bodily injury"or"property damage"occurring after"your work"for the additional insured has been completed or after that portion of .your work"out of which the"bodily injury"or'property damage"arises has been put to its intended use by any person or organization, whichever occurs frst 2. Unless specifically required by written contract,th s insurance provides additional insured coverage only for liability for-bodily injury". 'property damage or'personal and advertising njury'to the extent caused by the named insured's acts or omissions or the acts or omissions of those acting on the named insured s behalf. 3. This insurance does not apply to"bodily injury",'property damage"or"personal and advertising injury"for which the additional insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement except to the extent that the additional insured would have been obligated to pay such damages in the absence of the contract or agreement 4. This insurance does not apply to"bodily injury",-property damage"or"personal and advertising injury"ansing out of the rendering or failure to render any professional services by any insured or on any insureds behalf,including: a) The preparing,approving or failing to prepare or approve maps shop drawings,opinions,reports,surveys, field orders,change orders,drawings or specifications;or b) Supervisory,'nspection,architectural,or engineering services This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring,employment,training or monitoring of others by that insured.if the"occurrence'which caused the"bodily injury" or'property damage",or the offense which caused the"personal and advertising injury",involved the rendering of,or the failure to render,any professional architectural,engineering or surveying services. 5 This endorsement shall not apply to a person or organization if any other additional insured endorsement attached to this policy specifically applies to that person or organization. & The insurance afforded herein only applies to the extent permitted by applicable state law, including statutes governing additional insured coverage in the construction industry. 7. The insurance afforded to the additional insured shall not exceed the minimum limits required in the written contract. C. In no event shall the insurance provided to the additional insured exceed the minimum coverage required by the written contract,including but not limited to minimum limits,minimum scope of coverage,or minimum duration of coverage.If a written contract or agreement requires that additional insured status be provided by the use of specified edition dales of the ISO CG2010 and/or CG2037,then the terms of that endorsement are incorporated into this endorsement as respects such additional insured and shall supersede the coverage grant and limitations in Sections A. and B. of this endorsement. In the event that CG2010 and/or CG2037 are required but no edition dates are specified,the 04113 editions shall apply. D. This insurance is excess to any other insurance,whether primary, excess,contingent or on any other basis, available to the additional insured unless a written contract requires that this insurance be primary or primary and non-contributing.However,this insurance is always excess to other insurance,whether primary,excess,contingent or on any other basis,when the additional insured has been added to the other insurance as an additional insured. Nothing herein contained shall be held to vary,alter,waive or extend any of the terms,conditions,provisions,agreements or limitations of the mentioned Policy,other than as above slated. This endorsement changes the policy to which it is attached and is effective on the dale issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 6/1/2024 Policy No.: GL24ABC00046 Insured: SpawGlass Contractors, Inc., SpawGlass Construction Corp.,SpawGlass Civil Construction, Inc.,Westland Equipment and Supplies, LLC Insurance Company: American Contractors Insurance Company Risk Retention Group 20 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following. COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Persons or 0 2anization(s): Any person or organization for whom you have agreed by written contract to furnish this waiver. Section IV—Commercial General Liability Conditions, 14. Transfer of Rights of Recovery Against Others to Us Condition is amended by the addition of the following We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or"your work"done under a contract with that person or organization and included in the 'products-completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective 6(1/2024 Policy No.. GL24ABC00046 Insured SpawGlass Contractors, Ing.., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc.,Westland Equipment and Supplies, LLC Insurance Company. American Contractors Insurance Company Risk Retention Group 336 NOTICE OF CANCELLATION, NONRENEWAL OR MATERIAL CHANGE - CERTIFICATE HOLDERS This endorsement modifies insurance provided under the following.- COMMERCIAL ollowing:COMMERCIAL GENERAL LIABILITY COVERAGE PART The certificate of insurance holders shown in the schedule below have requested that they receive written notice of cancellation, nonrenewal or material change with respect to this policy. If we decide to cancel, nonrenew or make a material change to this policy, we agree to mail or deliver sixty(60)days advance written notice to the certificate of insurance holders shown in the schedule below. However, if we are cancelling or nonrenewing due to nonpayment of premium,we will only provide the certificate of insurance holders shown in the schedule below with ten(10) days advance written notice. The notice of cancellation, nonrenewal or material change will be mailed to the addresses provided to us by the certificate of insurance issuer. Proof of mailing will be considered sufficient proof of our good faith attempt to provide notice of cancellation, nonrenewal or material change to the certificate of insurance holders shown in the schedule below. SCHEDULE All certificate of insurance holders where written notice of cancellation, nonrenewal or material change to this policy is required by written contract, permit or agreement with the Named Insured. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 6/1/2024 Policy No.: GL24ABC00046 Insured: SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies. LLC Insurance Company: American Contractors Insurance Company Risk Retention Group AGGREGATE LIMITS OF INSURANCE (PER PROJECT) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART It is hereby understood and agreed the General Aggregate Limit under Section III, Limits of Insurance of the Coverage Form applies separately to each of your projects away from premises owned by or rented to you. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the po{icy) Policy Effective: 6/1/2024 Policy No GL24ABC00046 Insured SpawGlass Contractors Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Insurance Company. Amer can Contractors Insurance Company Risk Retention Group CNASpawGlass Contractors,Inc.,SpawGlass Construction Corp., Business Auto Policy SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,LLC ' CONTRACTORS EXTENDED COVERAGE ENDORSEMENT • PLUS THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM I. LIABILITY COVERAGE A. Who Is An Insured The following is added to Section II, Paragraph A.1., Who Is An Insured: 1. a. Any incorporated entity of which the Named Insured owns a majority of the voting stock on the date of inception of this Coverage Form; provided that, b. The Insurance afforded by this provision A.1. does not apply to any such entity that is an insured under any other liability "policy" providing auto coverage. 2. Any organization you newly acquire or form, other than a limited liability company, partnership or joint venture, and over which you maintain majority ownership interest. The insurance afforded by this provision A.2.: a. Is effective on the acquisition or formation date, and is afforded only until the end of the policy period of this Coverage Form, or the next anniversary of its inception date, whichever is earlier. b. Does not apply to: (1) Bodily injury or property damage caused by an accident that occurred before you acquired or formed the organization; or (2) Any such organization that is an insured under any other liability "policy" providing auto coverage. 334ny person or organization that you are required by a written contract to name as an additional insured is an insured but only with respect to their legal liability for acts or omissions of a person, who qualifies as an insured under SECTION If - WHO IS AN INSURED and for whom Liability Coverage is afforded under this policy. If required by written contract, this insurance will be primary and non-contributory to insurance on which the additional insured is a Named Insured. 4. An employee of yours is an insured while operating an auto hired or rented under a contract or agreement in that employee's name, with your permission, while performing duties related to the conduct of your business. "Policy", as used in this provision A. Who Is An Insured, includes those policies that were in force on the inception date of this Coverage Form but: 1. Which are no longer in force; or 2. Whose limits have been exhausted. B. Bail Bonds and Loss of Earnings Section 11, Paragraphs A.2. (2) and A.2. (4) are revised as follows: 1. In a.(2), the limit for the cost of bail bonds is changed from $2,000 to $5,000; and 2. In a.(4), the limit for the loss of earnings is changed from $250 to $500 a day. Form No: CNA63359XX 104-2012) Policy No:BUA 7033775696 Underwriting Company- Valley Forge Insurance Company Policy Effective Date:06'01'2024 Copyright CNA All Rights Reserved. Inc udes copyrighted material of the CNA Business Auto Policy Policy Endorsement C. Fellow Employee Section U, Paragraph B.5 does not apply. Such coverage as is afforded by this provision C. is excess over any other collectible insurance. II, PHYSICAL DAMAGE COVERAGE A. Glass Breakage - Hitting A Bird Or Animal - Falling Objects Or Missiles The following is added to Section III, Paragraph A.3.: With respect to any covered auto, any deductible shown in the Declarations will not apply to glass breakage if such glass is repaired, in a manner acceptable to us, rather than replaced. B. Transportation Expenses Section III, Paragraph A.4.a. is revised, with respect to transportation expense incurred by you, to provide: a. $60 per day, in lieu of $20; subject to b. $1,800 maximum, in lieu of $600. C. Loss of Use Expenses Section III, Paragraph A.4.b. is revised, with respect to loss of use expenses incurred by you, to provide: a. $1,000 maximum, in lieu of $600. D. Hired "Autos" The following is added to Section III. Paragraph A.: 5. Hired "Autos" If Physical Damage coverage is provided under this policy, and such coverage does not extend to Hired Autos, then Physical Damage coverage is extended to: a. Any covered auto you lease, hire, rent or borrow without a driver; and b. Any covered auto hired or rented by your employee without a driver, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. The most we will pay for any one accident or loss is the actual cash value, cost of repair, cost of replacement or $75,000, whichever is less, minus a $500 deductible for each covered auto. No deductible applies to loss caused by fire or lightning. d. The physical damage coverage as is provided by this provision is equal to the physical damage coverage(s) provided on your owned autos. e. Such physical damage coverage for hired autos will: (1) Include loss of use, provided it is the consequence of an accident for which the Named Insured is legally liable, and as a result of which a monetary loss is sustained by the leasing or rental concern. 121 Such coverage as is provided by this provision will be subject to a limit of $750 per accident. E. Airbag Coverage The following is added to Section 111, Paragraph B.3.: The accidental discharge of an airbag shall not be considered mechanical breakdown. Form No: CNA63359XX(04.2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date:06/01/2024 Copyright CNA Al, Rights Reserved. Includes copyrighted material of the CNA Business Auto Policy Policy Endorsement F. Electronic Equipment Section III, Paragraphs B.4.c and B.4.d. are deleted and replaced by the following: c. Physical Damage Coverage on a covered auto also applies to loss to any permanently Installed electronic equipment including its antennas and other accessories d. A $100 per occurrence deductible applies to the coverage provided by this provision. G. Diminution In Value The following is added to Section III, Paragraph B.6.: Subject to the following, the diminution in value exclusion does not apply to: a. Any covered auto of the private passenger type you lease, hire, rent or borrow, without a driver for a period of 30 days or less, while performing duties related to the conduct of your business; and b. Any covered auto of the private passenger type hired or rented by your employee without a driver for a period of 30 days or less, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. Such coverage as is provided by this provision is limited to a diminution in value loss arising directly out of accidental damage and not as a result of the failure to make repairs; faulty or incomplete maintenance or repairs; or the installation of substandard parts. d. The most we will pay for loss to a covered auto in any one accident is the lesser of: (1) $5,000; or (2) 20% of the auto's actual cash value IACV). III. Drive Other Car Coverage — Executive Officers The following is added to Sections II and III: 1. Any auto you don't own, hire or borrow is a covered auto for Liability Coverage while being used by, and for Physical Damage Coverage while in the care, custody or control of, any of your "executive officers", except: a. An auto owned by that "executive officer" or a member of that person's household; or b. An auto used by that "executive officer" while working in a business of selling, servicing, repairing or parking autos. Such Liability and/or Physical Damage Coverage as is afforded by this provision. 11) Equal to the greatest of those coverages afforded any covered auto; and (2) Excess over any other collectible insurance. 2. For purposes of this provision, "executive officer" means a person holding any of the officer positions created by your charter, constitution, by-laws or any other similar governing document, and, while a resident of the same household, includes that person's spouse. Such "executive officers" are insureds while using a covered auto described in this provision. IV. BUSINESS AUTO CONDITIONS A. Duties In The Event Of Accident, Claim, Suit Or Loss The following is added to Section IV, Paragraph A.2.a.: Form No: CNA63359XX (042012) Policy No-BUA 7033775896 Underwriting Company Valley Forge Insurance Company Policy Effective Date:06;01.2024 c Copyright CNA All Rights Reserved Includes copyrighted material of the CNA Business Auto Policy Policy Endorsement (4) Your employees may know of an accident or loss. This will not mean that you have such knowledge, unless such accident or loss is known to you or if you are not an individual, to any of your executive officers or partners or your insurance manager. The following is added to Section IV, Paragraph A.2.b.: (6) Your employees may know of documents received concerning a claim or suit This will not mean that you have such knowledge, unless receipt of such documents is known to you or if you are ,a4-E aRy-&t .4;cutive officers or partners or your insurance manager. B. Transfer Of Rights Of Recovery Against Others To Us 6 Yalfvt�iT*g+s addad to- a A.S. Transfer Of Rights Of Recovery Against Others To Us: We waive any right of recovery we may have, because of payments we make for injury or damage, against any person or organization for whom or which you are required by written contract or agreement to obtain this waiver from us. This injury or damage must arise out of your activities under a contract with that person or organization. You must agree to that requirement prior to an accident or loss. C. Concealment, Misrepresentation or Fraud The following is added to Section IV, Paragraph B.2.: Your failure to disclose all hazards existing on the date of inception of this Coverage Form shall not -- -prejudiceYOUi s ect to the coverage afforded provided such failure or omission is not intentional. CD. Other Insurance -Thr, ed to Section IV, Paragraph B.S.: Regardless of the provisions of Paragraphs 5.a. and 5.d. above, the coverage provided by this policy shall be on a primary non-contributory basis. This provision is applicable only when required by a written contract. That written contract must have been entered into prior to Accident or Loss. E. Policy Period, Coverage Territory Section IV, Paragraph B. 7.(5).(a). is revised to provide: a. 45 days of coverage in lieu of 30 days. V. DEFINITIONS Section V. paragraph C. is deleted and replaced by the following: Bodily injury means bodily injury, sickness or disease sustained by a person, including mental anguish, mental injury or death resulting from any of these. Form No: CNA63359XX (04-2012) Policy No:BUA 7033775696 Underwriting Company: Valley Forge Insurance Company Policy Elfecbve Date:06101+2024 Copyright CNA All Rights Reserved. Includes copyrighted material of the CNA Business Auto Policy Policy Endorsement ' NOTICE OF • TO CERTIFICATEHOLDER.S It is understood and agreed that: If you have agreed under written contract to provide notice of cancellation to a party to whom the Agent of Record has issued a Certificate of Insurance, and if we cancel a policy term described on that Certificate of Insurance for any reason other than nonpayment of premium, then notice of cancellation will be provided to such Certificateholders at least 30 days in advance of the date cancellation is effective. If notice is mailed, then proof of mailing to the last known mailing address of the Certificateholder on file with the Agent of Record will be sufficient to prove notice. Any failure by us to notify such persons or organizations will not extend or invalidate such cancellation, or impose any liability or obligation upon us or the Agent of Record. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy. SpawGlass Contractors,Inc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,LLC Form No: CNA68021 XX (02 2013) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06!01?2024 1 Copyright CNA A I Rights Reserved. Business Auto Policy CNA Policy Endorsement ADDITIONAL INSURED - PRIMARY AND NON-CONTRIBUTORY It is understood and agreed that this endorsement amends the BUSINESS AUTO COVERAGE FORM as follows: SCHEDULE Name of Additional Insured Person Or Organization ANY PERSON OR ORGANIZATION THAT YOU ARE REQUIRED BY WRITTEN CONTRACT OR WRITTEN AGREEMENT TO NAME AS AN ADDITIONAL INSURED 1. In conformance with paragraph A.l.c. of Who Is An Insured of Section II - LIABILITY COVERAGE, the person or organization scheduled above is an insured under this policy. 2. The insurance afforded to the additional insured under this policy will apply on a primary and non-contributory basis if you have committed it to be so in a written contract or written agreement executed prior to the date of the "accident" for which the additional insured seeks coverage under this policy. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy. Form No: CNA71527XX (102012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06101;2024 Insured:SpawGlass Contractors,inc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,L1.0 0 Copyright CNA A'i Rights Reserved. TEXAS WORKERS COMPENSATION AND EMPLOYERS LIABILITY POLICY WC 99 03 04 (Ed. 04-07) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3 A.of the Information Page We have the right to recover our payments from anyone liable for an injury covered by this policy We will not enforce our right aga nst the person or organization named in the Schedule,but this waiver applies only with respect to bodily injury arising out of the operations described in the Schedule where you are required by a written contract to obtain this waiver This waiver does not extend to the statutory right of reimbursement from a claimant who recovers any amount under Section 417.002 of the Texas Labor Code. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule. The premium for this endorsement is shown in the Schedule. Schedule 1. ( ) Specific Waiver Name of person organization ( X ) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. This waiver does not extend to the statutory right of reimbursement under Section 417.002 of the Texas Labor Code. 2. Operations: CONSTRUCTION AND RELATED CONSTRUCTION RELATED WORK ALL TEXAS OPERATIONS 3. Premium. The premium charge of this endorsement shall be 2 percent of the premium developed on payroll in connection with work performed for the above person(s)or organization(s)arising out of the operations described. 4. Minimum Premium. $0 5. Advance Premium SO This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: Same as Policy Effective Date unless otherwise indicated above Policy Effective Date: 6/1/2024 Policy No. WCA000008324 Insured SpawGlass Contractors, Inc.,SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies,LLC Carrier Name/Code: ACIG Insurance Company WC 99 03 04 (Ed 04-07) WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 42 06 01 (Ed 03 13) TEXAS NOTICE OF MATERIAL CHANGE ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3.A. of the Information Page. In the event of cancelation or other material change of the policy, we will mail advance notice to the person or organization named in the Schedule. The number of days advance notice is shown in the Schedule This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule Schedule 1 . Number of days advance notice: 60 days. However, in the case of cancellation or nonrenewal due to nonpayment of E,ze-ium, only 10 days advance notice will be provided. 2. Notice will be mailed to: All certificate holders where written notice of cancellation, nonrenewal or material change to this policy is required by written contract, permit or agreement with the Named Insured. The notice will be mailed to the addresses provided to us by the certificate of insurance issuer. Proof of mailing will be considered sufficient proof of our good faith attempt to provide written notice. This endorsement changes the pol cy to which it is attached and is effective on the date issued unless otherwise stated. (The information below Is required only when this endorsement is Issued subsequent to preparatlon of the policy.) EndorsemeniEtfective 06/01/2024 Policy No. w A 0008324 Insured SpawGlass Contractors,Inc. , SpawGlass Construction Corp. , Premium$ SpawGlass Civil Construction, Inc. , Westland Equipment and Supplies, LLC Insurance Company ACIG Insurance Company WC 42 06 01 Wolters Kluwer Financial Seances I Uniform Forms Page 1 of 1 (Ed 03.13) Im COMMERCIAL INLAND MARINE THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET LOSS PAYEES This endorsement modifies insurance provided under the COMMERCIAL INLAND MARINE COVERAGE PART The following is added to Section E — ADDITIONAL b. Pay any claim for loss or damage jointly to you COVERAGE CONDITIONS: and the Loss Payee as your interests may Loss Payable Provision appear. In the event of a Covered Cause of Loss to Covered This endorsement applies to all Covered Property for Property in which both you and a Loss Payee share which a Loss Payee is on file with us or your an insurable interest, we will: insurance agent or insurance broker. a. Adjust the loss or damage with you; and SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Travelers Property&Casualty Co Policy No. QT-630-7625635-0-TLC-24 CM U6 18 05 21 2:'z 1 The Trave ers Indemn ty Company Page 1 of 1 Includes copyrighted material of Insurance Services Office nc with its permission C H U B B Surct% o + 908 903 3485 202B Halls Md:Road PO Box 1650 F +908 903 3656 Whitehouse Station,NJ 08889-1650 Federal Insurance Company Liberty Mutual Insurance Company AIA Document A312 Performance Bond K41875616(Federal) 58S218527(Liberty Mutual) Any singular reference to Contractor,Surety.Owner or other party shall be considered plural where applicable. CONTRACTOR(Name and Address): SURETY(Name and Principal Place of 8ntsniess). SpawGlass Contractors, Inc. Federal Insurance Company(IN) 1 1 1 I Smith Road Liberty Mutual Insurance Company(MA) Austin,Texas 78721 OWNER(,vamr and Address): City of Round Rock 221 East Main Street Round Rock,TX 78644 CONSTRUCTION CONTRACT Date: j?D da) of,)An(4,arV .2025 Amount:$5,287,121.00 Five Million Two Hundred Eighty Seven Thousand One Hundred Twenty One& 00 100 Dollars Description (Name and Lncationi Old Settler's Part.Build Out-60%GMP for Rec Center-EARTHWORK BOND Date(Not earlier than Construction Contract Date) . day of 17 H 2024 AMOUNT: $5,287,121.00 Five Million Two Hundred Eighty Seven Thousand One Hundred Twenty One& 00/100 Dollars Modifications to this Bond: ® None ❑ See Page 3 CONTRACTORSAS SURETY PRINCIPAL Company: (Corporate Seal) SpawGlass Contractors,I Company: (Corporate Seal) ` Federal Insurance Liberty MutuSignature: Signature:Name and fele: vi n Name and Tit Prince Pr ' ent -Austin Division Attorney-in-Fact (Any additional signatures appear on page 3) (FOR/NFORM4TION OA`L)' Name Address and Telephone) AGENT or BROKER: Adams Insurance Service OWNER'S REPRESENTATIVE(Architect,Engineer orotherp,7rp) 427 W 20th.Suite 500 Houston,TX 77008 713-869-8346 Printed jot cooperation with the Anlencan Institute of Archt►ects(AIA)by Chubb The language in this docnunent conforms exacti) to the language used jot AIA Document AJ 12 December 1984 edition.Third Printing March 1981 Form 15.02-0779-FED(Rw 11 16) A312-1984 I I The Contractor and the Surety,jointly and severally, performance and payment bonds executed by a bind themselves, their heirs, executors, administrators, qualified surety equivalent to the bonds issued on the successors and assigns to the Owner for the performance of Construction Contract,and pay to the Owner the amount the Construction Contract,which is incorporated herein by of damages as described in Paragraph 6 in excess of the reference. Balance of the Contract Price incurred by the Owner 2 If the Contractor performs the Construction Contract, resulting from the Contractor's default;or the Surety and the Contractor shall have no obligation under 4.4 Waive its right to perform and complete, arrange this Bond,except to participate in conferences as provided for completion, or obtain a new contractor and with in Sub-paragraph 3.1. reasonable promptness under the circumstances: 3 If there is no Owner Default, the Surety's obligation .1 After investigation,determine the amount for under this Bond shall arise after: which it may be liable to the Ownerand,as soon 3.1 The Owner has notified the Contractor and the as practicable after the amount is determined, Surety at its address described in Paragraph 10 below tender payment therefor to the Owner;or that the Owner is considering declaring a Contractor .2 Deny liability in whole or in part and notify the Default and has requested and attempted to arrange a Owner citing reasons therefor. conference with the Contractor and the Surety to be held 5 If the Surety does not proceed as provided in Paragraph not later than fifteen days after receipt of such notice 4 with reasonable promptness,the Surety shall be deemed to discuss methods of performing the Construction to be in default on this Bond fifteen days after receipt of Contract. If the Owner,the Contractor and the Surety an additional written notice from the Owner to the Surety agree, the Contractor shall be allowed a reasonable demanding that the Surety perform its obligations under this time to perform the Construction Contract, but such Bond,and the Owner shall be entitled to enforce any remedy an agreement shall not waive the Owner's right,if any, available to the Owner.If the Surety proceeds as provided subsequently to declare a Contractor Default;and in Subparagraph 4.4,and the Owner refuses the payment 3.2 The Owner has declared a Contractor Default and tendered or the Surety has denied liability,in whole or in formally terminated the Contractor's right to complete part,without further notice the Owner shall be entitled to the contract. Such Contractor Default shall not be enforce any remedy available to the Owner. declared earlier than twenty days after the Contractor 6 After the Owner has terminated the Contractor's right and the Surety have received notice as provided in to complete the Construction Contract, and if the Surety Subparagraph 3.1;and elects to act under Subparagraph 9.1, 4.2, or 4.3 above, 3.3 The Owner has agreed to pay the Balance of the then the responsibilities of the Surety to the Owner shall Contract Price to the Surety in accordance with the terms not be greater than those of the Contractor under the of the Construction Contract or to a contractor selected Construction Contract,and the responsibilities of the Owner to perform the Construction Contract in accordance with to the Surety shalt not be greater than those of the Owner the terms of the contract with the Owner. under the Construction Contract.To the limit of the amount 4 When the Owner has satisfied the conditions of of this Bond, but subject to commitment by the Owner Paragraph 3,the Surety shall promptly and at the Surety's of the Balance of the Contract Price to mitigation of costs expense take one of the following actions: and damages on the Construction Contract, the Surety is obligated without duplication for: 4.1 Arrange for the Contractor, with consent of the 6.1 The responsibilities of the Contractor for correction Owner, to perform and complete the Construction of defective work and completion of the Construction Contract;or Contract; 4.2 Undertake to perform and complete the Construction Contract itself, through its agents or 6.2 Additional legal,design professional and delay costs through independent contractors;or resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under 4.3 Obtain bids or negotiated proposals from qualified Paragraph 4;and contractors acceptable to the Owner for a contract 6.3 Liquidated damages,or if no liquidated damages are for performance and completion of the Construction specified Contract, arrange for a contract to be prepared for fied in the Construction Contract,actual damages execution by the Owner and the contractor selected caused by delayed performance or non-performance of with the Owner's concurrence,to be secured with the Contractor. Printed in cooperation with the American institute ojArchitects(AIA)by Chubb.The language in this document conforms exactly to the language used in AIA Document A312 December 1984 edition,Third Printing,March 1987. Fmm 15,02•027 FM(Rev.11/16) A312-19842 7 The Surety shall not be liable to the Owner or others be deemed deleted herefrom and provisions conforming to for obligations of the Contractor that are unrelated to the such statutory or other legal requirement shall be deemed Construction Contract, and the Balance of the Contract incorporated herein. The intent is that this Bond shall be Price shall not be reduced or set off on account of any such construed as a statutory bond and not as a common law bond. unrelated obligations. No right of action shall accrue on this 12 DEFINITIONS Bond to any person or entity other than the Owner or its heirs,executors,administrators or successors. 12.1 Balance of the Contract Price:The total amount payable by the Owner to the Contractor under the 8 The surety hereby waives notice of any change,including Construction Contract after all proper adjustments have changes of time,to the Construction Contract or to related been made, including allowance to the Contractor of subcontractors,purchase orders and other obligations. any amounts received or to be received by the Owner in 9 Any proceeding,legal or equitable,under this Bond may settlement of insurance or other claims for damages to be instituted in any court of competent jurisdiction in the which the Contractor is entitled,reduced by all valid and location in which the work or part of the work is located and proper payments made to or on behalf of the Contractor shall be instituted within two years after Contractor Default under the Construction Contract. or within two years after the Contractor ceased working or 12,2 Construcdon Contract: The agreement between within two years after the Surety refuses or fails to perform the owner and the Contractor identified on the signature its obligations under this Bond,whichever occurs first. If the page, including all Contract Documents and changes provisions of this Paragraph are void or prohibited by law, thereto. the minimum period of limitation available to sureties as 12.3 Contractor Default: Failure of the Contractor, a defense in the jurisdiction of the suit shall be applicable. which has neither been remedied nor waived, to 10 Notice to the Surety,the Owner or the Contractor shall perform or otherwise to comply with the terms of the be mailed or delivered to the address shown on the signature Construction Contract. page. 12.4 Owner Default: Failure of the Owner,which has 11 When this Bond has been furnished to comply with a neither been remedied nor waived,to pay the Contractor statutory or other legal requirement in the location where as required by the Construction Contract or to perform the construction was to be performed,any provision in this and complete or comply with the other terms thereof. Bond conflicting with said statutory or legal requirement shall MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (CorporateSeal) Federal Insurance Company Signature: Signature:- Name and Title: Name and Title: Address: Address: Printed in cooperation with theAmerican Institute of Architects(AIA)by Chubb.The language in this document conforms exactly to the language used in AIA Document A312 December 1984 edition,Third Printing,March 1987. Form 1502-0279 FED(Rev.IWO A312-19843 CHUBB Power of Attorney Federal Insurance Company I Vigilant Insurance Company;Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents, that FEDERAL INSURANCE COMPANY. an Indiana corporation. VIGILANT INSURANCE COMPANY. a New York corporation. PACIFIC INDEMNITY COMPANY, a Wisconsin corporation. WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations of the Commonweah!,of Pennsylvania.do each herehy consthure and appoint Andrew A. Adams, Norman E. Adams, Michael Macomber, John A. Prince and Larry D.Snider of Houston,Texas---------------- ---- ---------------------------------------------------•-- -------- each as their true and lawful Attornes in-Fact to execute under such designation In their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise,bonds and undertakings and other writings obi gator•in the nature thereof(other than bail bonds)given or executed In the course of business,and any instruments amending or a'tering the same,and consents to the modiffcal ion or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have ear h executed and attested these presents and affixed their corporate seals on this 11 day oflune.2020. Dawn M Lhl;rm Asefuanl*sarclary pit-yyhen M llanc-�.lice Prosideril STATE OF NEW JERSEY County of Hunterdon On this 11 day of Junt,2020 before me,a Notary Public of Newlersey,personal)y came Dawn M Chloros and Stephen M.Haney,to me known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY VIGILANT INSURANCE COMPANY PACIFIC INDEMNITY COMPANY,WFSr(7(ESTF,R FIRE INSURANCE COMPANY and ACE AMERICAN INSI RANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Dawn M.Chloros and Stephen M.Haney.being by me duly swom.severally and each for herself and himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY. VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN 114SLJRANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto of toed by authority of said Companies:and that their signatures as such officers were duly affixed and subscribed by tike authority Notarial Seal KATHERINE J.AOELAAR � TAq NOTARY PUBL)C OF NEW JERSPY No.2116686 rllKt� ConYNMMr FSK J1/y 16,2024 Notary hLttc CERTIFICATION Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY.and PACIFIC INDEMNITY COMPANY on August 30.2016: WESTCHESTER FIRE INSURANCE COMPANY on December H.2006;and ACE AMERICAN INSURANCE COMPANY on March 20.2009: -RESOLVED,that the following authorizations relate to the execution,for and on behalf of the Company,of bonds.undertaldng.recognisances.contracts and other written commitments of the Company entered into in the ordinary course of business(each a-Written Conunitmem i. (U Each d rhe Chairman the Resident and the Vice Presidents of the Company is hereby authorized to execute any Written Cmmmdtment for and on behalfof the Compan),under the seal of the Company or otherwise (2) Each duty appointed attorney in-fact of the Company is hereby authorized to execute any Written tommhment for and on behalf of the Company,under the seal of the Company or otherwise,to the extent that such action is authorized by the grant of powers prOvlded for In such persons written appointment as such attorney-In.fact. (3) Each of the Chairman the Resident and the Vice Residents of the Company Is hereby atm horized,for and on behalf of the Company,to appoint In writing any person the attorney- In-fan of the Company with full power and authority to execute,for and on behalf of the Company under the seal of the Company o otherwise,such Written Commitments of the Company as may be specified In such written appointment,which specification may be by general type or dam of Written Com nlirnents orb)specification of one or more particular Wrimen Comm)trnenis (4) Each of the Chairman the Resident and ih,: Vice Residents of the Company is hereby authorized.for and on behalf of the Company.to delegate In writing to any other officer of the Company the authority to execute for and on behalf of the Company under the Company's seal or otherwise such written Commitments of the Company as are specified In such written delegation whish spedficatlon m ty be by general type or d.,A of Wrimen Commitments or by'speciflatfon ofone o snore partkular Wrimen Commitments. (5) The signature of any officer or other person executing any Wrinen CnrrnNtment or appointment or delegation pursua or to this Resoiut ion,and the seal of the Company,may be affixed by (acslmile on such Wrinen Commitment or wrtnen appointment or delegation FURTHER RESOLVED,that the foregoing Resolution shag not be deemed to be an exdusl yr statement of the powers and authority of off cem employees and other persons to an for and on behalf of the Cmrripany,and such Resolution shall not limit or othemise affect IN,exercise of any such power or authority otherwise validlygarxed or vested.' L Dawn M. Mloros.Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, PACIFIC INDEMNITY' COMPANY, WESTCHESTER FIPE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the-Companies--)do hereby certify than (i) the foregoing Resolutions adopted by the Board of Directors of the Companies are true correct and in full force and effect, (ii) the foregoing Power of Attorney is true correct and in full force and effect. !/ Given under my hand and seals of said Companies at Whitehouse Station,NJ,this � day of .J(�yp�t�Y , 20255 ® r fJa��. PSr�.tso�sS -- `�" Rrv:n�L(',hlnrtt:.A-�istant>ctrclaryt' l.N THE EVENT Y:"�WISH TO VERIFY'TfiE AUTHFNTICrn'OF THIS BOND OR NOTIFY IS OF ANY OTHER MATTER PLEASE CONTACT US AT Tele hone(908)903 3493 Fax(908)903:+656 a-small suretyachuhbmm Combined:FED-VIG-PI-WFIC-AAIC(rev 11.19) This Power of Attorney limits the ads of those named herein,and they have no authority to bind the Company except In the manner and to the extent herein stated. Liberty Liberty Mutual Insurance Company Mutual. The Ohio Casualty Insurance Company Certificate No 8205857-974105 West American Insurance Company SURETY POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire that Liberty Mutual Insurance Company is a corporation duly Organized under the laws of the State of Massachusetts,and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana(herein collectively called the'Companies'),pursuant to and by authority herein set forth,does hereby name oonslitute and appoint, Andrew A Adams John A Prince;Larry D.Snider Michael Macomber Norman E.Adams all of the city of Hoaslon state of TX each individually if there be more than one named its true and lawful attorney-in-fad to make execute,seal,acknowledge and deliver,for and on its behalf as surety and as its ad and deed,any and all undertakings,bonds,reoognizances and other surety obligations in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 28th day of June 2021 . Liberty Mutual Insurance Company 1NStj '�1Y INS` d 1NSUq The Ohio Casualty Insurance Company �J c°"r°" yc eJ c°•rOe*,�ty ��°o�fOti.-s° West American Insurance Company c3 r s 1912 1919 i 1991 0 0 0 vin By, ,= U @ David M Carey,Assistant Seaetary cr " M Stale of PENNSYLVANIA ss E � County of MONTGOMERY otm E U On this 28th da of June 2021 before me personally appeared David M-Care who acknowledged himself to be the Assistant Secreta of Li Mutual Insurance a> � Y Pe Y PP Y- Secretary �' M Company,The Ohio Casualty Company,and West American Insurance Company,and that he,as such,being authorized so to do,execute the foregoing instrument for the purposes 2Z— therein contained by signing on behalf of the corporations by himself as a duly authorized officer. > dCo — Z IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at King of Prussia,Pennsylvania,on the day and year first above written O 0S) Q�45pSITIt, Cm,ng lth a Pe"tvmle-Nomry Sul � Ys 1 Terata Pastels,Notary Public d-m �i *erycMa,y_ e . E v O N OF rM amslission etpues Marc°2a,2025 y E ori� cv��g mwber.P °Lmtw Assa°e ah w rrau w Teresa Paslella,Notary Public Q o f0 ` cli 4? This Power of Allorney is made and executed pursuant to and by authonty of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual 3 o S insurance Company,and West American Insurance Company which resolutions are now in full force and effect reading as follows 0E 00 M ARTICLE IV-OFFICERS:Section 12.Power of Attomey o 0 Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President,and subject to such limitation as the Chairman or the co President may prescribe,shall appoint such attomeys-in-fad,as may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety —_ m any and all undertakings,bonds,recognizances and other surety obligations.Such attomeys-in-fact,subject to the limitations set forth in their respective powers of attorney,shall c o t have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation.When so executed,such o w Z instruments shall be as binding as if signed by the President and attested to by the Secretary Any power or authority granted to any representative or attomeyin-fact under the omi provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer a officers granting such power or authority. ti— ARTICLE XIII-Execullon of Contracts:Section 5 Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such limitations as the chairman or the president may prescribe, shall appoint such aftomeys-in-fad,as may be necessary to act in behalf of the Company to make,execute,seal,admowledge,and deliver as surety any and all undertakings, bonds,reoognizances and other surety obligations Such ettomeys-in-tad subject to the limitations set forth in their respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company.When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation-The President of the Company,acting pursuant to the Bylaws of the Company,authorizes David M.Carey,Assistant Secretary to appoint such attomeys-in- fad as may be necessary to act on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizences and other surety obligations. Authorization-By unanimous consent of the Companys Board of Directors,the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds,shall be valid and binding upon the Company with the same force and effect as though manually affixed. 1,Renee C Llewellyn,the undersigned.Assistant Secretary,The Ohio Casualty Insurance Company,Liberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the orginal power of attorney of which the foregoing is a full,true and correct copy of the Power of Attorney executed by said Companies,is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this 2p—_ day of JAntillf, 2025 P`1HSU,1?, P�ZV INSU d 19st; 191 2C,1919 C i 1991 0 ' •Gym By. dp1'Ja�CNUe ja °t�`'N�rrs +oro fid, 'Np1ANr as Renee C Llewellyn,Assistant Secretary LMS-12873 LMIC OCIC WAIC MNIb Co 02121 C H U B B Surety o + 908 903 3485 202B Halls Mill Road,PO Box 1650 F +908 903 3656 Whitehouse Station.NJ 08889-1650 Federal Insurance Company Liberty Mutual Insurance Company AIA Document A312111-2010 Payment Bond K41875616(Federal) 585218527(Liberty Mutual) Any singular reference to Contractor,Surety,Owner or other party shall be considered plural where applicable CONTRACTOR SURETY (Nance, legal status and address) (Name, legal status and principal place of business) SpawGlass Contractors,Inc. Federal Insurance Company(IN) 1111 Smith Road Austin,Texas 78721 Liberty Mutual Insurance Company(MA) OWNER (Nance, legal status and address) City of Round Rock 221 East Main Street Round Rock,TX 7864 CONSTRUCTION CONTRACT Dale: w0 day of JanaqC.,2025 Amount- $5,287,121.00 Five Million Two Hundred Eighty Seven Thousand One Hundred Twenty One& 00/100 Dollars Description(A'anre and Location): Old Settlers Park Build Out- 6o%GMP for Rec Center-EARTHWORK BOND Date(Not earlier than Construction Contract Date):2Q day of Agjjs(V,2025 Amount: $5,287,121.00 Fivi Million Two Hundred Eighty Seven Thousand One Hundred Twenty One& 00/100 Dollars Modifications to this Bond: O None 0 See Page 4 CONTRACTORS AS PRINCIPAL SURETY Company. S Glass Con ors (Corporate Seal) Company: p Y� aw P P (CotyorareSeal) Federal Insurance C any ibe Mutual Insurance .omp Signature: Name and Title: vid p Signature: — --- ent -Austin Division Attorney-in-Fa ame: John A.Prince Signed and Sealed this e2Q_ day of rJAMW101of 2025 (Any additional signatures appear on the Iasi page of this Performance Bond) (FOR INFORMATION OA'L)' Name.Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE(Architect.Erigaverorotherparty) Adams Insurance Service 427 W loth.Suite 500 Houston,TX 77oo8 713-869-8346 Printed in cooperation it ith the 4 mencm Insmure of Architects(AIA)by Chubb 71m language in this document conforms to the language used in AIA Docunirnt A312 rv-2010. Form 15-02-0574-FED tRw 1 i 16, I L The Contractor and the Surety,jointly and severally,bind themselves,their heirs,executors,administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. 2 If the Contractor promptly makes payment of A sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. 3. If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13)of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. 4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand, lien or suit. 5. The Surety's obligations to a Claimant under this Bond shall arise after the following: 5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was,furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). 52 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety (at the address described in Section 13). G If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section S.I.I. 7. When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: 71 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and 72 Pay or arrange for payment of any undisputed amounts. 73 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing the Claimant. 8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 9. Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims,if any,under any construction performance bond.By the Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 TM•2010. Form 15-02-OS74-FED(Rev.11A6) 2 la The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligations to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. K The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. tZ No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is subject of the Construction Contract is located or after the expiration of one year from the date (1)on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page which their signature appears.Actual receipt of notice or Claims,however accomplished,shall be sufficient compliance as of the date received. it When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. K Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. I& DEFINITIONS 161 Claim.A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .tithe total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and, .Sthe total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. 16.2 Claimant:An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials,or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located.The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water,gas power,light, heat, oil gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 T"-2010. Form IS-02-0574-FED(Rev.11/16) 3 and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. 163 Construction Contract: The agreement between the Owner and the Contractor identified on the cover page,including all Contract Documents and all changes made to the agreement and the Contract Documents. 16.4 Owner Default:Failure of the Owner,which has neither been remedied nor waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 165 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. 17. If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. I& MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: I&I "Claim notices for FEDERAL INSURANCE COMPANY must be sent to the following address: Chubb,PO Box 2191, Chesapeake,Virginia 23327,Attention:Surety Support Team." (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (CorporateSeal) Company: (CorporateSeal) Federal Insurance Company Signature:__ _ Signature:_ Name and Title: Name and Title: Address: Address: Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 r"-2010. Form 1542-0574 FED(Rev.11/16) 4 CHUBB Power of Attorney Federal Insurance Company]Vigilant Insurance Company,t Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents, that FEDERAL INSURANCE COMPANY, an Indiana corporation VIGILANT INSURANCE COMPANY, a New York corporation, PACIFIC INDEMNITY COMPANY, a Wisconsin corporation. WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations of the Commo::weahh of Pennsylvania,do each hereby constitute and appoint Andrew A. Adams, Norman E. Adams, Michael Macomber, John A. Prince and LarryD Snider of Houston,Texas----------------------------- — _.- --- --------------------------------- --------------------------------------------- each as their true and lawfuAttorney in Fact to execute under su.h designation in(heir names and to affix thea corporate seals to and deliver for and on their behalf as surety thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed in the course of business,and any Instruments amending or altering the same and consents to the modificaron or alteration of any instrument referred to in said bonds or obligations. In witness Whereof.said FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have ea:h executed and attested these presents and affixed their corporate seals on this P day of June,2020. DaVn kI Chlorrs Ast4ganf.lCtroar) Stephen kf.Ilari N Ice PrvFMeni 06- C 0 4 D C) a T STATE OF NEW JERSEY County of Hunterdon s' On this 11 day of June,2020 before me.a Notary Public of New Jersey,personally came Dawn M Chloros and Stephen M.Haney,to me known to be Assistant Secretary and Vice President,respectively,of FEDERAL M1 1 RANCE COMPANY,VIGIIA.N INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY-WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Dawn M Chloros and Stephen M.Haney,being by me duly swum,severally and each for herself and himself did depose and say that they are Assistant Secretary and Vice Resident,respectively,of FEDERAL INSURANCE COMPANY. VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY WESnIIESTER FIRE.INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Anomey are such corporate seals and were thereto affixed by authority of said Companies:and that their signatures as such officers were duly affixed and subscribed by like authority Notarial Seat KATHERINE J. ER NOTARY PUBLIC OF NEWJERSEY ��� No.2J 166Bn PtRLY� CotrllNirten Eno"July.is,2011 Fivary Trtlk CERTIFICATION Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE.COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016; WESTCHESTER FIRE INSURANCE COMPANY on December Il,2006;and ACE AMERICAN INSURANCE COMPANY on March 20,2009: -RESOLVED.that the following authort:atfuns relate to the execution,for and on behalf of the Company,of bonds.undertaking,recogtizances.contracts and other written commitments of the Company entered Into In the ordinary course oftiusiness(each a-Wrinen Commitment'): (I) Each of the Chairman,the Resident and the Vice Presidents of the Company is hereby authorized to execute any Written Commhmem for and on behalf of the Company,under the seal of the Company or otherwise. (2) Each duly appointed anomeptridaci of the Company is hereby authorized to execute any written Commitment for and on behalf of the Company under the seal of the Company or otherwise,to the extent that such action is authorized by the grant of powers provided for in such person's written appoinimem as surh anorney-In-fact (3) Each of the Cltalman,the President and the Vice Presidents of the Company Is hereby authorized.for and on behalf of the Company,to appoint In writing any person the attorney N-fact of the Company with full power and authority to execute,for and on behalf of the Company,under the seal of the Company or otherwise,such Written Commitments of the Company as may be specified in such r.Tinen appointment which specification may be by general type or class of Written Commitments or by specificarion of one or more particular Written Commitments (4) Each of the Chairman.the Resident and the vice Presidents of the Company is herehy authorized.for and on behalf of the Company,to delegate In writing to any other officer of the Company the authority to execute.for and on behalf of the Company.under the Company's seal or otherwise,such Wrhten Commitments of the Company as are specified In such written delegarien.which specification may be by general type or class of Written Commhments cr byspectfication ofone or more particular Written Commhments (5) The signature o(any officer or other person executing any Written Commitment or appointment or delegation pursuant to this Resolutionand the seal of the Companymay be affixed by facsimile on such Written Commitment or wrhten appointment or delegation FURTHER RESOLVED, that the foregoing Resolution shall nN be deerned to be an exclusive statement of the powers and authority of officers,employees and oche,persons to act for and on behalf of the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or authority otherwise validly granted or vested.' 1, Dawn M. Chloros, Assistant Secretary of FEDERAL INSURANCE COMPANY. VIGIIANT INSURANCE COMPANY. PACIFIC INDEMNITY COMPANY. WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the-Companies")do hereby certify that (i) the foregoing Resoltnfons adopted by the Board of Directors of the Companies are true.correct and in full force and effect (R) the foregoing Power of Attorney is true,correct and in full force and elect. Given under my hand and seals of said Companies at Whitehouse Station.N.this -26— day of 202 rJ Rrv:n 1LChhxtx.A�istumSe<mat} Ili THE EVENT YOU WISH TO VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFI'US OF ANY OTHER MUTTER PLEASE CONTACT US AT: Telephone(908)903 3493 Fax(908)903.3656 a-nutl:surety@chubb.cum CorrminW,FED-VIG-PI-WFIGNtJCirev 11-19) This Power of Attorney limits the acts of those named hereln,and they have no authority to bind the Company except In the manner and to the extent herein stated. Liiberty Liberty Mutual Insurance Company Mutual. The Ohio Casualty Insurance Company Certificate No 8205857.974105 West American Insurance Company SURETY POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company.s a corporation duly organized under the laws of the Slate of New Hampshire that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts and West American Insurance Company is a corporation duly o(ganued under the laws of the State of Indiana{herein collectively ca led the'Compan as'),pursuant to and by authority herein set forth,does hereby name,constitute and appoint, Andrew A Adams John A Prmce Larry D Snider Michael Macomber Norman L.Adams all of the oty of Houston state of TX each indivdualty if there be more than one named,its true and lawful attomey-in-fad to make, execute,seat ad riowledge and deliver,for and on is behalf as surety and as its ad and deed,any and at undertakings,bonds,recognaances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper Persons. IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 28th day of Junc 2021 Liberty Mutual Insurance Company 1NSu 'vZ! INS& a %Hsuq, The Ohio Casualty Insurance Company tiJ�oNOJI, yJ°d 4Of,r�ty o��o�PO4r 1� West American Insurance Company 19i2�° c c 1919 i 19910 N E yrd9��+�cHu� L S�s�N�r►e�'W rro rd Mo,AM► JDA �s"7 G U c _t0 David M-Carey,Assistant Secretary � " tor State of PENNSYLVANIA 10 3 County of MONTGOMERY ss o E w � On this 28th da of June 2021 before me Personal tyaPPS red David MCarey who acknowledged himself to be the Assistant Secreta ryof Liberty YMutual Insurance d OW Company,The Ohio Casualty Company and West American Insurance Company,and that he,as such,being authorized so to do,execute the foregoing instrument for the purposes (-D> therein contained by signing on behalf of the corporations by himself as a duly authonzed officer a1 3 IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seat at King of Prussia.Pennsylvania,on the day and year first above written. O `O l' MPa,;44..Novy Pull.: L G1 p O y a F My[pmdaslon e.pm March 28,2025 By: � C G t6 r Commission nunDer 11280U � � ,`- *�p tors,oe a«wyiuw xsaocvaona Nobnn �ertsa Pasleila,Notary Public Q o cm fry °a r This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual 3 onto O S Insurance Company,and West American Insurance Cornpany which resolutions are now in full force and effect reading as follows: d ?? ARTICLE IV-OFFICERS:Section 12,Power of Attorney. p a Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President,and subject to such limitation as the Chairman or the-0 President may prescribe,Shan appoint such atomeys-in-tadas may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety m MN any and all undertakings,bonds,reoognizarnes and other surety obligations.Such aflomeys-in-fact,subject to the limitations set forth in their respective powers of attorney,shall-08 L have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation When so executed,such cc cr Z u instruments shall be as binding as it signed by the President and attested to by the Secretary.Any power or authority granted to any representative or attorney-in-fact under the'n m provisions of this article may be revoked at anytime by the Board,the Chairman,the President or by the officer or officers granting such power or authority. ti a ARTICLE XIII-Execution of Contracts:Section 5.Surety Bonds and Undertakings Any officer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such limitations as the chairman a the president may prescribe, shall appoint such attomeys-in-fact,as may be necessary to ad in behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings, bonds,recognizances and other surety obligations.Such attomeys-in-fad subject to the limitations set forth in their respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company.When so executed such instruments shall be as binding as if signed by the president and attested by the secretary Certificate of Designation-The President of the Company,acting pursuant to the Bylaws of the Company,authorizes David M-Carey,Assistant Secretary to appoint such attorneys-in- fad as may be necessary to act on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,iecagnizances and other surety obligations. Authorization-By unantmous consent of the Company's Board of Directors,the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bands,shall be valid and binding upon the Company with the same force and effect as though marwally affixed. 1,Renee C.Llewellyn,the undersigned,Assistant Secretary,The Ohio Casualty Insurance Company,Liberty Mutual Insurance Company,and West Amencan Insurance Company do hereby certify that the original paver of attorney of which the foregoing is a lull,true and correct copy of the Power of Attomey executed by said Companies,is in fug force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have hereunlo set my hand and affixed the seals of said Companies this�Q day of JAXAJ, 2025 1NSu� SY INS& %NSU da Y �1912 c o 1919 0 � 1991 0 o B vd�'",� u•�b o�a„n.N a rad Nm�«��+ar y Renee C.Llewellyn,Assistant Secretary LMS-12873 LMIC OCIC WAIC Multi Co 02(21 Have a complaint or need help? Vene una queja o necesita ayuda? IMPORTANT NOTICE AVISO IMPORTANTE If you have a problem with a claim or your premiums, call Si tiene un problema con un reclamo o las primas,llame your insurance company first. If you can't work out the primero a la empresa de seguros.Si no puede resolver el issue, the Texas Department of Insurance may be able to problema,el Departamento de Seguros del estado de Tejas help. puede ayudar. Even if you file a complaint with the Texas Department of Si registra una queja con el Departamento de Seguros del Insurance, you should also file a complaint or appeal estado de tejas,tambien debe presentar una queja o through your insurance company. If you don't, you may apelacion a traves de su compania de seguros.Si no to hate lose your right to appeal. puede perder su derecho de apelar. To get information or file a complaint with CHUBB: Para obtener information o registro de una queja con CHUBB: Call Toll-free:1-800-36-CHUBB 11ame al:1-800-36-CHUBB Mail: Eastern Claim Service Center Correo: Eastern Claim Service Center boo Independence Parkway 600 Independence Parkway Chesapeake,VA 23320 Chesapeake,VA 23320 Attn: Surety Support Attn: Surety Support Phone: 800-252-4670 Fax: 800-664-5358 Telefono: 800-252-4670 Fax: 800-664-5358 Email: ecsc.claims@chubb.com Correo electronico: eese.claims@chubb.com To get help with an insurance question or file a complaint Para ayuda con una pregunta de seguros o registrar una with the state: queja con el estado: The Texas Department of Insurance El Departamento de Seguros del Estado de Tejas Call with a question: 1-800-252-3439 Preguntas: 1-800-252-3439 File a complaint: www.tdi.texas.gov Quejas: www.tdi.texas.gov E-mail: ConsumerProtection@tdi.texas.gov Correo electronico: ConsumerProtection@tdi.texas.gov Mail: MC-1u-iA,P.O.Box 149091 Correo: MC-iii-iA,P.O.Box 149091 Austin,TX 78714-9091 Austin,TX 78714-9091 Form Is-10-0347(Rev.2/23) Lib uterty al u . SURETY TEXAS TEXAS IMPORTANT NOTICE AVISO IMPORTANTE To obtain information or make a complaint: Para obtener informacion o para someter una queja: You may call toll-free for information or to Usted puede Ilamar a] numero de telefono gratis make a complaint at para informacion o para someter una queja al 1-877-751-2640 1-877-751-2640 You may also write to: Usted tambien puede escribir a: 2200 Renaissance Blvd., Ste. 400 2200 Renaissance Blvd., Ste. 400 King of Prussia, PA 19406-2755 King of Prussia, PA 19406-2755 You may contact the Texas Department of Puede comunicarse con el Departamento de Insurance to obtain information on companies, Seguros de Texas para obtener informacion coverages, rights or complaints at acerca de companias, coberturas, derechos o 1-800-252-3439 quejas al 1-800-252-3439 You may write the Texas Department of Insurance Puede escribir al Departamento de Seguros Consumer Protection(I 1 1-I A) de Texas Consumer Protection(] I I-I A) P. O. Box 149091 P. O. Box 149091 Austin, TX 78714-9091 Austin, TX 78714-9091 FAX: (512)490-1007 FAX # (512)490-1007 Web: htip://www.tdi.ttxas.po Web: hnp://www.tdi.texas.eov E-mail: ConsumerPrgtection(2�tdi.texas,gov E-mail: ConsumerProtectionaa.tdJ.texas,gov PREMIUM OR CLAIM DISPUTES: DISPUTAS SOBRE PRIMAS O RECLAMOS: Should you have a dispute concerning your Si tiena una disputa concemiente a su prima o a premium or about a claim you should first un reclamo, debe comunicarse con el agente o contact the agent or call 1-800-843-6446. primero. Si no se resuelve la disputa, puede If the dispute is not resolved, you may contact the entonces comunicarse con el departamento(TDI) Texas Department of Insurance. ATTACH THIS NOTICE TO YOUR UNA ESTE AVISO A SU POLIZA: POLICY: This notice is for information only and does not Este aviso es solo para proposito de informacion become a part or condition of the attached y no se conviene en parte o condicion del document. documento adjunto. NP 70 68 09 01 LNSASM 10/15 CERTIFICATE OF INTERESTED PARTIES FORM 1295 toll Complete Nos 1 -4 and 6 if there are interested parties OFFICE USE ONLY Comple!e Nos 1,2,3 5,and 6 if there are no interested parties CERTIFICATION OF FILING 1 Name of business entity filing form,and the city,state and country of the business entity's place Certificate Number: of business. 2025-1258146 Spawi lass Contractors, Inc Austin,TX United States Date Filed: 2 Name of govemmental entity or state agency that is a party to the contract for which the form is 01116/2025 being filed. City of Round Rock Date Acknowledged: 3 Provide the identification number used by the governmental entity or state agency to track or identify the contract,and provide a description of the services,goods,or other property to be provided under the contract. 000000 -Rec Center Earthwork Construction Management services for the Rec Center Earthwork Package on the Old Settler's Park Buildout 4 Nature of interest Name of Interested Party City,State,Country(place of business) (check applicable) Controlling Intermediary SpawGlass Contractors, Inc. Austin,TX United States X 5 Check only If there is NO Interested Party. 6 UNSWORN DECLARATION My name is David Paden _ and my date of birth is My address is 1111 Smith Road Austin TX 78721 USA_. (street) (City) (state) (zip code) (country) ry I declare under penalty of perjury that the foregoing is true and correct Executed inTravis __County, state of_ Texas___ ,on Bte 16th January _ _day at_ !.20 25--. trnor+a+) (trear) ignat a authorized agent of contracting business entity (Declaranp Forms provided by Texas Ethics Commission www.ethics state.tx.us Version V4 1.0 5dd2ace2