The URL can be used to link to this page

R-2025-093 - 4/24/2025 RESOLUTION NO. R-2025-093 WHEREAS, the City of Round Rock entered into a contract on December 21, 2023 with SpawGlass Contractors, Inc., entitled "Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of Work Plus a Fee with a Guaranteed Maximum Price" ("Agreement'), and such contract is for the Old Settlers Park Buildout Project — Maintenance Facility (Package 3B); and WHEREAS, the terms of said Agreement require the submission of an Exhibit "A" to the Agreement titled, "Guaranteed Maximum Price Amendment' ("Amendment'); and WHEREAS, the City Council wishes to accept and execute said Amendment to the Agreement, Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK, TEXAS, That the Mayor is hereby authorized and directed to execute, on behalf of the City, Guaranteed Maximum Price Amendment to the Agreement with SpawGlass Contractors, Inc. for the Old Settlers Park Buildout Project—Maintenance Facility (Package 3B), a copy of said Amendment being attached hereto as Exhibit"A" and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date,hour,place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. RESOLVED this 24th day of April, 2025. CRAo MORG , Mayor City 6f Round ock,Texas AT ST: ANN FRANKLIN, City Clerk 0112.20252;4906-8582-2261 EXHIBIT „A„ -.V- ,;:AIA Document A133 - 2019 Exhibit A Guaranteed Maximum Price Amendment This Amendment dated the day of in the year,is incorporated into the accompanying AIA Document A 133T`t 2019,Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Pitts a Fee with a Guaranteed Maximum Price dated the day of in the year(the ADDITIONS AND DELETIONS: "Agreement") The author of this document may (In n'orrls, indicate dur, munch, and-year.) have revised the text of the original AIA standard form.An Additions for the following PROJECT: and Delettons Report that notes Name acrd address or locution) revisions to the standard form text is available from the author and should be reviewed.A vertical ine Old Selllers Park Buildout-Package 3B-Alaintenance Favilitl• in the left margin of this document 3300 E.Palm Valley Blvd indicates where the author has Round Rock,TX 78665 added to or de eted from the original AIA text. THE OWNER: This document has important legal (Nance. legal slams, and address) consequences.Consultation with an attorney is encouraged with City of Round Rock respect to its completion or 221 East Main St. modificat on. Round Rock,TX 78644 AIA Document A201 T"'-2017, THE CONSTRUCTION MANAGER: General Conditions of the Contract for Construction,is adopted in this (Name, legal status, and address) document by reference.Do not use SpawGlass Contractors, Inc. with other general conditions I I I I Smith Road unless this document is modified. Austin.TX 78721 TABLE OF ARTICLES A.1 GUARANTEED MAXIMUM PRICE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION A.3 INFORMATION UPON WHICH AMENDMENT IS BASED A.4 CONSTRUCTION MANAGER'S CONSULTANTS,CONTRACTORS,DESIGN PROFESSIONALS,AND SUPPLIERS ARTICLE A.1 GUARANTEED MAXIMUM PRICE §A.1.1 Guaranteed Maximum Price Pursuant to Section 3.2.6 of the Agreement,the Owner and Construction Manager hereby amend the Agreement to establish a Guaranteed Maximum Price. As agreed by the Owner and Construction Manager,the Guaranteed Maximum Price is an amount that the Contract Sum shall not exceed.The Contract Sum consists of the Construction Manager's Fee plus the Cost of the Work,as that tern is defined in Article 6 of the Agreement. §A.1.1.1 The Contract Sum is guaranteed by the Construction Manager not to exceed Two Million One Hundred and Eighty-One Thousand Six Hundred Twenty Dollars and Zero Cents(S 2,181,620.00),subject to additions and deductions by Change Order AIA Document At33-2019 Exhibit A.Copyright®1991,2003,2009,and 2019 AN rights reserved.-The American Institute of Architects,--American Institute of Architects,""AIA'the AIA Logo,and"AIA Contract Documents'are trademarks of The American Institute of Architects.This document was produced at 14 58 32 CDT on 0311212025 under Subscription No.20240040942 which expires on 0710512025,is not for resale,is licensed for one-lime use orgy,and may only be used in accordance with the AIA Contract Documents"Terms of Service.To report copyright violations,e-mail docinfo®aiacontracts.rbrrl. User Notes: (67ca10aac72d8d8f5efb3f94) ds pro%ided in the Contract Documents. §A.1.1.2 Itemized Statement of the Guaranteed Maximum Price. Provided below is an itemized statement of the Guaranteed Maximum Price organized by trade categories,including allowances;the Construction Manager's contingency; alternates; the Construction Manager's Fee;and other items that comprise the Guaranteed Maximum Price as defined in Section 3.2.1 of the Agreement. (Provide itrmized staternent below nr r%rence an attachillent) Reference attached GMP Package-Tab 06 §A.1.1.3 The Construction Manager's Fee is set forth in Section 6.1.2 of the Agreement. §A.1.1.4 The method of adjustment of the Construction Manager's Fee for changes In the Work is set forth in Section 6.1.3 of the Agreement. §A.1.1.5 Alternates §A.1.1.5.1 Alternates,if any, included in the Guaranteed Maximum Price: Item Price §A.1.1.5.2 Subject to the conditions noted below,the following alternates may be accepted by the Owner following execution of this Exhibit A.Upon acceptance,the Owner shall issue a Modification to the Agreement. (Insert below each alternate and the conditions that must be met for the Owner to accept the alternate.) Item Price Conditions for Acceptance §A.1.1.6 Unit prices,if any: (Identify the item and state the snit price and yuanti(l-lintitations, ijany, to which the unit price trill he applicable.) Item Units and Limitations Price per Unit($0.00) ARTICLE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION §A.2.1 The date of commencement of the Work shall be: (Check one of the following boxes.) [ ] The date of execution of this Amendment. j X] Established as follows: (Insert a date or a means to determine the elate of conimencentent of the Work.) May 8,2025 If a date of commencement of the Work is not selected,then the date of connmcncement shall be the date of execution of this Amendment. §A.2.2 Unless otherwise provided,the Contract Time is the period of time, including authorized adjustments,allotted in the Contract Documents for Substantial Completion of the Work.The Contract Time shall be measured from the date of commencement of the Work. §A.2.3 Substantial Completion §A.2.3.1 Subject to adjustments of the Contract Time as provided In the Contract Documents,the Construction Manager shall achieve Substantial Completion of the entire Work: (Check one(if the Jnlloiwing bove.s and complete the nece.s.sart'information) [ ] Not later than()calendar days from the date of commencement of the Work. AIA Document A133-2019 Exhibit A Copynght®1991,2003,2009,and 2019 AN rights reserved,'The American Institute of Architects,"'American Institute of Architects,"'AIA."the AIA Logo,and"AIA Contract Documents'are trademarks of The American Institute of Architects.This document was produced at 14 58 32 2 CDT on 03/12/2025 under Subscription No.20240040942 which expires on 07/0512025,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents"Terms of Service.To report copyright violations.e-mail docinfo@eiaconlracts.com. User Notes: (67cal0aac72d8d8f5etb3f94) [X] By the following date:November 24,2025 §A.2.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents, if portions of the Work arc to be completed prior to Substantial Completion of the entire Work,the Construction Manager shall achieve Substantial Completion of such portions by the following dates: Portion of Work Substantial Completion Date §A.2.3.3 If the Construction Manager fai'.s to achieve Substantial Completion as provided in this Section A.2.3, liquidated damages,if any,shall be assessed as set forth in Section 6.1.6 of the Agreement. ARTICLE A.3 INFORMATION UPON WHICH AMENDMENT IS BASED §A,3,1 The Guaranteed Maximum Price and Contract Time set forth in this Amendment arc based on the Contract Documents and the following: §A,3.1.1 The following Supplementary and other Conditions of the Contract: Document Title Date Pages §A.3.1.2 The following Specifications (Either list the Specifications here, or refer to an erhihat attached to this Amendment.) Old Settler's Park Buildout—Maintenance Facility 100%Construction Documents Technical Specifications issued December 2024 Geotechnical Engineering Report for Proposed Old Settlers Park Expansion Maintenance Yard as issued by UeS Profession Solutions 45,LLC on December 20,2024 Section Title Date Pages §A.3.1.3 The following Drawings: (Either list the Drawings here, or refer to an exhibit attached to this Amendment.) Old Settlers Park improvements-Maintenance Facility 100%Construction Documents issued December 2024 Number Title Date §A.3.1.4 The Sustainability Plan,if any: (/f the Owiter identified a Sustainable Objective in the Owner's Criteria. iaderuifir the doctnrtenr or documents that comprise the Sustainability Plait by title, date and number of pages,and include other identifying igforrnaliorl. The Sustainability Plant identifies and describes the Sustainable Objective;the targeted Sustainable afeasto•es; implementation strategies selected to achieve the Sustainable Afeasures;the Owner's and Construction Manager's roles and responsibilities associated with achieving die Sustainable Measures;the.specific details about design reviews, testing or metrics to verify achievement(?J'each Sustainable Measure;and the Su,ctainatbilit_v Documentation r•equir•ed for•the Project. as those terms arc,defined in Exhibit C to the Agreement) Title Date Pages Other identifying information: §A.3.1.5 Allowances,if any,included in the Guaranteed Maximum Price: (ldenti&each allowance.) Item Price AIA Document A133—2019 Exhibit A.Copynght m 1991,2003 2009,and 2019.All rights reserved,-The American Institute of Arch teats,-'Amencan Institute of Architects,' AIA;the AIA Logo,and'AIA Contract Documents-are trademarks of The American Institute of Architects.This dor:umefA was produced at 14 58 32 3 CDT on 0311212025 under Subscription No.20240040942 which expires on 07/05/2025 Is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documentsm Terms of Semce To report copyright violations e-mail docinfo@aia=cntracts.com User Notes: (67ca10aac72d8d8f5efb3f94) §A.3.1.6 Assumptions and clarifications, if any,upon which the Guaranteed Maximum Price is based: (Identtly each asstunption crud clarification.) Reference attached GMP Package-Tab 05 §A.3.1.7 The Guaranteed Maximum Price is based upon the following other documents and information- (List nformation(List ani,other documents or inlorrnation here,or refer to an exhibit attached to this Amendment.) ARTICLE AA CONSTRUCTION MANAGER'S CONSULTANTS, CONTRACTORS, DESIGN PROFESSIONALS, AND SUPPLIERS §AAA The Construction Manager shall retain the consultants,contractors,design professionals,and suppliers,identified below: (List narrre, discipline, address, and other m1brnratron.) This Amendment to the Agreement entered into as of the day and year first written above. OWNER(Signature) TRU MANAGER(Signature) BY:Craig Morgan,Mayor BY: David Paden,Austin Division President (Printed name and title) (Printed name and title) AIA Document At 33-2019 Exhibit A.Copyright®1991,2003,2009,and 2019.AN rights reserved.-The American Institute of Architects,' Amencan Institute of Architects,""AIA,'the AIA Logo,and-AIA Contract Documents'are trademarks of The American Institute of Architects.This document was produced at 14 58 32 4 CDT on 03112/2025 under Subscription No.20240040942 which expires on 07105!2025,is not for resale,is licensed for one-lime use only,and may only be used in accordance with the AIA Contract Documents"Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (67ca10aac72d8d8f5efb3f94) C H U S S Surety O + 908 903 3485 2028 Halls Milt Road,PO Box 1650 F +908 903 3656 Whitehouse Station NJ 08889-1650 Federal Insurance Company Liberty Mutual Insurance Company AIA Document A312 Performance Bond K42017115(Federal) 58S218546(Liberty Mutual) Any singular reference to Contractor,Surety,Owner or other party shall be considered plural where applicable CONTRACTOR(Nance curd Address): SURETY(Nance and Principal Place of Bumness) SpawGlass Contractors, Inc. Federal Insurance Company(IN) 11 I I Smith Road Liberty Mutual insurance Company(MA) Austin, Texas 78721 OWNER(Nome and Address): City of Round Rock, TX 221 East Main Street Round Rock,TX 78664 CONSTRUCTION CONTRACT Date. 4th day of March,2025 Amount:$2,181,620.00 Two Million One Hundred Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Description (Name and Location) City of Round Rock- Old Settler's Park Build Out-Package 3B- Maintenance Yard BOND Date(Not earlier than Conso uctron Contract Date) 5th day of March,2025 AMOUNT: $2,181,620.00 Two Million Ojtf nyp¢red Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Modifications to this Bond: ` GpN 0114i44f ® None O See Page 3 �� A CONTRACTORS AS F. t 0 M SURETY PRINCIPAL Company: orp � SpawGlass Contractors,Inc.. `�' :;D= Company: (Corporate �111 5 Federallnsuran Com n FXP:•'�� Liberty Mut Insu c ny Signaturert►tit t t`' �`` Signature: Name an ave en Name and Titl !oh Pn e ident -Austin Region Attomey-in-Fact (Any additional signatures appear on page 3) (FOR INFORN1.4770N OArI.}' Name, Address and Telephone) AGENT or BROKER: Adams Risk Management Services,LLC OWNER'S REPRESENTATI VE(Architect,Engineer or other parry) 1111 N Loop West Ste.600 Houston,TX 77008 713-869-8346 Pruned its cooperation with the American hlstrtute ojArchneets(AIA)hJ Chubb The language in this do:unrent conjorn,s esactly to the language used its AIA Document A312 December 1984 edition Third Prnurng March 1987 Faro IS-02.0279-FED(It" 11161 A312-1984 I I The Contractor and the Surety, jointly and severally, performance and payment bonds executed by a bind themselves, their heirs, executors, administrators, qualified surety equivalent to the bonds issued on the successors and assigns to the Owner for the performance of Construction Contract,and pay to the Owner the amount the Construction Contract,which is incorporated herein by of damages as described in Paragraph 6 in excess of the reference. Balance of the Contract Price incurred by the Owner 2 If the Contractor performs the Construction Contract, resulting from the Contractor's default;or the Surety and the Contractor shall have no obligation under 4.4 Waive its right to perform and complete, arrange this Bond,except to participate in conferences as provided for completion, or obtain a new contractor and with in Sub-paragraph 3.1. reasonable promptness under the circumstances: 3 If there is no Owner Default, the Surety's obligation .1 After investigation,determine the amount for under this Bond shall arise after: which it may be Gable to the Owner and,as soon 3.1 The Owner has notified the Contractor and the as practicable after the amount is determined, Surety at its address described in Paragraph 10 below tender payment therefor to the Owner;or that the Owner is considering declaring a Contractor .2 Deny liability in whole or in part and notify the Default and has requested and attempted to arrange a Owner citing reasons therefor. conferencewith the Contractor and the Surety to be held 5 If the Surety does not proceed as provided in Paragraph not later than fifteen days after receipt of such notice 4 with reasonable promptness,the Surety shall be deemed to discuss methods of performing the Construction to be in default on this Bond fifteen days after receipt of Contract. If the Owner,the Contractor and the Surety an additional written notice from the Owner to the Surety agree, the Contractor shall be allowed a reasonable demanding that the Surety perform its obligations under this time to perform the Construction Contract, but such Bond,and the Owner shall be entitled to enforce any remedy an agreement shall not waive the Owner's right,if any, available to the Owner.If the Surety proceeds as provided subsequently to declare a Contractor Default;and in Subparagraph 4.4,and the Owner refuses the payment 3.2 The Owner has declared a Contractor Default and tendered or the Surety has denied liability,in whole or in formally terminated the Contractor's right to complete part,without further notice the Owner shall be entitled to the contract. Such Contractor Default shall not be enforce any remedy available to the Owner. declared earlier than twenty days after the Contractor 6 After the Owner has terminated the Contractor's right and the Surety have received notice as provided in to complete the Construction Contract, and if the Surety Subparagraph 3.1;and elects to act under Subparagraph 4.1, 4.2, or 4.3 above, 3.3 The Owner has agreed to pay the Balance of the then the responsibilities of the Surety to the Owner shall Contract Price to the Surety in accordance with the terms not be greater than those of the Contractor under the of the Construction Contract or to a contractor selected Construction Contract,and the responsibilities of the Owner to perform the Construction Contract in accordance with to the Surety shall not be greater than those of the Owner the terms of the contract with the Owner. under the Construction Contract.To the limit of the amount 4 When the Owner has satisfied the conditions of of this Bond, but subject to commitment by the Owner Paragraph 3,the Surety shall promptly and at the Surety's of the Balance of the Contract Price to mitigation of costs expense take one of the following actions: and damages on the Construction Contract, the Surety is obligated without duplication for: 4.1 Arrange for the Contractor, with consent of the 6.1 The responsibilities of the Contractor for correction Owner, to perform and complete the Construction of defective work and completion of the Construction Contract;or Contract; 4.2 Undertake to perform and complete the 6.2 Additional legal,design professional and delay costs Construction Contract itself, through its agents or resulting from the Contractor's Default,and resulting through independent contractors;or from the actions or failure to act of the Surety under 4.3 Obtain bids or negotiated proposals from qualified Paragraph 4;and contractors acceptable to the Owner for a contract 6.3 Liquidated damages,or if no liquidated damages are for performance and completion of the Construction specified Contract, arrange for a contract to be prepared for fied in the Construction Contract,actual damages execution by the Owner and the contractor selected caused by delayed performance or non-performance of with the Owner's concurrence,to be secured with the Contractor. Printed in cooperation with the American Institute of Architects(AIA)by Chubb.The language in this document conforms exactly to the language used in AIA Document A312 December 1984 edition,Third Printing,March 1987. Form 15-02-0779 FEU mcg 11 tat A312-19842 7 The Surety shall not be liable to the Owner or others be deemed deleted herefrom and provisions conforming to for obligations of the Contractor that are unrelated to the such statutory or other legal requirement shall be deemed Construction Contract, and the Balance of the Contract incorporated herein. The intent is that this Bond shall be Price shall not be reduced or set off on account of any such construed as a statutory bond and not as a common law bond. unrelated obligations. No right of action shall accrue on this 12 DEFINITIONS Bond to any person or entity other than the Owner or its heirs,executors,administrators or successors. 12.1 Balance of the Contract Price:The total amount payable by the Owner to the Contractor under the 8 The surety hereby waives notice of any change,including Construction Contract after all proper adjustments have changes of time,to the Construction Contract or to related been made, including allowance to the Contractor of subcontractors,purchase orders and other obligations. any amounts received or to be received by the owner in 9 Any proceeding,legal or equitable,under this Bond may settlement of insurance or other claims for damages to be instituted in any court of competent jurisdiction in the which the Contractor is entitled,reduced by all valid and location in which the work or part of the work is located and proper payments made to or on behalf of the contractor shall be instituted within two years after Contractor Default under the Construction Contract. or within two years after the Contractor ceased working or 12.2 Construction Contract: The agreement between within two years after the Surety refuses or fails to perform the owner and the Contractor identified on the signature its obligations under this Bond,whichever occurs first.If the page, including all Contract Documents and changes provisions of this Paragraph are void or prohibited by law, thereto. the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to 10 Notice to the Surety,the Owner or the Contractor shall perform or otherwise to comply with the terms of the be mailed or delivered to the address shown on the signature Construction Contract. page. 12.4 Owner Default: Failure of the Owner,which has 11 When this Bond has been furnished to comply with a neither been remedied nor waived,to pay the Contractor statutory or other legal requirement in the location where as required by the Construction Contract or to perform the construction was to be performed,any provision in this and complete or comply with the other terms thereof. Bond conflicting with said statutory or legal requirement shall MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (CotporateSeal) Company: (Corpor•ateSeat) Federal Insurance Company Signature: Signature: Name and Title: Name and Title: Address: Address: Printed in cooperation with the American Institute of Architects(AIA)by Chubb.The language in this document conforms exacit,to the language used in AIA Document A312 December 1984 edition,Third Printing,March 1987. Form 1542-0279 FED titer 11 16- A312.19843 CHUBB Power of Attorney Federal Insurance Company I Vigilant Insurance Company I Pacific indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents,that FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY,a New York corporation,PACIFIC INDEMNITY COMPANY,a Wisconsin corporation,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations ofthe Commonwealth of Pennsylvania, do each hereby constitute and appoint Andrew A.Adams,Norman E.Adams,Michael Macomber,John A.Prince and Larry D.Snider of Houston,Texas---- each as their true and lawful Attorney-In Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surely thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than hall bonds)given or executed In the course of business,and any instruments amending or altering the same,and consents to the modification or alteration ofany Instrument referred to In said bonds or obligations In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have each executed and attested these presents and affixed their corporate seals on this 10th day of April 2024. Rupert HD Shritsdells,Assistant See ratary U arrm Ekhhrm.\'ke PrNdtni GOD-ft-00 STATE OF N EW JERSEY County of Hunterdon SS On this 10th day of April,2024 before me,a Notary Public of New Jersey,personally came Rupert HD Swindells and Warren Etchhorn,to me known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSU RANCE COMPANY.PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Rupert HD Swindells and Warren Etchhorn,being by me duly sworn, severally and each for himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of said Companies;ami that their signatures as such officers were duly affixed and subscribed by like authority Notarial Seal Albaes C noursi NOTARY rUBiIC OF WW MERSEY -raAa No 50202368 • avaltc Comwrrlivbn Eveivrs Autgsion 22.2077 Maury Pnhae CERTIFICATION Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016, WESTCHESTER FIRE INSURANCE COMPANY on December 11.2006,and ACE AMERICAN INSURANCE.COMPANY on March 20,2009: 'RESOLVtD that the foil:wing authorizations relate to the execution for and on behalf or the Company of bonds.undertakings recogntzances,contracts and other written commitments of the Company enured Into In the ordinary count of business I ta:h a'Written Commitment') (1) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized to exemte any Written Commitment for and on behal(of the Company under the seal of the Connpany or otherwise (2) Each duly appointed attorney-infect d the Company is hereby authorized to execute any Written Commitment for and on behalf ofthe Company,under the seal of the Company or otherwise. to the extent that su.-h action.s authorized by the grant of powers provided for In such person's written appointment as such anorney-In-fact 13) Each of the Chairman,the President and the V:ce Pres:dents of the Company is hereby authorized,for and an behalfofthe Company.to appoint In writing any person the attorney-in. (act of the Company with full power and authority to executefor and on behalfof he Company under the seal ofthe Company or otherw Ise,such Written Commitments ofthe Company as may be specified in such written appo ntment,which specilla adon may be by general type or lass of Written Commitments or by spedficaUon of one or more parumiar written Commitments 1 s) Each of the Chairman, the Pre:.dent a d the Vi.e Presidents of the Company is hereby authorized,6:r and en behalf of the Company,to delegate In writing to any other officer of the Company the autt,>rity to execute for and on behalf of the Company.under the Company's seal or otherwise such Written Commitments ofthe Company as are specifled In such written delegation,which spec10caUen may be by genera type or class of Written Commitments or by speciriau in of one or more particular Written Commitments I$) The signature of any officer or other person executing any Written Commitment or appointment or delegation Pursuant to this Rwlutiom and the seal of the Company,may be affixed by facsimile n such Written Commitment or written appointment ordelegaunn FURTH EN RESOLVED, that the foregoing Resolution shall not be deemed to be an exclusive statement of Ne powers and auth,rity of officers.employees and other persons to act for and on behalf of the Company,and such Resolution shall net limit or otherwise affect the exeretse,f any such poweror authority otherwise validly granted or vested' I,Rupert HD Swindells,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE.INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the'Companies-)do hereby certify that (I) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and In full force and effect, (11) the foregoing Power of Attorney is true correct and In full force and effect Given under my hand and seals of said Companies at Whitehouse Station,NJ this 5th day of March, 2025 Rupert HD Sr+indeBs AssisUat Setsvnry IN THE EVENT Y-U WISH T)VERIFY THE AIjTHENT MY:,F THIS BON-OR HOT FY I'i r.F ANY�THER MATTER PLEASE CONTACT US AT Telephzne(9)81903 3493 Fax(908)90, 3656 a mal' surecy0c1tubbcom C:omoined FED-VIG-P1-WFIC-A 1,:-arty 11.19' This Power of Attorney Ilmits the acts of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Liberty Mutual Insurance Company Mutual. The Ohio Casualty Insurance Company Certificate No 8205857-974105 SURETY West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the Slate of New Hampshire,that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts,and West American Insurance Company is a corporation duly organized under the laws 0 the Stale of Indiana(herein collectively called Ute'Companies'),pursuant to and by authonty herein se(forth,does hereby name,constilute and appoint. Andrew A. Adams'John A Prince,I any D Snider Michael htacombct;Norman E.Adams all of the city of Houston state of TX each individually if there be more than one named,Its true and lawful aftomey-n-fact to make, execute,seal,acknowledge and deliver,for and on its behalf as surety and as its act and deed any and all undertakings,bonds.recognizances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF,this Power of Altomey has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 28th day of June 2021 Liberty Mutual Insurance Company %Nsur4 x`11 INS& A tN stj The Ohio Casualty Insurance Company ooy�ticr hJ `d•oar �r�o••o l r tic West Amencan Insurance Company � 3b rn kt d fo m W 3 ''o T vi r � 1912 o c t1919� 0 1991 0 �/� HE lr'i `s • y Yd,J''�,c Rust Ja O�wAr•�•d ! rs '•aAM' .ase � U C BV J . *� 1 i M • �� By: M David M Carey,Assistant Secretary c " m State of PENNSYLVANIA 40) County of MONTGOMERY ss c E 0 u j On this 28th day of June 2021 before me personally appeared David M Carey,who acknowledged himself to be the Assistant Secretary of Liberty Mulual Insurance v) mm Company,The Ohio Casualty Company,and West American Insurance Company,and that he,as such,being authorized so to do,execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer > oc .� IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at ting of Prussia.Pennsylvania.on the day and year first above written M �� P d O qsT O 4P vY ` Q� pMwp F( CannP*+eaxn of VemsyMnr-Nobry Seal pj t«esa Pareea.rotary Ktk (D ry 0 y OF Wy oam.asw e.pm LLionvwwyeta ch 28.2025 By; �L/1 � c aEi Teresa Pastefla,Notary Public Q o 0) "t R1't p cr(V This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company Liberty Mutual 300 0.9 insurance Company,and West Amencan Insurance Company which resolutions are now In full force and effect reading as follows 0 E ARTICLE IV-OFFICERS:Section 12 Power of Attorney o 00 @CD Any officer or other official of the Corporation authorized for that purpose In writing by the Charman or the President,and subject to such limitation as the Chairman or the 'a President may prescribe,shall appoint such attorneys-in-fact,as may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety U MC any and all undertakings,bonds,reoognizances and other surety obligations Such attomeys-n fact,subject to the limitations set forth in their respective powers of allomey,shall c have fug power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation When so executed,such 0 CID ZL) instruments shah be as binding as if signed by the President and attested to by the Secretary Any power or authority granted to any representative a attorney-m-fact under the-0M provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer or officers granting such power or authority sC> CL — ARTICLE XIII-Execution of Contracts:Section 5-Surety Bonds and Undertakings Any cfticer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such limilabons as the chairman or the pres denl may prescribe. shall appoint such attorneys-in-fact,as may be necessary to act in behalf of he Company to make,execute seal,acknowledge and deliver as surety any and all undertalungs, bonds,recognizances and other surety obligations Such attomeys-in-tad subject to the limitations set forth in their respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company When so executed such instruments shall be as binding as if signed by the president and attested by the secretary Certificate of Designation-The President of the Company,acting pursuant to the Bylaws of the Company,authorizes David M Carey,Assistant Secretary to appoint such attomeys-in- fad as may be necessary to ad on behalf of the Company to make execute seal acknowledge and deliver as surety any and all undertakings,bonds,recogn¢ances and other surety obligations Authorization-By unanimous consent of the Company's Board of Directors,the Company consents that facslm le or mechanically reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds,shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C.Llewellyn,the undersgned,Assistant Secretary.The Ohio Casualty Insurance Company Liberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the original paver of attorney of which the foregoing is a full true and correct copy of the Power of Attorney executed by said Companies,is in full force and effect and has not been revoked IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seats of said Companies this 5th day of March 2025 '`iNStxrq� r�1`I INS& d %NSUrp, J `orro,y o nm �J •cyr�' � 4r`or`ro�r• ti� � 1912 � 0 1919 � i 1991 90'� t By: d�r�,cwust Ab �w,rr��is Yd ° rr Ja Renee C Llewellyn,Assistant Secretary ar> T-� �ti1 • 't, dk , luau LLIS-12877 LIVIC OCIC WA1C Mulh Co OMI C H U B B surety o + 908 903 3485 202B llalls Mill Road PO Box 1650 F +908 903 3656 Whitehouse Station NJ 08889-1650 Federal Insurance Company Liberty Mutual Insurance Company AIA Document A312111-2010 Payment Bond K42017115(Federal) 58S2t8546(Liberty Mutual) Any singular reference to Contractor.Surely,Owner or other party shall be considered plural where applicable CONTRACTOR SURETY (A'ame,legal status and address) (Name, legal status and principal place of business) SpawGlass Contractors,Inc. Federal Insurance Company(IN) 1111 Smith Road Austin,Texas 78721 Liberty Mutual Insurance Company(MA) OWNER (Name, legal status and address) City of Round Rock,TX 221 East Main Street Round Rock,TX 78664 CONSTRUCTION CONTRACT Date: 4th day of March,2025 Amount: $2,181,620.00 Two Million One Hundred Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Description(A'ame and Location) City of Round Rock—Old Settler's Park Build Out-Package 3B—Maintenance Yard BOND Date(Not earlier than Construction Contract Date) 5h day of March,2025 Amount: $2,181,620.00 Two Million One Hundred Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Modifications to this Bond: �1W1I I I 1112'''' O None O Sec Page 4 C Nl CONTRACTORS AS PRINCIPAL `�QQ�' :GpRPOp_• % SURETY _ Company: Spa s,In`:�LGrpm y yt tri•�� Company: ,: _f WorporateSeab CC77�' —��''I1L — Federal Insurajwi Compa rty 1.95 t 0= Mutual Ins ice Com Signatul __ %�,'•� 3 :;�� Name a D Paden ��s. ""':' �� Signatl(re: President -Austin Region ��` Attorney-in-L ct Name John A.Prince Signed and Sealed this 5th day of March, 2025 (Any additional signatures appear on the last page of this Performance Bond) (FOR INFORA1A7'10N OAT)' Name, Address and Telephone) AGENTorBROKER: OWNER'S REPRESENTATIVE(4rclutecr.Eagirreerorotlterp -,.i) Adams Risk Management Services,LLC 1111 N Loop West Ste.boo Houston,TX 77oo8 713-869-8346 Punted in cooperation with the Antericon Institute of Architects(AIA)by Chubb The language to this document conform to the language used to AM Document A312 Fw-2010. Foran 15-02-0574•FED(R" )1 16) h L The Contractor and the Surety,jointly and severally,bind themselves,their heirs,executors,administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. 2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. 3. If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13)of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. 4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. S. The Surety's obligations to a Claimant under this Bond shall arise after the following: 5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was, furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). 52 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety (at the address described in Section 13). & If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section S.I.I. 7. When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: 7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and 7.2 Pay or arrange for payment of any undisputed amounts. 73 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing the Claimant. 8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 9 Amounts owed by the Owner to the Contractor tinder the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any,tinder any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. Prirued in cooperation with the Arnericao Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 T"-2010. turm1501-0574-FEL)(R"11.16) 2 10. The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligations to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. IL The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is subject of the Construction Contract is located or after the expiration of one year from the date(1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs. If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 11 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page which their signature appears. Actual receipt of notice or Claims, however accomplished,shall be sufficient compliance as of the date received. 14. When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 15, Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. 16. DEFINITIONS 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant, .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .tithe total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and, .8the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. 162 Claimant:An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials,or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located.The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water,gas power, light, heat, oil gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor Printed in cooperation with the American Institute ol'Archilects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 1"-2010. Fm In IS 02-0574 F4 n(R.,11 Ib. 3 and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. 163Construction Contract: The agreement between the Owner and the Contractor identified on the cover page,including all Contract Documents and all changes made to the agreement and the Contract Documents. 16.40wner Default:Failure of the Owner,which has neither been remedied nor waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 165 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. 17. If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 18. MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: IS.I "Claim notices for FEDERAL INSURANCE COMPANY must be sent to the following address: Chubb,PO Box 2191, Chesapeake,Virginia 23327,Attention:Surety Support Team." (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (CorporateSeal) Company: (CorporateSeal) Federal Insurance Company Signature: Signature:_ Name and Title: Name and Title: Address: Address: Printed in cooperation with the American institute of Architects(AIA)by Chubb. The language in this document confornns to the language used in AIA Document A312 T"-2010. Form 1502057.1-M)fl(—11716) 4 CHUBB Power of Attorney Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents,that FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY,a New York corporation,PACIFIC INDEMNITY COMPANY,a Wisconsin corporation,WESTCHESTER FIRE INSURANCE COMPANY and ACEAMERICAN INSURANCE COMPANY corporations of the Commonwealth of Pennsylvania do each hereby constitute and appoint Andrew A.Adams,Norman E.Adams,Michael Macomber,john A.Prince and Larry D.Snider of Houston,Texas each as their true and lawful Attorney-in Fact to execute under such designation In their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed In the course of business,and any Instruments amending or altering the same,and consents to the modification or alteration of any Instrument referred to in said bonds or obligations. In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have each executed and attested these presents and affixed their corporate seals on this 10th day ofApril 2024. Rupert HD SwindeUs.Assistant Seeretazy Warren Eichhrim.Vke Pre 4dmf owo STATE OF NEW JERSEY County of Hunterdon SS. On this 10th day of April,2024 before me,a Notary Public of New Jersey,personally came Rupert HD Swindells and Warren Elchhorn,tome known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Rupert HD Swindells and Warren Elchhorn,being by me duly sworn, severally and each for himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of said Companies;and that their signatures as such officers were duly affixed and subscribed by like authority Notarial Seal IMb.re rontranl -- No7ARY PMX OF NEW IEFSEY No$0202369 'betW CONWrAssic.EVires ALTO a 22.24122 Notary Powe CERTIFICATION Resolutions adopted by the Hoards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016: WESTCHESTER FIRE INSURANCE COMPANY on December 11,2006,and ACE AMERICAN INSURANCE COMPANY on March 20,2009: 'RESOLVED,that the following authorizations relate to the execution,for and on behalf of the Company,of bonds,undertakings,recol antes.contracts and other written commitments of the Company entered Into in the ordinary coumeof business(each a'WrI ten Commitment'). (1) Each of the Chalrman,the President and the Vice Presidents of the Company is hereby authorized toexecuteany Written Commitment for and on belialfofthe Company,under the seal of the Company or otherwise (2) Each duly appointed attorney-in-fact of the Company Is hereby authorized to execute any Written Commitment forand on behalfof the Company,under the seal of the Company or otherwise, to the extent that such action Is authorized by the grant of powers provided for In such person's wrinen appointment as such attorney-in-fact (3) Each of the Chairman,the President and the Vice Presidents of the C,mpany Is hereby authorized.for and on behalfof the Company,to appoint In writing any person the attorney-Io- fact of the Company with full power and authority toexecute,for and on behalfof the Company,under the sealofthe Company or otherwise,such Written Comm fitments ofthe Company as may be specified in such written appointment,which specifionon may be by general type or class of written Commitments or by specification of one or more particular Written Commitments. (4) Each of the Chairman, the President and the Vice Presidents of the Company Is hereby authorized,for and on behalfof the Company.to delegate In writing to any other officer of the Company the authority toexecute for and nbehalf of the Company,under the Company's seal or otherwise,such Written Commimnents of the Companyasare specified in such written delegation,which specification may be by general type or class of Written Commitments or by speclncation of one or more particular Written Commitments. (5) The signature of any officer or other person executing any Written Commitment or appointment c r de egation pursuant to this Resolution,and the seal of the Company,may be affixed by faosimlle on such Written Commitment or written appointment or delegation. FURTHER RESOLVED,that the foregoing Resolution shall rot be deemed to be an exclusive statement of the powers and authority of of kers,employees and other persons to an for and on behalfof the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or authority otherwise validly granted or rested" 1,Rupert HD Swindells,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the'Companies-)do hereby certify that (I) the foregoing Resolutions adopted by the board of Directors of the Companies are true,correct and In full force and effect, (11) the foregoing Power of Attorney is true,correct and In full force and effect. Given under my hand and seals of said Companies atWhitehruse Stat,on,NJ this 5th day of March, 2025 *011146NDO Rupert HD Stviodells.Asrisnet Seartuy IN THE EVENT YOU WISH 70 VERIFY THE AUTHE,4TICITY OF THIS BOND OR NOTIFY US 7F ANY OTHER HATTER PLEASE CONTACT US AT: -- Telephone(9013)903.3493 Fax(906)903.36S6 a ma I sunery@chubbmm Combined.FED-VIG-Pt-WFIC-AAIC(rev 11.19) This Power of Attorney limits the acts of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Liberty Mutual Insurance Company Mutual. The Ohio Casualty Insurance Company Certificate No 6205857-974105 - --- West American Insurance Company SURETY POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized ,under the laws of the State of New Hampshire,that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachl-sells and West America, Insurance Company is a corporation duly organized under the laws of the State of indlana(herein collectively called the'Companies').pursuant b:and by authoity herein set forth d..-*es hereby name,constitute and appoint Andrew A Adams,John A Pr nc�,I am D Snider;Michael Macomber;Norman F.Adams all of the city of Houston state of T\ each individuafhy if there be more than cne named,its true and lawful attomey-in-fact to make execute,seal,acknowledge and deliver,for and on its behalf as surety and as its ad and deed,any and all undertakings bonds,retognizances and other surety obligations in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 28th day of June 2021 . Liberty Mutual Insurance Company 1NSu� 01 INS& %Hsup, The Ohio Casualty Insurance Company ?`oa►o— y,� yJ=`oaro�r�gy VV,`oaroIyC West Amencan Insurance Company 1912e o 1919 0 a �1991� o d�1��dACMuaja Z�iHArra`'rJDro ra 'roux► Jar By: r m @ David M Carey,Assistant Secretary m State of PENNSYLVANIA County of MONTGOMERY c E 0 a On this 28th day of June 2021 before me personally appeared David M Carey,who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance is Company,The Ohio Casualty Company and West American Insurance Company,and That he as such,being authorized so to do,execute the foregoing instrument for the purposes`E therein contained by signing on behalf of the corporations by himself as a duly authorized officer. > N (O � — IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial'seal at King of Prussia,Pennsylvania on the day and year first above written O Nria c — a O O Q�6 VnrrwP TFC rwmmmm*aa d P&v"nia Notary Seal 7er PwteBa.Notary F'OK ci C ftl t r MonWy 1e Cai,ty E p rd„ My omansion espies March 28,2025O C (`10 �,� Corrm uon minter 11260" By- . L_ \C- M~P—y% .ii A W w,ann, Teresa Pastel a,Notary Public Q `o 4Fr1'W' p o r Q? This Power of Attorney 1s made and executed pursuant to and by authority of the following By-laws and Authorizations of The Oho Casualty Insurance Company Liberty Mutual' 3 C9 O-E Insurance Company,and West American Insurance Company which resolutions are now In full force and effect reading as follows O M CL 00 E ARTICLE IV-OFFICERS:Section 12 Power of Attorney. 66 Any officer or other official of the Corporation authorized for that purpose In writing by the Chairman or the President and subject to such lim lation as the Chairman or the-o ca President may prescrbe s .appoint such omeys- itealh attin-fad,as may be necessary to ad in behalf of the Corporatirr,to make,execute sea acknowledge and deliver as surety w U — Co> C: any and all undertakings bonds recognizances and other surety obligations Such attorneys-in-fad,subject to the limitations set forth in their respective powers of attomey shall c o t have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the sea of the Corporation When so executed,such o cur Z U instruments shall be as binding as.f signed by the President and attested to by the Secretary.Any power or authority granted to any representative a attorney-in-fact under the provisions of this ar5:le may be revoked at any lime by the Board the Chairman,the President or by the officer or officers granting such power or authonty a ARTICLE XIII-Execution of Contracts:Section 5 Surety Bonds and Undertakings Any officer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such Iim lations as the chairman or the president may prescr be shag appoint such attomeys-in-fad as may be necessary to ad in behalf of the Company to make,execute,sea,acknowledge and del ver as surety any and al'undertakings bonds,recognizances and other surety obligations.Such attomeys-in-fad subject to the limitations set hath in their respective powers of attorney shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company When so executed such nstruments shall be as tHnding as if signed by the president and attested by the secretary. Certificate of Designation-The President of the Company,acting pursuant to the Bylaws of the Company,authorizes Da:d M -afey Assistant Secretary to appanl such ahomeys in fad as may be necessary to act on behalf of the Company to make,execute,sea acknowledge and deliver as surely any and all undertakings,bonds recogntzances and other surety obligations. Authorization-By unanimous consent of the Company's Board of Directors,the Company consents that facsimile or mechanically reproduced signature rf any assistant secretary of the Crwripany,wherever appeanng upon a certified copy of any power of attorney issued by the Company n connection with surety bonds,shall be val d and binding upon the Company with the same force and effect as though manually affixed. I,Renee C Llewellyn,the undersigned Assistant Secretary,The Ohio Casualty Insurance Company,Uberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full,true and correct copy of the Power of Attorney executed by said Companies,is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have nereunio set my hand and affixed the seats of said Companies th s 5th day of March 2025 %NSU Ott INS& 7NSU,� a rc`,ar o'y�•f✓R` Z. O%rO,(, Lr� �r`oaeo4', y(+ E r r 1912 o t 1919 o A 1991 Q By: is, ZOtiArraw JD= rs �aAMr ,Oats Renee C Llewellyn Assisla,t Secretary ''M ♦ Fa LMS-12873 LMIC OCIC WAIC Mutb Co 0221 Have a complaint or need help? Ilene una queja o necesita ayuda? IMPORTANT NOTICF. AVISO IMPORT ANTE' If you have a problem with a claim or your premiums, call Si tiene un problema con un reclamo o las primas,Ilame your insurance company first. if you can't work out the primero a la empresa de seguros.Si no puede resolver el issue, the Texas Department of Insurance may be able to problema,el Departamento de Seguros del estado de Tejas help. puede ayudar. Even if you file a complaint with the Texas Department of Si registra una queja con el Departamento de Seguros del Insurance, you should also file a complaint or appeal estado de tejas,tambien debe presentar una queja o through your insurance company. If you don't, you may apelacion a traves de su compania de seguros.Si no to hace lose your right to appeal. puede perder su derecho de apelar. To get information or file a complaint with CHUBB: Para obtener informacion o registro de una queja con CHUBB: Call Toll-free:i-Soo-36-CHUBB Llame al:1-Boo-36-CHUBB Mail: Eastern Claim Service Center Correo: Eastern Claim Service Center boo Independence Parkway 600 Independence Parkway Chesapeake,VA 23320 Chesapeake,VA 23320 Attn: Surety Support Attn: Surety Support Phone: 800-252-467o Fax: 800-664-5358 Telefono: 8o0-252-4670 Fax:800-664-5358 Email: ecsc.claims@chubb.com Correo electronico: ecsc.claims@chubb.com To get help with an insurance question or file a complaint Para ayuda con una pregunta de seguros o registrar una with the state: queja con el estado: The Texas Department of Insurance El Departamento de Seguros del Estado de Tejas Call with a question: 1-800-252-3439 Preguntas: 1-800-252-3439 File a complaint: www.tdi.texas.gov Quejas: www.tdi.texas.gov E-mail: ConsumerProtection@tdi.texas.gov Correo electronico: ConsumerProtection@tdi.texas.gov Mail: MC-iii-iA,P.O.Box 149091 Correo: MC-iii-1A,P.O.Box 149091 Austin,TX 78714-9091 Austin,TX 78714-9091 FOrn,15-10 0347(Re% 2,23) Liberty mutual. SURETY TEXAS TEXAS IMPORTANT NOTICE AVISO IMPORTANTE To obtain information or make a complaint: Para obtener informacion o para someter una queja: You may call toll-free for information or to Usted puede Ilamar al numero de telefono gratis make a complaint at para informacion o para someter una queja al 1-877-751-2640 1-877-751-2640 You may also write to: Usted tambien puede eseribir a: 2200 Renaissance Blvd.,Ste.400 2200 Renaissance Blvd., Ste. 400 King of Prussia,PA 19406-2755 King of Prussia, PA 19406-2755 You may contact the Texas Department of Puede comunicarse con el Departamento de Insurance to obtain information on companies, Seguros de Texas para obtener informacion coverages, rights or complaints at acerca de companies, cobetturas, derechos o 1-800-252-3439 quejas al 1-800-252-3439 You may write the Texas Department of Insurance Puede escribir al Departamento de Seguros Consumer Protection(I 1 I-1 A) de Texas Consumer Protection (I 11-)A) P.O. Box 149091 P. O. Box 149091 Austin,TX 78714-9091 Austin,TX 78714-9091 FAX: (512)490-1007 FAX#(5 12)490-1007 Web: htip://www.tdi.texas.gov Web: hnp://www.tdi.texas.gov E-mail: ConsumerProtectionaldi.texas,gov E-mail: ConsumerProtection&tdi.texas.gov_ PREMIUM OR CLAIM DISPUTES- DISPUTAS SOBRE PRIMAS O RECLAMOS: Should you have a dispute concerning your Si tiena una disputa concemiente a su prima o a premium or about a claim you should first un reclamo, debe comunicarse con el agente o contact the agent or call 1-800-843-6446. primero. Si no se resuelve la disputa, puede If the dispute is not resolved,you may contact the entonces comunicarse con el departamento(TDI) Texas Department of Insurance. ATTACH THIS NOTICE TO YOUR UNA ESTE AVISO A SU POLIZA: POLICY. This notice is for information only and does not Este aviso es solo para proposito de informacion become a part or condition of the attached y no se convierte en parte o condicion del document. documento adjunto. NP 70 68 09 01 LMS 15297'0'1 � I SpawGhlSS Providing the Absohae Best Construction Evperience y x- Px• 1' T k rF 1. -N wim TABLE OF CONTENTS TAB 1 TAB 6 BUDGET ESTIMATE OVERVIEW BUDGET PROPOSAL COST BREAKDOWN TAB 2 TAB 7 EXECUTIVE PROJECT SUMMARY MASTER PROJECT SCHEDULE TAB 3 TAB 8 PROJECT TEAM BID/PROPOSAL PACKAGE STRATEGY TAB 4 TAB 9 LIST OF DOCUMENTS TAB 5 ASSUMPTIONS & CLARIFICATIONS BUDGET ESTIMATE OVERVIEW . 411 J r S�awGl��s 1 (� Providing Absolute Construction ExperienceF Project Cost Summary 100% CD ESTIMATE OVERVIEW SpawGlass Contractors, Inc. hereby submits to the City of Round Rock for the use and benefit of the new Old Settler's Park Buildout Package 3B Maintenance Yard, based on the 100% CD Drawings, as follows: 1. The proposed amount for the Direct Cost of the Work: $ 1,838,431 2. General Conditions: $ 59,463 3. Builder's Risk Insurance: $ 5,705 4. General Liability Insurance: $ 17,017 S. Payment & Performance Bonds: $ 25,316 6. Subcontractor Default Insurance (1.25%): $ 22,980 7. Warranty: $ 5,454 8. Contractor's Contingency (3.0%): $ 65,449 9. Design Progression Contingency (3.0%): $ 65,449 10.Construction Phase Fee (3.50%): $ 76,356 11. Price Forecasting/Tariffs: $ 0 12.TOTAL: LINE ITEMS i THROUGH 11: $ 2,181,620 Tyu.r WLr a1.L_-, -_ Tyler Wenzel, Project Executive TAB 2 -� EXECUTIVE PROJECT �b SUMMARY f 1 1 L SpawGlass Executive Summary City of Round Rock - Old Settler's Park Build Out Package 3B - Maintenance Yard 100% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 Scope of Work Package 3B - Maintenance Yard is the construction of the new Warehouse, Remote Pole Barn, Remote Maintenance Facility site work, and site improvements. This includes demo of existing structures and site, earthwork, site utilities, concrete flatwork, electrical work, and landscaping. Overview The new Maintenance Yard package is planned to be completed in one main package: - Construction is planned to start in May 2025. 1 I� AB 3 PROJECT TEAM 1 / ti S avvGlass ORGANIZATION CHART LEGEND Management Support M Team Lead/Single Point-of-Contact On site Team Safety CITY OF ROUND ROCK 0 PreconstructaNEstmatmgSuppart DAVID PADEN TOM MCCLANAHAN DIVISION PRESIDENT FE SENIOR ESTIMATOR JOEY GEORGE ADAM WARDEN OPERATIONS MANAGER ESTIMATO? JUAN MARQUEZ BRIAN CLAXTON DINATOR BIM/YDC COORDINATOR TYLER WENZEL PROJECT EXECUTIVE' PRECONSTRUCTION SERVICES MANAGLF 11 PARKER BLASCHKE HARRISON HOLLEY SENIOR PROJECT MANAGE k SENIOR SUPERINTENDENT CHRIS SOTO © ASSISTANT SUPERINTENDENTS ASSISTANT PROJECT MANAGER I DAYLON=�Pl(�)ORDINATOq 0 ASSISTANT PROJECT MANAGER QUALITY C TAB 4 LIST OF DOCUMENTS PS awGlass . w • 1f List of Documents City of Round Rock - Old Settler's Park Build Out Package 36 - Maintenance Yard 100% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 # SHEET TITLE ISSUE DATE REVISION DATE C-0.0 COVER C-1.0 KEY SHEET DECEMBER 2024 C-2.0 GENERAL NOTES DECEMBER 2024 C-3.0 EXISTING CONDITIONS DECEMBER 2024 C-4.0 DEMOLITION PLAN DECEMBER 2024 C-5.0 DEMOLITION PLAN DECEMBER 2024 C-6.0 GRADING AND DRAINAGE PLAN DECEMBER 2024 C-7.0 SITE PLAN DECEMBER 2024 C-$.0 PAVING PLAN DECEMBER 2024 C-9.0 UTILITY PLAN DECEMBER 2024 C-10.0 REMOTE MAINTENANCE FACILITY PLAN DECEMBER 2024 C-11.0 CONSTRUCTION DETAILS DECEMBER 2024 C-11.1 CONSTRUCTION DETAILS DECEMBER 2024 C-11.2 CONSTRUCTION DETAILS DECEMBER 2024 L-1.00 LANDSCAPE PLAN DECEMBER 2024 L-1.01 LANDSCAPE PLAN DECEMBER 2024 L-1.02 LANDSCAPE PLAN DECEMBER 2024 L-2.00 LANDSCAPE DETAILS DECEMBER 2024 L-3.00 LANDSCAPE SPECIFICATIONS DECEMBER 2024 IR-1.0 IRRIGATION PLAN DECEMBER 2024 IR-1.1 IRRIGATION PLAN DECEMBER 2024 IR-2.0 IRRIGATION DETAILS DECEMBER 2024 IR-2.1 IRRIGATION SPECIFICATIONS DECEMBER 2024 A1.101 POLE BARN #1 FLOOR PLAN DECEMBER 2024 A1.102 POLE BARN #2 FLOOR PLAN DECEMBER 2024 A1.103 POLE BARN #1 & #2 ROOF PLAN DECEMBER 2024 A1.104 POLE BARN CROSS SECTIONS DECEMBER 2024 ASI-1 POLE BARN #1 GENERAL NOTES DECEMBER 2024 ASI-2 POLE BARN #1 FOUNDATION PLAN DECEMBER 2024 AS1-3 POLE BARN #1 FOUNDATION DETAILS DECEMBER 2024 AS2-1 POLE BARN #2 GENERAL NOTES DECEMBER 2024 AS2-2 POLE BARN #2 FOUNDATION PLAN DECEMBER 2024 AS2-3 POLE BARN #2 FOUNDATION DETAILS DECEMBER 2024 AS3-1 CHEMICAL BUILDING GENERAL NOTES DECEMBER 2024 AS3-2 CHEMICAL BUILDING FOUNDATION PLAN DECEMBER 2024 E-0 LEGEND DECEMBER 2024 E-1 SITE PLAN DECEMBER 2024 E-2 POLE BARN #1 PLAN DECEMBER 2024 List of Documents E-3 POLE BARN #2 PLAN DECEMBER 2024 E-4 ELECTRICAL RISER DIAGRAM DECEMBER 2024 E-S ELECTRICAL DETAILS DECEMBER 2024 9 MOM .r., Providing the Absolute Best Construction Experience Assumptions and Clarifications City of Round Rock —Old Settler's Park Build Out Package 3Bb — Maintenance Yard 100% Construction Documents - GMP 1301 N Kenney Fort Blvd., Round Rock, TX 78665 GENERAL QUALIFICATIONS 1. Kimley Horn and Associates, Inc. is the civil engineer/prime consultant of record. 2. Based on an anticipated NTP of May 2025. 3. Specifications provided. 4. The baseline schedule is based on a 5-day work week. S. Normal working hours have been included from 7:00 AM to 5:30 PM unless otherwise noted, with exception to early concrete operations as deemed necessary. It is also assumed that work can occur on a 7 day a week schedule if required. 6. In order to subcontract scopes of work in a timely manner to meet the construction schedule it is assumed that buyout packages will be reviewed within 5 business days of their submission. 7. LEED Certifications or Green Building Programs are not incorporated into the project. 8. Builders Risk Insurance is provided by SpawGlass. Builder's Risk deductible to be paid from construction contingency. 9. Performance & Payment Bonds are provided by SpawGlass. 10. General Liability is provided by SpawGlass. 11. Proposal assumes that the specified material and equipment are available as required to meet the schedule. If they are not available as required, we assume the Owner/Architect will authorize alternate material or equipment selections. 12. Owner must accept GMP within 30 calendar days, at which time pricing may expire. 13. General conditions - Any general conditions savings or losses from that package are to be rolled into the other GMP packages. 14. Tariffs are an unknown factor at this time. Any cost or schedule impacts related with tariffs will be negotiated with Owner for reimbursement. Contractor shall provide information reasonably requested by Owner to document such impacts, such as quotes, invoices, or receipts. SPECIFIC QUALIFICATIONS Division 0 — General Rgguirements and General Conditions 1. SpawGlass general requirements assume a 6 month project construction schedule. 2. Construction photos will be taken on a regular basis by SpawGlass. Digital files will be turned in monthly. 3. As-Built drawings, record drawings and record submittals will be kept in electronic format These files will be accessible to all on the jobsite. Assumptions and Clarifications 4. Reasonable repairs or damage caused by contractor(s) will be funded from the CM Contingency if funds remain and approved by CoRR. 5. Dimensional Control for the Project is included. 6. Individual non-photographic hard hat stickers for workers will be utilized. 7. Temporary barriers and enclosures are included to delineate construction zone from the public. 8. No sound/vibration monitoring included. Division 02 - Existing Conditions 1. Site demolition and clearing is included. 2. Removal of fencing at Remote Facility Division 03 - Concrete 1. Slabs on grade for PEMBs 2. Concrete curbing, mow strips under fencing, light pole bases, and setting steel bollards 3. 2' x 2' x 1' D pads for containers - 16 Each 4. 4"paving for Ranger Shed, Chemical Storage Building, Fuel Storage, and Lubricant Cabinets. 5. Concrete paving for storage area and Wash 6. Curbs around the Fuel Storage and lubricant cabinets. 7. Concrete paving for the Remote Facility. Division 04 - Masonry 1. NA Division 05 - Metals 1. Steel Bollards Division 06 - Wood, Plastics, and Com og_sites 1. NA Division 07 - Thermal and Moisture Protection 1. Site Sealants 2. Slab on Grade Sealants Division 08 - Openings 1. One Hollow metal door, frame, hardware, and Installation 2. One 12' x 12' overhead door with chain drive with factory paint finish Division 09 - Finishes 1. Painting hollow metal door& frame 2. Paint steel bollards Assumptions and Clarifications 3. Metal stud framing for horizontal wall panels on the Remote PEMB Division 10 - Speciafisias 1. Fire Extinguishers on Brackets in PEMB(s) 2. Knox Boxes on Entry Gates Across Driveways Division 11 - Equipment 1. Includes removing and relocating fuel storage tank &Cover; lubricant cabinets &cover; chemical storage building & ramp; and Ranger Shed (Morgan Building). Division 12 - Furnishinas 1. NA Division 13 - Special Construction 1. PEMB - Chief basis of design not used but Red Dot Buildings. SpawGlass feels that this is the current best value for the City of Round Rock. 2. SSPC Primer Standard Metal Building Factory Primer for Field Finish coat painting by Others 3. Soffit panels are factory painted steel - not Petersen Aluminum in specifications. 4. Collateral Load 17.5 PSF 5. R-30 Insulation 2 Plys at the roof for the Remote PEMB only. Division 14 - Conveying Equipment 1. NA Division 21 - Fire Suppression 1. NA Division 22 - Plumbing 1. NA Division 23 - HVAC and Controls 1. NA Division 26 - Electrical 1. Primary conduit 2. Secondary service 3. Pole Lighting 4. Power for Chemical Storage Division 27 - Communications 1. Underground conduit as noted on drawings conductors by CoRR Division 28 - Electronic Safety & Security Assumptions and Clarifications 1. NA Division 31 - Earthwork 1. Includes clear and grub. 2. SWPPP setup included. 3. SpawGlass assumes that all water can be taken from existing City of Round Rock water utilities on-site, and no water will need to be trucked in from other cities due to water restrictions. 4. Includes removal of fat clays and placement of 12"of select fill at building pads for 1" PVR. 5. Includes 12"of base and 2"of asphalt at parking lot. 6. Includes stockpiling of existing onsite material for respread of 4"over hydro mulched areas. 7. Includes stripping and stockpiling of topsoil for respreading 4", B. Includes excavation, embankment, and import of soil as needed 9. Includes subgrade preparation for concrete paving at Remote Facility. 10. Includes compacted road base for paved surface at the Main Facility. Division 32 - Exterior Improvements 1. Remote Facility - Chain Link fencing gaivanized, 8' High, 9 gage mesh, 3 strands of barbed wire, and manual double gate 2. Main Facility - Service Area Fencing - Chain Link fencing galvanized, 8' High, 9 gage mesh, 3 strands of barbed wire, and three manual double gates. The fencing will be extended behind the pole barns if the Alternates are not elected. 3. Main Facility - Privacy Fencing - Chain Link fencing vinyl coating, 9 gage, vinyl privacy slats, 3 Strands of Barbed Wire, and one motor operated slide gate across driveway. 4. Includes importing and placing 2"of topsoil blended with 4"of respread by earthwork contractor. 5. Hydro Seeding - Bermuda grass seeding in lieu of sod as requested by CoRR. 6. Irrigation - Includes permanent, temporary, and sleeves as noted on the drawings. 7. Includes 90-day maintenance after substantial completion. 8. Includes Knox Boxes at the Remote and Main Facility driveway gates. 9. Painted parking striping if asphalt or concrete paving alternates are elected. 10. Wheel stops at parking spaces as indicated on the drawings. Division 33 - Utilities 1. Site utilities are included. 2. Reuse Water Service 3. Domestic Water Service includes connection, meter, backflow, piping, and hose bibbs. 4 Storm scope of work includes culverts with SSTs f Assumptions and Clarifications EXCLUSIONS 1. Permits, by Owner. 2. LEED documentation and Submittals. 3. We have not included the following items as we assume, they will be provided in a timely manner by the Owner at no cost to SpawGlass: a. Materials Testing Services b. Excludes all local electrical utility fees for permanent power 4. Preconstruction costs for the Project are not included in this budget. 5. Contaminated soils - hauling or disposal s ;� BUDGET PROPOSAL COST ;'a ; �� BREAKDOWN „s moi'�A 1 - Spaw(71ass Providing thAbsolute Best �� Construction Experience Summary Report OSP Maintenance Yard 100% CD GMP - Rev 02 Revision 02 Including Asphalt Paving Estimate Date: 03/03/2025 Documents Date: 12/04/2024 Project Size (SF): 335,284 Project *: 3023121.02C Project Location: 1301 N. Kenny Fort Blvd., Lead Estimator: Tom McClanahan ITEM COST COST I SF "/o OF TOTAL GR's (335,284 SF) 130,871 0.39 6.00 % Main Facility (328,051 SF) 1,364,211 4.16 62.53 % Remote Maintenance Facility (7,234 SF) 343,350 47.46 15.74 % Indirect Costs 343,189 1.02 15.73 % Total Cost $ 2,181,620 $ 6.51 100.000/0 OSP Maintenance Yard 100%CD GMP-Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page I of I Documents Date: 1210412024 Recap Report OSP Maintenance Yard 100% CD GMP - Rev 02 Revision 02 Including Asphalt Paving Estimate Date: 03/03/2025 Documents Date: 12/04/2024 Project Size (SF): 335,284 Project #: 3023121.02C Project Location: 1301 N. Kenny Fort Blvd., Lead Estimator: Tom McClanahan ITEM COST COST I SF % OF TOTAL GR's (335,284 SF) 130,871 0.39 6.00 Div. 01 - General Requirements 130,871 0.39 100.00 % Main Facility (328,051 SF) 1,364,211 4.16 62.53 Div. 05 - Metals 2,200 0.01 0.16 % Div. 07 - Thermal & Moisture Protection 1,200 0.00 0.09 Div. 09 - Finishes 450 0.00 0.03 % Div. 10 - Specialties 750 0.00 0.05 Div. 11 - Equipment 18,000 0.05 1.32 Div. 26 - Electrical 145,000 0.44 10.63 % Div. 31 - Earthwork 543,200 1.66 39.82 % Div. 32 - Exterior Improvements 442,411 1.35 32.43 % Div. 33 - Utilities 211,000 0.64 15.47 % Remote Maintenance Facility (7,234 SF) 343,350 47.46 15.74 % Div. 07 - Thermal & Moisture Protection 2,724 0.38 0.79 Div. 08 - Openings 26,550 3.67 7.73 Div. 09 - Finishes 18,000 2.49 5.24 Div. 10 - Specialties 1,289 0.18 0.38 Div. 13 - Special Construction 112,000 15.48 32.62 Div. 31 - Earthwork 52,100 7.20 15.17 Div. 32 - Exterior Improvements 130,687 18.07 38.06 OSP Maintenance Yard 100% CD GMP Rev 02 Estimate Date:03/03/2025 Revision 02 Including Asphalt Paving Page 1 of 2 Documents Date: 12/04/2024 ITEM COST COST I SF °V6 OF TOTAL Indirect Costs 343,189 1.02 15.73 % General Conditions 59,463 0.18 2.73 % Builder's Risk Insurance 5,705 0.02 0.26 % General Liability Insurance 17,017 0.05 0.78 Payment and Performance Bands 25,316 0.08 1.16 % Subcontractor Default Insurance (SDI): 22,980 0.07 1.05 % Warranty 5,454 0.02 0.25 % Contractor's Contingency 65,449 0.20 3.00 % Owner/ Design Contingency 65,449 0.20 3.00 % Overhead and Profit 76,357 0.23 3.50 % Total Cost $ 2,181,620 $ 6.51 100.000/0 OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 03/03/2025 Revision 02 Including Asphalt Paving Page 2 of 2 Documents Date: 12/04/2024 Detail Report (Direct Costs Only) OSP Maintenance Yard 100% CD GMP - Rev 02 Revision 02 Including Asphalt Paving Estimate Date: 03/03/2025 Documents Date: 12/04/2024 Project Size (SF): 335,284 Project #: 3023121.02C Project Location: 1301 N. Kenny Fort Blvd., Lead Estimator: Tom McClanahan ITEM QUANTITY I UM UNIT COST TOTAL COST GR's 130,871 Div. 01 - General Requirements 130,871 General Requirements 130,871 As-Bullts/ Drawings 2.0 Sets 378.88 758 Job Photos/ Videos 3.5 Mos 148.36 519 Water, Ice, &Cups (for Field) 3.5 Mos 540.28 1,891 General Safety Supplies 3.5 Mos 216.50 758 Portable Toilets - Rental & Handwash (tea) 12.0 Mos 194.85 2,338 Misc. Fuel, Oil, &Grease 4.0 Mos 270.62 1,082 Misc. Small Tools 1.0 LS 3,788.75 3,789 Main Facility - Temporary Fencing - Rental (6' h 3,538.0 LF 8.00 28,304 Chain Link Fence w/ Driven Posts) Remote Facility - Temporary Fencing - Rental (6' h 380.7 LF 8.00 3,046 Chain Link Fence w/ Driven Posts) Project Signs 1.0 Each 1,267.95 1,268 Surveying Supplies 6.0 Wks 154.95 930 Licensed Professional Certified Survey (Intial 1.0 LS 3,000.00 3,000 Control Points) Licensed Professional Certified Survey (Final) 1.0 Each 3,000.00 3,000 Onsite Misc Labor 28.0 Wks 1,450.00 40,600 Final Cleaning - Site - LOC/ Work Area Disturbed 335,284.5 SF 0,05 16,764 (7.70 Acres) Trash Dumpsters (40 Yd.) - Pulls 20.0 Each 541.25 10,825 Dust Control EQ 3.5 Mos 1,714.12 5,999 Surface Water Pumping / Dewatering 3.5 Mos 1,714.12 5,999 Main Facility 1,364,211 Div. Structural/Miscellaneous Steel -- Fabrication 2,200 OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 03103/2025 Revision 02 Including Asphalt Paving Page 1 of 4 Documents Date: 12104/2024 ITEM QUANTITY I UM UNIT COST TOTAL COST Supply Steel Pipe Bollards 4.0 Each 550.00 2,200 Div. 1 If Waterproofing/Dampproofing /Joint Sealants 1,200 Main Joint Sealants Concrete Flat Wotk 1.0 LS 1,200.00 1,200 Div. 09 - Finishes 450 Painting / Wall Coverings 450 Painting Steel Bollards - Main Facility 1.0 LS 450.00 450 Div. 10 - Specialties 750 , Fire Protection Specialties 750 Knox Box on Gate 1.0 Each 750.00 7S0 •iv. 11 - Equipment 18,000 Maintenance Equipment 18,000 Relocation of Ranger Shed / Morgan Building; Chemical Building & Ramp; Fuel Storage Tank & 1.0 LS 18,000.00 18,000 Cover; and Lubricant Cabinets &Cover • IIf Electrical 145,000 Electrical Primary Conduit, Secondary, and Site 1.0 LS 145,000.00 145,000 •iv. 31 - Earthwork 543,200 Earthwork 508,200 Clear and Grub Site, Stock Pile Top Soil,Cuts, 1.0 LS 269,000.00 269,000 Embankment, and Respread 4" of Top Soil Additional Base and Asphalt Pavement - Elected 1.0 LS 239,200.00 239,200 Alternate 03-03-2025 Erosion Control 35,000 SWPPP, Inspections, Silt Fencing, Tree Protection, Concrete Wash-Out Containers, Maintenance, and 1.0 LS 35,000.00 35,000 Removal •iv. 32 - Exterior Improvements Site Concrete 160,000 Ribbon Curbing, Mow Strips, Setting Bollards, Concrete Paving as Noted, Footing Blocks For Containers, Slabs for Ranger Shed, Chemical 1.0 LS 160,000.00 160,000 Storage Building, Fuel and Lubricant Cabinet Slabs and Curbs, and Light Pole Bases Trac Markings/Signage 4,118 Wheelstops 15.0 Each 125.00 1,875 Parking Space Striping - Paint 1.0 LS 2,243.00 2,243 OSP Maintenance Yard 100% CD GMP Rev 02 Estimate Date:0310312025 Revision 02 Including Asphalt Paving Page 2 of 4 Documents Date: 1210412024 ITEM QUANTITY i UM UNIT COST TOTAL COST Fences / Gates 137,093 Privacy Fence 8' Chain Link 9 Gage Vinyl Coated, Vinyl Slats, and 3 Rows of Barbed Wire; Service Fencing 8' + V Barbed Wire Galv Finish 9 Gage; 1.0 Is 137,093.00 137,093 Service Gates 3 Each Manual; One Motorized Slide Gate at Entry Retaining Walls 31,200 Retaining Walls ILO Pole Barn #2 130 LF @ 4' T 520,0 SF 60.00 31,200 With Embedment Landscaping / Irrigation 110,000 Hydromulching, Sleeves, Permanent &Temporay 1.0 LS 110,000.00 110,000 Irrigation, and 90 Day Maintenance I III Site Utilities 211,000 Site Utilities - Storm Culverts, Safety End Treatments, Domestic Water&Hydrants, and 1.0 LS 211,000.00 211,000 Reuse Water System Remote Maintenance Facility 343,350 07 - Thermal& Moisture Protection 2,724 : Waterproofing / Dampproofing /Joint Sealants 2,724 Remote - Joint Sealants - Concrete Paving and 1.0 LS 2,724.00 2,724 Slab on Grade I : Openings 26,55OR Doors / Frames/ Hardware 4,100 Hollow Metal Door, Frame, Hardware,and 1.0 Each 4,100.00 4,100 Installation OH/Coiling Doors / Grilles 13,500 Coiling Doors (Manual) 12' x 12' Shop Painted 1.0 Each 13,500.00 13,500 Finish Chain Operated Non Insulated Louvers / Vents 8,950 Remote - Gable End Louvers Including Engineering 1.0 LS 8,950.00 8,950 and Installation 09 I Drywall/Acoustical 9,500 6" Mtl. Studs to Support Horizontal Siding on PEMB 1.0 LS 9,500.00 9,500 Painting / Wall Coverings 8,500 Painting Steel Building Frames & Perlins and Hollow Metal Door& Frame - Primer Coat Applied 1.0 LS 8,500.00 8,500 in Shop By Fabricator and Painted Onsite After Erected Div. I - Specialties 1,2 OSP Maintenance Yard 100%CD GMP- Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page 3 of 4 Documents Date: 1210412024 ITEM QUANTITY I UM UNIT COST TOTAL COST Fire Protection Specialties 1,289 Fire Extinguishers 2.0 Each 269.42 539 Knox Box on Gate 1.0 Each 750.00 750 Div. 13 - Special Construction 112,000 Pre-Engineered Metal Buildings 112,000 Pre-Engineered Metal Building, Includes: Frame, 1.0 LS 112,000.00 112,000 Roof, Exterior Metal Wall Panels Div. 31 - Earthwork 00 Earthwork 49,600 Clear and Grub Site, Stock Pile Top Soil, Respread 4", Cuts, Embankment, 10" Compacted Base For 1.0 LS 49,600.00 49,600 Concrete Paved Area Erosion Control 2,500 Silt Fencing, Safety Caps, Wash-Out Containers, 1.0 LS 2,500.00 2,500 Maintenance, and Inspections Div. 32 - Exterior Improvements e ,687 Site Concrete 104,000 SOG, Concrete Driveway, Heavy Duty Paving, and 1.0 LS 104,000.00 104,000 Mow Strip Under Fencing Fences / Gates 14,687 Remote Facility - 8' Chain Link Fencing Galvanized 9 Gage + 1' Barbed Wire and Manual Double Gate 1.0 LS 14,687.00 14,687 Across Driveway Landscaping/ Irrigation 12,000 Hydromulching, Sleeves, Permanent&Temporay 1.0 LS 12,000.00 12,000 Irrigation, and 90 Day Maintenance Total - Direct Costs $ 1,838,431 OSP Maintenance Yard 100%CD GMP- Rev 02 Estimate Date: 03/03/2025 Revision 02 Including Asphalt Paving Page 4 of 4 Documents Date: 1210412024 p e F s n � r mN o g= r u N e� ty rF �p F N ooh 88$8. 8.$ 88 888 888888688 8 88 I I ^ � a N M 88888.888.8888888888888888 8 8$ 6 8 c N O O O aaa __- al full, 11,95 � R » a . . . . . . . X S 888 888888.8.8.88.8888888888888888 888 $888 z 8 888 h AB 7 'S MASTER PROJECT SCHEDULE �• ' °• - , ''fit;f 1! 5 ' r rr c .. am-TAM a� SI)aWGIaSS R r� Activity I D Activity Name orig Rem Start Finish Tctal 2�11.15 2026 2027 Our Our • • • • • • • F! Pl�cp Milestones280 280 19-Feb-25 27-Mar-26 6% 3 W)dpatgRe� MSTONE-10 GMPApproval_3A.2-Hanel Pkwy 0 0 19-Feb-25 0% 28 G.WiApprpyal_*2.6*;R P1MN MSTONE-11 Construction Start_3,k2-Harrel Pkwy 0 0 19-Feb-25 0% 28 ii Construction Start 3A.2=Hertel Pkwy MSTONE-10 Construction Start_3B-Tennis/Pfddeball 0 0 19-Feb-25 0% 12 ii Coh§trGdtibriStari 36=TehhiBtRddeba MSTONE-11 GMP Appmval 3C-RocKN Rarer 0 0 19-Feb-25 0% 3 0 GMP.ApptDvaO_3C,RoclM Rarer MSTONE-11• Construction Start_3C-RocWN River 0 0 19-Feb-25 0% 3 6 Clonstructlon Start-3C RockN Rhes MSTONE-11 GMP Approval_3C-Rec Center Complex 0 0 19-Feb-25 0% 44 0 <tMIJ.Apprpyo k�04 CQnRer QrPA� MSTONE-12 Substantial Completion_3C-RocXN River 0 0 27-Mar-26' 0% 3 ♦ Substantia Camp ie Early Procurement 180 35 1!Jiu-24A 08-Apr-25 80.56% 523 Earl*Pr§0x ment Administration Submittalsr ProouremenF Procurement —230 3A.1-Harrell Pkwy Contech Pedestrian Underpass Pmcure� 160 0 17-Jul-24 A 23-Jan-25 A 100% 3A 1 - iareell pkwy�ontedn Pedesfian LJ A5250 3A.1 -Harrell Pkwy Pedestrian Bridge Procurement 180 35 31 Jul-24 A 08-Apr-25 80.56% 523 1= 3Fr.1,Harrbll R"POdettttiAri Brxlga 2-Lakeview 250 140 14-Oct-24 A 05-Sep-25 "% .6 2;LAMMM Issues&Constraints0�-�- 0 Design Budgeting 60%Lakeview Dt'awings o o GMP �� Buy-Out and CwbmdAdministration 0 0 0% 0 144)C-24A 05-Sep-25 Constiruicbm I' LtCVW-129 Construction(See Lakeview Construction Schedule) 250 140 14-Oct-24 A 05Sep-25 44% 16 ;CtlnsttuXtfcar:(See:E:akAvieW. 3X1 -Harrell Pkwy,Lakeview Parking&Apex Fields Rebcabon 310 220 21-W-24A 02-Jan-26 2903% 20 :31A 1 -;fiaireu`Fkwy,'La Issues& • .. —Fesgn 00 Budgefing 3X130°/6 Drawings 0 0 0% o Padkage 3X1 60%Drawings 0 0 0°'6 0 Start Date: 15-Jan-24 moo—iiiiiiiiiiiiii Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 =)--=o Remaining Work Summary WBS Layout-All Activities • • Data Date 19-Feb-25 r w—iiia Critical Remaining Work ® Level of Effort Page 1 of 7 Run Date 19-Feb-25 -Activity I D ActiAty Name Ong Rem Start Finish % Total 125 2026 2027 Dur Dur Float GMP 1 f 0' --' - - — Buy-Out and CoMradAdmtftlshati0rl 0 0 0% 0 ;GaQ,stit► 3A.1-140 Construction(See Harrell ParkweyConstruction Schedule) 310 220 21-W-24A 02-Jan-26 29.03% 20 :Coristructiort4sele:HefrO 3A2-Harrell Pkwy 138 95 08-Jan-25A 02-Jul-25 31.16% 363 ;�A HajtpO issues&Constraints Design • �NMI CAUSE 1 E Budgeting . . .: . . . . . a Package 3A2 30%Drawings 0 0 0-,� o Package 3A2 60%Drawings 0 0 0% 0 A5370 CoRR provide approval for recommended subcontractors ©� 08-Jan-25A 14J 100% T - pRR Ptp�ji�e;gppioYsl fof isOgrgrpgnFi4d Buy-Out and ContradAdn***'atbn 25 0 154en 25 A 18-Feb-25 A 100% Bu Otit e�td Cortttiat AdminisUadori A2110 SG administer contracts to subcontractors for Package 3A.2 10 0 15-Jan-25 A 28,7an-25 A 100% i SG"rn "oorttriats to Wboiritrpibm ft A2120 Subcontractors review SG subcontract for Package 3A.2 5 0 29-Jan-25 A 04-Feb-25A 100% II:StJ*dnh*cWrd rb0"SG bUbb6rftdt fdr• A2130 SG finalize and execute subcontracts for Package 3A.2 5 0 05-Feb-25A 11-Feb-25 A 100% I; SIG fitrati;wgMd e28MM WbWntradS br . A2140 Mobilization of preliminary subcontractors for Package 3A.2 5 0 12-Feb-25 A 18-Feb-25 A 100% N: Motift9tion 0 pmkrftry,subcpRltiagt7 Sutlils 40 0 19-Feb-25A 15-Apr-25A 100% A2150 "Submittals-Long lead materials for Package 3A.2(Eec,a 40 0 19-Feb-25A 15-Apr-25 A 100% bald;"****(oj Procurement 0 0 0% 0 ; Northam Section 95 95 19-Feb-25A 02-Jul-25 00k 225 :Nd,6irrn Bid" A5290 Demolition of existing site elements 20 15 19-Feb-25A 11-Mar-25 25% 28 b;b' 'dlifioin4iJistiri�tiRi eisritirits A5300 Underground utilities 40 40 19-Feb-25 15-Apr-25 0% 28 Cd: UhdohglyduhCl Udldiee A5320 Construct roadway and sidewalks 70 70 26-Mar--25 02-Jul-25 0% 225 :Cahsttutt' y arld:sidaWrllos; Southern Section o 0 0% a NW Section o 0 0% o Punchist/Cbseout 0 0 0% 0 r 3X3-Harrell Pkwy(Bridge) ?i 1' 23 14-Oct-24 A 21-Mar-25 77.23% 3",-HarN P idly' 9ridjp ): Start Date. 15-Jan-24 w+--� Actual Work • • Milestone CoRR OSP -Preconstruction Schedule Finish Date: 08-Mar-27 coo Remaining Work 9 9 Summary •WBS Layout-All Activities Data Date: 19-Feb-25 f.iiiiiiii Critical Remaining Work c=11111=0 Level of Effort Page 2 of 7 zz Run Date: 19-Feb-25 27 Ong Rem Start Flnish % Total 20251 1 Activity 10 Activity Name Dur Dur Float constraintsissues& 1 1 1' 1 � . __ 1 1 5 23 O�* �21-M a r-2�5 ! 7171 Design A2220 Development of Package 3A3 100%Drowngs 24 2 14-Od-24A 20-Feb-25 91.67% — 14 Qeyak�pmont:of Pac age:3A.1100% A2230 SG receipt of Package 3A_3 100%Drawings jarget Date 11 1 1 21-Feb-25 21-Feb-25 0% 14 Sol Mo t gf pacoga 3 1.00%O'awi A2240 Cdy review of Package 3A.3 100%Drawngs 10 10 24-Feb-25 07-Mar-25 0% `65 It City r9viewof Padrage-3AZAMak Draw A2250 Final p+an revisions for Package 3A.3 10 10 10-Mar-25 21-Mar-25 0% .,65 i .Q Viral{pan%%orisfor PacKa0a 3A.3 Budgeting Package 3A.3 30%Drawings 0 0 0% ° Padcage 3A.3 W%Drawings 0 0 0% R -• 1 GMP A2330 SG prvwde consnuctability review comments on 1 DO%Pack 5 5 24-Feb-25 28-Feb-25 0% ',4 q SG provti MrMrudabfriCY MAew A2340 Conduct page flip meeting reviewing 100%Package 3A.3 d 1 1 03-Ma r-25 034Aar-25 0% 14 CgnfluG pagwfllp meebrig rlvlein91 Pre-Construction 1 1 / LBuy-Out and Contract Administration 0 0 0% o Subn*als 0 0 0 Procurement 0 0 0% 0 3B-Tennis/Picklebaii '5 - 40 _08Jan-25A �15y4pr-25 48.87°k -418 %1efrrjrlFlyik f�f; Issues& • 1 1 /Design 1' 1 Budgeting Package 38-Tennis/Picideba9 30°/6 Drawings Padcage 3B-Tennis!Fticlebal 60%Drawings 0 0 0% ° GMP /. 1 i - _........... �__ 0 ... .._._Via— SSA 100% t�yyQl+�and:0m"ctAOmmi�abor. I _ Buy-Out and CantractAdmin�stratiorl . . A2850 SG administer contracts to subcontractors for Package 3B- 5 0 08Jan 25 A 14Jan-25 A 0091 so 0gr►rihStercpnlfapts t4 9ut►Wf�c iors f A2860 Subcontractors review SG subcontract for Package 3B-Ten 5 0 15Ja n-25 A 21 Ja n-25 A 100% Sir6 Vadprs review sultiContrad for a A2870 SG finzive and exec t,subcontracts for Package 38-Tenn 5 0 22-Jan-25A 28Jan-25 A 100% SG fkl bo aW Araboje AAKbh**2sYO► Pa A2880 Mobilization of preliminary subcontractors for Package 3B-1 5 0 29Jark-25 A 04-Feb-25 A 100% Mobil¢ation of pteh MnrLy$000fQ 8=1R tc ( Su 40 20 05-Feb-25A 18-Mar-25 50% 438 Submitidls bMWIS Start Date: 15-Jan-24 an— Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 c=pm— Remaining Work Summary .WBS Layout-All Activities ra � Data Date: 19-Feb-25 mw . Critical Remaining Work Level of Effort Page 3 of 7 Run Date 19-Feb-25 O • Rem $Ian Finish % Total 2025t2027 Dur Dur Float A28% "Submittals-Long lead materials for Package 3113-Temic! 40 20 05-Feb-25A 18Uar-25 50% 438 "SOin tai-,Long Wiled:Rreter"far Procurement 0 0 0% 0 A5590 Demolition of epsting site elements 10 0 05-Feb-25A 18 Fe!}25 A 10096 : Pemplition:of aMng Arte elements ( ' A5600 Earthwork/Pad Prep for Courts 45 30 19-Feb-25A 1S AW-25 33.33% '2 b Urth*ork!pad Pmp fn-Coutts 1 313-MaintenanceArea 57 30 06-Jan-25A 01-Apr-25 47.37% 25 3&AA"VaitianodAMa Issues&Constraints 1 Design . 1 �� Budgeting 1 1 � Padcage 3B-Maintenance Area 30%Drawings 0 0 096 0 Package 3B-Maintenance Area 60%Drawings 0 0 0% 0 Padcage 3B Maintenance Area 90%Drawings 0 0 0% 0 - "3180 SG provide constructability review comments on 100%Pads 5 0 0"n-25A i0,Jsn-25 A 100% 56 pfaW"mrig ,ct3oility rawer,"cocitnents A3190 Conduct page flip meeting reviewing 100%Package 313-M. 1 0 13-Jan-25A 13-Jan-25A 100% conducipage Rp meetin9 ra'.1s orng:100% ' I A3200 SG solicit 100%Package 38-Maintenance Area for GMP 15 0 04+eb-25 A 12-Feb-25 A 100% : SGSolipt 100%P,amage 313,Main;er'a A3210 SG compde GAAP for Package 36-Maintenance Area from, 4 0 13-Fat)-25A 18-Feb-25 A 100% f iSG;caritp Gam,fv:Nsga 3d-Mari A3220 SG submit GMP for Package 3B-Maintenance Area 1 0 19-Feb-25A 19.Fe 25A 100% ► SGa+lt,rnl GMP for aackne:36-Mein A3230 Owner/Design Team review GMP for Package 3B-Mainter 5 5 19-Feb-25 25-FeD-25 0°% 24 a Ueher+De"i Sear^vt,wlGMPfbr Ra A3240 SG review comments for Package 3B-Maintenance Area G 4 4 26-Fe6-25 03-Mar-25 0% 24 0 SG oeview comments for PackagB 39-M A3250 SG resubmit Package 38-Maintenance Area GMP 1 1 04-Mar-25 04-Mar-25 0% 24 + 3G resubmit Package 30-Mm%ena-ice A3260 Ownerfomard Package 38-Maintenance Area GMP to Col 5 5 05-Mar-25 11-Mar-25 0% 24 ! 0er foiw Papkagy$ l$Aprnten A5460 CoRR City Councl approval process for Package 3B-Main 15 15 12-Mar-25 01,W-25 0% 25 :9 ;CoR3x Clty Lound epproMhl orvicess f _ . .in �� ;Prd Cdnkttticfion Buy-Out and ConttadAdmnistration w 10 10 12-Mar-26 25-Mar--25 0% 24 V:Buy-0kat and CbAtfat:tAd4ninls47tibr1 A3270 SG conduct buyout meetings for pre limmary scopes of work 10 10 12-Mar-25 25-Mar--25 0°% 24 :rY :SG obtldud buybdt MebgrigS fot orallrrl. Submttals 0 0 0% 0 Procurement 0 0 0% 0 - Construction 3C-Ro&N River 310 280 08-Jan-25A 27-Mar-26 968% 1T8 ; ; ; : :3C RocKN RAW: Issues&Constraints Start Date: 15-Jan-24 an-mass AMal Work ♦ ♦ Maestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 ao Remaining Work V008'ss"11111' Summary WBS Layout-All Activities Data Date: 19-Feb-25 res Critical Remaining Work - Level of Effort Page 4 of 7 Run Date: 19-Feb-25 r Rem Stait Finish % Total 2025 O Dur Float Budgeting Package 3C-RocIeN River 30%Drawings o o Package 3C-RocWN River 60%Drawings 0 0 0% o QQ 0' : . 080: •r Pr�Gpr,structron Buy-Out and ContradAdminisbation 25 0 olwan-28A 11-Feb-25A 100% SuyOtQor.dContract Adnrtt*mtran A3710 SG administer contracts to subcontractors for Package 3C- 10 0 OAJan-25A 21 Jan-25 A 100% SGtaorrmtncster oor."cts tp XftWtractorn A3720 Subcontractors review SG subcontract for Package 3C-Rok 5 0 22Jan-25 A 28-Jan-25 A 100% gub4on"clors mview$113*6MntMc9 for P A3730 SG finalize and execute subcontracts for Package 3C-Rod 5 0 29Jar-25 A 04-Feb-25 A 100% SG fmaf¢e and exebike*ubaontrads for FN A3740 Mobilization of pre:rmmary subcontractors for Package 3C-f 5 0 05-Feb-25A 114-eb-25 A 100% Mob.U2.6on b:P*Wriinliij 'swbcbntiattoB Subfrliftak5 40 35 12•Feb-25A 08-Apr-25 12.5% 423 111W Sibrnittals A3750 "Submittals-Long lead materials for Package 3C-RocKN 40 35 12-Feb-25A 08-Apr-25 12.5% 423 "Submiral6:t.&V jind rnatanals for M Prmrement 0 0 W100 Construction A5950 Earthwork!Building Pads 90 90 19-Feb-25 25,1un-25 0% 3 *)9uilding Pods A5960 underground Uttlrties'MEP Rough-In 100 100 14-May-25 03-0ct-25 0% 3 o U^dergrouro V**kx l p A5970 Concrete Foundations 60 60 11 Jul-25 03-0d-25 0% 3 0 (0,ni;;mte rptMoOon¢ A5980 Structural Steel 80 80 08-Sep-25 02-Jan-26 0% 3 0 $t uGtr�rarl Sft!#e) ; ; A6000 Masonry Stuom 90 90 03-Nov-25 13-Mar-26 0% 43 : . © MpsornY{$*jj= A6020 Finishes 60 60 17-Dec,25 13-Mar-26 D°Eo 43 A6060 Punchhst and Closeout?Commissioning 30 30 16-Feb,-26 27-Mar-26 0% 3 P6rKhw 040 C)"• 3C Rec Center Complex Site 55 30 20-Dec-24A 01-Apr-25 45 45% 29 3C-pec Cpnb9r•C�4ttlOW-$ft: Issues&Constraints Design Budgetingc , P11110111211191111113C-Rec Center Complex-Sibe 30%Drawings 0 0 0% 0 Padrage 3C-Roc Center Complex-Ste 60%DrawhP 0 0 0% o � . : : . A4090 Owner t Design Team revs w GMP for Parcrage 3C-Ree Ce --S 0 200ac-24 A 14Jan-25 A 100% On!+erl04sti9i►Ydam IevgwONpIcy padkQ A4100 SG ravww comments for Package 3C-Rec Center Compo 4 0 15-Jan-25 A 20-tan-25 A 10( S. G.,*A",compnertts for Package 3C-Rec Start Date: 15-Jan-24 Actual work ♦ • Milestone CoRR OSP - Preeonstruction Schedule Finish Date_ 08-Mar-27 Remaining Work Summary WBS Layout-All Activities Data Date: 19-Feb-25 f� Coal Remaining Work ® Levet of Effort Page 5 of 7 Run Date 19-Feb-25 � zn Ong Rem Start Finish % Total 2025 / ACtil.*10 Adiwfty Name Dur Dur Float A4110 --=resubmit Package 3C-Rec Center Comp ex-Site GMF 1 0 21-Jan-25 A 21-Jan-25 A 100% SQr08ubrilk PedtAyp 3G: MM COT. A4120 Droner forward Package 3C-Rec Center Complex-Site Gh 5 0 22,Jan-25 A 28-Jan-25 A 100% f npi,fprj tp�pgk e F ec00(ttpi A5760 CoRR City Council approval process for Package 3C-Rec 30 0 29-Jan-25 A 13-Feb-25 A 100% CAR Cray',Gouital apQfoval prgosiq for'•F! A5770 SG provide CoRR list of recommended prarity suboontracto 1 0 14-Feb-25A 14-Feb-25 A 100% �: SG IuVitlA CARR ABt bfMcbt tA�brldstl A5780 CoRR provide approval for recommended subcontractors 5 5 17-Feb-25A 11-Mar-25 0% 29 ;CORR pMWO:appR"lbrMOMW#0-0 ;_ Pre-Construction �� • I: 1 Pre GoristniWo Buy-W and ContractAdministration 45 30 29-Jan-25A 01-AW-25 33.33% 29I :&w-CManidQDn4AdrroftMbn ; A4130 SG conduct buyout meetings for preliminary scopes of work 20 10 29Jan-25A 04-Mar-25 50% 29 or :SO Conduct bvyoutmeetirtgsfor pe9fm' A4140 SG administer contracts to subcontractors for Package 3C- 10 10 12-Mar-25 25-Mar-25 0% 29 :6 :SC ad'rnjnjs*pon stp 04'bpW"qtqi A4150 Subcontractors review SG subcontract for Package 3C-Re( 5 5 264Aw 25 01-Apr-25 0% 29 5ubodnbgCtol9 review SG suboontraat f Submittals 0 0 0% 0 Prowrernent 0 0 0% 0 Construction 3C-Rec Center Complex-Buildings 61 49 16-Deo-24A 28-Apr-25 19.67% 99 ;3C-A C�tltOr:Colripbk:BUiKfiA$s, ConstraintsIssues& O .esign • :D1 it ARM A6290 Development of Package 3C-Rec Center Complex 90%D 38 20 16-Deo-24 A 18-Mar-25 47.37% 52 DbveloNd'tBAt of RAdrtlgb 3C;-PM A6300 SG receipt of Package 3C-Rec Center Complex 90%Draw 1 1 19-Mar-25 19-Mar-25 0% 52 r' SG:rdmiptad PadcW311M RoC COM A6340 City review of Package 3C-Rec Center Complex 90%Draw 10 10 20-Mar-25 02-Apr-25 0% 99 !;9 City retview Pt Owll;Me 3C'-ROC itiriviir A6350 Development of Package 3C-Rec Center Complex 100%i 18 18 03-Apr-25 26-AW-25 0% 99 rr; o 00*i0*li 4f POOOO 40 todlic, ,111 Budgeting Package 3C-Rec Center Complex-Buldngs 30%Drawings 0 0 0% o Package 3C-Rec Center Complex-Buildings 60%Drawings 0 0 0% 0 GMP A6510 SG provide consbuctabildy review comments on 90%Packa 5 5 20-Mar-25 26-Mar-25 0% 52 d :SG provide aorieftidabti,Ry ieview born A6550 Conduct page flip meeting reviewing 90%Package 3C-Re 1 1 27-Mar-25 27-Mar-25 0% 52 r Conduct fip Mb6tkt$te1n" . A6520 SG solicit 90%Package 3C-Rec Center Complex for GMP 15 15 28-Mar-25 17-Apr-25 0% 52 : o: SGwkk 90%P9du*e 3C;-Re0 Cert Buy-Wand ContractAdministration 0 0 0% 0 Subn>dtals 0 0 0% 0 Pr'oamernent 0 0 0% 0 Start Date 15-Jan-24 �� Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date 08-Mar-27 0—= Remaining Work Summary WBS Layout-All Activities SpawGlass Data Date 19-Feb-25 w Critical Remaining Work Level of Effort Page 6 of 7 Run Date 19-Feb-25 i Activity ID Activity Name Orig Rem Star! Fin0sh % Total 2025 2026 Dur Dur Float • • 1 • •% • - 3D Mul6- Purpose Center Expansion 118 55 1OSep-24 A 064Aay-25 5339% 96 ;3A Mult 'lism Genter .giee+.ion issues&Constraint w + 1 . . . . A4280 Development of Package 3D-Muni-Purpose Center F.xpanr 43 0 104e04 A 04-Feb-25 A 100% D9vftment Of;Padfage D!MO-Pu A4290 SG Receip!of Package 3D -Multi.Purposa Center E)pan5ic 1 0 05-Feb 25A 05-Feb-25 A 100°/° $G�tpgeip�gf P� 4��C�1 MOI4�4rR4s4 A4300 City review of Package 3D-Mutti-Purpose Center Expansioi 10 0 06-Feb-25 A 19-Feb-25A 00°e : C4 i6viewof PhOOge 3D=W&Ptirpose A4310 Development of Package 3D.Multi-Purpose Center Expan: 25 25 02-Apr-25 06-May-25 0% 96 b f.4.66, 71rt. 6f; A 3D•Mu � Budge� 1. r •: •. : ting Budgeting Padcage 3D-Multi-Purpose Center Expansion 30%Drawings o 0 0% 0 Package 3D-Mul&Purpose Center Expansion 60%Drawings 39 30 06-Feb-25A 01,Apr-25 23.08% 96 A4450 SG provide constructabikty review comments on 60%Packa 5 0 06-Feb-25A 12-Feb-25 A 100% SG WoV49 OonLtMM611111yt MVWW CWnMn A4460 Conduct page flip meeting reviewing 60%Package 30-Mu 1 0 13-Fel A 13-Feb-25 A 100% r: cwxk apo"fops rneiir lj reriq v*ig;0* A4470 SG solicit 60%Package 3D-Multi-Purpose Center ExpansK 15 15 14-Feb-25 A 11-Mar-25 0% 96 0: ¢glipt60%,Fla*giip i$0 MO*Nroo A4480 SG compile pricing for 60%Package 3D-Multi-Purpose Cek 4 4 12-Mar-25 17-Mar-25 0% 96 :r+: SG;egmptle prion'!OrW%Pagka' 3d A4490 SG submit budgetary pricing for 60%Package 3D-Multi-Pu 1 1 18-Mar-25 1&Mar-25 0% 96 r: 5G:sutlrAft: uH " ibtW%Pd A4500 Owner provide comments on 60%Package 3D-Multi-Purpc 5 5 19-Mar-25 25-Mar-25 0% 96 ri :ON1 6r.p W*eomntantre1n:60W IRAW A4510 SG revise 60%Package 3D-Multi-Purpose Center Expansi 5 5 26-Mar-25 01-Apr-25 0% 96 4 ;$C3 rB'liee OMPaclinj SD liii!116"rp GMP -_ ---- 00fe 0 — BuyOtA and ConVWAdministraGon o 0 Submillais 0 0 0% a Prowranent 0 0 0% 0 Construction 3D.1-Far Easlem Fields o 0 0°6 0 3D2-Middle Fields/Arne Balding 0 0 0% 0 3D.3-Far Western Fields i Club House 0 0 0% 0 0 Overal3D o 0 096 start Date 15-Jan-24 Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date- 08-Mar-27 coo Remaining Work P� Summary WBS Layout-All Activities awrGlass Data Date 19-Feb-25 on— Critical Remaining Work ® Level of Effort Page 7 of 7 ISP Run Date 19-Feb-25 I I— TAB 8 = _ BID/PROPOSAL PACKAGE • STRATEGY 4 1 a ti Sp, v&31ass Bid Proposal Package Strategy City of Round Rock — Old Settler's Park Build Out Package 3B — Maintenance Yard 100% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 Long Lead Time Equipment and Material PEMB's would be the only long lead item at this time. Construction Document Packages Multiple packages will not be required to satisfy material procurement and/or drawing development. Proposal Package Strategy The project will be advertised for proposals from suppliers, subcontractors, and vendors for all major features of work. Proposals shall be received via mail, email, courier, or hand delivered from subcontractors and suppliers. Any addendums that may be required will be issued one week prior to receiving proposals. The respondents will be evaluated on the subcontractors' ability to perform the work. Subcontractors will be recommended based on their company's personnel and corporate qualifications. SpawGlass will recommend the best value supplier and/or subcontractor to the Owner for concurrence prior to negotiating their contract. Spav&-ilass Providing bsolute Best Construction SAF w.. t *, �• �r� �¢ 1 y «T y Y f �y. 1 SpawGlass Contractors, Inc. 1111 Smith Road Austin, TX 78721 q 512-719-5251 SpawGlass.com y---1 A�o,Ro® CERTIFICATE 4F LIABILITY INSURANCE DAT3/5/2025YYY. THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(les)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME Adams Risk Management Services, LLC PHONE Mlrta Tamez FAX Adams Insurance Service, Inc (AiC,No,Est) (713)869.8346 (Arc,No)-(713)869-9144 1 111 North Loop W.Suite 600 ADDRESS mtamez@adamsins.com Houston TX 77008 INSURERS)AFFORDING COVERAGE NAIC r INSURER A American Contractors Insurance Co RRG 12300 INSURED .-ADMIN-.1 INSURERS ACIG Insurance Company 19984 SpawGlassContractors, Inc. 1111 Smith Road INSURER C;Valley Forge Insurance Company 20508 Austin,TX 78721 INSURER o The Continental Insurance Company 35289 INSURER E Travelers Lloyds Insurance Company 41262 INSURER F. XL Insurance America.Inc. 24554 COVERAGES CERTIFICATE NUMBER:502582730 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN 'SSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH TH'S CERTIFICATE MAY BE ISSUED OR MAY PERTAIN THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LTR POLICY NUMBER MM'DDYYYY MM,DDYYYY LIMITS A X COMMERCIAL GENERAL LIABILITY Y Y GL24ABC00046 6112024 6/1/2025 EACHOw_-C_RREN,-_E _$10.000,000 G AMS MADE X OCCUR DAMAGE Tb RENTED PREMISL S.(Ea occurrence? $100,000 MED EXP(Any one person: s 5 000 PERSONA/-&ADV INJURY _s 10,000,000 GEN'L AGGREGATE LIMIT APP_IES PER GENERA. AGGRE.bATE S 10,000,000 POLCY X JECOT LOC PRODU-TS COMP,OP AGG $10,000.000 OTHER S C AUTOMOBILE LIABILITY Y Y BUA7033775896 6 1 2024 6/1/2025 COMBINED SINGLE LIMIT s 5,DOO,000 Ea ac.demi X ANY AUTO R-)OILY IN,URY/Per person/ S OWNE" SCHEDULED AUTOS ONLY AUTOS 8001LY W..URY(Per accident; s X HIRED X NON-OWNED PROPER I DAMAGE $ AUTOS ONLY AUTOS ONLY ,Per accdent) , $ D UMBRELLA LIAR X OCCUR Y Y CUE7034067095 61112024 611 2025 EACH Or,GJRREN,.E $10,000.000 X EXCESS LIAR CLAIMS MADE Ar _ GAEGATE _ S 10,000,000 OED RETENTION S $ B WORKERAND SOCOMPENSATION RS'N AT ON Y N Y WCA000008324 6!1(2024 611 202; X STATUTE ER ANYPROPRtr TOR PARTNER EXECUTIVEN E L EACH ACC DENT $1.000.000 OFFICER MEMBER EXCLUDED? N A (Mandatory in NH) E DISEASE EA EMP_OYEE S 1,000,000 It yes desu,be under DESCRIPTION OF OPERATIONS below El DISEASE POI-.•,Y LIMIT $1,000,000 E CONTRACTORS EQUIPMENT QT-630.7625835-;J TLC-24 6 112024 611 2025 LEASEDrRENTED SEE BELOW F BUILDERS RISK(BROAD FORM) U SOO 1 16369CA24 A 6112024 611 2025 PROJECT AMOUNT <$10.000,000 SEE PAGE 2 DESCRIPTION OF OPERATIONS 1 LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached it more space's required) Contractors Equipment Continued. Per Item:51 500.000 Aggregate$3 000,000 The Automobl a pol cy Inc udes the following endorsements: 1)CNA53359-Blanket Additional Insured as required by written Contract executed prior to the bodily Injury or property damage.2 1 CNA63359-Blanket Waiver of Subrogation as required by written _ontraa exe_uted prior to the bodily Injury or property damage 3)CNA63359 8 CNA71527 Primary Non-Contributory basis only when required by a written contract pnor to Accident or Loss 4)CNA68021 -Notice of Cancellation-30 days blanket as required by written contract. See Attached CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Round Rock 221 East Street Round Rockck TX 78644 JJ AUTHORIZED REPRESENTATIVE T ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016 03) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: SGADMIN IY LOC q: ACOR" ADDITIONAL REMARKS SCHEDULE page 1 of 1 AGENCY NAMED INSURED Adams Risk Management Services LLC SpawGlass Contractors, Inc 1111 Smith Road POLICY NUMBER A.Ist'n,TX 78721 CARRIER NAIC CODE EFFECTIVE DATE ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 _ FORM TITLE: CERTIFICATE OF L'ABIt ITY INSURANCE The General Liability policy includes the following endorsements: 1 I 1 170-Additional Insured-Automatic Status as required by Contract-Blanket-Who Is an insured is amended to�nclude as Additional Insured any person or organ zation when you have agreed in a written contract that such person or organization be added as an additional Insured on your policy The endorsement also provides for the coverage to apply on a primary and non-contributory basis for ongoing and completed operations when required by written contract 2)205-Blanket Waiver of Subrogation when required in a written contract or agreement.3)336- Notice of Cancellation Nonrenewal or Material Change-30 days blanket as required by written contract 4)9-Aggregate Limits of insurance Per Project. The Workers'Compensation policy includes the following endorsements 1)WC990304-Wa ver of Subrogation-Blanket waiver for any person or organization for whom the named Insured has agreed in a written contract to furnish the waiver 21 WC420601 -Notice of Cancellation-30 days blanket as required by written contract The Umbrella/Excess Liability policy applies In excess and follows form of the underlying General Liability,Automobile Liability and Employers Liability policies above including the terms of any additional insured,waiver of subrogation and 30 day notice of cancellation endorsements. The policy follows the terms and conditions of such underlying policies unless they are Inconsistent with the terms of the policy The Equipment Floater policy includes a Blanket Automatic Loss Payee Endorsement CMU618 that provides Loss Payee status to the Certificate Holder only when there is a written contract between the Named Insured and the Certificate Holder that requ res such status Re.Project:Old Settler's Park Buildout,Package 38-Maintenance Yard 100'':CD Drawings.3300 E.Palm Valley Blvd.,Round Rock,TX 78665 Project Amount:$2,181,620.00 ACORD 101 (2008101) ?:2008 ACORD CORPORATION- All rights reserved. The ACORD name and logo are registered marks of ACORD ADDITIONAL INSURED - AUTOMATIC STATUS X70 AS REQUIRED BY CONTRACT - BLANKET This endorsement modifies insurance provided under the following COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Any person or organization that you are required by written contract to include as an additional insured on[his policy it the contract is executed prior to the loss A Section ti,Who Is An Insured is amended to include as an additional insured any person or organization shown in the above SCHEDULE (called additional insured).but only with respect to liability for-bodily injury" "property damage"or personal and advertising injury ansrng out of your premises or your operations for the additional insured, and only to the extent and for the minimum limits required in the written contract B The insurance provided to the addrt ona insured is subject to the following I milations 1 Unless a written contract specific ally requ res additiona insured coverage for your completed operat ons,this insurance does not apply to"bod ly injury or property damage'occumng after your work"for the additional insured has been completed or after that portion of .your work'out of which the bodily in,ury'or'property damage arises has been put to its intended use by any person or organization whichever occurs first 2 Unless specifically required by written contract th s insurance provides add trona nsured coverage only for I ability for bodily injury 'property damage'or personal and advertising nlury to the extent caused by the named insured's acts or omissions or the acts or omissions of those acting on the named insured s beha f 3 This insurance does not appy to bodily injury', property damage"or'persona and advertising injury"for which the additional insured is obligated to pay damages by reason of the assumption of hab lily in a contract or agreement except to the extent that the additional insured would have been obligated to pay such damages in the absence of the contract or agreement 4 This insurance does not apply to'bodily njuryproperty damage"or"personal and advertising injury'arising out of the rendering or failure to render any professional services by any insured or on any nsured's behalf, including a) The preparing. approving or fading to prepare or approve maps shop drawings, cp n ons,reports, surveys field orders,change orders drawings or specifications.or b) Supervisory. inspection architectural,or engineering seances This exclusion applies even it the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment,training or monitoring of others by that insured,if the"occurrence"which caused the"bodily injury or"property dami or the offense which caused the"personal and advertising injury",involved the rendering of,or the failure to render,any professional architectural,engineering or surveying services. 5 This endorsement shall not apply to a person or organization if any other additional nsured endorsement attached to this policy specifically applies to that person or organization. 6 The insurance afforded herein only applies to the extent permitted by applicable state law, including statutes governing additional insured coverage in the construction industry. 7 The insurance afforded to the additional insured shall not exceed the minimum limits required in the written contract. C In no event shall the insurance provided to the additional insured exceed the minimum coverage requ red by the written contract,including but not limited to minimum limits,minimum scope of coverage,or minimum duration of coverage If a written contract or agreement requires that additional insured status be provided by the use of specified edition dates of the ISO CG2010 and or CG2037,then the terms of that endorsement are incorporated into this endorsement as respects such additional insured and shall supersede the c overage grant and limitations in Sections A. and B. of this endorsement In the event that CG2010 and-or CG2037 are required but no edition dates are specified,the 04/13 editions shall apply. D. This insurance is excess to any other insurance, whether primary, excess, contingent or on any other basis available to the additional insured unless a written contract requires that this insurance be primary or primary and non-contributng.However,this insurance is a ways excess to other insurance,whether primary,excess,contingent or on any other basis,when the addilicnal insured has been added to the other insurance as an additional insured. Nothing herein contained shall be held to vary,alter,waive or extend any of the terms,conditions,provrsicns agreements or limitat.ons of the mentioned Policy,other than as above slated This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective 6/1/2024 Policy No GL24ABC00046 Insured: SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc.,Westland Equipment and Supplies,LLC Insurance Company American Contractors Insurance Company Risk Retention Group los WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Persons or Organization(s): Any person or organization for whom you have agreed by written contract to furnish this waiver. Section IV— Commercial General Liability Conditions, 14. Transfer of Rights of Recovery Against Others to Us Condition is amended by the addition of the following: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or"your work"done under a contract with that person or organization and included in the "products-completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 61112024 Policy No.: GL24ABC00046 Insured: SpawGlass Contractors, Inc;., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc.,Westland Equipment and Supplies, LLC Insurance Company: American Contractors Insurance Company Risk Retention Group NOTICE OF CANCELLATION, NONRENEWAL OR MATERIAL CHANGE - CERTIFICATE HOLDERS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART The certificate of insurance holders shown in the schedule below have requested that they receive written notice of cancellation, nonrenewal or material change with respect to this policy. If we decide to cancel, nonrenew or make a material change to this policy, we agree to mail or deliver sixty(60) days advance written notice to the certificate of insurance holders shown in the schedule below. However, if we are cancelling or nonrenewing due to nonpayment of premium, we will only provide the certificate of insurance holders shown in the schedule below with ten (10) days advance written notice. The notice of cancellation, nonrenewal or material change will be mailed to the addresses provided to us by the certificate of insurance issuer. Proof of mailing will be considered sufficient proof of our good faith attempt to prov de notice of cancellation, nonrenewal or material change to the certificate of insurance holders shown in the schedule below. SCHEDULE All certificate of insurance holders where written notice of cancellation, nonrenewal or material change to this policy is required by written contract, permit or agreement with the Named Insured. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it is attached and is effect ve on the date issued un'ess otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective 6 1 2024 Policy No GL24ABC00046 Insured: SpawGlass C antra_tors In- , SpawGlass Construction Corp SpawGlass Civil Construction. In-, . Westland Equipment and Supplies, LLC Insurance Company Amer can Contractors insurance Company Risk Retention Group AGGREGATE LIMITS OF INSURANCE (PER PROJECT) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART It is hereby understood and agreed the General Aggregate Limit under Section III, Limits of Insurance of the Coverage Form applies separately to each of your projects away from premises owned by or rented to you. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 6/1/2024 Policy No.: GL24ASC00046 Insured: SpawGlass Contractors, Inc , SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies,LLC Insurance Company: American Contractors Insurance Company Risk Retention Group CNASpawGlass Contractors,Inc,SpawGlass Construction Corp, Business Auto Policy SpawGlass Civil Construction,Inc,Westland Equipment and Supplies, LLC ' CONTRACTORS EXTENDED COVERAGE ENDORSEMENT • PLUS THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM I. LIABILITY COVERAGE A. Who Is An Insured The following is added to Section II, Paragraph A.1., Who Is An Insured: 1. a. Any incorporated entity of which the Named Insured owns a majority of the voting stock on the date of inception of this Coverage Form; provided that, b. The insurance afforded by this provision A.1. does not apply to any such entity that is an insured under any other liability "policy" providing auto coverage. 2. Any organization you newly acquire or form, other than a limited liability company, partnership or joint venture, and over which you maintain majority ownership interest. The insurance afforded by this provision A.2.: a. Is effective on the acquisition or formation date, and is afforded only until the end of the policy period of this Coverage Form, or the next anniversary of its inception date, whichever is earlier. b. Does not apply to: (1) Bodily injury or property damage caused by an accident that occurred before you acquired or formed the organization; or (2) Any such organization that is an insured under any other liability "policy" providing auto coverage. 3. Any person or organization that you are required by a written contract to name as an additional insured is an insured but only with respect to their legal liability for acts or omissions of a person, who qualifies as an insured under SECTION II - WHO IS AN INSURED and for whom Liability Coverage is afforded under this policy. If required by written contract, this insurance will be primary and non-contributory to insurance on which the additional insured is a Named Insured. 4. An employee of yours is an insured while operating an auto hired or rented under a contract or agreement in that employee's name, with your permission, while performing duties related to the conduct of your business. "Policy", as used in this provision A. Who Is An Insured, includes those policies that were in force on the inception date of this Coverage Form but: 1. Which are no longer in force; or 2. Whose limits have been exhausted. B. Bail Bonds and Loss of Earnings Section Il, Paragraphs A.2. (2) and A.2. (4) are revised as follows: 1. In a.(2), the limit for the cost of bail bonds is changed from $2,000 to $5,000; and 2. In a.(4), the limit for the loss of earnings is changed from $250 to $500 a day. Form No: CNA63359XX (04 2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date:06'01 2024 Copyright CNA All Rights Reserved. Includes copyrighted material of the CNA Business Auto Policy ?olicy Endorsement C. Fellow Employee Section Il, Paragraph B.5 does not apply. Such coverage as is afforded by this provision C. is excess over any other collectible insurance. II. PHYSICAL DAMAGE COVERAGE A. Glass Breakage - Hitting A Bird Or Animal - Falling Objects Or Missiles The following is added to Section III, Paragraph A.3.: With respect to any covered auto, any deductible shown in the Declarations will not apply to glass breakage if such glass is repaired, in a manner acceptable to us, rather than replaced. B. Transportation Expenses Section III, Paragraph A.4.a. is revised, with respect to transportation expense incurred by you, to provide: a. $60 per day, in lieu of $20; subject to b. $1,800 maximum, in lieu of $600. C. Loss of Use Expenses Section III, Paragraph A.4.b. is revised, with respect to loss of use expenses incurred by you, to provide: a. $1,000 maximum, in lieu of $600. D. Hired "Autos" The following is added to Section III. Paragraph A.: 5. Hired "Autos" If Physical Damage coverage is provided under this policy, and such coverage does not extend to Hired Autos, then Physical Damage coverage is extended to: a. Any covered auto you lease, hire, rent or borrow without a driver; and b. Any covered auto hired or rented by your employee without a driver, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. The most we will pay for any one accident or loss is the actual cash value, cost of repair, cost of replacement or $75,000, whichever is less, minus a $500 deductible for each covered auto. No deductible applies to loss caused by fire or lightning. d. The physical damage coverage as is provided by this provision is equal to the physical damage coverage(s) provided on your owned autos. e. Such physical damage coverage for hired autos will: (1) include loss of use, provided it is the consequence of an accident for which the Named Insured is legally liable, and as a result of which a monetary loss is sustained by the leasing or rental concern. (21 Such coverage as is provided by this provision will be subject to a limit of $750 per accident. E. Airbag Coverage The following is added to Section III, Paragraph 8.3.: The accidental discharge of an airbag shall not be considered mechanical breakdown. Form No: CNA63359XX (04-2012) Policy No-BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date 06;01,-2024 c Copyright CNA All Rights Reserved. Includes copyrighted material of the Business Auto Policy CAVA /� Policy Enda F. Electronic Equipment Section III, Paragraphs B.4.c and 0.4.d. are deleted and replaced by the following: c. Physical Damage Coverage on a covered auto also applies to loss to any permanently installed electronic equipment including its antennas and other accessories d. A $100 per occurrence deductible applies to the coverage provided by this provision. G. Diminution In Value The following is added to Section III, Paragraph B.6.: Subject to the following, the diminution in value exclusion does not apply to: a. Any covered auto of the private passenger type you lease, hire, rent or borrow, without a driver for a period of 30 days or less, while performing duties related to the conduct of your business; and b. Any covered auto of the private passenger type hired or rented by your employee without a driver for a period of 30 days or less, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. Such coverage as is provided by this provision is limited to a diminution in value loss arising directly out of accidental damage and not as a result of the failure to make repairs; faulty or incomplete maintenance or repairs; or the installation of substandard parts. d. The most we will pay for loss to a covered auto in any one accident is the lesser of: (1) $5,000; or (2) 20% of the auto's actual cash value (ACV). Ill. Drive Other Car Coverage — Executive Officers The following is added to Sections II and III: 1. Any auto you don't own, hire or borrow is a covered auto for Liability Coverage while being used by, and for Physical Damage Coverage while in the care, custody or control of, any of your "executive officers", except: a. An auto owned by that "executive officer" or a member of that person's household; or b. An auto used by that "executive officer" while working in a business of selling, servicing, repairing or parking autos. Such Liability and/or Physical Damage Coverage as is afforded by this provision. (1) Equal to the greatest of those coverages afforded any covered auto; and (2) Excess over any other collectible insurance. 2. For purposes of this provision, "executive officer" means a person holding any of the officer positions created by your charter, constitution, by-laws or any other similar governing document, and, while a resident of the same household, includes that person's spouse. Such "executive officers" are insureds while using a covered auto described in this provision. IV. BUSINESS AUTO CONDITIONS A. Duties In The Event Of Accident, Claim, Suit Or Loss The following is added to Section IV, Paragraph A.2.a.: Form No. CNA63359XX (04 2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06'01 2024 Copyr ght CNA All Rights Reserved Includes copyrighted mater al of the CNA Business Auto Policy Policy Endorsement (4) Your employees may know of an accident or loss. This will not mean that you have such knowledge, unless such accident or loss is known to you or if you are not an individual, to any of your executive officers or partners or your insurance manager. The following is added to Section IV, Paragraph A.2.b.: 16) Your employees may know of documents received concerning a claim or suit. This will not mean that you have such knowledge, unless receipt of such documents is known to you or if you are _ -_ to La facutive officers or partners or your insurance manager. 6. Transfer Of Rights Of Recovery Against Others To Us e �saddad-to-SestierrkV—, Par-a�rap A.5. Transfer Of Rights Of Recovery Against Others To Us: We waive any right of recovery we may have, because of payments we make for injury or damage, against any person or organization for whom or which you are required by written contract or agreement to obtain this waiver from us. This injury or damage must arise out of your activities under a contract with that person or organization. You must agree to that requirement prior to an accident or loss. C. Concealment, Misrepresentation or Fraud The following is added to Section IV, Paragraph 8.2.: Your failure to disclose all hazards existing on the date of inception of this Coverage Form shall not -prcjt:rdiue Vots sect to the coverage afforded provided such failure or omission is not intentional. D. he Insurance feHewirngis�V4d to Section IV, Paragraph B.5.: Regardless of the provisions of Paragraphs 5.a. and 5.d. above, the coverage provided by this policy shall be on a primary non-contributory basis. This provision is applicable only when required by a written contract. That written contract must have been entered into prior to Accident or Loss. E. Policy Period, Coverage Territory Section IV, Paragraph B. 7.(5).(a). is revised to provide: a. 45 days of coverage in lieu of 30 days. V. DEFINITIONS Section V. paragraph C. is deleted and replaced by the following: Bodily injury means bodily injury, sickness or disease sustained by a person, including mental anguish, mental injury or death resulting from any of these. Form No: CNA63359XX (04 2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06101,-2024 Copyrght CNA All Rights Reserved Includes copyrighted material of the SHA Business Auto Policy Policy Endorsement ' NOTICE OF • TO CERTIFICATEHOLIDERS It is understood and agreed that: If you have agreed under written contract to provide notice of cancellation to a party to whom the Agent of Record has issued a Certificate of Insurance, and if we cancel a policy term described on that Certificate of Insurance for any reason other than nonpayment of premium, then notice of cancellation will be provided to such Certificateholders at least 30 days in advance of the date cancellation is effective. If nonce is mailed, then proof of mailing to the last known mailing address of the Certificateholder on file with the Agent of Record will be sufficient to prove notice. Any failure by us to notify such persons or organizations will not extend or invalidate such cancellation, or impose any liability or obligation upon us or the Agent of Record. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date ithe Endorsement Effective Date) is shown below, and expires concurrently with said policy. SpawGlass Contractors,Inc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,LLC Form No: CNA68021 XX 102 20131 Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06:01:2024 Copyright CNA All Rights Reserved. CNA Business Auto Policy they Endorsement MU101TIONAL INSURED - PRIMARY AND NON-CONTRIBUTORY It is understood and agreed that this endorsement amends the BUSINESS AUTO COVERAGE FORM as follows: SCHEDULE Name of Additional Insured Person Or Organization ANY PERSON OR ORGANIZATION THAT YOU ARE REQUIRED BY WRITTEN CONTRACT OR WRITTEN AGREEMENT TO NAME AS AN ADDITIONAL INSURED 1. In conformance with paragraph A.1.c. of Who Is An Insured of Section II LIABILITY COVERAGE, the person or organization scheduled above is an insured under this policy. 2. The insurance afforded to the additional insured under this policy will apply on a primary and non-contributory basis if you have committed it to be so in a written contract or written agreement executed prior to the date of the "accident" for which the additional insured seeks coverage under this policy. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy. Form No: CNA71527XX (10 2012) Policy No BUA 7033775696 Underwriting Company: Valley Forge Insurance Company Policy Effective Date:06!01!2024 Insured:SpawGlass Contractors,Inc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,LLC 0 Copyright CNA All Rights Reserved. TEXAS WORKERS COMPENSATION AND EMPLOYERS LIABILITY POLICY WC 99 03 04 — (Ed. 04-07) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT This endorsement apples only to the insurance prov ded by the policy because Texas .s shown in Item 3.A. of the Information Page We have the right to recover our payments from anyane fable for an injury covered by this policy We will not enforce our right against the person or organization named in the Schedule,but this waiver applies only with respect to bodily injury arising out of the operations described •n the Schedule where you are requ red by a written contract to obtain this waiver. This waiver does not extend to the statutory right of reimbursement from a claimant who recovers any amount under Section 417.002 of the Texas Labor Code. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule The premium for this endorsement is shown in the Schedule Schedule 1. ( ) Specific Waiver Name of person organization ( X ) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. This waiver does not extend to the statutory right of reimbursement under Section 417.002 of the Texas Labor Code. 2 Operations CONSTRUCTION AND RELATED CONSTRUCTION RELATED WORK ALL TEXAS OPERAT-ONS 3 Premium. The premium charge of this endorsement shall be 2 percent of the premium developed on payroll in connection with work performed for the above person(s)or organization(s)arising out of the operations described 4 Minimum Premium $0 5. Advance Premium $fl This endorsement changes the policy to which t is attached and s effe:;tive on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective Same as Policy Effective Date unless otherwise indicated above. Policy Effective Date 6,11'2024 Policy No WCA000008324 Insured SpawGlass Contractors, Inc. SpawGlass Construct on Corp , SpawGlass C vil Construction, Inc., Westland Equipment and Supplies, LLC Carrier Name Code ACIG Insurance Company WC 99 03 04 (Ed. 04-07) WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 42 06 01 (Ed. 03 13) TEXAS NOTICE OF MATERIAL CHANGE ENDORSEMENT This endorsement applies only to the insurance provided by the po'icy because Texas is shown in Item 3.A. of the Information Page. In the event of cancelation or other material change of the policy, we will mail advance notice to the person or organization named in the Schedule. The number of days advance notice is shown in the Schedule This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule Schedule 1 . Number of days advance notice: 60 days. However, in the case of cancellation or nonrenewal due to nonpayment of t.-emium, only 10 days advance notice will be provided. 2. Notice will be mailed to: All certificate holders where written notice of -ancellation, nonrenewal or material change to this policy is required by written contLact, permit ,)r agreement with the Named Insured. The notice will be mailed to the addresses provided to us by the certificate of insurance issuer . Proof of mailing will be considered sufficient proof of our good faith attempt to provide written notice. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated (The Information below Is required only when this endorsement Is Issued subsequent to preparation of the policy.) Endorsement Effective 06/01/2 _4 Policy No. WCA000008324 Insured SpawGlass Contractors,Inc. , SpawGlass Construction Corp. , Premium$ spawGlasz Civil Construction, Inc. , Westland Equipment and Supplies, LLC Insurance Company A,-IG Insurance Company WC 42 06 01 Wolters Kluwer Financial Services I Uniform Forms Page 1 of 1 (Ed. 03-13) TAI COMMERCIAL INLAND MARINt THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET LOSS PAYEES This endorsement modifies insurance provided under the COMMERCIAL INLAND MARINE COVERAGE PART The following is added to Section E — ADDITIONAL b. Pay any claim for loss or damage jointly to yo, COVERAGE CONDITIONS: and the Loss Payee as y your interests may Loss Payable Provision appear In the event of a Covered Cause of Loss to Covered This endorsement applies to all Covered Property for Property in which both you and a Loss Payee share an insurable interest, we will: which a Loss Payee is on file with us or your insurance agent or insurance broker a. Adjust the loss or damage with you, and SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Traveters Property 8 Casualty Co. Policy No OT-630-7625835-0-TLC-24 CM U6 18 05 21 2021 1 he Travelers Indemnify Company Page 1 of t Includes copyrighted materia of Insurance Services Office Inc with its permission