The URL can be used to link to this page

Contract - SpawGlass Contractors, Inc. - 4/24/2025 >> R Document A1 33 - 2019 Exhibit A Guaranteed Maximum Price Amendment This Amendment dated the day of in the year,is incorporated into the accompanying AIA Document A 133T"*1-2019,Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Plus a Fee with a Guaranteed Maximum Price dated the day of in the year(the ADDITIONS AND DELETIONS: "Agreement") The author of this document may (In words, indicate dav, month,and year.) have revised the text of the original AIA standard form An Additions for the following PROJECT: and Deletions Report that notes Name and address or location) revisions to the standard form text is available from the author and should be reviewed.A vertical line Old Settlers Park Buildout-Package 3B-Maintenance Facility in the left margin of this document 3300 E.Palm Valley Blvd indicates where the author has Round Rock,TX 78665 added to or deleted from the original AIA text. THE OWNER: This document has important legal (Name, legal status, and address) consequences.Consultation with an attorney is encouraged with City of Round Rock respect to its completion or 221 East Main St. modification. Round Rock,TX 78644 AIA Document A201""-2017, THE CONSTRUCTION MANAGER: General Conditions of the Contract (Name, legal status, and address) for Construction,is adopted in this document by reference.Do not use SpawGlass Contractors,Inc. with other general conditions 1111 Smith Road unless this document is modified. Austin.TX 78721 TABLE OF ARTICLES A.1 GUARANTEED MAXIMUM PRICE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION A.3 INFORMATION UPON WHICH AMENDMENT IS BASED A.4 CONSTRUCTION MANAGER'S CONSULTANTS, CONTRACTORS, DESIGN PROFESSIONALS,AND SUPPLIERS ARTICLE A.1 GUARANTEED MAXIMUM PRICE §A.1.1 Guaranteed Maximum Price Pursuant to Section 3.2.6 of the Agreement,the Owner and Construction Manager hereby amend the Agreement to establish a Guaranteed Maximum Price.As agreed by the Owner and Construction Manager,the Guaranteed Maximum Price is an amount that the Contract Sum shall not exceed.The Contract Sum consists of the Construction Manager's Fee plus the Cost of the Work,as that term is defined in Article 6 of the Agreement. §A.1.1.1 The Contract Sum is guaranteed by the Construction Manager not to exceed Two Million One Hundred and Eighty-One Thousand Six Hundred Twenty Dollars and Zero Cents(S 2,181,620.00),subject to additions and deductions by Change Order AIA Document A133—2019 Exhibit A.Copyright©1991,2003,2009,and 2019.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 14:58:32 CDT on 03/12/2025 under Subscription No.20240040942 which expires on 07/05/2025,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documentsa Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (67ca10aac72d8d8f5efb3f94) as provided in the Contract Documents. §A.1.1.2 Itemized Statement of the Guaranteed Maximum Price. Provided below is an itemized statement of the Guaranteed Maximum Price organized by trade categories,including allowances;the Construction Manager's contingency;alternates; the Construction Manager's Fee;and other items that comprise the Guaranteed Maximum Price as defined in Section 3.2.1 of the Agreement. (Provide itemized statement below or reference an attachment.) Reference attached GMP Package-Tab 06 §A.1.1.3 The Construction Manager's Fee is set forth in Section 6.1.2 of the Agreement. §A.1.1.4 The method of adjustment of the Construction Manager's Fee for changes in the Work is set forth in Section 6.1.3 of the Agreement. §A.1.1.5 Alternates §A.1.1.5.1 Alternates,if any,included in the Guaranteed Maximum Price: Item Price §A.1.1.5.2 Subject to the conditions noted below,the following alternates may be accepted by the Owner following execution of this Exhibit A.Upon acceptance,the Owner shall issue a Modification to the Agreement. (Insert below each alternate and the conditions that must be met for the Owner to accept the alternate) Item Price Conditions for Acceptance §A.1.1.6 Unit prices,if any: (Identify the item and state the unit price and quantity limitations, if any, to which the unit price will be applicable.) Item Units and Limitations Price per Unit($0.00) ARTICLE A.2 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION §A.2.1 The date of commencement of the Work shall be: (Check one of the following boxes.) [ ] The date of execution of this Amendment. [X] Established as follows: (Insert a date or a means to determine the date of commencement of the Work.) May 8,2025 If a date of commencement of the Work is not selected,then the date of commencement shall be the date of execution of this Amendment. §A.2.2 Unless otherwise provided,the Contract Time is the period of time,including authorized adjustments,allotted in the Contract Documents for Substantial Completion of the Work.The Contract Time shall be measured from the date of commencement of the Work. §A.2.3 Substantial Completion §A.2.3.1 Subject to adjustments of the Contract Time as provided in the Contract Documents,the Construction Manager shall achieve Substantial Completion of the entire Work: (Check one of the following boxes and complete the necessary information.) [ ] Not later than()calendar days from the date of commencement of the Work. AIA Document A133—2019 Exhibit A.Copyright©1991,2003,2009,and 2019.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 14:58:32 2 CDT on 03/12/2025 under Subscription No.20240040942 which expires on 07/05/2025,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents"Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (67ca10aac72d8d8f5efb3f94) [X] By the following date:November 24,2025 §A.2.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents,if portions of the Work are to be completed prior to Substantial Completion of the entire Work,the Construction Manager shall achieve Substantial Completion of such portions by the following dates: Portion of Work Substantial Completion Date §A.2.3.3 If the Construction Manager fails to achieve Substantial Completion as provided in this Section A.2.3,liquidated damages,if any,shall be assessed as set forth in Section 6.1.6 of the Agreement. ARTICLE A.3 INFORMATION UPON WHICH AMENDMENT IS BASED §A.3.1 The Guaranteed Maximum Price and Contract Time set forth in this Amendment are based on the Contract Documents and the following: §A.3.1.1 The following Supplementary and other Conditions of the Contract: Document Tale Date Pages §A.3.1.2 The following Specifications: (Either list the Specifications here, or refer to an exhibit attached to this Amendment.) Old Settler's Park Buildout—Maintenance Facility 100%Construction Documents Technical Specifications issued December 2024 Geotechnical Engineering Report for Proposed Old Settlers Park Expansion Maintenance Yard as issued by UeS Profession Solutions 45,LLC on December 20,2024 Section Title Date Pages §A.3.1.3 The following Drawings: (Either list the Drawings here, or refer to an exhibit attached to this Amendment.) Old Settlers Park Improvements-Maintenance Facility 100%Construction Documents issued December 2024 Number Title Date §A.3.1.4 The Sustainability Plan,if any: (If the Owner identified a Sustainable Objective in the Owner's Criteria, identify the document or documents that comprise the Sustainability Plan by title, date and number ofpages, and include other identijying information. The Sustainability Plan identifies and describes the Sustainable Objective; the targeted Sustainable Measures; implementation strategies selected to achieve the Sustainable Measures;the Owner's and Construction Manager's roles and responsibilities associated with achieving the Sustainable Measures;the specific details about design reviews, testing or metrics to verify achievement of each Sustainable Measure;and the Sustainability Documentation required for the Project, as those terms are defined in Exhibit C to the Agreement.) Title Date Pages Other identifying information: §A.3.1.5 Allowances,if any,included in the Guaranteed Maximum Price: (Identify each allowance.) Item Price AIA Document A133—2019 Exhibit A.Copyright @ 1991,2003,2009,and 2019.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 14:58:32 3 CDT on 03/12/2025 under Subscription No.20240040942 which expires on 07/05/2025,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documentse Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (67ca10aac72d8d8f5efb3f94) §A.3.1.6 Assumptions and clarifications,if any,upon which the Guaranteed Maximum Price is based: (Idents each assumption and clarification) Reference attached GMP Package-Tab 05 §A.3.1.7 The Guaranteed Maximum Price is based upon the following other documents and information: (List any other documents or information here, or refer to an exhibit attached to this Amendment.) ARTICLE A.4 CONSTRUCTION MANAGER'S CONSULTANTS, CONTRACTORS, DESIGN PROFESSIONALS, AND SUPPLIERS §A.4.1 The Construction Manager shall retain the consultants,contractors,design professionals,and suppliers,identified below: (List name,discipline, address, and other information) This Amendment to the Agreement entered into as of the day and year first written above. OWNER(Signatu e) fRUCPbN MANAGER(Signature) BY: Craig Morgan,Mayor V BY:David Paden,Austin Division President (Printed name and title) (Printed name and title) AIA Document A133—2019 Exhibit A.Copyright©1991,2003,2009,and 2019.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 14:58:32 4 CDT on 03/12/2025 under Subscription No.20240040942 which expires on 07/05/2025,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (67ca10aac72d8d8f5efb3f94) CHUBS surety o + 908.903.3485 202B Halls Mill Road,PO Box 1650 F +908.903.3656 Whitehouse Station.N108889-1650 Federal Insurance Company Liberty Mutual Insurance Company AIA Document A312 Performance Bond K42017115(Federal) 58S218546(Liberty Mutual) Any singular reference to Contractor,Surety,Owner or other party shall be considered plural where applicable. CONTRACTOR(Name and Address): SURETY(Name and Principal Place of Business): SpawGlass Contractors, Inc. Federal Insurance Company(IN) I 1 I I Smith Road Liberty Mutual Insurance Company(MA) Austin, Texas 78721 OWNER(Name and Address): City of Round Rock, TX 221 East Main Street Round Rock, TX 78664 CONSTRUCTION CONTRACT Date: 4th day of March,2025 Amount:$2,181,620.00 Two Million One Hundred Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Description (Name and Location): City of Round Rock—Old Settler's Park Build Out-Package 3B—Maintenance Yard BOND Date(Not earlier than Construction Contract Date): 5th day of March,2025 AMOUNT: $2,181,620.00 Two Million On �i p�red Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Modifications to this Bond: ��.%tONpjite.,i�, ® None 13 See Page 3 otipoR•q�.,�% CONTRACTORS AS Ft PRINCIPAL Company: �iorp e •O_ SURETY SpawGlass Contractors,Inc.. — 55 :;7_ Company: (Corporate Seal) �•;�� Federal Insuran Com n �✓ 6'••'•F X P '��`� Liberty Mut Insur c ny Signatur � • . �� Signature: _--_ Name an avi aden t t t t t Name and Titl Joh A.Pn fte sident -Austin Region Attorney-in-Fact (Any additional signatures appear on page 3) (FOR INFORMATIOA'ONL I'-- Name,Address and Telephone) AGENT or BROKER: Adams Risk Management Services,LLC OWNER'S REPRESENTATIVE(Architect,Engineer or other pal)): 1111 N Loop West Ste.600 Houston,TX 77008 713-869-8346 Printed in cooperation with the American Institute of Architects(AIA)b1•Chubb. The language in this document conforms exactly to the language used in AIA Document A312 December 1984 edition, Third Printing.Mach 1987. Fom 15-02-0279-FED(Re 11/16) A312-1984 1 I The Contractor and the Surety, jointly and severally, performance and payment bonds executed by a bind themselves, their heirs, executors, administrators, qualified surety equivalent to the bonds issued on the successors and assigns to the Owner for the performance of Construction Contract,and pay to the Owner the amount the Construction Contract,which is incorporated herein by of damages as described in Paragraph 6 in excess of the reference. Balance of the Contract Price incurred by the Owner 2 If the Contractor performs the Construction Contract, resulting from the Contractor's default;or the Surety and the Contractor shall have no obligation under 4.4 Waive its right to perform and complete, arrange this Bond,except to participate in conferences as provided for completion, or obtain a new contractor and with in Sub-paragraph 3.1. reasonable promptness under the circumstances: 3 If there is no Owner Default, the Surety's obligation .1 After investigation,determine the amount for under this Bond shall arise after: which it may be liable to the Owner and,as soon 3.1 The Owner has notified the Contractor and the as practicable after the amount is determined, Surety at its address described in Paragraph 10 below tender payment therefor to the Owner;or that the Owner is considering declaring a Contractor .2 Deny liability in whole or in part and notify the Default and has requested and attempted to arrange a Owner citing reasons therefor. conference with the Contractor and the Surety to be held 5 If the Surety does not proceed as provided in Paragraph not later than fifteen days after receipt of such notice 4 with reasonable promptness,the Surety shall be deemed to discuss methods of performing the Construction to be in default on this Bond fifteen days after receipt of Contract. If the Owner,the Contractor and the Surety an additional written notice from the Owner to the Surety agree, the Contractor shall be allowed a reasonable demanding that the Surety perform its obligations under this time to perform the Construction Contract, but such Bond,and the Owner shall be entitled to enforce any remedy an agreement shall not waive the Owner's right,if any, available to the Owner.If the Surety proceeds as provided subsequently to declare a Contractor Default;and in Subparagraph 4.4, and the Owner refuses the payment 3.2 The Owner has declared a Contractor Default and tendered or the Surety has denied liability, in whole or in formally terminated the Contractor's right to complete part, without further notice the Owner shall be entitled to the contract. Such Contractor Default shall not be enforce any remedy available to the Owner. declared earlier than twenty days after the Contractor 6 After the Owner has terminated the Contractor's right and the Surety have received notice as provided in to complete the Construction Contract, and if the Surety Subparagraph 3.1;and elects to act under Subparagraph 4.1, 4.2, or 4.3 above, 3.3 The Owner has agreed to pay the Balance of the then the responsibilities of the Surety to the Owner shall Contract Price to the Surety in accordance with the terms not be greater than those of the Contractor under the of the Construction Contract or to a contractor selected Construction Contract,and the responsibilities of the Owner to perform the Construction Contract in accordance with to the Surety shall not be greater than those of the Owner the terms of the contract with the Owner. under the Construction Contract. To the limit of the amount 4 When the Owner has satisfied the conditions of of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs Paragraph 3, the Surety shall promptly and at the Surety's and damages on the Construction Contract, the Surety is expense take one of the following actions: obligated without duplication for: 4.1 Arrange for the Contractor, with consent of the 6.1 The responsibilities of the Contractor for correction Owner, to perform and complete the Construction of defective work and completion of the Construction Contract;or Contract; 4.2 Undertake to perform and complete the 6.2 Additionallegal,design professional and delay costs Construction Contract itself, through its agents or resulting from the Contractor's Default, and resulting through independent contractors;or from the actions or failure to act of the Surety under 4.3 Obtain bids or negotiated proposals from qualified Paragraph 4;and contractors acceptable to the Owner for a contract 6.3 Liquidated damages,or if no liquidated damages are for performance and completion of the Construction specified Contract, arrange for a contract to be prepared for fied in the Construction Contract,actual damages execution by the Owner and the contractor selected caused by delayed performance or non-performance of with the Owner's concurrence, to be secured with the Contractor. Printed in cooperation with the American Institute of Architects(AIA)by Chubb.The language in this document conforms exactly to the language used in AIA Document A312 December 1984 edition,Third Printing,March 1987. Form 15-02-0279-FED(Rev.11/16) A312-19842 7 The Surety shall not be liable to the Owner or others be deemed deleted herefrom and provisions conforming to for obligations of the Contractor that are unrelated to the such statutory or other legal requirement shall be deemed Construction Contract, and the Balance of the Contract incorporated herein. The intent is that this Bond shall be Price shall not be reduced or set off on account of any such construed as a statutory bond and not as a common law bond. unrelated obligations. No right of action shall accrue on this 12 DEFINITIONS Bond to any person or entity other than the Owner or its heirs,executors,administrators or successors. 12.1 Balance of the Contract Price:The total amount 8 The surety hereby waives notice of any change,including payable by the Owner to the Contractor under the changes of time,to the Construction Contract or to related Construction Contract after all proper adjustments have subcontractors,purchase orders and other obligations. been made, including allowance to the Contractor of any amounts received or to be received by the owner in 9 Any proceeding,legal or equitable,under this Bond may settlement of insurance or other claims for damages to be instituted in any court of competent jurisdiction in the which the Contractor is entitled,reduced by all valid and location in which the work or part of the work is located and proper payments made to or on behalf of the Contractor shall be instituted within two years after Contractor Default under the Construction Contract. or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform 12.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature its obligations under this Bond,whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, Page, including all Contract Documents and changes thereto. the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to 10 Notice to the Surety,the Owner or the Contractor shall perform or otherwise to comply with the terms of the be mailed or delivered to the address shown on the signature Construction Contract. page. 12.4 Owner Default: Failure of the Owner,which has 11 When this Bond has been furnished to comply with a neither been remedied nor waived,to pay the Contractor statutory or other legal requirement in the location where as required by the Construction Contract or to perform the construction was to be performed,any provision in this and complete or comply with the other terms thereof. Bond conflicting with said statutory or legal requirement shall MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (CorporateSeal) Federal Insurance Company Signature: Signature: Name and Title: Name and Title: Address: Address: Printed in cooperation with the American Institute of Architects(AIA)by Chubb.The language in this document conforms exactly to the language used in AIA Document A312 December 1984 edition,Third Printing,March 1987. Form 15-020279-FED(Rev.11116) A312-19843 CHUBB Power of Attorney Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know All by These Presents,that FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY,a New York corporation,PACIFIC INDEMNITY COMPANY,a Wisconsin corporation,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations of the Commonwealth of Pennsylvania, do each hereby constitute and appoint Andrew A.Adams,Norman E.Adams,Michael Macomber,John A.Prince and Larry D.Snider of Houston,Texas---- each as their true and lawful Attorney-in-Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed in the course of business,and any instruments amending or altering the same,and consents to the modification or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have each executed and attested these presents and affixed their corporate seals on this 10th day of April 2024. C--Z -&j:Z> Rupert HD Swindeft Assistant Secretary Warren Eich hmt.l ice President CONDO *00wo STATE OF NEW JERSEY County of Hunterdon Ss. On this IOm day ofApril,2024 before me,a Notary Public of New Jersey,personally came Rupert HD Swindells and Warren Eichhorn,to me known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Rupert HD Swindells and Warren Eichhorn,being by me duly sworn, severally and each for himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of said Companies;and that their signatures as such officers were duly affixed and subscribed by like authority. Notarial Seal Alban Curaurid NOTARY PUBLIC OF NEW JERSEY OF �TMr No SA2DYii9 'ttetW Carmdmion Expires August 22,2027 Mearp fxxblte CERTIFICATION Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016; WESTCHESTER FIRE INSURANCE COMPANY on December 11,2006;and ACE AMERICAN INSURANCE COMPANY on March 20,2009: `RESOLVED,that the following authorizations relate to the execution,for and on behalf of the Company,of bonds,undertakings,recognizances,contracts and other written commitments of the Company entered Into in the ordinary course of business(each a"Written Commitment"): (1) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized to execute any Written Commitment for and on behalf of the Company,under the seal of the Company or otherwise. (2) Each duly appointed attorney-in-fact of the Company Is hereby authorized to execute any Written Commitment for and on behalf of the Company,under the seat of the Company or otherwise, to the extent that such action is authorized by the grant of powers provided for In such person's written appointment as such attorney-in-fact (3) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalf of the Company,to appoint in writing any person the attorney-in- fact of the Company with full power and authority to execute,for and on behalfofthe Company,under the seal ofthe Company or otherwise,such Written Commitments ofthe Company as may be specified in such written appointment,which specification may be by general type or class of Written Commitments or by specification of one or more particular Written Commitments. (4) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalf of the Company,to delegate in writing to any other officer of the Company the authority to execute,for and on behalf of the Company,under the Company's seal or otherwise,such Written Commitments of the Company as are specified In such written delegation,which specification may be by general type or class of Written Commitments or by specification of one or more particular Written Commitments. (5) The signature of any officer or other person executing any Written Commitment or appointment or delegation pursuant to this Resolution,and the seal of the Company,may be affixed by facsimile on such Written Commitment or written appointment or delegation. FURTHER RESOLVED,that the foregoing Resolution shall not be deemed to be an exclusive statement of the powers and authority of officers,employees and other persons to act for and on behalf of the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or authority otherwise validly granted or vested' 1,Rupert HD Swindells,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the"Companies)do hereby certify that (i) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and in full force and effect, (it) the foregoing Power of Attorney is true,correct and in full force and effect Given under my hand and seals of said Companies at Whitehouse Station,NJ,this 5th day of March, 2025 Rupert HD Sm indells,Assistant Secretary GO 10(o a IN THE EVENT YOU WISH TO VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER PLEASE CONTACT US AT: Telephone(908)903-3493 Fax(908)903-3656 e-mail:surety@chubb.com Combined:FED-%AG-PI-WFIC-AAIC(rev.11-19) This Power of Attorney limits the acts of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Liberty Mutual Insurance Company Mutual® The Ohio Casualty Insurance Company Certificate No 8205857-974105 10 West American Insurance Company SURETY POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire,that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts,and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana(herein collectively called the"Companies"),pursuant to and by authority herein set forth,does hereby name,constitute and appoint, Andrew A. Adams;John A.Prince;Larry D.Snider;Michael Macomber;Norman E.Adams all of the city of Houston state of TX each individually if there be more than one named,its true and lawful attomey-in-fact to make, execute,seal,acknowledge and deliver,for and on its behalf as surety and as its act and deed,any and all undertakings,bonds,recognizances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 28th day of June 2021 Liberty Mutual Insurance Company P�1NSu P01 INS& a \NSUo The Ohio Casualty Insurance Company AJ `oaPorl, ►C1 yJ 4°aro�yT�y vP 4oavORyr 4� West American Insurance Company lu 1912 0 0 1919 0 1991 0 O i W O Q O � Yp�'�s�CNUg�•Aa ��/AMPe'�as YS �NDIAN� tea; � � C�i' '�_ U David M.Carey,Assistant Secretary :3 c t`p State of PENNSYLVANIA ss :3 :3County of MONTGOMERY E 0 .� :43) On this 28th day of June 2021 before me personally appeared David M.Carey,who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance o Iffi Company,The Ohio Casualty Company,and West American Insurance Company,and that he,as such,being authorized so to do,execute the foregoing instrument for the purposes 4)> therein contained by signing on behalf of the corporations by himself as a duty authorized officer. IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at King of Prussia,Pennsylvania,on the day and year first above written. Cc P 0 0 0 6 AS d= onw TF! Commonwealth of Pennsylvania-Notary Seal Teresa Pastelle,Notary Pudic N•� wM- y County E O r OF My commission expires March 28,2025 B O 0)T �� comn"ssiDn number 11260" y eresa Pastella,Notary Public Q `o Member,Pennsyl am Association d Notaries to �T p O ARy `N 'to)_d) This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual 3 ao EG Insurance Company,and West American Insurance Company which resolutions are now in full force and effect reading as follows: 0 CL 00 d ARTICLE IV-OFFICERS:Section 12.Power of Attomey. o w Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the;6o President may prescribe,shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety R > C: any and all undertakings,bonds,recognizances and other surety obligations.Such attomeys-in-fact,subject to the limitations set forth in their respective powers of attomey,shall c u o t have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation.When so executed, such 0 y Z U instruments shall be as binding as if signed by the President and attested to by the Secretary.Any power or authority granted to any representative or attomey-in-fact under the M provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer or officers granting such power or authority. ti— ARTICLE XIII-Execution of Contracts:Section 5.Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings, bonds,recognizances and other surety obligations.Such attomeys-in-fact subject to the limitations set forth in their respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company.When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation-The President of the Company,acting pursuant to the Bylaws of the Company,authorizes David M.Carey,Assistant Secretary to appoint such attomeys-in- fact as may be necessary to act on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations. Authorization-By unanimous consent of the Company's Board of Directors,the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds,shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C.Llewellyn,the undersigned,Assistant Secretary,The Ohio Casualty Insurance Company,Liberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full,true and correct copy of the Power of Attorney executed by said Companies,is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this 5th day of March 2025 P�\NStu P�1*1 INS& d \NSU AJ c°aP 4°arog4T� VPcoav°pql LCA J ct "b to A. Fo m + 1912 O = 1919 W o Q 1991 2C' N�stvs�aa� rut+ 'MAW' aa! By.Renee C.Llewellyn,Assistant Secretary LMS-12873 LMIC OCIC WAIC Multi Co 02121 C H U B B Surety O + 908.903.3485 202B Halls Mill Road,PO Box 1650 F +908.903.3656 Whitehouse Station,NJ 08889-1650 Federal Insurance Company Liberty Mutual Insurance Company AIA Document A312 TM- 2010 Payment Bond K42017115(Federal) 58S218546(1iberty Mutual) Any singular reference to Contractor,Surety,Owner or other party shall be considered plural where applicable. CONTRACTOR SURETY (Name, legal status and address): (Name, legal status and principal place of business): SpawGlass Contractors,Inc. Federal Insurance Company(IN) 1111 Smith Road Austin,Texas 78721 Liberty Mutual Insurance Company(MA) OWNER (Name, legal status and address): City of Round Rock,TX 221 East Main Street Round Rock,TX 78664 CONSTRUCTION CONTRACT Date: 4th day of March,2025 Amount: $2,181,620.00 Two Million One Hundred Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Description(Name and Location): City of Round Rock—Old Settler's Park Build Out-Package 3B—Maintenance Yard BOND Date(Not earlier than Construction Contract Date): 5h day of March,2025 Amount: $2,181,620.00 Two Million One Hundred Eighty One Thousand Six Hundred Twenty& 00/100 Dollars Modifications to this Bond: ```,%iOI fill '��i El None ❑ Sec Page 4 CONTRACTORS AS PRINCIPAL C :G � SURETY 00 Company: SpawGlass s, op, Company:Company: p rty (Corporate Seat) (((��"• —�'1 — Federal Insura a Compa S3 ,' Mutual Ins ce Com Signatu, ,�Cq Name a e: D Paden "' 61.��""' Signat re: President -Austin Region��//*1 t t��``` Attorney-in�ctNamT John A.Prince Signed and Sealed this 5th day of March, 2025 (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONL)'—-Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE(Architect.Engoweror otherparty) Adams Risk Management Services,LLC 1111 N Loop West Ste.600 Houston,TX T7oo8 713-869-8346 Printed in cooperation ivith the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A311"/-1010. Fo m l5-02-0574-FED(Rev 11/16) 1 L The Contractor and the Surety,jointly and severally,bind themselves,their heirs,executors,administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. 2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. 3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13)of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. 4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. 5. The Surety's obligations to a Claimant under this Bond shall arise after the following: 51 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). 52 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety (at the address described in Section 13). 6. if a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section S.I.I. 7. When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: 71 Send an answer to the Claimant, with a copy to the Owner,within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and 72 Pay or arrange for payment of any undisputed amounts. 73 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing the Claimant. 8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 9. Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any,under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 TM-2010. Form 15-02-0574-FED(Rev.11/16) Z 10. The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligations to make payments to,or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. 1L The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. V- No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs. If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 13. Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. it When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 15. Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. 16. DEFINITIONS 161 Claim.A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .tithe total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and, .8the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. 162 Claimant:An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials,or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water,gas power, light, heat, oil gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 TM'-2010. Farm 15-02-0574 FED(Rev.II/16) 3 and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 163 Construction Contract: The agreement between the Owner and the Contractor identified on the cover page,including all Contract Documents and all changes made to the agreement and the Contract Documents. 16A Owner Default:Failure of the Owner,which has neither been remedied nor waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 165 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. f1. If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. IS. MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: 18.1 "Claim notices for FEDERAL INSURANCE COMPANY must be sent to the following address: Chubb,PO Box 2191, Chesapeake,Virginia 23327,Attention:Surety Support Team." (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Federal Insurance Company Signature: Signature: Name and Title: Name and Title: Address: Address: Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in AIA Document A312 Tm-2010. Form I5-02-0574-FED(Rm Ili 16) 4 CHUBB Power of Attorney Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company Westchester Fire Insurance Company I ACE American Insurance Company Know AH by These Presents,that FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY,a New York corporation,PACIFIC INDEMNITY COMPANY,a Wisconsin corporation,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY corporations of the Commonwealth of Pennsylvania, do each hereby constitute and appoint Andrew A.Adams,Norman E.Adams,Michael Macomber,John A.Prince and Larry D.Snider of Houston,Texas---- each as their true and lawful Attorney-in-Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed in the course of business,and any instruments amending or altering the same,and consents to the modification or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY have each executed and attested these presents and affixed their corporate seals on this IOW day of Apr112024. `�GCZ� �S7 OU�wj We>,s.iw. Rupert HD Swindells,Assistant Secretary Warrtn Eich hrrn.Vice Prmdenl *0000 0 STATE OF NEW JERSEY County of Hunterdon Ss. On this IOm day of April,2024 before me,a Notary Public of New Jersey,personally came Rupert HD Swindells and Warren Eichhorn,to me known to be Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY,the companies which executed the foregoing Power of Attorney,and the said Rupert HD Swindells and Warren Eichhorn,being by me duly sworn, severally and each for himself did depose and say that they are Assistant Secretary and Vice President,respectively,of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY and know the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of said Companies;and that their signatures as such officers were duly affixed and subscribed by like authority. Notarial Seal Albert CANNuti NOTARY PLOKK OF NEW JERSEY No 50202969 1+euW Lanwnlssion EWk"Asquat 22,2027 Notary Public CERTIFICATION Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016; WESTCHESTER FIRE INSURANCE COMPANY on December 11,2006;and ACE AMERICAN INSURANCE COMPANY on March 20,2009: 'RESOLVED,that the following authorizations relate to the execution,for and on behalf of the Company,of bonds,undertakings,recognizances,contracts and other written commitments of the Company entered Into in the ordinary course of business(each a"Written Commitment"): (S) Each of the Chairman,the President and the Vice Presidents of the Company Is hereby authorized to execute any Written Commitment for and on behalf of the Company,under the seal of the Company or otherwise. (2) Each duly appointed attorney-In-fact of the Company is hereby authorized to execute any Written Commitment for and on behalf of the Company,under the seal of the Company or otherwise, to the extent that such action Is authorized by the grant of powers provided for in such person's written appointment as such attorney-in-fact (3) Each of the Chairman,the President and the Vice Presidents of the Company Is hereby authorized,for and on behalf of the Company,to appoint in writing any person the attorney-in- fact of the Company with full power and authority to execute,for and on behalf of the Company,under the seal of the Company or otherwise,such Written Commitments of the Company as may be specified in such written appointment,which specification may be by general type or class of Written Commitments or by specification of one or more particular Written Commitments. (4) Each of the Chairman, the President and the Vice Presidents of the Company Is hereby authorized,for and on behalf of the Company,to delegate in writing to any other officer of the Company the authority to execute,for and on behalf of the Company,under the Company's seal or otherwise,such Written Commitments of the Company as are specified in such written delegation,which specification may be by general type or class of Written Commitments or by specification of one or more particular Written Commitments. (5) The signature of any officer or other person executing any Written Commitment or appointment or delegation pursuant to this Resolution,and the seal of the Company,may be affixed by facsimile on such Written Commitment or written appointment or delegation. FURTHER RESOLVED,that the foregoing Resolution shall not be deemed to be an exclusive statement of the powers and authority of officers,employees and other persons to act for and on behalf of the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or authority otherwise validly granted or vested' 1,Rupert HD Swindells,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,PACIFIC INDEMNITY COMPANY,WESTCHESTER FIRE INSURANCE COMPANY and ACE AMERICAN INSURANCE COMPANY(the"Companies")do hereby certify that (i) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and in full force and effect, (ii) the foregoing Power of Attorney is true,correct and in full force and effect. Given under my hand and seals of said Companies at Whitehouse Station,NJ,this 5th day of March, 2025 - , - 4W... . QDRupert H D St1-ioddls.Assismcr Secetm y __7 IN THE EVENT YOU WISH TO VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER PLEASE CONTACT US AT: Telephone(908)903-3493 Fax(908)903-3656 e-mail:surety@chubb.com Combined:FED-VIGPI-WFIC-AAIC(rev.11-19) This Power of Attorney limits the acts of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Liberty Mutual Insurance Company Mutual. The Ohio Casualty Insurance Company Certificate No:8205857.974105 SURETY West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire,that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts,and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana(herein collectively called the"Companies"),pursuant to and by authority herein set forth,does hereby name,constitute and appoint, Andrew A. Adams;John A.Prince;Larry D.Snider;Michael Macomber;Norman E.Adams all of the city of Houston state of TX each individually if there be more than one named,its true and lawful attomey-in-fact to make, execute,seal,acknowledge and deliver,for and on its behalf as surety and as its act and deed,any and all undertakings,bonds,recognizances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 28th day of June 2021 Liberty Mutual Insurance Company P�1NSu� P�tV INS& a 1NSURq The Ohio Casualty Insurance Company jR,rFoy�ca oil°�Tayn �P:oaP°P,ro?� West American Insurance Company 1912 0 0 1919 1991 daN.MPS�,aD rs DIANi' .as; ' k..y to David M.Carey,Assistant Secretary v cc State of PENNSYLVANIA ss c a) :3 County of MONTGOMERY o On this 28th day of June 2021 before me personally appeared David M.Carey,who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance ) m Company,The Ohio Casualty Company,and West American Insurance Company,and that he,as such,being authorized so to do,execute the foregoing instrument for the purposes V> therein contained bffiy signing on behalf of the corporations by himself as a duly authorized officer. o IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at King of Prussia,Pennsylvania,on the day and year first above written. O ('2 6P PAS a0 0 Q74�sp°N W l�f Commonwea8h of Pennsylvania-Notary Seal '< Ter le,fPublic C � 6 O 'r Teresa Y OFMy oanmission expires March 28,2025 By: 00 c`vg, �PCommission be`11014 Teresa Pastella,Notary Public Q `o %2 Member,Permytmm Association of Nofenes co a� N This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual 3°o O Insurance Company,and West American Insurance Company which resolutions are now in full force and effect reading as follows: d M ARTICLE IV-OFFICERS:Section 12.Power of Attorney. c°O Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President,and subject to such limitation as the Chairman or the-a o President may prescribe,shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations.Such attomeys-in-fact,subject to the limitations set forth in their respective powers of attorney,shall c have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed,such O m Zinstruments shall be as binding as if signed by the President and attested to by the Secretary.Any power or authority granted to any representative orattorney in-fact under the m provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer or officers granting such power or authority. LL n ARTICLE XIII-Execution of Contracts:Section 5.Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings, bonds,recognizances and other surety obligations.Such attomeys-in-fad subject to the limitations set forth in their respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company.When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation-The President of the Company,acting pursuant to the Bylaws of the Company,authorizes David M.Carey,Assistant Secretary to appoint such attomeys-in- fact as may be necessary to act on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations. Authorization-By unanimous consent of the Company's Board of Directors,the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds,shall be valid and binding upon the Company with the same force and effect as though manually affixed. I,Renee C.Llewellyn,the undersigned,Assistant Secretary,The Ohio Casualty Insurance Company,Liberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full,true and correct copy of the Power of Attomey executed by said Companies,is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this 5th day of March 2025 P�[NSUgq P�Z`r INS& a [NSU AJ c°Nv°�qrr f, yJ o°wrolprr'Qyy `4Pavok 'YC+ 0 3 b m W n f 1912 c = 1919 W c � 1991 By. UPS aa� �S �holA �Nda; Renee C.Llewellyn,Assistant eh • *� '�Ht * �N ''M + l� Y Secretary LMS-12873 LMIC OCIC WAIC Mufti Co 0221 Have a complaint or need help? Tiene una queja o necesita ayuda? IMPORTANT NOTICE AVISO IMPOR TANTE If you have a problem with a claim or your premiums, call Si tiene un problema con un reclamo o las primas,llame your insurance company first. If you can't work out the primero a la empresa de seguros.Si no puede resolver el issue, the Texas Department of Insurance may be able to problema,el Departamento de Seguros del estado de Tejas help. puede ayudar. Even if you file a complaint with the Texas Department of Si registra una queja con el Departamento de Seguros del Insurance, you should also file a complaint or appeal estado de tejas,tambien debe presentar una queja o through your insurance company. If you don't, you may apelacion a traves de su compania de seguros.Si no to hace lose your right to appeal. puede perder su derecho de apelar. To get information or file a complaint with CHUBB: Para obtener informacion o registro de una queja con CHUBB: Call Toll-free:i-Soo-36-CHUBB Llame al:1-800-36-CHUBB Mail: Eastern Claim Service Center Correo: Eastern Claim Service Center 600 Independence Parkway 600 Independence Parkway Chesapeake,VA 23320 Chesapeake,VA 23320 Attn: Surety Support Attn: Surety Support Phone: 800-252-4670 Fax: 800-664-5358 Telefono: 800-252-4670 Fax: 800-664-5358 Email: ecsc.claims@chubb.com Correo electronico: ecsc.claims@chubb.com To get help with an insurance question or file a complaint Para ayuda con una pregunta de seguros o registrar una with the state: queja con el estado: The Texas Department of Insurance El Departamento de Seguros del Estado de Tejas Call with a question: 1-800-252-3439 Preguntas: 1-800-252-3439 File a complaint: www.tdi.texas.gov Quejas: www.tdi.texas.gov E-mail: ConsumerProtection@tdi.texas.gov Correo electronico: ConsumerProtection@tdi.texas.gov Mail: MC-111-1A,P.O.Box 149091 Correo: MC-iii-1A,P.O.Box 149091 Austin,TX 78714-9091 Austin,TX 78714-9091 Form 15-10-0347(Rev.2/23) Liber 1Y utum- SURETY TEXAS TEXAS IMPORTANT NOTICE AVISO IMPORTANTE To obtain information or make a complaint: Para obtener informacion o para someter una queja: You may call toll-free for information or to Usted puede llamar al numero de telefono gratis make a complaint at para informacion o para someter una queja al 1-877-751-2640 1-877-751-2640 You may also write to: Usted tambien puede escribir a: 2200 Renaissance Blvd., Ste. 400 2200 Renaissance Blvd., Ste. 400 King of Prussia, PA 19406-2755 King of Prussia, PA 19406-2755 You may contact the Texas Department of Puede comunicarse con el Departamento de Insurance to obtain information on companies, Seguros de Texas para obtener informacion coverages, rights or complaints at acerca de companias, coberturas, derechos o 1-800-252-3439 quejas a] 1-800-252-3439 You may write the Texas Department of Insurance Puede escribir al Departamento de Seguros Consumer Protection(111-1 A) de Texas Consumer Protection(I 11-1 A) P. 0. Box 149091 P. 0. Box 149091 Austin, TX 78714-9091 Austin,TX 78714-9091 FAX: (512)490-1007 FAX#(512)490-1007 Web: hqp://www.tdi.texas.gov Web: hnp://www.tdi.texas.izov E-mail: ConsumerProtection a@tdi.texas,gov E-mail: ConsumerProtection&tdi.texas.gov PREMIUM OR CLAIM DISPUTES: DISPUTAS SOBRE PRIMAS 0 RECLAMOS: Should you have a dispute concerning your Si tiena una disputa concerniente a su prima o a premium or about a claim you should first un reclamo, debe comunicarse con el agente o contact the agent or call 1-800-843-6446. primero. Si no se resuelve la disputa, puede If the dispute is not resolved, you may contact the entonces comunicarse con el departamento(TDI) Texas Department of Insurance. ATTACH THIS NOTICE TO YOUR UNA ESTE AVISO A SU POLIZA: POLICY: This notice is for information only and does not Este aviso es solo para proposito de informacion become a part or condition of the attached y no se convierte en parte o condicion del document. documento adjunto. NP 70 68 09 01 LMS-15292 10115 SpawGIass Providing the Absolute Best Construction Experience LL 11 ' , 1 • r 4 vY. r.. v I TABLE OF CONTENTS TAB 1 TAB 6 BUDGET ESTIMATE OVERVIEW BUDGET PROPOSAL COST BREAKDOWN TAB 2 TAB 7 EXECUTIVE PROJECT SUMMARY MASTER PROJECT SCHEDULE TAB 3 TAB 8 PROJECT TEAM BID/PROPOSAL PACKAGE STRATEGY TAB 4 TAB 9 LIST OF DOCUMENTS TAB 5 ASSUMPTIONS & CLARIFICATIONS t Providing the Absolute Best Construction Experience 1S Project Cost Summary 100% CD ESTIMATE OVERVIEW SpawGlass Contractors, Inc. hereby submits to the City of Round Rock for the use and benefit of the new Old Settler's Park Buildout - Package 3B Maintenance Yard, based on the 100% CD Drawings, as follows: 1. The proposed amount for the Direct Cost of the Work: $ 1,838,431 2. General Conditions: $ 59,463 3. Builder's Risk Insurance: $ 5,705 4. General Liability Insurance: $ 17,017 5. Payment & Performance Bonds: $ 25,316 6. Subcontractor Default Insurance (1.25%): $ 22,980 7. Warranty: $ 5,454 8. Contractor's Contingency (3.0%): $ 65,449 9. Design Progression Contingency (3.0%): $ 65,449 10.Construction Phase Fee (3.50%): $ 76,356 11. Price Forecasting/Tariffs: $ 0 12.TOTAL: LINE ITEMS 1 THROUGH 11: $ 2,181,620 -rte ems' W e i5a PA, Tyler Wenzel, Project Executive i AB 2 EXECUTIVE PROJECT SUMMARY A n 1 k , n SpawGlass � `An i . Executive Summary City of Round Rock - Old Settler's Park Build Out Package 3B - Maintenance Yard 100% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 Scope of Work Package 3B - Maintenance Yard is the construction of the new Warehouse, Remote Pole Barn, Remote Maintenance Facility site work, and site improvements. This includes demo of existing structures and site, earthwork, site utilities, concrete flatwork, electrical work, and landscaping. Overview The new Maintenance Yard package is planned to be completed in one main package: - Construction is planned to start in May 2025. 1 I AB 3 PROJECT TEAM , ,000 i L, VA FA �•� � , Uwe_. i y 4 f ••:� - Sp awGla.ss ORGANIZATION CHART LEGEND Management Support Team Lead/Single Point-of-Contact On-site Team Safety CITY OF ROUND ROCK 0 Preconstruction/Estimating Support DAVID PADEN J7 T TOM MCCLANAHAN DIVISION PRESIDENT SENIOR ESTIMATOR JOEY GEORGE ADAM WARDEN OPERATIONS MANAGER ESTIMATOR I I �¢ JUAN MARQUEZ BRIAN CLAXTON 13IM/VDC COORDINATOR TYLER WENZEL PROJECT EXECUTIVE/ PRECONSTRUCTION SERVICES MANAGER PARKER BLASCHKE HARRISON HOLLEY r�NIOR RROILCI MAN• SENIOR SUPERINTENDENT CHRIS SOTO © ASSISTANT SUPERINTENDENTS ASSISTANT PROJECT MANAGEf DAYLON DYESS 0 ASSISTANT PROJECT MANAGER QUALITY CONTROL COORDINATOR t w. lkl _a i 1 IY f A Nrwr f� ;-rte ,SSL, _ ��, ' � • x 4 7. Providing the Absolute Best Construction Experience I'I List of Documents City of Round Rock - Old Settler's Park Build Out Package 3B - Maintenance Yard 100% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 # SHEET TITLE ISSUE DATE REVISION DATE C-0.0 COVER C-1.0 KEY SHEET DECEMBER 2024 C-2.0 GENERAL NOTES DECEMBER 2024 C-3.0 EXISTING CONDITIONS DECEMBER 2024 C-4.0 DEMOLITION PLAN DECEMBER 2024 C-5.0 DEMOLITION PLAN DECEMBER 2024 C-6.0 GRADING AND DRAINAGE PLAN DECEMBER 2024 C-7.0 SITE PLAN DECEMBER 2024 C-8.0 PAVING PLAN DECEMBER 2024 C-9.0 UTILITY PLAN DECEMBER 2024 C-10.0 REMOTE MAINTENANCE FACILITY PLAN DECEMBER 2024 C-11.0 CONSTRUCTION DETAILS DECEMBER 2024 C-11.1 CONSTRUCTION DETAILS DECEMBER 2024 C-11.2 CONSTRUCTION DETAILS DECEMBER 2024 L-1.00 LANDSCAPE PLAN DECEMBER 2024 L-1.01 LANDSCAPE PLAN DECEMBER 2024 L-1.02 LANDSCAPE PLAN DECEMBER 2024 L-2.00 LANDSCAPE DETAILS DECEMBER 2024 L-3.00 LANDSCAPE SPECIFICATIONS DECEMBER 2024 IR-1.0 IRRIGATION PLAN DECEMBER 2024 IR-1.1 IRRIGATION PLAN DECEMBER 2024 IR-2.0 IRRIGATION DETAILS DECEMBER 2024 IR-2.1 IRRIGATION SPECIFICATIONS DECEMBER 2024 A1.101 POLE BARN #1 FLOOR PLAN DECEMBER 2024 Al.102 POLE BARN #2 FLOOR PLAN DECEMBER 2024 A1.103 POLE BARN #1 & #2 ROOF PLAN DECEMBER 2024 Al.104 POLE BARN CROSS SECTIONS DECEMBER 2024 AS1-1 POLE BARN #1 GENERAL NOTES DECEMBER 2024 AS1-2 POLE BARN #1 FOUNDATION PLAN DECEMBER 2024 AS1-3 POLE BARN #1 FOUNDATION DETAILS DECEMBER 2024 AS2-1 POLE BARN #2 GENERAL NOTES DECEMBER 2024 AS2-2 POLE BARN #2 FOUNDATION PLAN DECEMBER 2024 AS2-3 POLE BARN #2 FOUNDATION DETAILS DECEMBER 2024 AS3-1 CHEMICAL BUILDING GENERAL NOTES DECEMBER 2024 AS3-2 CHEMICAL BUILDING FOUNDATION PLAN DECEMBER 2024 E-0 LEGEND DECEMBER 2024 E-1 SITE PLAN DECEMBER 2024 E-2 POLE BARN #1 PLAN DECEMBER 2024 1 ' List of Documents E-3 POLE BARN #2 PLAN DECEMBER 2024 E-4 ELECTRICAL RISER DIAGRAM DECEMBER 2024 E-5 ELECTRICAL DETAILS DECEMBER 2024 I 'r Providing the Absolute Best Construction Experience Assumptions and Clarifications City of Round Rock — Old Settler's Park Build Out Package 3Bb — Maintenance Yard 100% Construction Documents - GMP 1301 N Kenney Fort Blvd., Round Rock, TX 78665 GENERAL QUALIFICATIONS 1. Kimley Horn and Associates, Inc. is the civil engineer/prime consultant of record. 2. Based on an anticipated NTP of May 2025. 3. Specifications provided. 4. The baseline schedule is based on a 5-day work week. 5. Normal working hours have been included from 7:00 AM to 5:30 PM unless otherwise noted, with exception to early concrete operations as deemed necessary. It is also assumed that work can occur on a 7 day a week schedule if required. 6. In order to subcontract scopes of work in a timely manner to meet the construction schedule it is assumed that buyout packages will be reviewed within 5 business days of their submission. 7. LEED Certifications or Green Building Programs are not incorporated into the project. 8. Builders Risk Insurance is provided by SpawGlass. Builder's Risk deductible to be paid from construction contingency. 9. Performance & Payment Bonds are provided by SpawGlass. 10. General Liability is provided by SpawGlass. 11. Proposal assumes that the specified material and equipment are available as required to meet the schedule. If they are not available as required, we assume the Owner/Architect will authorize alternate material or equipment selections. 12. Owner must accept GMP within 30 calendar days, at which time pricing may expire. 13. General conditions - Any general conditions savings or losses from that package are to be rolled into the other GMP packages. 14. Tariffs are an unknown factor at this time. Any cost or schedule impacts related with tariffs will be negotiated with Owner for reimbursement. Contractor shall provide information reasonably requested by Owner to document such impacts, such as quotes, invoices, or receipts. SPECIFIC QUALIFICATIONS Division 01 — General Requirements and General Conditions 1. SpawGlass general requirements assume a 6 month project construction schedule. 2. Construction photos will be taken on a regular basis by SpawGlass. Digital files will be turned in monthly. 3. As-Built drawings, record drawings and record submittals will be kept in electronic format. These files will be accessible to all on the jobsite. 1 . Assumptions and Clarifications 4. Reasonable repairs or damage caused by contractor(s) will be funded from the CM Contingency if funds remain and approved by CoRR. 5. Dimensional Control for the Project is included. 6. Individual non-photographic hard hat stickers for workers will be utilized. 7. Temporary barriers and enclosures are included to delineate construction zone from the public. S. No sound/vibration monitoring included. Division 02 - Existing Conditions 1. Site demolition and clearing is included. 2. Removal of fencing at Remote Facility Division 03 - Concrete 1. Slabs on grade for PEMBs 2. Concrete curbing, mow strips under fencing, light pole bases, and setting steel bollards 3. 2' x 2' x 1' D pads for containers - 16 Each 4. 4" paving for Ranger Shed, Chemical Storage Building, Fuel Storage, and Lubricant Cabinets. 5. Concrete paving for storage area and Wash 6. Curbs around the Fuel Storage and lubricant cabinets. 7. Concrete paving for the Remote Facility. Division 04 - Masonry 1. NA Division 05 - Metals 1. Steel Bollards Division 06 - Wood, Plastics, and Composites 1. NA Division 07 - Thermal and Moisture Protection 1. Site Sealants 2. Slab on Grade Sealants Division 08 - Openings 1. One Hollow metal door, frame, hardware, and Installation 2. One 12' x 12' overhead door with chain drive with factory paint finish Division 09 - Finishes 1. Painting hollow metal door & frame 2. Paint steel bollards Assumptions and Clarifications 3. Metal stud framing for horizontal wall panels on the Remote PEMB Division 10 - Specialties 1. Fire Extinguishers on Brackets in PEMB(s) 2. Knox Boxes on Entry Gates Across Driveways Division 11 - Equipment 1. Includes removing and relocating fuel storage tank & Cover; lubricant cabinets & cover; chemical storage building & ramp; and Ranger Shed (Morgan Building). Division 12 - Furnishings 1. NA Division 13 - Special Construction 1. PEMB - Chief basis of design not used but Red Dot Buildings. SpawGlass feels that this is the current best value for the City of Round Rock. 2. SSPC Primer Standard Metal Building Factory Primer for Field Finish coat painting by Others 3. Soffit panels are factory painted steel - not Petersen Aluminum in specifications. 4. Collateral Load 17.5 PSF 5. R-30 Insulation 2 Plys at the roof for the Remote PEMB only. Division 14 - Conveying Equipment 1. NA Division 21 - Fire Suppression 1. NA Division 22 - Plumbing 1. NA Division 23 - HVAC and Controls 1. NA Division 26 - Electrical 1. Primary conduit 2. Secondary service 3. Pole Lighting 4. Power for Chemical Storage Division 27 - Communications 1. Underground conduit as noted on drawings - conductors by CoRR Division 28 - Electronic Safety & Security Assumptions and Clarifications 1. NA Division 31 - Earthwork 1. Includes clear and grub. 2. SWPPP setup included. 3. SpawGlass assumes that all water can be taken from existing City of Round Rock water utilities on-site, and no water will need to be trucked in from other cities due to water restrictions. 4. Includes removal of fat clays and placement of 12" of select fill at building pads for 1" PVR. 5. Includes 12" of base and 2" of asphalt at parking lot. 6. Includes stockpiling of existing onsite material for respread of 4" over hydro mulched areas. 7. Includes stripping and stockpiling of topsoil for respreading 4". 8. Includes excavation, embankment, and import of soil as needed 9. Includes subgrade preparation for concrete paving at Remote Facility. 10. Includes compacted road base for paved surface at the Main Facility. Division 32 - Exterior Improvements 1. Remote Facility - Chain Link fencing galvanized, 8' High, 9 gage mesh, 3 strands of barbed wire, and manual double gate 2. Main Facility - Service Area Fencing - Chain Link fencing galvanized, 8' High, 9 gage mesh, 3 strands of barbed wire, and three manual double gates. The fencing will be extended behind the pole barns if the Alternates are not elected. 3. Main Facility - Privacy Fencing - Chain Link fencing vinyl coating, 9 gage, vinyl privacy slats, 3 Strands of Barbed Wire, and one motor operated slide gate across driveway. 4. Includes importing and placing 2" of topsoil blended with 4" of respread by earthwork contractor. 5. Hydro Seeding - Bermuda grass seeding in lieu of sod as requested by CoRR. 6. Irrigation - Includes permanent, temporary, and sleeves as noted on the drawings. 7. Includes 90-day maintenance after substantial completion. 8. Includes Knox Boxes at the Remote and Main Facility driveway gates. 9. Painted parking striping if asphalt or concrete paving alternates are elected. 10. Wheel stops at parking spaces as indicated on the drawings. Division 33 - Utilities 1. Site utilities are included. 2. Reuse Water Service 3. Domestic Water Service includes connection, meter, backflow, piping, and hose bibbs. 4. Storm scope of work includes culverts with SETs 1 . Assumptions and Clarifications EXCLUSIONS 1. Permits, by Owner. 2. LEED documentation and Submittals. 3. We have not included the following items as we assume, they will be provided in a timely manner by the Owner at no cost to SpawGlass: a. Materials Testing Services b. Excludes all local electrical utility fees for permanent power 4. Preconstruction costs for the Project are not included in this budget. 5. Contaminated soils - hauling or disposal �,,I� BUDGET PROPOSAL COST '�i�� ,� BREAKDOWN %i Vis!•• SpawGlass AL Providing Absolute Be 6;1::7� Summary Report OSP Maintenance Yard 100% CD GMP - Rev 02 Revision 02 Including Asphalt Paving Estimate Date: 03/03/2025 Documents Date: 12/04/2024 Project Size (SF): 335,284 Project #: 3023121.02C Project Location: 1301 N. Kenny Fort Blvd., Lead Estimator: Tom McClanahan ITEM COST COST I SF % OF TOTAL GR's (335,284 SF) 130,871 0.39 6.00 % ---- - ------------- Main Facility (328,051 SF) 1,364,211 4.16 62.53 Remote Maintenance Facility (7,234 SF) I 343,350 47.46 15.74 Indirect Costs 343,189 1.02 15.73 Total Cost $ 2,181,620 $ 6.51 100.000/0 OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page 1 of 1 Documents Date: 1210412024 Recap Report OSP Maintenance Yard 100% CD GMP - Rev 02 Revision 02 Including Asphalt Paving Estimate Date: 03/03/2025 Documents Date: 12/04/2024 Project Size (SF): 335,284 Project #: 3023121.02C Project Location: 1301 N. Kenny Fort Blvd., Lead Estimator: Tom McClanahan ITEM COST COST I SF %OF TOTAL GR's (335,284 SF) 130,871 0.39 6.000/0 Div. 01 - General Requirements 130,871 0.39 100.00 Main Facility (328,051 SF) 1,364,211 4.16 62.53 Div. 05 - Metals 2,200 0.01 0.16 Div. 07 - Thermal &Moisture Protection 1,200 0.00 0.09 % Div. 09 - Finishes —�– 450 0.00 0.03 Div. 10 - Specialties j 750 0.00 0.05 % Div. 11 - Equipment 18,000 0.05 1.32 % Div. 26 - Electrical 145,000 0.44 10.63 % Div. 31 - Earthwork 543,200 1.66 39.82 Div. 32 - Exterior Improvements 1 442,411 1.35 32.43 Div. 33 - Utilities 211,000 0.64 15.47 Remote Maintenance Facility (7,234 SF) 343,350 47.46 15.74 % Div. 07 - Thermal & Moisture Protection 2,724 0.38 I 0.79 Div. 08 - Openings 26,550 3.67 7.73 % Div. 09 - Finishes 18,000 2.49 5.24 % Div. 10 - Specialties i 1,289 0.18 0.38 % Div. 13 - Special Construction 112,000 15.48 32.62 % Div. 31 - Earthwork 52,100 7.20 15.17 % Div. 32 - Exterior Improvements 130,687 18.07 1 38.06 % – OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 03/03/2025 Revision 02 Including Asphalt Paving Page 1 of 2 Documents Date: 12/04/2024 ITEM COST COST I SF % OF TOTAL Indirect Costs 343,189 1.02 15.73 % General Conditions 1 59,463 0.18 1 2.73 % Builder's Risk Insurance 5,705 0.02 1 0.26 % General Liability Insurance 17,017 0.05 0.78 % Payment and Performance Bonds 25,316 0.08 1.16 % Subcontractor Default Insurance (SDI): 22,980 1 0.07 1 1.05 % Warranty 5,454 0.02 0.25 Contractor's Contingency 65,449 0.20 3.00 % Owner/ Design Contingency 65,449 0.20 3.00 % Overhead and Profit 76,357 0.23 3.50 Total Cost $ 2,181,620 $ 6.51 100.000/0 OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page 2 of 2 Documents Date: 1210412024 Detail Report (Direct Costs Only) OSP Maintenance Yard 100% CD GMP - Rev 02 Revision 02 Including Asphalt Paving Estimate Date: 03/03/2025 Documents Date: 12/04/2024 Project Size (SF): 335,284 Project #: 3023121.02C Project Location: 1301 N. Kenny Fort Blvd., Lead Estimator: Tom McClanahan ITEM QUANTITY I UM UNIT COST TOTAL COST GR's 130,871 01 - General Requirements 130,871 General Requirements ! 130,871 r-- 11 - - --+-- -- ---Drawings 2.0 758 Job Photos/tVideos .0_ --- -- ------ --- - -- -- 3Mos 148.86 -- - _ 519 Water, Ice, &Cups (for Field) 3.5 Mos 540.28 1,891 General Safety Supplies 3.5 Mos 216.50 758 Portable Toilets - Rental & Handwash (2ea) 12.0 Mos 194.85 2,338 Misc. Fuel, Oil, & Grease 4.0 Mos 270.62 1,082 Misc. Small Tools 1.0 LS 3,788.75 3,789 Main Facility -Temporary Fencing - Rental (6' h 3,538.0 LF 8.00 28,304 Chain Link Fence w/ Driven Posts) Remote Facility -Temporary Fencing - Rental (6' h 380.7 LF 8.00 3,046 Chain Link Fence w/ Driven Posts) Project Signs 1.0 Each 1,267.95 1,268 Surveying Supplies 6.0 Wks _ 154.95 930 Licensed Professional Certified Survey (Intial — 1.0 LS 3,000.00 3,000 Control Points) Licensed Professional Certified Survey (Final) 1.0 Each 3,000.00 3,000 Onsite Misc Labor I 28.0 Wks 1,450.00 40,600 Final Cleaning - Site - LOC/ Work Area Disturbed 335,284.5 SF 0.05 16,764 (7.70 Acres) Trash Dumpsters (40 Yd.) - Pulls 20.0 Each 541.25 10,825 Dust Control EQ 3.5 mos 1,714.12 5,999 Surface Water Pumping / Dewatering 3.5 Mos 1,714.12 5,999 Main Facility 1,364,211 D Structural/Miscellaneous Steel-Fabrication 2,200 OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page 1 of 4 Documents Date: 1210412024 ITEM QUANTITY I UM UNIT COST TOTAL COST Supply Steel Pipe Bollards 4.0 Each 550.00 2,200 I7 - Thermal & Moisture ProtectionIl Waterproofing / Dampproofing /Joint Sealants 1,200 Main - Joint Sealants - Concrete Flat Wotk 1.0 LS 1,200.00 1,200 09 I Painting / Wall Coverings _ 450 Painting Steel Bollards - Main Facility 1.0 LS 450.00 450 I Div. I - Specialties 7501, Fire Protection Specialties 7SO Knox Box on Gate 1.0 Each 750.00 750 Equipment 18,000 ! Maintenance Equipment 18,000 Relocation of Ranger Shed/ Morgan Building; Chemical Building & Ramp; Fuel Storage Tank & 1.0 LS 18,000.00 18,000 Cover; and Lubricant Cabinets &Cover Div. 26 - Electrical III Electrical 145,000 Electrical Primary Conduit, Secondary, and Site 1.0 LS 145,000.00 145,000 Iiv. 31 - Earthwork 543,200 Earthwork I 508,200 ----- --------- Clear and Grub Site, Stock Pile Top Soil,Cuts, 1.0 LS 269,000.00 269,000 Embankment, and Respread 4" of Top Soil Additional Base and Asphalt Pavement - Elected Alternate 03-03-2025 1.0 LS 239,200.00 239,200 Erosion Control 35,000 SWPPP, Inspections, Silt Fencing, Tree Protection, Concrete Wash-Out Containers, Maintenance, and 1.0 LS 35,000.00 35,000 Removal Exteriorr . Site Concrete 160,000 Ribbon Curbing, Mow Strips, Setting Bollards, Concrete Paving as Noted, Footing Blocks For Containers, Slabs for Ranger Shed, Chemical 1.0 LS 160,000.00 160,000 Storage Building, Fuel and Lubricant Cabinet Slabs and Curbs, and Light Pole Bases _ --- - - g g 4,118 Traffic Markin9 s/Sina e Wheelstops 15.0 Each 125.00 1,875 Parking Space Striping - Paint 1.0 LS 2,243.00 2,243 OSP Maintenance Yard 100010 CD GMP - Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page 2 of 4 Documents Date: 1210412024 ITEM QUANTITY I UM UNIT COST TOTAL COST Fences/ Gates 137,093 Privacy Fence - 8' Chain Link 9 Gage Vinyl Coated, Vinyl Slats, and 3 Rows of Barbed Wire; Service Fencing 8' + 1' Barbed Wire Galv Finish 9 Gage; 1.0 LS 137,093.00 137,093 Service Gates 3 Each Manual; One Motorized Slide Gate at Entry Retaining Walls 31,200 Retaining Walls - ILO Pole Barn #2 - 130 LF @ 4' T 520.0 SF 60.00 31,200 With Embedment Landscaping/Irrigation 110,000 Hydromulching, Sleeves, Permanent &Temporay 1.0 LS 110,000.00 110,000 Irrigation, and 90 Day Maintenance Div. 33 - Utilities 211,000 Site Utilities 211,000 Site Utilities - Storm Culverts, Safety End Treatments, Domestic Water & Hydrants, and 1.0 LS 211,000.00 211,000 Reuse Water System Remote Maintenance Facility 343,350 Div. I7 - Thermal & Moisture Protection Waterproofing/Dampproofing/Joint Sealants 2,724 Remote - Joint Sealants - Concrete Paving and 1.0 LS 2,724.00 2,724 Slab on Grade I Openings 26,550 Doors / Frames / Hardware j 4,100 Hollow Metal Door, Frame, Hardware,and 1.0 Each 4,100.00 4,100 Installation OH/Coiling Doors / Grilles 13,500 Coiling Doors (Manual) 12' x 12' Shop Painted 1.0 Each 13,500.00 13,500 Finish Chain Operated Non Insulated Louvers/ Vents 8,950 Remote - Gable End Louvers Including Engineering 1.0 LS 8,950.00 8,950 and Installation Div. 09 - Finishes 18,000 Drywall/Acoustical 9,500 6" Md. Studs to Support Horizontal Siding on PEMB 1.0 LS 9,500.00 ! 91500 Painting / Wall Coverings 8,500 Painting Steel Building Frames & Perlins and Hollow Metal Door & Frame - Primer Coat Applied in Shop By Fabricator and Painted Onsite After 1.0 LS 8,500.00 8,500 Erected 1 Div. ISpecialties OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page 3 of 4 Documents Date: 1210412024 ITEM QUANTITY I UM UNIT COST TOTAL COST Fire Protection Specialties 1,289 Fire Extinguishers 2.0 Each 269.42 539 Knox Box on Gate 1.0 Each 750.00 750 Div. 13 - Special Construction 112,000 Pre-Engineered Metal Buildings 112,000 Pre-Engineered Metal Building, Includes: Frame, 1.0 LS 112,000.00 112,000 Roof, Exterior Metal Wall Panels Div. 31 - Earthwork 52,100 Earthwork 49,600 Clear and Grub Site, Stock Pile Top Soil, Respread 4", Cuts, Embankment, 10" Compacted Base For 1.0 LS 49,600.00 49,600 Concrete Paved Area _ Erosion Control 2,500 Silt Fencing, Safety Caps, Wash-Out Containers, Maintenance, and Inspections 1.0 l5 2,500.00 2,500 Div. 32 - Exterior Zmprovernents Site Concrete 104,000 SOG, Concrete Driveway, Heavy Duty Paving, and 1.0 LS 104,000.00 104,000 Mow Strip Under Fencing Fences / Gates 14,687 Remote Facility - 8' Chain Link Fencing Galvanized 9 Gage + 1' Barbed Wire and Manual Double Gate 1.0 LS 14,687.00 14,687 Across Driveway Landscaping/Irrigation 12,000 Hydromulching, Sleeves, Permanent &Temporay 1.0 LS 12,000.00 12,000 Irrigation, and 90 Day Maintenance Total - Direct Costs $ 1,838,431 OSP Maintenance Yard 100% CD GMP- Rev 02 Estimate Date: 0310312025 Revision 02 Including Asphalt Paving Page 4 of 4 Documents Date: 1210412024 ® General Conditions Name: City of Round Rock-OSP A Duration(Mos): 33.0 Project p: 0 Location: Duration(Wks): 143.0 Total From GRs GL 3R Bond Type: Bid Date:Data: Total GCs: $ 3,878,755 f 51,728.08 S 1,055,600.00 S 210,000.00 $ 896,368.00 Gross Area(SF): - Priced By: Paden Cost I Mo: $ 117,538 6,092,450.66 4.35% USE: 6,093,000.00 Template updated on 10120/2022 6.250% ---Enter Selea Taa R.I. Labor Labor Total Mabdal Material Total < Subcontract Subcontract Equipment Equipment Total Total By Description Quantity Unit Unit Price (wl Burden) Unit Price Iwr Sales Taa) Unit Price Total Unit Price Iwl Sales Taal Total Category Project PersonnelOperations Manager Manager _ Wks 2,500.00 - - ProjectF_xecuti--Tyler Wenzel _ - Wks 3,395.00 - - Sr Project Manager-Parker 143.0 Wks 2,900,00 566,314 566,314 Assistant Project Manager-Field/Sae _ 143.0 Wks 2.540.00 496,013 - - - 496.013 Assistant Project Manager-Roadway 77.4 Wks 1,545.00 183,303 - _"- 163,303 -- Sr Superintendent-Hanson 143.0 Wks 3,330.00 650,285 - - __ 850,235 Superintendent-TBD 143.0 Wks 2,600.00 507,730 - 507,730 Superintendent-TBD - Wks 2,860.00 - - AssistantSuperntendent-TBD 94.6 Wks 2,100.00 271,290 - _ _ - 271.290 Assistant Superintendent-TBD 64.5 Wks 2,100.00 184,971 - _ _ - __.,. 184,971._., _ Assistant Superintendent TBD - Wks 1,600.00 -- PMA Wks 650.00 Project Engineer/Eipedilor - Wks 1,100.00 - - --- Submittal Clerk/FSS 143.0 Wks 1,200.00 234,337 - 234,337- QualilyControlManager Wks 2,000.00 - - - QualsyConbol-Archaectural Wks 1,600.00 - - - - QualkyControl-Structural Wks 1,600.00 Quality Control-MEP Wks 1,600.00 - Pro)Safety Coordinator(PSC)/Safety Proctor 143.0 Wks 2.000.00 390,562 _____ 390,562 Project Safety Assistant(PSA) Wks 1,650.00 - _ - - - MEP Coordinator/Specialist-Dayton-OPP.GRs/COW - Wks 2,586.00 -- LEED Coordinator Wks 1,400.00 - SIMEngneer - Wks 1,450.00 - - --- - Scheduler Wks 2,000.00 - SafetyEngineer(Consultant) 2000. Hrs - 100.00 21,650 - __. - 21,650 .. Structural Engineer(Consultant) Hrs - 125.00 - Mechanical Engineer(Consultant) Hrs - 150.00 - IN COW Waterproofing/Budding Envelope(Consultant) Hrs 125.00 Add Line Subtotal: 3,466,454 ----- Misc.Expenses for Project Personnel Computers($180 per person per month) '2E1:0 Mos - 300.00 75,017 - 75.017 Cell Phones 1 ' `x231.0 Wks - 68.00 22.005 - 22.005 NA Vehicle Allowances Wks 300.00 - - NA Parkin Allowances LS 16.000.00 - - NA Relocation E>,penses(Out of Town) Each 1,500'00 NA Housing Allowances(Out of Town) Wks 275,00 NA Luing/Per Diem Altowances(Out of Town) Wks 175.00 - NA Travel Allowance President(Out of Town) Trips - 500.00 - NA Travel Allowance-Ops.Mgr.(Out of Town) Trips - 500.00 NA Travel Allowance-Pro)Exec.(Out of Town) Trips - 500.00 - - - Add Lne 97,022 Subtotal: Construction Documentation Construction Documents(Blueprint Repro.) ';9a0 Sets - 350.00 3,789 3.789 Construction Documents(CDs) LS 50.00 - 75.00 - AsBuiltDocuments Sets 500.00 1,624 1,624 COW/BIM CAD Generated As-Bust Documents LS - 15,000.00 - - P6 Scheduling Software 33.0 Mos - 195.00 6,966 - 6,966 Construction Schedules(Color Copies) Mos 50.00 - 1,624 - Project Reference Manuals S,; •'''''1fi LS - 1,500.00 1,824 Digital Cameras Each - 250.00 - Via-Cameras Each 500.00 - Job Photos/Videos - Mos 100.00 - - - - - MV in COW as GF Professional Aerial Photos .. "'08$ Mos 325.00 11,810 11.610 Add Line Subtotal: Health a Safety First Aid Kits(for Office Traders) 2.0 Each - 300.00 650 - - 650 First Aid Supplies(for Office Traders) , �33t0 Mos 200.00 7,145 - 7,145 CoR OSP-G-1 Candboiu Page 1.12 Gensrsl Conations n i w ! m i F id�gpI Tm < O II , ail 0 g g a 8 888 SS8888S8888888888888888588 888 8888 m . . . . . . . . . . . . . . . m sss ' i i l v ! i ' c E F R a o $ E m u E e cri� � �gUio v ms U, c =.E g i U e .-� w3� LLOOOLL OLLac°�0u �aaog'a Iaaw� u N y y o 80,o a :may ,�>� MASTER PROJECT SCHEDULE i. SpawGlass J .3 • • • Rem Start Finish % Total 20251 Dur Dur Float MileStOnes 280 280 19-Feb-25 27-Mar-26 0% 3 jAr�il tgtgrjep j MSTONE-10 GMP Approval_3A.2-Harrel Pkwy 0 0 19-Feb-25 0% 28 fMaAjpprp Hprjel Fyl� uuy MSTONE-11 Construction Start_3A.2-Hamel Pkwy 0 0 19-Feb-25 0% 28 Construatibri Stet: 3A.2:Herta Pkwy; MSTONE-10 Construction Start_3B-Tennis/Piddeball 0 0 19-Feb-25 0% 12 bohstrLidtibd Stlsrt: 36�TehhiW FIddet MSTONE-11 GMPApproval_3C-RockN River 0 0 19-Feb-25 0% 3 �ONIPA�prtrYap+3t~r Rbdc'IV;RiVer r MSTONE-11• Construction Start_3C-Rock N River 0 0 19-Feb-25 0% 3 ( (rgtruCtiprl$t8ft L k6c W,t4 Rim MSTONE-11 GMP Approval_3C-Rec Center Complex 0 0 19-Feb-25 0% 44 C MP!Ajpprp�ajl i �ipq OgnWr 0p01914 MSTONE-12 Substantial Completion_3C-Rock'N River 0 0 27-Mar-26* 0% 3 :Sub staritiel Comp; Early Procurement 180 35 17-Jul-24 A 08-Apr-25 80.56% 523riY Proirerrient Administration Submittals Procurernent :1 ® 1: Proouieiri h A5230 3A.1 -Harrell Pkwy Contech Pedestrian Underpass Procurer 160 0 17-Jul-24A 23Jan-25A 100% :3N1;-:ieriell.Pkvwy?Con. . . . . . . iiari U0 A5250 3A.1 -Harrell Pkwy Pedestrian Bridge Procurement 180 35 31-Jul-24A 08-Apr-25 80.56% 523 ;3A.t;Ham6ll R"Pektri Brido$ R 2-Lakeview 250 140 14-Oct-24 A 05-Sep-25 44% 16 r2;L'ekdvieW: Issues&Constraints Design Budgeting 60%Lakeview Drawngs 0 0 0°� 0 GIVIP Pre-Constructil• Buy-Out and Contract-Administration 0 0 0% 0 Construction �� • 1 ,Constrtxlicar; LKVW-129 Construction(See Lakeview Construction Schedule) 250 140 14-Oct-24 A 05-Sep-25 44% 16 ;Canl;tt cboln(SAe;LmdView 3A.1 -Harrell Pkwy,Lakeview Parking&Apex Fields Relocation 310 220 21-Oct-24A 02Jan-26 29.03% 20 ;3A 1; Pkwy.Lmke Issues&Constraints Design Budgeting JF Package 3A.1 30%Drawings 0 0 0% o -fl-T-i i-T"i l"f l"T-i l-ri-T'i 9-ri-T-i l-'r Package 3A.1 60%Drawings 0 0 0% 0 Start Date: 15-Jan-24 f— Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 Remaining Work � Summary WBS Layout-All Activities SpawGlass Data Date: 19-Feb-25 w.— Critical Remaining Work — Level of Effort Page 1 of 7 Run Date: 19-Feb-25 Activity I D Activity Name • . Rem start Finlsh % Total FloatDur Dur iart AIL GMP • �. • —Buy-Out and ContractAdrrinWration U 0 — — 0% 0 3A.1-140 Construction(See Harrell Parkway Construction Schedule) 310 220 21-Od-24A 02-Jan-26 29.03% 20 ;Canstrurtion;(Seee;Harre 3A.2-Harrell Pkwy 138 95 08-Jan-25A 02-Jul-25 31.16% 363 HajrrsllA" Issues&Constraints MINE DesignBudgeting � Package 3A.2 30%Drawings 0 0 0% 0 Package 3A.2 60%Drawings 0 0 0% 0 pp •,' Mp A5370 CoRR provide approval for recommended subcontractors 5 0 08-Jan-25 A 14-Jan-25 A 100% prpryiee,rapproysl f4 reG4n!►Crend4d ' Pre-Construction • pre�C'.onstrua3ioar Buy-Out and Contract Administration 25 0 15Jan-25A 18-Feb-25A 100% guX-Out i3hd CoriradtAalrj iniiaiabdri A2110 SG administer contracts to subcontractors for Package 3A.2 10 0 15-Jan-25A 28Jan-25 A 100% SG administer c6nir66W to Wboritra60 f A2120 Subcontractors review SG subcontract for Package 3A.2 5 0 29-Jan-25 A 04-Feb-25 A 100% SUbt 6ntrkdtdrd 0616W SG Wbbcfnibr� for A2130 SG finalize and execute subcontracts for Package 3A.2 5 0 05-Feb-25 A 11-Feb-25 A 100% �' SGiAalize;ahtl *ecut@ 5rido0rttrgCt4 for A2140 Mobilization of preliminary subcontractors for Package 3A.2 5 0 12-Feb-25 A 18-Feb-25 A 100% preIMrmty:sut)cpntrapWcs f _L!_11---J_L!_1_l J_L!_1_L J_L!_1_._J.-,L Submittals 40 0 19-Feb-25A 15-Apr-25A 100% Nbrrjitlais; A2150 "Submittals-Long lead materials for Package 3A.2(Elec,a 40 0 19-Feb-25 A 15-Apr-25 A 100% . � i3el,rt'iitka)sL i_prjg;1*:nr04ripl jbf, Procurement 0 0 0% 0 Construction ��®®® � • . �Constiuctioit Northern Section 95 95 19-Feb-25 A 02-Jul-25 0% 225 Northenh 96"H A5290 Demolition of existing site elements 20 15 19-Feb-25 A 11-Mar-25 25% 28 b bemdlifrort of 6"irio srte elements A5300 Underground utilities 40 40 19-Feb-25 15-Apr-25 0% 28 Uhdeoduhd irtllilds: ; A5320 Construct roadway and sidewalks 70 70 26-Mar-25 02-Jul-25 0% 225 ;Ccln$Wttrogdmii B d;sid&MIks; Southern Section 0 0 0% o . Mid Section o 0 0% o i_r i-T";"i"r i-T-.-i-r i-T i'-r i- Punchlist/Closeout 0 0 0% 0 3A.3-Harrell Pkwy(Bridge) 101 23 14-Oct-24A 21-Mar-25 77.23% 165 Uz2l,-HarrWl Pkw ,(Bridgo); Start Date: 15-Jan-24 f� Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 mo=o Remaining Work V====17 Summary WBS Layout-All Activities Data Date: 19-Feb-25 i.� Critical Remaining Work — Level of Effort Page 2 of 7 Run Date: 19-Feb-25 Activity I D Activity Name Orig Rem Start Finish % Total 1 1 • 2027 Dur Dur Float issues& • 1 1 1' 1 Design �® S165 Design A2220 Development of Package 3A.3 100%Drawings 24 2 14-Oct-24 A 20-Feb-25 91.67% 14 OW Deiraklpmsnt:4 08clk8ge:3J4:3;10p46A� A2230 SG receipt of Package 3A.3 100%Drawings(Target Date 11 1 1 21-Feb-25 21-Feb-25 0% 14 6G;it Opio(of Gkpg�$Aj$1001K C}rpvpir! A2240 City review of Package 3A.3 100%Drawings 10 10 24-Feb-25 07-Mar-25 0% 165 City:rr31iAjewof Aedcage3l�. 1b0°k Drawl A2250 Final plan revisions for Package 3A.3 10 10 10-Mar-25 21-Mar-25 0% 165 :o: :FinAl iah beVi gssfbr:PadraoA 3A.3 Package 3A.3 30%Drawings 0 0 0% 0 Package 3A.3 60%Drawings 0 0 0% 0 VGMP A2330 SG provide constructability review comments on 100%Pack 5 5 24-Feb-25 28-Feb-25 0% 14 :SG provldb bortstnlcla�bCitf�r hWibW COMMO A2340 Conduct page flip meeting reviewing 100%Package 3A.3 d 1 1 03-Mar-25 03-Mar-25 0% 14 + ;d6np6ct pag4 flip Triels it :r�vieyuing 100 ! ! !_1_'_!_L!_1_'_'_L!_ Buy-Out and Contract Administration 0 0 0% 0 Submittals 0 0 0% 0 Procurement 0 0 0% 0 Construction 3B-Tennis/Pk*Jeball 75 40 08-Jan-25A 15-Apr-25 46.67% 418 , , $1$1 '_l!_1_'_!_1_'_J_L!_1_'_J_l!_1 Issues&Constraints ��-■-� 1 Design Budgeting Package 3B-Tennis/Pickleball 30%°Drawings 0 0 0% 0 Package 3B-Tennis/Pickleball60%Drawings 0 0 0% 0 GIVIP r Buy-Out and Contract Administration 20 0 08-Jan-25A 04-Feb-25A 100% j yy }uk jr�d;C ojt c$lldrrjirjisjtr. . A2850 SG administer contracts to subcontractors for Package 313- 5 0 08-Jan-25 A 14-Jan-25 A 100% 00G0rili6i00c:PM:0 o,s'Ui' *0ojs;fp A2860 Subcontractors review SG subcontract for Package 36-Ten 5 0 15-Jan-25 A 21 Jan-25 A 100% 5uboontiactors reviewSGsuboontiad for p A2870 SG finalize and execute subcontracts for Package 313-Tenn 5 0 22-Jan-25 A 28Jan-25 A 100% SG flnl3ltz6 9rld dxbute dubk ohVdcts;fdr A2880 Mobilization of preliminary subcontractors for Package 36-1 5 0 29-Jan-25 A 04-Feb-25 A 100% :Mobilitatibn 0f:plydimih2ry SUIDOO&UdOrB tc Submittals 40 20 05-Feb-25A 18-Mar-25 50% 438 SUbmittads ; Start Date: 15-Jan-24 f— Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 c=- Remaining Work Summary WBS Layout-All Activities ' Data Date: 19-Feb-25 wo. iiiiiiiiiiiiii Critical Remaining Work o Level of Effort Page 3 of 7 Run Date: 19-Feb-25 Activity I D Activity Name Ong Rem Start Finish % Total 202512027 Dur Dur Float A2890 "Submittals-Long lead materials for Package 36-Tennis/ 40 20 05-Feb-25 A 18-Mar-25 50% 438 "'SU4ms-�OnS bad;materials foT Pa Procurement o 0 0% 0 • 1 1Pns�rV9R A5590 Demolition of existing site elements 10 0 05-Feb-25 A 18-Feb-25 A 100% ...of le ng>fit. . . .n. .. A5600 Earthwork/Pad Prep for Courts 45 30 19-Feb-25 A 15-Apr-25 33.33% 12 i� �arttwork 1 I?ad F7rep for Couits 3B-Maintenance Area 57 30 06-Jan-25A 01-Apr-25 47.37% 25 ••- :36-MJaihthAdnbdArb9 Design • 1 Package 3B-Maintenance Area 30%Drawings 0 0 0% o Package 3B-Maintenance Area 60%Drawings 0 0 0% 0 Package 3B-Maintenance Area 90%Drawings o 0 0% 0 i ®®i 1. j. 1 :laliAR A3180 SG provide constructability review comments on 100%Pack 5 0 06-Jan-25A 10-Jan-25A 100% pd�iride dohStrUE tJility r�vlelNi cbinhibittJ; A3190 Conduct page flip meeting reviewing 100%Package 313-M. 1 0 13-Jan-25 A 13-Jan-25 A 100% Cbriduct Pagel ftipl meeaing rt3vievong:1100%: A3200 SG solicit 100%Package 313-Maintenance Area for GMP 15 0 04-Feb-25 A 12-Feb-25 A 100% isplipt i0b'/•;P"biiii$4',Maintonan A3210 SG compile GMP for Package 36-Maintenance Area from 4 0 13-Feb-25 A 18-Feb-25 A 100% 1; ;oprjtpil�GMP fpr;P!ap�agq$� lyl�ir}tp A3220 SG submit GMP for Package 3B-Maintenance Area 1 0 19-Feb-25 A 19-Feb-25A 100% sutirnit GMp foa PBokaae;3g-Main A3230 Owner/Design Team review GMP for Package 3B-Mainter 5 5 19-Feb-25 25-Feb-25 0% 24 0&6r:/D" ri Tebrh sviaWGMRf6r:P A3240 SG review comments for Package 36-Maintenance Area G 4 4 26-Feb-25 03-Mar-25 0% 24 M ;id"viCohriniehts,for Padogel 313- A3250 SG resubmit Package 313-Maintenance Area GMP 1 1 04-Mar-25 04-Mar-25 0% 24 ? ;$(3 ieS milli Package 313-:Ma r0gnanQe' A3260 Owner forward Package 313-Maintenance Area GMP to Col 5 5 05-Mar-25 11-Mar-25 0% 24 p A5460 CoRR City Council approval process for Package 313-Main 15 15 12-Mar-25 01-Apr-25 0% 25 ;d :C6R "i Oourial apprdvaCpioo¢ss;fo Buy-Out and Contract Administration 10 10 12-Mar-25 25-Mar-25 0% 24 ;Bud Ort ahtl CbdtfaCtAtl�ninistr�tibd A3270 SG conduct buy-out meetings for preliminary scopes of work 10 10 12-Mar-25 25-Mar-25 0% 24 :ci :SG ebrhdubGW t1thieb6rigS fol pr�Urr i Submittals o 0 0% o - _ - Procurement 0 0 0% o .................... . . , Construction 3C-Rock'N River 310 280 08-Jan-25 A 27-Mar--26 9.68% 178 :3C,-RWN RWr: ConstraintsIssues& Start Date: 15-Jan-24 Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 r Remaining Work Summary WBS Layout-All Activities ' e / Data Date: 19-Feb-25 rrwiiiiiiiiiiiiii Critical Remaining Work Level of Effort Page 4 of 7 Run Date: 19-Feb-25 Activity I D Activity Name • Rem Start Finish % Total 202512027 Dur Dur Float Design 1 1' 1 �� ■-® 1 Budgeting Package 3C-Rock'N River 30%Drawings 0 0 0% 0 Package 3C-Rock'N River 60%Drawings 0 0 0% 0 GMP r Buy-Out and Contract Administration an-25A 11-Feb-25 A 100% B,,wre� d and A3710 SG administer contracts to subcontractors for Package 3C- 10 0 08-Jan-25 A 21-Jan-25A 100% $0aldmintsWr contmcWto sL4)e4ntmcitUrs fb A3720 Subcontractors review SG subcontract for Package 3C-Roc 5 0 22Jan-25 A 28-Jan-25 A 100% *3 iUW*1r44 fot Ey A3730 SG finalize and execute subcontracts for Package 3C-Roc 5 0 29-Jan-25 A 04-Feb-25 A 100% SG firiatize and iXebjte skibcontrii its for p A3740 Mobilization of preliminary subcontractors for Package 3C-f 5 0 05-Feb-25 A 11-Feb-25 A 100% : Mbbillzilitbh bf drglitnlnlw�y40i tr`aftbrls f Submittals 40 35 12-Feb-25A 08-Apr-25 12.5% 423 'SUbtnfttfal8' A3750 "Submittals-Long lead materials for Package 3C-Rock'N 40 35 12-Feb-25 A 08-Apr-25 12.5% 423 a= ;"Subtnfttglg,Long faad"Oteliald fbr P Procurement 0 0 0% 0 A5950 Earthwork!Building Pads 90 90 19-Feb-2525Jun-25 0% 3 ;Eadhwotk:/Building Pada ; A5960 Underground Utilities/MEP Rough-In 100 100 14-May-25 03-Oct-25 0% 3 Qtoitjes(M 15 A5970 Concrete Foundations 60 60 11-Jul-25 03-Oct-25 0% 3 'o C onp tja Fptjr>rt�tjojtd A5980 Structural Steel 80 80 08-Sep-25 02Jan-26 0% 3 to ; trNtrtll;sjttjel A6000 Mason /Stucco 90 90 03-Nov-25 13-Mar-26 0% 43 o I�Ir��ojtyiltuo; A602 i hes 60 60 17-Dec-25 13-Mar-26 0% 43 , , o; finishes 0 Finishes A6060 Punchlist and Closeout/Commissioning 30 30 16-Feb-26 27-Mar-26 0% 3 o AjnGhk�r 3C-Rec Center Complex-Site 55 30 20-Dec-24 A 01-Apr-25 45.45% 29 f ep C�ntnr,�. . . .e. $i�e Issues&Constraints D- • �� —�� Budgeting _L J_L_L J._L1_1_i 1_L J_1_i J_L!_1_'-J-L! Package 3C-Rec Center Complex-Site 30%Drawings 0 0 0% 0 Package 3C-Rec Center Complex-Site 60%Drawings 0 0 0% 0 A4090 Owner/Design Team review GMP for Package 3C-Rec Ce 5 0 20-Dec-24 A 14-Jan-25 A 100% {tri r/Clgslgn: 94M ipyiovy i pddcn A4100 SG review comments for Package 3C-Rec Center Comple 4 0 15-Jan-25A 20Jan-25 A 100% SG rreview:cornilnbrits foY Nic kage 3CI-Rec Start Date: 15-Jan-24 f— Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 c=- Remaining Work WcO!�W Summary WBS Layout-All Activities Data Date: 19-Feb-25 am- Critical Remaining Work Level of Effort Page 5 of 7 Run Date: 19-Feb-25 Activity I D Activity Name • Rem Start Finish % Total 20251 D Dur Float A4110 SG resubmit Package 3C-Rec Center Complex-Site GMF 1 0 21 Jan-25 A 21 Jan-25 A 100% ;SIG;resubmit Package 3C:-Roc CenterG`o A4120 Owner forward Package 3C-Rec Center Complex-Site GK 5 0 22-Jan-25 A 28Jan-25 A 100% Cujrt¢�fgrwglrp p�kge, � Iec Geptpr A5760 CoRR City Council approval process for Package 3C-Rec 30 0 29-Jan-25 A 13-Feb-25A 100% CoRFt Cky'Counal;apprWal prokiess for P A5770 SG provide CoRR list of recommended priority subcontracto 1 0 14-Feb-25A 14-Feb-25 A 100% SG ptoiritlb CgRR IM df:rdcbrhinbrlided p A5780 CoRR provide approval for recommended subcontractors 5 5 17-Feb-25A 11-Mar-25 0% 29 Q: CORR proVide:apprDvad for i'Mandef _T_:_2_T__l_f _T__l_r__ __I_f__T-:-I'-f ctiprY l' Pre-C. . : Pteonstro Buy-Out and ContractAdministration 45 30 29-Jan-25 A 01,Apr--25 33.33% 29Suy-'Qut and;gontraotAd'rrtanistmtion A4130 SG conduct buyout meetings for preliminary scopes of work 20 10 29-Jan-25A 04-Mar-25 50% 29 1q :30 condLict bWpput meetings fqr pge6min A4140 SG administer contracts to subcontractors for Package 3C- 10 10 12-Mar-25 25-Mar-25 0% 29 adjnlnls}etgtfr�ks tpcjbpgrjtr�Gtkt A4150 Subcontractors review SG subcontract for Package 3C-Rec 5 5 26-Mar-25 01-Apr-25 0% 29 a Sub¢ontradors rWi"SG su'boontrakit f Submittals 0 0 0% 0 NJ Procurement 0 0 0% 0 Construction 3C-Rec Center Complex-Buildings 61 49 16-Deo-24 A 28-Apr-25 19.67% 99FW:3'C:-P.At C13dtdr:Co."f :adildihos: Issues&Constraints QO �� Design ; •• ;Deed ' A6290 Development of Package 3C-Rec Center Complex 90%D 38 20 16-Dec-24A 18-Mar-25 47.37% 52 : Dbelop"Ot of PelckElgb 3C;-RM C6rlt A6300 SG receipt of Package 3C-Rec Center Complex 90%Drav 1 1 19-Mar-25 19-Mar-25 0% 52 1: SG:receiptaf Padkage:31Q-:Ret 090t6t A6340 City review of Package 3C-Rec Center Complex 90%Drav 10 10 20-Mar-25 02-Apr-25 0% 99 I,q :did reivilaW pt O=WQo 3C�Rec�@rtta A6350 Development of Package 3C-Rec Center Complex 100%1 18 18 03-Apr-25 28-Apr-25 0% 99 qc. , n:geC-Rec Center Complex-Buildings 30%Drawings 0 0 0% 0 C-Rec Center Complex-Buildings 60%Drawings 0 0 0% 0 A6510 SG provide constructability review comments on 90%Padka- 5 5 20-Mar-25 26-Mar--25 0% 52 SG provide ckiristruk ability ie�iew comrn A6550 Conduct page flip meeting reviewing 90%Package 3C-Re, 1 1 27-Mar-25 27-Mar-25 0% 52 : t :CohdJd oaoA flip fniebtin$IeVib�uih�90 A6520 SG solicit 90%Package 3C-Rec Center Complex for GMP 15 15 28-Mar-25 17-Apr-25 0% 52 : P: SG Wlidt 90°19 Packdgb 3C:-RbC C6rit Pre-Construction Buy-Out and Contract Administration 0 0 0% 0 Submittals 0 0 0% 0 : : . -f l'T'i TT'i 1-fl-T'i l'f--T-i l-r'�'i'i 1-r'' Procurement 0 0 0% 0 Start Date: 15-Jan-24 fiiiiiiiiiii Actual Work ♦ ♦ Milestone CoRR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 c=i=—a Remaining Work Summary WBS Layout-All Activities Data Date: 19-Feb-25 f� Critical Remaining Work — Level of Effort Page 6 of 7 Run Date: 19-Feb-25 Activity I D Activity Name Cirig Rem Start Finish % Total 1 1 D Dur Float Construction 1 1 1' 1 3D-Multi-Purpose Center Expansion 118 55 10Sep-24 A 06-May-25 53.39% 96 ;3A MUltOurpo'n tenter'Evansion Issues&Constraints Design �� 1 �il�iii� n Design , A4280 Development of Package 3D-Mufti-Purpose Center Expan! 43 0 10-Sep-24 A 04-Feb-25 A 100% ;t�evsbpment Of;Pacloge D+MGId-�U A4290 SG Receipt of Package 3D-Multi-Purpose Center Expansic 1 0 05-Feb-25 A 05-Feb-25 A 100% ;$ iedeiat gf;PppcpgQ 3Ci Njl�ltj-I�yrpgsp A4300 City review of Package 3D Multi-Purpose Center Expansioi 10 0 06-Feb-25 A 19-Feb-25 A 100% �atjl�evievr of a kege 3d Multi-(.4rpc" A4310 Development of Package 3D-Multi-Purpose Center Expan: 25 25 02-Apr-25 06-May-25 0% 96 Ddvftori qnt bf;Pad4a$6 3D:IWuIG-f? Bux Package 3D-MuftWurpose Center Expansion 30%Drawings 0 0 0% 0 Package 3D-Mult-Purpose Center Expansion 60%Drawings 39 30 06-Feb-25A 01-Apr-25 23.08% 96 ;Pafckage 3D MUM.PWPOWGentht A4450 SG provide constructability review comments on 60%Packa 5 0 06-Feb-25 A 12-Feb-25 A 100% Cohjtputt9bit 1' r64i"aommlen A4460 Conduct page flip meeting reviewing 60%Package 3D-Mu 1 0 13-Feb-25A 13-Feb-25A 100% G6e4uGtpa9e f6p meeting reVieOng;6U!/d A4470 SG solicit 60%Package 3D-Multi-Purpose Center Expansk 15 15 14-Feb-25 A 11-Mar-25 0% 96 6: $0�41io:Q'0 pat-ka90$D-MOu K A4480 SG compile pricing for 60%Package 3D-Multi-Purpose Cei 4 4 12-Mar-25 17-Mar-25 0% 96 1 SG:cgmpile 006n§dor 80%peaksge 311 A4490 SG submit budgetary pricing for 60%Package 3D-Multi-Pu 1 1 18-Mar-25 18-Mar-25 0% 96 C SG;sOrrl'rt:butlo"I 0ritih0 fot60°A ft A4500 Owner provide comments on 60%Package 3D-Mufti-Purpc 5 5 19-Mar-25 25-Mar-25 0% 96 K ;0M@r,phMd6 o0rnr0dnts;W:60%:Pa A4510 SG revise 60%Package 3D-Mufti-Purpose Center Expansi 5 5 26-Mar-25 01-Apr-25 0% 96 ; 1 ;S(3 r6'-' 0*.'Padiag@ sD L 44lti-Pu Buy-Out and Contract Administration 0 0 0% 0 Submittals 0 0 0% 0 Procurement 0 0 0% 0 3D.1 -Far Eastern Fields 0 0 0% 0 3D.2-Middle Fields/Aux Building 0 0 0% 0 3D.3-Far Western Fields/Club House o 0 0% 0 Overall 3D 0 0 0% 0 Start Date: 15-Jan-24 Actual Work ♦ ♦ Milestone CORR OSP - Preconstruction Schedule Finish Date: 08-Mar-27 —o Remaining Work Vc=� 9 Summary WBS Layout-All Activities Data Date: 19-Feb-25 fiiiiiiiiiii Critical Remaining Work Level of Effort Page 7 of 7 Run Date: 19-Feb-25 amw r We OF a Providing the Absolute Best Construction Experience 1 Bid Proposal Package Strategy City of Round Rock - Old Settler's Park Build Out Package 3B - Maintenance Yard 100% CD Drawings 3300 E Palm Valley Blvd Round Rock, TX 78665 Long Lead Time Equipment and Material PEMB's would be the only long lead item at this time. Construction Document Packages Multiple packages will not be required to satisfy material procurement and/or drawing development. Proposal Package Strategy The project will be advertised for proposals from suppliers, subcontractors, and vendors for all major features of work. Proposals shall be received via mail, email, courier, or hand delivered from subcontractors and suppliers. Any addendums that may be required will be issued one week prior to receiving proposals. The respondents will be evaluated on the subcontractors' ability to perform the work. Subcontractors will be recommended based on their company's personnel and corporate qualifications. SpawGlass will recommend the best value supplier and/or subcontractor to the Owner for concurrence prior to negotiating their contract. z r 'ref s :x r SpawGlass Contractors, Inc. 1111 Smith Road Austin, TX 78721 r ' 512-719-5251 SpawGlass.com ® 73/5/2025 E(MM'DD YYYY) AC OROCERTIFICATE OF LIABILITY INSURANCE THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Mlrta Tamez Adams Risk Management Services, LLC PHONE FAX Adams Insurance Service, Inc. (AC.No,Ext): (713)869-8346 (A/C,No):(713)869-9144 1111 North Loop W, Suite 600 ADDRESS: mtamez@adamsins.com Houston TX 77008 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:American Contractors Insurance Co.RRG 12300 INSURED SGADMIN-01 INSURER B:ACIG Insurance Company 19984 SpawGlass Contractors, Inc. 1 111 Smith Road INSURER C:Valley Forge Insurance Company 20508 Austin, TX 78721 INSURER D:The Continental Insurance Company 35289 INSURER E:Travelers Lloyds Insurance Company 41262 INSURER F: XL Insurance America, Inc. 24554 COVERAGES CERTIFICATE NUMBER:502582730 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR LTAPOLICY EFF POLICY EXP POLICY NUMBER MM'DD/YVYY MM DD/YYVV LIMITS A X COMMERCIAL GENERAL LIABILITY Y Y GL24ABC00046 6/1/2024 6/1/2025 EACH OCCURRENCE _ $10,000,000 DAMAGE TO RENTED - ----- -- CLAIMS MADE X OCCUR PREMISES(Ea occurrence _ _$100,000 MED EXP(Any one person) s5,000 PERSONAL it ADV INJURY s 10,000,000 GEN'L AGGREGATE LIMIT APPLIES PER GENERAL AGGREGATE $10,000,000 X PRO- POLICYE LOC PRODUCTS COMP/OP AGG $10,000,000 OTHER. $ C AUTOMOBILE LIABILITY Y Y BUA7033775896 6/1/2024 6/1/2025 COMBINED SINGLE LIMIT $5,000.000 LEA accident) X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ _ AUTOS ONLY , AUTOS X HIRED X NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY (Per accident) D UMBRELLA LIAS X OCCUR Y Y CUE7034067095 6/1/2024 6/1/2025 EACH OCCURRENCE $10,000,000 X EXCESS LIAB CLAIMS MADE AGGREGATE $10,000,000 DED RETENTION$ $ B WORKERS COMPENSATION Y WCA000008324 6/1/2024 6/1/2025 X PER OTH AND EMPLOYERS'LIABILITY Y/N _ ___STATUTE _ ER ANYPROPRIETORPARTNER'EXECUTIVE rNI E.L.EACH ACCIDENT $1,000,000 OFFICER;MEMBER EXCLUDE N/A - - - - (Mandatory in NH) E.L.DISEASE-EA EM_PLOYEE $1,000,000_ _ If yes,describe under DESCRIPTION OF OPERATIONS below E L DISEASE POLICY LIMIT $1,000,000 E CONTRACTORS EQUIPMENT QT-630-7625B35-0-TLC-24 6/1/2024 6/1/2025 LEASEDrRENTED SEE BELOW F BUILDERS RISK(BROAD FORM) US00116369CA24A 6/1/2024 6/1/2025 PROJECT AMOUNT <$10.000,000 SEE PAGE 2. DESCRIPTION OF OPERATIONS'LOCATIONS VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached it more space is required) Contractors Equipment Continued: Per Item:$1,500,000 Aggregate:$3,000,000 The Automobile policy includes the following endorsements: 1)CNA63359-Blanket Additional Insured as required by written contract executed prior to the bodily injury or property damage.2)CNA63359-Blanket Waiver of Subrogation as required by written contract executed prior to the bodily injury or property damage. 3)CNA63359 8 CNA71527-Primary Non-Contributory basis only when required by a written contract prior to Accident or Loss.4)CNA68021 -Notice of Cancellation-30 days blanket as required by written contract. See Attached... CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Round Rock 221 East Main Street AUTM RIZED REPRESENTATIVE Round Rock TX 78644 ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: SGADMIN-01 LOC#: A`ORO ADDITIONAL REMARKS SCHEDULE Page 1 of 1 AGENCY NAMED INSURED Adams Risk Management Services, LLC SpawGlass Contractors, Inc. 1111 Smith Road POLICY NUMBER Austin,TX 78721 CARRIER NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: CERTIFICATE OF LIABILITY INSURANCE The General Liability policy includes the following endorsements: 1)1170-Additional Insured-Automatic Status as required by Contract-Blanket-Who is an insured is amended to include as Additional Insured any person or organization when you have agreed in a written contract that such person or organization be added as an additional insured on your policy.The endorsement also provides for the coverage to apply on a primary and non-contributory basis for ongoing and completed operations when required by written contract.2)205-Blanket Waiver of Subrogation when required In a written contract or agreement.3)336- Notice of Cancellation,Nonrenewal or Material Change-30 days blanket as required by written contract.4)9-Aggregate Limits of insurance Per Project. The Workers'Compensation policy includes the following endorsements: 1)WC990304-Waiver of Subrogation-Blanket waiver for any person or organization for whom the named insured has agreed in a written contract to furnish the waiver.2)WC420601 -Notice of Cancellation-30 days blanket as required by written contract. The Umbrella/Excess Liability policy applies in excess and follows form of the underlying General Liability,Automobile Liability and Employers Liability policies above including the terms of any additional insured,waiver of subrogation and 30 day notice of cancellation endorsements.The policy follows the terms and conditions of such underlying policies unless they are inconsistent with the terms of the policy. The Equipment Floater policy includes a Blanket Automatic Loss Payee Endorsement CMU618 that provides Loss Payee status to the Certificate Holder only when there is a written contract between the Named Insured and the Certificate Holder that requires such status. Re.Project:Old Settler's Park Buildout, Package 313—Maintenance Yard 100%CD Drawings,3300 E.Palm Valley Blvd.,Round Rock,TX 78665 Project Amount:$2,181,620.00. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD ADDITIONAL INSURED - AUTOMATIC STATUS 170 AS REQUIRED BY CONTRACT - BLANKET This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Any person or organization that you are required by written contract to include as an additional insured on this policy if the contract is executed prior to the loss. A. Section II,Who Is An Insured is amended to include as an additional insured any person or organization shown in the above SCHEDULE (called additional insured), but only with respect to liability for"bodily injury","property damage"or"personal and advertising injury"arising out of your premises or your operations for the additional insured, and only to the extent and for the minimum limits required in the written contract. B. The insurance provided to the additional insured is subject to the following limitations: 1. Unless a written contract specifically requires additional insured coverage for your completed operations,this insurance does not apply to"bodily injury"or"property damage"occurring after"your work"for the additional insured has been completed or after that portion of "your work"out of which the"bodily injury"or"property damage"arises has been put to its intended use by any person or organization, whichever occurs first. 2. Unless specifically required by written contract,this insurance provides additional insured coverage only for liability for"bodily injury", "property damage"or"personal and advertising injury"to the extent caused by the named insured's acts or omissions or the acts or omissions of those acting on the named insured's behalf. 3. This insurance does not apply to"bodily injury","property damage"or"personal and advertising injury"for which the additional insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement except to the extent that the additional insured would have been obligated to pay such damages in the absence of the contract or agreement. 4. This insurance does not apply to"bodily injury", "property damage"or"personal and advertising injury"arising out of the rendering or failure to render any professional services by any insured or on any insured's behalf,including: a) The preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders,change orders,drawings or specifications;or b) Supervisory,inspection,architectural, or engineering services. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment,training or monitoring of others by that insured,if the"occurrence"which caused the"bodily injury" or"property damage",or the offense which caused the"personal and advertising injury", involved the rendering of, or the failure to render, any professional architectural,engineering or surveying services. 5. This endorsement shall not apply to a person or organization if any other additional insured endorsement attached to this policy specifically applies to that person or organization. 6. The insurance afforded herein only applies to the extent permitted by applicable state law, including statutes governing additional insured coverage in the construction industry. 7. The insurance afforded to the additional insured shall not exceed the minimum limits required in the written contract. C. In no event shall the insurance provided to the additional insured exceed the minimum coverage required by the written contract,including but not limited to minimum limits,minimum scope of coverage,or minimum duration of coverage. If a written contract or agreement requires that additional insured status be provided by the use of specified edition dates of the ISO CG2010 and/or CG2037,then the terms of that endorsement are incorporated into this endorsement as respects such additional insured and shall supersede the coverage grant and limitations in Sections A. and B. of this endorsement. In the event that CG2010 and/or CG2037 are required but no edition dates are specified,the 04/13 editions shall apply. D. This insurance is excess to any other insurance, whether primary, excess, contingent or on any other basis, available to the additional insured unless a written contract requires that this insurance be primary or primary and non-contributing.However,this insurance is always excess to other insurance,whether primary, excess,contingent or on any other basis,when the additional insured has been added to the other insurance as an additional insured. Nothing herein contained shall be held to vary,alter,waive or extend any of the terms,conditions, provisions,agreements or limitations of the mentioned Policy,other than as above stated. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 6/1/2024 Policy No.: GL24ABC00046 Insured: SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Insurance Company: American Contractors Insurance Company Risk Retention Group 205 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Persons or Organization(s): Any person or organization for whom you have agreed by written contract to furnish this waiver. Section IV—Commercial General Liability Conditions, 14. Transfer of Rights of Recovery Against Others to Us Condition is amended by the addition of the following: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or"your work" done under a contract with that person or organization and included in the "products-completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 6/1/2024 Policy No.: GL24ABC00046 Insured: SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc.,Westland Equipment and Supplies, LLC Insurance Company: American Contractors Insurance Company Risk Retention Group 336 NOTICE OF CANCELLATION, NONRENEWAL OR MATERIAL CHANGE - CERTIFICATE HOLDERS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART The certificate of insurance holders shown in the schedule below have requested that they receive written notice of cancellation, nonrenewal or material change with respect to this policy. If we decide to cancel, nonrenew or make a material change to this policy, we agree to mail or deliver sixty (60) days advance written notice to the certificate of insurance holders shown in the schedule below. However, if we are cancelling or nonrenewing due to nonpayment of premium, we will only provide the certificate of insurance holders shown in the schedule below with ten (10) days advance written notice. The notice of cancellation, nonrenewal or material change will be mailed to the addresses provided to us by the certificate of insurance issuer. Proof of mailing will be considered sufficient proof of our good faith attempt to provide notice of cancellation, nonrenewal or material change to the certificate of insurance holders shown in the schedule below. SCHEDULE All certificate of insurance holders where written notice of cancellation, nonrenewal or material change to this policy is required by written contract, permit or agreement with the Named Insured. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 6/1/2024 Policy No.: GL24ABC00046 Insured: SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Insurance Company: American Contractors Insurance Company Risk Retention Group 9 AGGREGATE LIMITS OF INSURANCE (PER PROJECT) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART It is hereby understood and agreed the General Aggregate Limit under Section III, Limits of Insurance of the Coverage Form applies separately to each of your projects away from premises owned by or rented to you. Nothing herein contained shall be held to vary, alter, waive or extend any of the terms, conditions, provisions, agreements or limitations of the mentioned Policy, other than as above stated. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Policy Effective: 6/1/2024 Policy No.: GL24ABC00046 Insured: SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Insurance Company: American Contractors Insurance Company Risk Retention Group CNASpawGlass Contractors,Inc.,SpawGlass Construction Corp., Business Auto Policy SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,LLC CONTRACTORS EXTENDED COVERAGE ENDORSEMENT • PLUS THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM I. LIABILITY COVERAGE A. Who Is An Insured The following is added to Section II, Paragraph A.1., Who Is An Insured: 1. a. Any incorporated entity of which the Named Insured owns a majority of the voting stock on the date of inception of this Coverage Form; provided that, b. The insurance afforded by this provision A.1. does not apply to any such entity that is an insured under any other liability "policy" providing auto coverage. 2. Any organization you newly acquire or form, other than a limited liability company, partnership or joint venture, and over which you maintain majority ownership interest. The insurance afforded by this provision A.2.: a. Is effective on the acquisition or formation date, and is afforded only until the end of the policy period of this Coverage Form, or the next anniversary of its inception date, whichever is earlier. b. Does not apply to: (1) Bodily injury or property damage caused by an accident that occurred before you acquired or formed the organization; or 12► Any such organization that is an insured under any other liability "policy" providing auto coverage. 3O4ny person or organization that you are required by a written contract to name as an additional Insured is an insured but only with respect to their legal liability for acts or omissions of a person, who qualifies as an insured under SECTION II — WHO IS AN INSURED and for whom Liability Coverage is afforded under this policy. If required by written contract, this insurance will be primary and non-contributory to insurance on which the additional insured is a Named Insured. 4. An employee of yours is an insured while operating an auto hired or rented under a contract or agreement in that employee's name, with your permission, while performing duties related to the conduct of your business. "Policy", as used in this provision A. Who Is An Insured, includes those policies that were in force on the inception date of this Coverage Form but: 1. Which are no longer in force; or 2. Whose limits have been exhausted. B. Bail Bonds and Loss of Earnings Section II, Paragraphs A.2. (2) and A.2. (4) are revised as follows: 1. In a.(2), the limit for the cost of bail bonds is changed from $2,000 to $5,000; and 2. In a.(4), the limit for the loss of earnings is changed from $250 to $500 a day. Form No: CNA63359XX (04-2012) Policy No: BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06/01/2024 a Copyright CNA All Rights Reserved. Includes copyrighted material of the CPF Business Auto Policy Policy Endorsement C. Fellow Employee Section II, Paragraph B.5 does not apply. Such coverage as is afforded by this provision C. is excess over any other collectible insurance. 11. PHYSICAL DAMAGE COVERAGE A. Glass Breakage - Hitting A Bird Or Animal - Falling Objects Or Missiles The following is added to Section 111, Paragraph A.3.: With respect to any covered auto, any deductible shown in the Declarations will not apply to glass breakage if such glass is repaired, in a manner acceptable to us, rather than replaced. B. Transportation Expenses Section III, Paragraph A.4.a. is revised, with respect to transportation expense incurred by you, to provide: a. $60 per day, in lieu of $20; subject to b. $1,800 maximum, in lieu of $600. C. Loss of Use Expenses Section III, Paragraph A.4.b. is revised, with respect to loss of use expenses incurred by you, to provide: a. $1,000 maximum, in lieu of $600. D. Hired "Autos" The following is added to Section III. Paragraph A.: 5. Hired "Autos" If Physical Damage coverage is provided under this policy, and such coverage does not extend to Hired Autos, then Physical Damage coverage is extended to: a. Any covered auto you lease, hire, rent or borrow without a driver; and b. Any covered auto hired or rented by your employee without a driver, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. The most we will pay for any one accident or loss is the actual cash value, cost of repair, cost of replacement or $75,000, whichever is less, minus a $500 deductible for each covered auto. No deductible applies to loss caused by fire or lightning. d. The physical damage coverage as is provided by this provision is equal to the physical damage coverage(s) provided on your owned autos. e. Such physical damage coverage for hired autos will: (1) Include loss of use, provided it is the consequence of an accident for which the Named Insured is legally liable, and as a result of which a monetary loss is sustained by the leasing or rental concern. (2) Such coverage as is provided by this provision will be subject to a limit of $750 per accident. E. Airbag Coverage The following is added to Section III, Paragraph B.3.: The accidental discharge of an airbag shall not be considered mechanical breakdown. Form No: CNA63359XX (04-2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06/01/2024 Copyright CNA All Rights Reserved. Includes copyrighted material of the CNA Business Auto Policy Policy Endorsement F. Electronic Equipment Section III, Paragraphs B.4.c and B.4.d. are deleted and replaced by the following: c. Physical Damage Coverage on a covered auto also applies to loss to any permanently installed electronic equipment including its antennas and other accessories d. A $100 per occurrence deductible applies to the coverage provided by this provision. G. Diminution In Value The following is added to Section III, Paragraph B.6.: Subject to the following, the diminution in value exclusion does not apply to: a. Any covered auto of the private passenger type you lease, hire, rent or borrow, without a driver for a period of 30 days or less, while performing duties related to the conduct of your business; and b. Any covered auto of the private passenger type hired or rented by your employee without a driver for a period of 30 days or less, under a contract in that individual employee's name, with your permission, while performing duties related to the conduct of your business. c. Such coverage as is provided by this provision is limited to a diminution in value loss arising directly out of accidental damage and not as a result of the failure to make repairs; faulty or incomplete maintenance or repairs; or the installation of substandard parts. d. The most we will pay for loss to a covered auto in any one accident is the lesser of: (1) $5,000; or (2) 20% of the auto's actual cash value (ACV). III. Drive Other Car Coverage — Executive Officers The following is added to Sections II and III: 1. Any auto you don't own, hire or borrow is a covered auto for Liability Coverage while being used by, and for Physical Damage Coverage while in the care, custody or control of, any of your "executive officers", except: a. An auto owned by that "executive officer" or a member of that person's household; or b. An auto used by that "executive officer" while working in a business of selling, servicing, repairing or parking autos. Such Liability and/or Physical Damage Coverage as is afforded by this provision. (1) Equal to the greatest of those coverages afforded any covered auto; and (2) Excess over any other collectible insurance. 2. For purposes of this provision, "executive officer" means a person holding any of the officer positions created by your charter, constitution, by-laws or any other similar governing document, and, while a resident of the same household, includes that person's spouse. Such "executive officers" are insureds while using a covered auto described in this provision. IV. BUSINESS AUTO CONDITIONS A. Duties In The Event Of Accident, Claim, Suit Or Loss The following is added to Section IV, Paragraph A.2.a.: Form No: CNA63359XX (04-2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06101/2024 a Copyright CNA All Rights Reserved. Includes copyrighted material of the CNA Business Auto Policy Policy Endorsement (4) Your employees may know of an accident or loss. This will not mean that you have such knowledge, unless such accident or loss is known to you or if you are not an individual, to any of your executive officers or partners or your insurance manager. The following is added to Section IV, Paragraph A.2.b.: 16) Your employees may know of documents received concerning a claim or suit. This will not mean that you have such knowledge, unless receipt of such documents is known to you or if you are cutive officers or partners or your insurance manager. B. Transfer Of Rights Of Recovery Against Others To Us e rap A.S. Transfer Of Rights Of Recovery Against Others To Us: We waive any right of recovery we may have, because of payments we make for injury or damage, against any person or organization for whom or which you are required by written contract or agreement to obtain this waiver from us. This injury or damage must arise out of your activities under a contract with that person or organization. You must agree to that requirement prior to an accident or loss. C. Concealment, Misrepresentation or Fraud The following is added to Section IV, Paragraph B.2.: Your failure to disclose all hazards existing on the date of inception of this Coverage Form shall not -Preludice gosect to the coverage afforded provided such failure or omission is not intentional. D. Other Insurance ed to Section IV, Paragraph B.S.: Regardless of the provisions of Paragraphs 5.a. and 5.d. above, the coverage provided by this policy shall be on a primary non-contributory basis. This provision is applicable only when required by a written contract. That written contract must have been entered into prior to Accident or Loss. E. Policy Period, Coverage Territory Section IV, Paragraph B. 7.(5).(a). is revised to provide: a. 45 days of coverage in lieu of 30 days. V. DEFINITIONS Section V. paragraph C. is deleted and replaced by the following: Bodily injury means bodily injury, sickness or disease sustained by a person, including mental anguish, mental injury or death resulting from any of these. Form No: CNA63359XX (04-2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06/01/2024 91 Copyright CNA All Rights Reserved. Includes copyrighted material of the CNA Business Auto Policy Policy Endorsement NOTICEOF • TO CERTIFICATEHOLDERS It is understood and agreed that: If you have agreed under written contract to provide notice of cancellation to a party to whom the Agent of Record has issued a Certificate of Insurance, and if we cancel a policy term described on that Certificate of Insurance for any reason other than nonpayment of premium, then notice of cancellation will be provided to such Certificateholders at least 30 days in advance of the date cancellation is effective. If notice is mailed, then proof of mailing to the last known mailing address of the Certificateholder on file with the Agent of Record will be sufficient to prove notice. Any failure by us to notify such persons or organizations will not extend or invalidate such cancellation, or impose any liability or obligation upon us or the Agent of Record. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy. SpawGlass Contractors,Inc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,LLC Form No: CNA68021 XX (02-2013) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06/01/2024 ®Copyright CNA All Rights Reserved. CNA Business Auto Policy Policy Endorsement • . . • . • • • _. I ti It is understood and agreed that this endorsement amends the BUSINESS AUTO COVERAGE FORM as follows: SCHEDULE Name of Additional Insured Person Or Organization ANY PERSON OR ORGANIZATION THAT YOU ARE REQUIRED BY WRITTEN CONTRACT OR WRITTEN AGREEMENT TO NAME AS AN ADDITIONAL INSURED 1. In conformance with paragraph A.1.c. of Who Is An Insured of Section II - LIABILITY COVERAGE, the person or organization scheduled above is an insured under this policy. 2. The insurance afforded to the additional insured under this policy will apply on a primary and non-contributory basis if you have committed it to be so in a written contract or written agreement executed prior to the date of the "accident" for which the additional insured seeks coverage under this policy. All other terms and conditions of the policy remain unchanged This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy. Form No: CNA71527XX (10-2012) Policy No:BUA 7033775896 Underwriting Company: Valley Forge Insurance Company Policy Effective Date: 06/0112024 Insured:SpawGlass Contractors,Inc.,SpawGlass Construction Corp., SpawGlass Civil Construction,Inc.,Westland Equipment and Supplies,LLC Copyright CNA All Rights Reserved. TEXAS WORKERS COMPENSATION AND EMPLOYERS LIABILITY POLICY WC 99 03 04 (Ed. 04-07) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3.A. of the Information Page. We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule, but this waiver applies only with respect to bodily injury arising out of the operations described in the Schedule where you are required by a written contract to obtain this waiver. This waiver does not extend to the statutory right of reimbursement from a claimant who recovers any amount under Section 417.002 of the Texas Labor Code. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule. The premium for this endorsement is shown in the Schedule. Schedule 1. ( ) Specific Waiver Name of person organization ( X ) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. This waiver does not extend to the statutory right of reimbursement under Section 417.002 of the Texas Labor Code. 2. Operations: CONSTRUCTION AND RELATED CONSTRUCTION RELATED WORK ALL TEXAS OPERATIONS 3. Premium: The premium charge of this endorsement shall be 2 percent of the premium developed on payroll in connection with work performed for the above person(s)or organization(s)arising out of the operations described. 4. Minimum Premium: $0 5. Advance Premium: $0 This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: Same as Policy Effective Date unless otherwise indicated above. Policy Effective Date: 6/1/2024 Policy No. WCA000008324 Insured SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Carrier Name/Code: ACIG Insurance Company WC 99 03 04 (Ed. 04-07) WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 42 06 01 (Ed. 03-13) TEXAS NOTICE OF MATERIAL CHANGE ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3.A. of the Information Page. In the event of cancelation or other material change of the policy, we will mail advance notice to the person or organization named in the Schedule. The number of days advance notice is shown in the Schedule. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule 1 . Number of days advance notice: 60 days. However, in the case of cancellation or nonrenewal due to nonpayment of premium, only 10 days advance notice will be provided. 2. Notice will be mailed to: All certificate holders where written notice of cancellation, nonrenewal or material change to this policy is required by written contract, permit or agreement with the Named Insured. The notice will be mailed to the addresses provided to us by the certificate of insurance issuer. Proof of mailing will be considered sufficient proof of our good faith attempt to provide written notice. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective 06/01/2024 Policy No. WCA000008324 Insured SpawGlass Contractors,Inc. , SpawGlass Construction Corp. , Premium$ SpawGlass Civil Construction, Inc. , Westland Equipment and Supplies, LLC Insurance Company ACIG Insurance Company WC 42 06 01 Wolters Kluwer Financial Services I Uniform Forms Page 1 of 1 (Ed.03-13) TM COMMERCIAL INLAND MARINE THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET LOSS PAYEES This endorsement modifies insurance provided under the COMMERCIAL INLAND MARINE COVERAGE PART The following is added to Section E — ADDITIONAL b. Pay any claim for loss or damage jointly to you COVERAGE CONDITIONS: and the Loss Payee as your interests may Loss Payable Provision appear. In the event of a Covered Cause of Loss to Covered This endorsement applies to all Covered Property for Property in which both you and a Loss Payee share which a Loss Payee is on file with us or your an insurable interest, we will: insurance agent or insurance broker. a. Adjust the loss or damage with you; and SpawGlass Contractors, Inc., SpawGlass Construction Corp., SpawGlass Civil Construction, Inc., Westland Equipment and Supplies, LLC Travelers Property& Casualty Co. Policy No. QT-630-7625635-0-TLC-24 CM U6 18 05 21 c)2021 The Travelers Indemnity Company Page 1 of 1 Includes copyrighted material of Insurance Services Office, Inc.with its permission.