Loading...
R-02-11-26-10D1 - 11/26/2002RESOLUTION NO. R- 02- 11- 26 -10D1 v WHEREAS, the City of Round Rock desires to retain engineering services for the G.O. Bond Project, Corridor Enhancement Program - Phase I, and WHEREAS, Fisher Hagood, Inc. has submitted an Agreement for Preliminary Engineering Services to provide said services, and WHEREAS, the City Council desires to enter into said agreement with Fisher Hagood, Inc., Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK, TEXAS, That the Mayor is hereby authorized and directed to execute on behalf of the City an Agreement for Preliminary Engineering Services with Fisher Hagood, Inc., for the G.O. Bond Project, Corridor Enhancement Program - Phase I, a copy of said agreement being attached hereto as Exhibit "A" and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date, hour, place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended RESOLVED this 26th day of November, c02 ATTEST: CHRISTINE R. MARTINEZ, City Secretary ∎ ODMA\ XORLDOX\ 0 + \"DOX\RESOLUTI \R21126DL.NPD /,c WELL, Mayor of Round Rock, Texas ROUND ROCK, TEXAS PURPOSE PASSION PROSPERITY THE STATE OF TEXAS COUNTY OF WILLIAMSON CITY OF ROUND ROCK AGREEMENT FOR PRELIMINARY ENGINEERING SERVICES WITH FISHER HAGOOD, INC. 1 RECITALS: Contract No. Iv EXHIBIT Re: McNeil Corridor Enhancement Program Development THIS AGREEMENT FOR ENGINEERING SERVICES ( "Agreement ") is made and entered into on this the twelfth (12 day of the month of December, 2002, by and between the CITY OF ROUND ROCK, a Texas home -rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664 -5299, (hereinafter referred to as "City"), and Fisher Hagood, Inc. whose principal place of business is located at One Chisholm Trail, Suite 5200, Round Rock, Texas 78681, (hereinafter called "Engineer "), and such Agreement is for the purpose of contracting for professional engineering services. WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW, THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: CONTRACT DOCUMENTS The Contract Documents consist of this Agreement and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Agreement) and all Supplemental Agreements (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Agreement as if attached to this Agreement or repeated herein. ARTICLE 1 SCOPE OF SERVICES TO BE PERFORMED BY CITY City shall perform or provide services as identified in Exhibit A entitled "Services to be Performed by City." ARTICLE 2 SCOPE OF SERVICES TO BE PERFORMED BY ENGINEER Engineer shall perform engineering services as identified in Exhibit B entitled "Services to be Performed by Engineer." Engineer shall perform the mutually acceptable schedule of work as identified in Exhibit C entitled "Work Schedule." Such Work Schedule contains a complete schedule so that the Engineer's Scope of Services under this Agreement may be accomplished within the specified time and specified not to exceed cost. The Work Schedule provides specific work sequences and definite review times by City and Engineer of all work performed. Should the review times take longer than shown on the Work Schedule, through no fault of Engineer, additional time may be authorized by City through a written Supplemental Agreement only if same is requested by a timely written request from Engineer which is approved by City. ARTICLE 3 CONTRACT TERM (1) Term. This Agreement shall be from the date hereof and shall terminate at the close of business on the Thirty -first day of the month of August, 2003, unless extended by written Supplemental Agreement executed by Engineer and City prior to the date of termination, or as otherwise terminated as provided in Article 20 entitled "Termination." Any work performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he /she /it determines, or reasonably anticipates, that the work under this Agreement will not be completed before the termination date. In that event City may, at its sole discretion, extend the contract term by timely written Supplemental Agreement. Engineer shall allow adequate time for review and approval of his/her /its request for time extension by City prior to expiration of this Agreement. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all services required under this Agreement in the highest professional manner. (3) Notice to Proceed. After execution of this Agreement, Engineer shall not proceed with work delineated in Article 2 entitled "Scope of Services to be Performed by Engineer" and in Exhibit B entitled "Services to be Performed by Engineer" until authorized in writing by City to proceed as provided in Article 7 entitled "Notice to Proceed." See Exhibit E entitled "Work Authorizations" for work authorization controls related to this agreement. 2 City shall pay and Engineer agrees to accept an amount not to exceed the amount shown below as full compensation for all engineering services performed and to be performed under this Agreement. The amount payable under this Agreement, without modification of the Agreement as provided herein, is the not to exceed sum of Thirty Thousand, Four Hundred Sixty Dollars and Forty -Eight Cents ($30,460.48) as shown in Exhibit D entitled "Fee Schedule." The exceed sum amount payable may be increased only by written Supplemental Agreement in the event of a change in scope, additional complexity from that originally anticipated, or change in character of work as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the work and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B entitled "Services to be Performed by Engineer." Satisfactory progress of work shall be maintained as an absolute condition of payment. The fee herein referenced may be adjusted for additional work requested and performed only if approved by written Supplemental Agreement. Professional Service's Contract -Fisher Iingood ARTICLE 4 COMPENSATION ARTICLE 5 METHOD OF PAYMENT Payments to Engineer for services rendered shall be made while work is in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of work accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and two (2) copies of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of work tasks identified in Exhibit D entitled "Estimated Fee Schedule." Progress payments shall be made by City based upon work actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which, notwithstanding anything herein to the contrary, is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory work performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her /its negligence. 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which City receives the supplies, materials, equipment, or within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for the supplies, materials, equipment, or services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply to payments made by City in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Agreement or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non - disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED City shall issue a written authorization to proceed with work identified in the Scope of Services. City shall not be responsible for actions by Engineer or any costs incurred by Engineer relating to additional work not included in Exhibit B entitled "Services to be Performed by Engineer." ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Agreement is as follows: William J. Dobrowolski 111, PE, Senior Engineer 2008 Enterprise Drive Round Rock, Texas 78664 (512) 218 -6601 Office (512) 218 -5563 Fax City's Designated Representative shall be authorized to act on City's behalf with respect to this project. 4 City or City's Designated Representative shall render decisions in a timely mariner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineer's services. Engineer's Designated Representative for purposes of this Agreement is as follows: Fisher Hagood, Inc. Attention: Terry R. Haygood, PE, Principal One Chisholm Trail, Suite 5200 Round Rock, Texas 78681 (512) 244 -1546 ext 12 Office (512) 388 -3698 Fax ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the work, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the work. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of Engineer's services and work. Should City determine that the progress in production of work does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the work, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to attain program objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the work schedule goals sooner than anticipated. ARTICLE 10 SUSPENSION Should City desire to suspend the work, but not to terminate this Agreement, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty -day notice may be waived in writing by agreement and signature of both parties. The work may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the work. Such sixty-day notice may be waived in writing by agreement and signature of both parties. Professional Service's Contract- Fisher Hagood 5 If City suspends the work, the contract period as determined in Article 3 is not affected and this Agreement will terminate on the date specified unless this Agreement is amended indicating otherwise. City assumes no liability for work performed or costs incurred prior to the date authorized by City for Engineer to begin work, and /or during periods when work is suspended, and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL WORK If Engineer forms a reasonable opinion that any work he/she /it has been directed to perform is beyond the scope of this Agreement and as such constitutes extra work, he/she /it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Agreement will be executed between the parties as provided in Article 13 entitled "Supplemental Agreements." Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Agreement. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the work authorized in this Agreement or any amendments thereto. ARTICLE 12 CHANGES IN WORK ARTICLE 13 SUPPLEMENTAL AGREEMENTS 6 If City deems it necessary to request changes to previously satisfactorily completed work or parts thereof which involve changes to the original scope of services or character of work under this Agreement, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional work and paid for as specified under Article 11 entitled "Additional Work." Engineer shall make revisions to work authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such work. The terms of this Agreement may be modified by written Supplemental Agreement if City determines that there has been a significant change in (1) the scope, complexity or character of the service to be performed, or (2) the duration of the work. Any such Supplemental Agreement must be duly authorized by City Council Resolution. Where such City Council authorization is required, Engineer shall not proceed until the appropriate Resolution has been adopted. Additional compensation, if appropriate, shall be identified as provided in Article 4 entitled "Compensation." Both parties must execute any written Supplemental Agreement within the contract period specified in Article 3 entitled "Contract Term." It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until City grants full execution of the written Supplemental Agreement and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory work performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Agreement are the exclusive property of City and shall be furnished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Agreement. Engineer, at his/her /its own expense, may retain copies of such documents or any other data which he /she/it has furnished City under this Agreement. Any release of information shall be in conformance with requirements of the Texas Open Records Act. ARTICLE 15 PERSONNEL, EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at his/her /its own expense, quarters for the performance of all services, and adequate and sufficient personnel and equipment to perform the services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the work shall immediately be removed from association with the project when so instructed by City. Engineer certifies that he /she/it presently has adequate qualified personnel in his/her /its employment for performance of the services required under this Agreement, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the work under this Agreement without prior written approval from City. All subcontracts shall include the provisions required in this Agreement and shall be approved as to form, in writing, by City prior to work being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Agreement. ARTICLE 17 EVALUATION OF WORK City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the work performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. Professional Service's Contract-Fisher Hagood 7 ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Agreement, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Agreement may be terminated before the stated termination date by any of the following conditions. (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all services and obligations described herein. Should City terminate this Agreement as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the work performed by Engineer prior to termination, City shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should City terminate this Agreement under Subsection (4) immediately above, then the amount charged during the thirty (30) day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Agreement or if City terminates this Agreement for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the work to the date of default, the amount of work required which was satisfactorily completed to date of default, the value of the work which is usable to City, the cost to City of employing another firm to complete the work required and the time required to do so, and other factors which affect the value to City of the work performed at the time of default. 8 ARTICLE 21 COMPLIANCE WITH LAWS The termination of this Agreement and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Agreement, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Agreement is due to the failure of Engineer to fulfill his/her /its contractual obligations, then City may take over the project and prosecute the work to completion. In such case, Engineer shall be liable to City for any additional costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the scope of services under this Agreement. (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Agreement, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her /its compliance. Engineer shall further obtain all permits and licenses required in the performance of the professional services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her /itself and his/her /its agents or employees, performed under this Agreement, which are caused by or which result from error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such activities by Engineer, its agents, or employees. Professional Service's Contract - Fisher Hagood ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her /its work and shall promptly make necessary revisions or corrections resulting from errors, omissions, or negligent acts, and same shall be 9 done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON - COLLUSION, FINANCIAL INTEREST PROHIBITED (1) Non - collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Agreement, and that he /she /it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City reserves and shall have the right to annul this Agreement without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her /its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Agreement is in effect minimum professional liability insurance coverage in the amount of Five Hundred Thousand Dollars ($500,000.00) from a company authorized to do insurance business in Texas and otherwise acceptable to City. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Agreement to maintain during the term of the Agreement, at the subconsultant's own expense, professional liability insurance coverage in the amount of Five Hundred Thousand Dollars ($500,000.00), including the required provisions and additional policy conditions as shown immediately below in Subsection (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Agreement, and shall have the responsibility of enforcing these insurance 10 requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: (1) Each policy shall require that thirty (30) days prior to the expiration, cancellation, non - renewal or any material change in coverage, a notice thereof shall be given to City by certified mail to: (2) Companies issuing the insurance policies shall have no recourse against City for payment of any premiums or assessments for any deductibles which all are at the sole responsibility and risk of Engineer. (3) City Manager City of Round Rock 221 East Main Street Round Rock, Texas 78664 Engineer shall also notify City, within twenty-four (24) hours of receipt, of any notices of expiration, cancellation, non - renewal, or material change in coverage it receives from its insurer. The term "City" or "City of Round Rock" shall include all authorities, Boards, Commissions, Departments, and officers of City and the individual members, employees and agents thereof in their official capacities, and/or while acting on behalf of the City of Round Rock. (4) The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self- Insured Retentions of whatever nature. (5) Engineer and City mutually waive subrogation rights each may have against the other for loss or damage, to the extent same is covered by the proceeds of insurance. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such certificates of insurance are evidenced herein as Exhibit F entitled "Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. Professional Service's Contract - Fisher Hagood 11 City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 and to: ARTICLE 28 SUCCESSORS AND ASSIGNS This Agreement shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Agreement, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Agreement constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Agreement may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 33 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Agreement. ARTICLE 34 NOTICES All notices to either party by the other required under this Agreement shall be personally delivered or mailed to such party at the following respective addresses: 12 Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: Fisher Hagood, Inc. Attention: Terry R. Haygood, PE, Principal One Chisholm Trail, Suite 5200 Round Rock, Texas 78681 Professional Services Contract-Fisher Hagood ARTICLE 35 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the services for each phase of this Agreement within the agreed Work Schedule may constitute a material breach of this Agreement. Engineer shall be fully responsible for his/her /its delays or for failures to use his/her /its best efforts in accordance with the terms of this Agreement. Where damage is caused to City due to Engineer's failure to perform in these circumstances, City may withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Agreement if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Agreement shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Agreement shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. 13 ARTICLE 36 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he /she has executed this Agreement and that he /she has full and complete authority to enter into this Agreement on behalf of the firm. The above - stated representations and warranties are made for the purpose of inducing City to enter into this Agreement. IN WITNESS WHEREOF, the City of Round Rock has caused this Agreement to be signed in its corporate name by its Mayor, duly authorized to execute the same on its behalf by Resolution No. , approved by the City Council on the day of the month of 200_, and Engineer, signing by and through his/her /its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK, TEXAS: By: Mayor ATTEST: By: City Secretary ENGINEER: By: By: ignature of 12rincipal Printed Name: Terry R. Haygood, PE Principal, Fisher Hagood, Inc. ATTEST: 14 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development LIST OF EXHIBITS ATTACHED (1) Exhibit A "Services to be Performed by City" (2) Exhibit B "Services to be Performed by Engineer" (3) Exhibit C "Work Schedule" (4) Exhibit D "Fee Schedule" (5) Exhibit E "Work Authorizations" (6) Exhibit F "Certificates of Insurance" Professional Service's Contract-Fisher Hagood 15 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT A - Services to be Performed by City The scope of services to be performed by the City is to facilitate the scope of services shown in Exhibit B, by administering this contract, reviewing the work performed by the Engineer, accepting the Engineer's McNeil Corridor Enhancement Program. Specifically: 1. ROUTE STUDY a. Collection of available information 1) Review Existing Records for Potential: a) Provide available information on Survey Conflicts b) Provide available information on Linc of Sight Problems c) Provide available information on Ownership Problems d) Provide available information on ROW or Easement Problems 2) Walk through entire project for Determination of a) Provide available information on existing Corridor Enhancements b) Provide available information on existing Line of Sight Problems c) Provide available information on potential Accessibility Issues d) Provide available information on existing water, waste water, drainage, and other existing utilities b. Provide GIS files for pertinent areas of the project c. Provide hard and digital copies of aerial photographs with ortho contours and existing parcel overlay for pertinent areas. d. Provide timely reviews and guidance 2. COORDINATION WITH POTENTIAL PARTICIPATING ENTITIES a. Identification and Initial Contact I) Help Identify Parties (Railroad, Companies, HOAs, EAA, etc.) 2) Help Identify Contact Points 3) Help Initial Contact Schedule and Coordinate Meeting 4) Help Schedule and Coordinate Meetings 5) Attend Meetings b. Participation Scope 1) Help Develop Plan 2) Help Presentation & Negotiation of Plan 3) Help Develop Memorandums of Understanding 4) Help Schedule and Coordinate Meetings 5) Attend Meetings c. Provide timely reviews and guidance 3 PRESENTATION OF CONCEPTUAL RECOMMENDATIONS Provide timely reviews and guidance 4. CITIZEN PARTICIPATION a. Provide timely reviews and guidance b. Help Schedule and Coordinate Meetings c. Attend Meetings 16 The scope of services to be performed by the Engineer is to facilitate the scope of services shown in Exhibit A, by performing the preliminary engineering studies & calculation, coordinating surveying, environmental studies & reports, and coordinating, required to develop the McNeil Corridor Enhancement Program. Specifically: GENERAL CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT B - Services to be Performed by Engineer (Page I of 3) • The work effort and the management for the project included in this contract will be for the most part conducted in Round Rock, Texas. • The engineer will be readily accessible to the City of Round Rock staff and will meet with the City's project manager as necessary. • Monthly progress reports will be submitted, which will detail on -going work as well as work accomplished since the previous report. • When feasible, the City's standard drawings and specifications of previously approved special provisions/specifications will be utilized. • If a special provision or special specification must be developed under this contract, it shall be in the City's format, and to the extent possible, incorporate references to the City's approved test procedures. • The plan sheets will adhere in format and content to current City of Round Rock (CORR) standards. • The Engineer is fully responsible for any traffic control required from any data collection activities. Professional Service's Contract - Fisher Hagood.doc 17 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT B - Services to be Performed by Engineer (Page 2 of 3) 1. ROUTE STUDY a. Collection of available information 1) Review Existing Records for Potential: a) Survey Conflicts b) Line of Sight Problems c) Ownership Problems d) ROW or Easement Problems 2) Walk through entire project for Determination of a) Existing Corridor Enhancements b) Existing Line of Sight Problems c) Potential Accessibility Issues d) Drainage Concerns e) Conflicts: utility, irrigation, trees, etc. b. Report c. City Review 2. COORDINATION WITH POTENTIAL PARTICIPATING ENTITIES a. Identification and Initial Contact 1) Identify Parties (Railroad, Companies, HOAs, EAA, etc.) 2) Identify Contact Points 3) Initial Contact b. Participation Scope 1) Develop Plan 2) Presentation & Negotiation of Plan 3) Develop Memorandums of Understanding c. Report d. City Review 18 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT B - Services to be Performed by Engineer (Page 3 of 3) 3. PRESENTATION OF CONCEPTUAL RECOMMENDATIONS a. Preparation of schematic plan 1) Develop Potential Grand Scope of Project 2) Develop Presentation Documents 3) First Refine Scope of Project based on Participation Amount b. Preliminary cost estimate on First Refined Scope c. Report d. City Review (Status Meeting) 4. CITIZEN PARTICIPATION a. Develop a Communication Plan b. Report c. City Review d. Initial contact public notice /meeting e. Media outreach Professional Service's Contract- Fisher Hagood 19 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT C - Work Schedule (Behind this page) 20 CLASSIFICATION SALARY RATE HOURLY RATE* PROFIT ® 15% TOTAL STANDARD RATE Princiapl Project Manager $ 46.00 $ 155.02 $ 23.26 $ 178.28 Engineer $ 38.00 $ 128.06 $ 19.21 $ 147.27 Technician $ 28.85 $ 97.22 $ 14.59 $ 111.81 Field Representative $ 22.00 $ 74.14 $ 11.13 $ 85.27 Clerical $ 18.55 $ 62.51 $ 9.38 $ 71.89 CLASSIFICATION TOTAL STANDARD RATE TOTAL EXPERT TESTIMONY RATE* Princiapl Project Manager $ 178.28 $ 222.85 Engineer $ 147.27 $ 184.09 Technician $ 111.81 $ 139.76 Field Representative $ 85.27 $ 106.59 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT D - Fee Schedule (Page 1 of 2) HOURLY RATE SCHEDULE ourly rates are based on salary costs with a 2.37 multiplier. EXPERT TESTIMONY, IF REQUIRED BY THE CITY MINIMUM 4 HOURS PER DAY * Rates are based on "Total Standard Rate" with a 1.25 multiplier. Professional Service's Contract-Fisher Ilagood 21 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT D - Fee Schedule (Page 2 of 2) LABOR COSTS ,a { Total Direct Overhead Labor + Fixed Fee Qa Labor ® 237% Overhead 15% Total Cost Route Study $531.00 $1,258.47 $1,789.47 $ 268.42 $ 2,057.89 Coordination with participation entities 81,072.00 $2,540.64 $3,612.64 $ 541.90 $ 4,154.54 Presentaion of preliminary recommendations $814.00 $1,929.18 $2,743.18 $ 411.48 $ 3,154.66 Citizens participation $984.00 $2,332.08 $3,316.08 $ 497.41 $ 3,813.49 Total Labor Costs $3,401.00 $8,060.37 $11,461.37 $ 1,719.21 $ 13,180.58 DIRECT COST Expenses Reproduction Copies - 8.5811 Copies - 1 1 x 17 Mileage Mail & Deliveries Total Expenses Subcontracts , Hall Bargainer Total Subcontracts Total Direct Costs Administration 10% Maximum Direct Costs TOTAL COMPENSATION FOR BASIC SERVICES NOT TO EXCEED: $ 30,460.48 22 $ 1,000.00 $ 14,709.00 $ 14,709.00 $ 15,709.00 $ 1,570.90 $ 17,279.90 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT E - Work Authorizations (Behind this page) Professional Service's Contract-Fisher Hagood 23 • • / 5411APMCSIJOIRICII ACZN.VPIGI/EFROCAVICNES ROAD C0401100/1 EN11/411MAIEFITPI7OG II 12. 11/11 -_ \ ' 095; • 1 . - - , , N W+E S Corridor Enhancement Program Phase 1 ROOD ROCK TEXAS rt,,,,,nssa. nannw x • • / 5411APMCSIJOIRICII ACZN.VPIGI/EFROCAVICNES ROAD C0401100/1 EN11/411MAIEFITPI7OG II 12. 11/11 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT F - Certificates of Insurance (Behind this page) 24 o- 1 11/14/2002 17:01 FAX 5122185563 CORR PUBLIC WORKS - NOV -14 2002 4:49Ph,1, , ; FISHER HR000D, INC. CERTIFICATE OF 4d148IUTY INSURANCE ozNEAALunnaATY el5aRA2 12/01/01 12'01/02 stTT0N0E0911ABI127 660ICIIA2152 12/01/01 12 01/02 A c IDOCIO3111430A7 600822V4091 12/01/91 32.01/02 avosscese• colon esArt{N osahlActoYIDer imam 6I0 izcort 430 1.2/01/01 12 01/02 DESCSISITOti 08 OPPMATiON3nocAmo.vvoccuodsracts I n'23 'SPTIOal 310VAN i SHEETS 244 -1010 Tlete: sof3.1102 1.200 10ER COMPANIES AFF08DMI CO VERAQE T eas 23ooc. ataa iDenrars A Barr -ford 710pd's• Ins Co 1114 T.OSt Creek D1.2d, 440a Avatin. Tx 78746 13 1art$Ord Inn co r,4reat ] NSDREriletert liagc,od, Iran C Eareerd 90deXNritQY3 one Chisholm Tr, 020D Bound Rack, Ts D Continental Ca6ualtp THIS ]8 TO CELRTIFY TArsT :1u Eams°daam'°d abaoc 4 b eared by the Catmmim listed above with lopped to the of the rt � a ada r rd pd :�c by mmQ,mior, sad Earths hars,n r dcsmbed. Fs°Pti0n. t the policies oetcd hclow. CO TYPE OFINEIJR +NCE POLICY ETFECTIVE EXPIRATLQY WEIS LTR NDIFIUER DATE DATE arAMUSaeclamAs2e s 2000000 64002)4 4e0147QO Mks. 2000000 PWONALACADY.IIaXY 0 1006000 EACH acCtWJt lce 51000000 1Zt8DASS426(my to are) 5 300000 X60.1121231432 (AV= Pte) $ 10002 c0{S80ID ELME ours 1 1000000 TnDS.rwrtacYO'c}.s.N 1 NDODYQOORYffv uplda0 2A0p64T/0AMAO6 0 2ACA 0DLS11URSiCYa AOGREKTA i (Awe l:a sco sO11C2 IAar COMM - EAca manor= 0500000 DmIDc D DADS LXAM xLay24Y3D 01.fLdf02 1 SO /Da A59. Pas Clain $500000 31000000 51000000 ooacoo = 500000 200000 The etty of Round Rook, nsa,d eat irswod wlh tcryxt t0 ;.L Kb=e0 aa WrAtn � o 6 and 2 1 5Aodd a,y etas ahava deaiul paiaeo bt c,nmxd or chanzei to days arinen notice to the catiLatte boWa n3med below CERTIFICATES POLDER: r.TTV NA NAr.22 CITY Or ROUND R0 C1: 221 E. NA/ N ST ROUND ROOK, I7L 73664 et . 'AUIHOYSZED i ' 4 ! /M! iaTee' Yak 8 IR 002 P.2 i + s 11/14/2002 THU 15:45 [TX/RX NO 5858] Ia002 • . . • 1 DATE: November 21, 2002 SUBJECT: City Council Meeting — November 26, 2002 • f ITEM: 10.D.1. Consider a resolution authorizing the Mayor to execute an Agreement for Preliminary Engineering Services with Fisher Hagood, Inc. for the G.O. Bond Project, Corridor Enhancement Program - Phase I. Resource: Jim Nuse, Director of Public Works William J. Dobrowolski III, Senior Engineer History: The City reviewed statements of intent and qualification from a number of engineering firms and preformed interviews with the qualifying companies. Fisher Hagood, Inc. was selected as the firm to provide engineering services for the McNeil Corridor Enhancement Program. McNeil is different form the other corridors in this G. 0. Bond program with the parallel railroad, business industry, and residential along the right -of -way, therefore a program needs to be developed tailored for this project. Funding: Cost: $ 30,460.48 Source of funds: Capital Project Funds (G. 0. Bond 2002) Outside Resources: Fisher Hagood, Inc. Impact/Benefrt: A program will be developed to scope the needed improvements along this high traffic Corridor into the City of Round Rock. Public Comment: N/A Sponsor: N/A " ROCK, TEXAS PURPOSE PASSION. PROSPERITY THE STATE OF TEXAS COUNTY OF WILLIAMSON R-0-11-11)-10D1 / CITY OF ROUND ROCK AGREEMENT FOR PRELIMINARY ENGINEERING SERVICES WITH FISHER HAGOOD, INC. NOW, THEREFORE, WITNESSETH: 1 Re: M Corridor Enhancement Program Development Contract No. THIS AGREEMENT FOR ENGINEERING SERVICES ( "Agreement ") is made and entered into on this the twelfth (12 day of the month of December, 2002, by and between the CITY OF ROUND ROCK, a Texas home -rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664 -5299, (hereinafter referred to as "City "), and Fisher Hagood, Inc. whose principal place of business is located at One Chisholm Trail, Suite 5200, Round Rock, Texas 78681, (hereinafter called "Engineer "), and such Agreement is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: CONTRACT DOCUMENTS The Contract Documents consist of this Agreement and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Agreement) and all Supplemental Agreements (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Agreement as if attached to this Agreement or repeated herein. ARTICLE 1 SCOPE OF SERVICES TO BE PERFORMED BY CITY City shall perform or provide services as identified in Exhibit A entitled "Services to be Performed by City." ARTICLE 2 SCOPE OF SERVICES TO BE PERFORMED BY ENGINEER Engineer shall perform engineering services as identified in Exhibit B entitled "Services to be Performed by Engineer." Engineer shall perform the mutually acceptable schedule of work as identified in Exhibit C entitled "Work Schedule." Such Work Schedule contains a complete schedule so that the Engineer's Scope of Services under this Agreement may be accomplished within the specified time and specified not to exceed cost. The Work Schedule provides specific work sequences and definite review times by City and Engineer of all work performed. Should the review times take longer than shown on the Work Schedule, through no fault of Engineer, additional time may be authorized by City through a written Supplemental Agreement only if same is requested by a timely written request from Engineer which is approved by City. ARTICLE 3 CONTRACT TERM (1) Term. This Agreement shall be from the date hereof and shall terminate at the close of business on the Thirty -first day of the month of August, 2003, unless extended by written Supplemental Agreement executed by Engineer and City prior to the date of termination, or as otherwise terminated as provided in Article 20 entitled "Termination." Any work performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he /she /it determines, or reasonably anticipates, that the work under this Agreement will not be completed before the termination date. In that event City may, at its sole discretion, extend the contract term by timely written Supplemental Agreement. Engineer shall allow adequate time for review and approval of his/her /its request for time extension by City prior to expiration of this Agreement. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all services required under this Agreement in the highest professional manner. (3) Notice to Proceed. After execution of this Agreement, Engineer shall not proceed with work delineated in Article 2 entitled "Scope of Services to be Performed by Engineer" and in Exhibit B entitled "Services to be Performed by Engineer" until authorized in writing by City to proceed as provided in Article 7 entitled "Notice to Proceed." See Exhibit E entitled "Work Authorizations" for work authorization controls related to this agreement. 2 ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept an amount not to exceed the amount shown below as full compensation for all engineering services performed and to be performed under this Agreement. The amount payable under this Agreement, without modification of the Agreement as provided herein, is the not to exceed sum of Thirty Thousand, Four Hundred Sixty Dollars and Forty -Eight Cents ($30,460.48) as shown in Exhibit D entitled "Fee Schedule." The exceed sum amount payable may be increased only by written Supplemental Agreement in the event of a change in scope, additional complexity from that originally anticipated, or change in character of work as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the work and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B entitled "Services to be Performed by Engineer." Satisfactory progress of work shall be maintained as an absolute condition of payment. The fee herein referenced may be adjusted for additional work requested and performed only if approved by written Supplemental Agreement. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer for services rendered shall be made while work is in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of work accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and two (2) copies of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of work tasks identified m Exhibit D entitled "Estimated Fee Schedule." Progress payments shall be made by City based upon work actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which, notwithstanding anything herein to the contrary, is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory work performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. The certified statements shall show the total amount eamed to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her /its negligence. Professional Services Contract- Fisher Hagood 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which City receives the supplies, materials, equipment, or within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the clay on which City receives a correct invoice for the supplies, materials, equipment, or services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply to payments made by City in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Agreement or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non - disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED City shall issue a written authorization to proceed with work identified in the Scope of Services. City shall not be responsible for actions by Engineer or any costs incurred by Engineer relating to additional work not included in Exhibit B entitled "Services to be Performed by Engineer." ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Agreement is as follows: William J. Dobrowolski III, PE, Senior Engineer 2008 Enterprise Drive Round Rock, Texas 78664 (512) 218 -6601 Office (512) 218 -5563 Fax City's Designated Representative shall be authorized to act on City's behalf with respect to this project. 4 City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineer's services. Engineer's Designated Representative for purposes of this Agreement is as follows: Fisher Hagood, Inc. Attention: Terry R. Haygood, PE, Principal One Chisholm Trail, Suite 5200 Round Rock, Texas 78681 (512) 244 -1546 ext 12 Office (512) 388 -3698 Fax ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the work, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the work. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of Engineer's services and work. Should City determine that the progress in production of work does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the work, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to attain program objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the work schedule goals sooner than anticipated. Professional Service's Contract - Fisher Hagood ARTICLE 10 SUSPENSION Should City desire to suspend the work, but not to terminate this Agreement, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty -day notice may be waived in writing by agreement and signature of both parties. The work may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the work. Such sixty-day notice may be waived in writing by agreement and signature of both parties. 5 If City suspends the work, the contract period as determined in Article 3 is not affected and this Agreement will terminate on the date specified unless this Agreement is amended indicating otherwise. City assumes no liability for work performed or costs incurred prior to the date authorized by City for Engineer to begin work, and/or during periods when work is suspended, and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL WORK If Engineer forms a reasonable opinion that any work he /she /it has been directed to perform is beyond the scope of this Agreement and as such constitutes extra work, he /she /it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Agreement will be executed between the parties as provided in Article 13 entitled "Supplemental Agreements." Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Agreement. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the work authorized in this Agreement or any amendments thereto. ARTICLE 12 CHANGES IN WORK If City deems it necessary to request changes to previously satisfactorily completed work or parts thereof which involve changes to the original scope of services or character of work under this Agreement, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional work and paid for as specified under Article 11 entitled "Additional Work." Engineer shall make revisions to work authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such work. ARTICLE 13 SUPPLEMENTAL AGREEMENTS The terms of this Agreement may be modified by written Supplemental Agreement if City determines that there has been a significant change in (1) the scope, complexity or character of the service to be performed, or (2) the duration of the work. Any such Supplemental Agreement must be duly authorized by City Council Resolution. Where such City Council authorization is required, Engineer shall not proceed until the appropriate Resolution has been adopted. Additional compensation, if appropriate, shall be identified as provided in Article 4 entitled "Compensation." Both parties must execute any written Supplemental Agreement within the contract period specified in Article 3 entitled "Contract Term." 6 It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until City grants full execution of the written Supplemental Agreement and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory work performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Agreement are the exclusive property of City and shall be furnished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Agreement. Engineer, at his/her /its own expense, may retain copies of such documents or any other data which he /she /it has furnished City under this Agreement. Any release of information shall be in conformance with requirements of the Texas Open Records Act. ARTICLE 15 PERSONNEL, EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at his/her /its own expense, quarters for the performance of all services, and adequate and sufficient personnel and equipment to perform the services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the work shall immediately be removed from association with the project when so instructed by City. Engineer certifies that he /she /it presently has adequate qualified personnel in his/her /its employment for performance of the services required under this Agreement, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. Engineer shall not assign, subcontract or transfer any portion of the work under this Agreement without prior written approval from City. All subcontracts shall include the provisions required in this Agreement and shall be approved as to form, in writing, by City prior to work being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Agreement. City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the work performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. Professional Service's Contract- Fisher Hagood ARTICLE 16 SUBCONTRACTING ARTICLE 17 EVALUATION OF WORK 7 ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Agreement, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Agreement may be terminated before the stated termination date by any of the following conditions. (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all services and obligations described herein. Should City terminate this Agreement as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the work performed by Engineer prior to termination, City shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should City terminate this Agreement under Subsection (4) immediately above, then the amount charged during the thirty (30) day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Agreement or if City terminates this Agreement for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the work to the date of default, the amount of work required which was satisfactorily completed to date of default, the value of the work which is usable to City, the cost to City of employing another firm to complete the work required and the time required to do so, and other factors which affect the value to City of the work performed at the time of default. 8 The termination of this Agreement and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Agreement, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Agreement is due to the failure of Engineer to fulfill his/her /its contractual obligations, then City may take over the project and prosecute the work to completion. In such case, Engineer shall be liable to City for any additional costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the scope of services under this Agreement. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Agreement, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her /its compliance. Engineer shall further obtain all permits and licenses required in the performance of the professional services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her /itself and his/her /its agents or employees, performed under this Agreement, which are caused by or which result from error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such activities by Engineer, its agents, or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her /its work and shall promptly make necessary revisions or corrections resulting from errors, omissions, or negligent acts, and same shall be Professional Services Contract- Fisher Hagood 9 done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON - COLLUSION, FINANCIAL INTEREST PROHIBITED (1) Non - collusion. Engineer warrants that he /she /it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Agreement, and that he /she /it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City reserves and shall have the right to annul this Agreement without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her /its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Agreement is in effect minimum professional liability insurance coverage in the amount of Five Hundred Thousand Dollars ($500,000.00) from a company authorized to do insurance business in Texas and otherwise acceptable to City. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Agreement to maintain during the term of the Agreement, at the subconsultant's own expense, professional liability insurance coverage in the amount of Five Hundred Thousand Dollars ($500,000.00), including the required provisions and additional policy conditions as shown immediately below in Subsection (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Agreement, and shall have the responsibility of enforcing these insurance 10 requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: (1) (3) (5) Each policy shall require that thirty (30) days prior to the expiration, cancellation, non - renewal or any material change in coverage, a notice thereof shall be given to City by certified mail to: City Manager City of Round Rock 221 East Main Street Round Rock, Texas 78664 Engineer shall also notify City, within twenty-four (24) hours of receipt, of any notices of expiration, cancellation, non - renewal, or material change in coverage it receives from its insurer. (2) Companies issuing the insurance policies shall have no recourse against City for payment of any premiums or assessments for any deductibles which all are at the sole responsibility and risk of Engineer. The term "City" or "City of Round Rock" shall include all authorities, Boards, Commissions, Departments, and officers of City and the individual members, employees and agents thereof in their official capacities, and/or while acting on behalf of the City of Round Rock. (4) The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self- Insured Retentions of whatever nature. Engineer and City mutually waive subrogation rights each may have against the other for loss or damage, to the extent same is covered by the proceeds of insurance. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such certificates of insurance are evidenced herein as Exhibit F entitled "Certificates of Insurance." City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. Professional Service's Contract- Fisher Hagood ARTICLE 27 COPYRIGHTS 11 This Agreement shall be binding upon and inure to the benefit of the parties hereto, their successors, Lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Agreement, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 and to: ARTICLE 28 SUCCESSORS AND ASSIGNS ARTICLE 29 SEVERABILITY ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Agreement constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Agreement may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 33 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Agreement. ARTICLE 34 NOTICES All notices to either party by the other required under this Agreement shall be personally delivered or mailed to such party at the following respective addresses: 12 Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: Fisher Hagood, Inc. Attention: Terry R. Haygood, PE, Principal One Chisholm Trail, Suite 5200 Round Rock, Texas 78681 Professional Services Contract- Fisher Hagood ARTICLE 35 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the services for each phase of this Agreement within the agreed Work Schedule may constitute a material breach of this Agreement. Engineer shall be fully responsible for his/her /its delays or for failures to use his/her /its best efforts in accordance with the terms of this Agreement. Where damage is caused to City due to Engineer's failure to perform in these circumstances, City may withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Agreement if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Agreement shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Agreement shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. 13 The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he /she has executed this Agreement and that he /she has full and complete authority to enter into this Agreement on behalf of the firm. The above - stated representations and warranties are made for the purpose of inducing City to enter into this Agreement. IN WITNESS WHEREOF, the City of Round Rock has caused this Agreement to be signed in its corporate name by its Mayor, duly authorized to execute the same on its behalf by Resolution No. 2 -O -II-a(a -/01)1 , approved by the City Council on the to day of the month of NOV Fm6E , 200 a , and Engineer, /= 13 14612 1111 GOOD �N C. signing by and through his/her /its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK, TE By: ATTEST: By: ENGINEER: By: ATTEST: By: M ARTICLE 36 SIGNATORY WARRANTY ignature of frncipal Printed Name: Terry R. Haygood, PE Principal, Fisher Hagood, Inc. 14 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development LIST OF EXHIBITS ATTACHED (1) Exhibit A "Services to be Performed by City" (2) Exhibit B "Services to be Performed by Engineer" (3) Exhibit C "Work Schedule" (4) Exhibit D "Fee Schedule" (5) Exhibit E "Work Authorizations" (6) Exhibit F "Certificates of Insurance" Professional Service's Contract- Fisher Hagood 15 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT A - Services to be Performed by City The scope of services to be performed by the City is to facilitate the scope of services shown in Exhibit B, by administering this contract, reviewing the work performed by the Engineer, accepting the Engineer's McNeil Corridor Enhancement Program. Specifically: 1. ROUTE STUDY a. Collection of available information 1) Review Existing Records for Potential: a) Provide available information on Survey Conflicts b) Provide available information on Line of Sight Problems c) Provide available information on Ownership Problems d) Provide available information on ROW or Easement Problems 2) Walk through entire project for Determination of a) Provide available information on existing Corridor Enhancements b) Provide available information on existing Line of Sight Problems c) Provide available information on potential Accessibility Issues d) Provide available information on existing water, waste water, drainage, and other existing utilities b. Provide GIS files for pertinent areas of the project c. Provide hard and digital copies of aerial photographs with ortho contours and existing parcel overlay for pertinent areas. d. Provide timely reviews and guidance 2. COORDINATION WITH POTENTIAL PARTICIPATING ENTITIES a. Identification and Initial Contact 1) Help Identify Parties (Railroad, Companies, HOAs, EAA, etc.) 2) Help Identify Contact Points 3) Help Initial Contact Schedule and Coordinate Meeting 4) Help Schedule and Coordinate Meetings 5) Attend Meetings b. Participation Scope I) Help Develop Plan 2) Help Presentation & Negotiation of Plan 3) Help Develop Memorandums of Understanding 4) Help Schedule and Coordinate Meetings 5) Attend Meetings c. Provide timely reviews and guidance 3. PRESENTATION OF CONCEPTUAL RECOMMENDATIONS Provide timely reviews and guidance 4. CITIZEN PARTICIPATION a. Provide timely reviews and guidance b. Help Schedule and Coordinate Meetings c. Attend Meetings 16 The scope of services to be performed by the Engineer is to facilitate the scope of services shown in Exhibit A, by performing the preliminary engineering studies & calculation, coordinating surveying, environmental studies & reports, and coordinating, required to develop the McNeil Corridor Enhancement Program. Specifically: GENERAL CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT B - Services to be Performed by Engineer (Page 1 of 3) • The work effort and the management for the project included in this contract will be for the most part conducted in Round Rock, Texas. • The engineer will be readily accessible to the City of Round Rock staff and will meet with the City's project manager as necessary. • Monthly progress reports will be submitted, which will detail on -going work as well as work accomplished since the previous report. • When feasible, the City's standard drawings and specifications of previously approved special provisions/specifications will be utilized. • If a special provision or special specification must be developed under this contract, it shall be in the City's format, and to the extent possible, incorporate references to the City's approved test procedures. • The plan sheets will adhere in format and content to current City of Round Rock (CORR) standards. • The Engineer is fully responsible for any traffic control required from any data collection activities. Professional Service's Contract- Fisher Hagood.doc 17 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT B - Services to be Performed by Engineer (Page 2 of 3) 1. ROUTE STUDY a. Collection of available information 1) Review Existing Records for Potential: a) Survey Conflicts b) Line of Sight Problems c) Ownership Problems d) ROW or Easement Problems 2) Walk through entire project for Determination of a) Existing Corridor Enhancements b) Existing Line of Sight Problems c) Potential Accessibility Issues d) Drainage Concerns e) Conflicts: utility, irrigation, trees, etc. b. Report c. City Review 2. COORDINATION WITH POTENTIAL PARTICIPATING ENTITIES a. Identification and Initial Contact 1) Identify Parties (Railroad, Companies, HOAs, EAA, etc.) 2) Identify Contact Points 3) Initial Contact b. Participation Scope 1) Develop Plan 2) Presentation & Negotiation of Plan 3) Develop Memorandums of Understanding c. Report d. City Review 18 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT B - Services to be Performed by Engineer (Page 3 of 3) 3. PRESENTATION OF CONCEPTUAL RECOMMENDATIONS a. Preparation of schematic plan 1) Develop Potential Grand Scope of Project 2) Develop Presentation Documents 3) First Refine Scope of Project based on Participation Amount b. Preliminary cost estimate on First Refined Scope c. Report d. City Review (Status Meeting) 4. CITIZEN PARTICIPATION a. Develop a Communication Plan b. Report c. City Review d. Initial contact public notice /meeting e. Media outreach Professional Service's Contract - Fisher Hagood 19 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT C - Work Schedule (Behind this page) 20 CLASSIFICATION SALARY RATE HOURLY RATE* PROFIT r® 15% TOTAL STANDARD RATE Princiapl Project Manager $ 46.00 $ 155.02 $ 23.26 $ 178.28 Engineer $ 38.00 $ 128.06 $ 19.21 $ 147.27 Technician $ 28.85 $ 97.22 $ 14.59 $ 111.81 Field Representative $ 22.00 $ 74.14 $ 11.13 $ 85.27 Clerical $ 18.55 $ 62.51 $ 9.38 $ 71.89 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT D - Fee Schedule (Page 1 of 2) HOURLY RATE SCHEDULE * Hourly rates are based on salary costs with a 2.37 multiplier. EXPERT TESTIMONY, IF REQUIRED BY THE CITY MINIMUM 4 HOURS PER DAY * Rates are based on "Total Standard Rate" with a 1.25 multiplier. Professional Service's Contract- Fisher Hagood 21 TOTAL TOTAL EXPERT CLASSIFICATION STANDARD TESTIMONY RATE RATE* Princiapl Project Manager $ 178.28 $ 222.85 Engineer $ 147.27 $ 184.09 Technician $ 111.81 $ 139.76 Field Representative $ 85.27 $ 106.59 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT D - Fee Schedule (Page 1 of 2) HOURLY RATE SCHEDULE * Hourly rates are based on salary costs with a 2.37 multiplier. EXPERT TESTIMONY, IF REQUIRED BY THE CITY MINIMUM 4 HOURS PER DAY * Rates are based on "Total Standard Rate" with a 1.25 multiplier. Professional Service's Contract- Fisher Hagood 21 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT D - Fee Schedule (Page 2 of 2) LABOR COSTS Route Study $531.00 $1,258.47 $1,789.47 $ 268.42 $ 2,057.89 Coordination with participation entities $1,072.00 $2,540.64 $3,612.64 $ 541.90 $ 4,154.54 Presentaion of preliminary recommendations $814.00 $1,929.18 $2,743.18 $ 411.48 $ 3,154.66 Citizens participation $984.00 $2,332.08 $3,316.08 $ 497.41 $ 3,813.49 Total Labor Costs $3,401.00 $8,060.37 $11,461.37 $ 1,719.21 $ 13,180.58 DIRECT COST Expenses Reproduction Copies - 8.5x11 Copies - 11x17 Mileage Mail & Deliveries Total Expenses Subcontracts Hall Bargainer Total Subcontracts Total Direct Costs Administration 10% Maximum Direct Costs Total Direct Overhead Labor + Fixed Fee @ Labor @ 237% Overhead 15% Total Cost TOTAL COMPENSATION FOR BASIC SERVICES NOT TO EXCEED: $ 30,460.48 22 $ 1,000.00 $ 14,709.00 $ 14,709.00 $ 15,709.00 $ 1,570.90 $ 17,279.90 CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT E - Work Authorizations (Behind this page) Professional Service's Contract- Fisher Hagood 23 II I k 1 . .") 7 ‘C)'W■ N Corridor Enhancement Program W+E ROUhD ROIX. TIDOS Phase / warceumsacto.srverrt S 3.1.41.105.0.1C11. AGFJOATN4IHEEP11.4.710L11.0 001.11.11D011 ENHANCEMENT PROO PLR 0. CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Fisher Hagood, Inc. McNeil Corridor Enhancement Program Development EXHIBIT F - Certificates of Insurance (Behind this page) 24 11/14/2002 17:01 FAX 5122185569 CORR PUBLIC WORKS - NOV -14 2002 4:49PM FISHER HRGOOD, INC. CERTIFICATE OF LIABILITY INSURANCE PROOtJL`6R Tezaa AaaOC'L.0..A0S IDS0.rcre 1114 2O.xt creak Blvd, 400 7Wltin, Tx 78746 c SYt535331A5io.0'r MAIM D PROS =AB 3.1X/34513u X Q flitAtOld971 12/01/02 12'01102 pVrOM0311132.01 Iit 75 6606CO5 222 12/01/01 12 01/02 6al717.71 02 /01/01 22.01/02 w10.0.0• GW Ra,1051eN AFD Q,gep1r/001.0.0711TY 0b2tato24430 51/01/01 12 01/02 DES thsn N OF OPEAT0105,3cA110101YB - 0 '6 8 100020 -. SHEETS 244 -1010 te : 9/11/02 CUMPAN1 2 AFEDIIDCIG CO VERAQS A Barceo14 7.107d'a IO2 CO S StlrtIord Ina Co OILthru0t C 6arttOrd tioderWritQ2s NSMIlimber, Aagalad, Iua One Chisholm T. /52014 Bound Recto. TX I) Continental Vardalty Co rips 13 TO CZRTWY T14. T the Tan+tedmmcd sbow 4 b avmd by the It Pared stove with ?Tact to the business operations hereinafter described, for tho tying of msuanao and in. accardaaCC with the provisamts 0f the ataoda[d palicim used by ,k sos 0ooies, and further heremudier dcsczsbed. Exceptions to the policies are noted below. CO TYPE OFINSURA`]CLr POLIYY EF C vE EXPIRATION 1.13,111S DATE S7.00W10-03Ot Aaa. 1130084LdAD IWORT EApi OCC170 It 1.20,0 Ue3E(AOTa c 8101 }GA IOP203 (Asp mcpF.4y cousa 33=LCLem 80Le.TfF1O GY 0crP Ii0O0.Y arruitir P.r v#dop vtatarvntmAas SACS 0CC[1RIENEE AGGREGATE YfATOTORY nacM SAnt ACCUBYI rt2SAea- POLICY MGT Etil tae.EACH n010"n" Bson0nn 01 /L0/O2 s 02/ 1 99= Paz clams $500000 3 2000000 + 2000000 1 1080000 3 100ODIC 5 300000 5 10000 3 1000000 51000000 s.ocoa00 5 000000 Y 500000 5 500000 The City of Round Roil is nms+d so z dditions! cstend rah sospC o to :.e pow 4 W01033' Coolcrusam1 2515009103'05' L1tht,Y• 015514 any oftbe thew doailn 0000paCOn thereat the if iimeoc7psny wit can at (30] days vaten notice se de oceiLot to helda:001d babe CERTIFICAT8 POLDER: CITY NANAr_F.x CITY OP ROUND ROGIL 221 E. 11AIN 1T ROUND ROOK, TX 73664 31t1NATJ ATNI50EIZED A '2 e lli !! ! r IFin _ I 0002 p. 2 11/14/2002 THU 15:45 [TX/RI NO 5858] 0002 Mayor Nyle Maxwell Mayor Pro-tem Tom Nielson City Manager Robert 1, Bennett, Jr City Attorney Stephan L Sheets ROUND ROCK, TEXAS PURPOSE. PASSION. PROSPERITY. January 14, 2003 Dear Mr. Hagood: Council Members Man McGraw Enclosure Carne Put Scot Knight Isabel Gallahan Gary Coe Christine R. Martinez City Secretary Mr. Terry Hagood, PE, Principal Fisher Hagood, Inc. One Chisholm Trail, Suite 5200 Round Rock, TX 78681 The Round Rock City Council approved Resolution No. R- 02- 11 -26- 10D 1 at their regularly scheduled meeting on November 26, 2002. This resolution approves the agreement for Preliminary Engineering Services for the G.O. Bond Project, Corridor Enhancement Program - Phase I. Enclosed is a copy of the resolution and original agreement for your files. If you have any questions, please do not hesitate to contact William Dobrowolski at 218 -6601. CITY OF ROUND ROCK 221 East Main Street • Round Rock, Texas 78664 Phone 512 218 5400 - Fax- 512 218.7097 • www ci round-rock tx us