Loading...
R-02-12-19-9D2 - 12/19/2002“oDNMwoRLoox \o. \woox MSOLUrx \n21219D2.wen /aC and r RESOLUTION NO. R 02 12 19 - 9D2 WHEREAS, the City of Round Rock desires to retain engineering services for the development of a stormwater management program to improve water quality by controlling polluted runoff from urban areas, WHEREAS, Camp Dresser & McKee, Inc. has submitted an Agreement for Engineering Services to provide said services, and WHEREAS, the City Council desires to enter into said agreement with Camp Dresser & McKee, Inc., Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK, TEXAS, That the Mayor is hereby authorized and directed to execute on behalf of the City an Agreement for Engineering Services with Camp Dresser & McKee, Inc., for the development of a stormwater management program to improve water quality by conrolling polluted runoff from urban areas, a copy of said agreement being attached hereto as Exhibit "A” and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date, hour, place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended. ArEST: RESOLVED this 19th day of December, 2002. CHRISTINE R. MARTINEZ, City Secret 2 Y WELL, Mayor y of Round Rock, Texas ROUND ROCK. TEXAS PURPOSE PASSION PROSPERITY THE STATE OF TEXAS COUNTY OF WILLIAMSON CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Camp Dresser & McKee Inc. (CDM) THIS AGREEMENT FOR ENGINEERING SERVICES ("Agreement") is made and entered into on this the day of the month of , 2002 by and between the CITY OF ROUND ROCK, a Texas home -rule municipal corporation, whose offices are Located at 221 East Main Street, Round Rock, Texas 78664 -5299, (hereinafter referred to as "City "), and Camp Dresser & McKee Inc. (CDM), a Massachusetts Corporation, whose principal place of business is located at One Cambridge Place, 50 Hampshire Street, Cambridge, MA 02139 , (hereinafter called "Engineer"), and such Agreement is for the purpose of contracting for professional engineering services. NOW, THEREFORE, WITNESSETH: RECITALS: 1 Contract No. WHEREAS, V.T.C.A., Govemment Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: CONTRACT DOCUMENTS The Contract Documents consist of this Agreement and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Agreement) and all Supplemental Agreements (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Agreement as if attached to this Agreement or repeated herein. EXHIBIT 111A 11 ARTICLE 1 SCOPE OF SERVICES TO BE PERFORMED BY CITY City shall perform or provide services as identified in Exhibit A entitled "Services to be Performed by City." ARTICLE 2 SCOPE OF SERVICES TO BE PERFORMED BY ENGINEER Engineer shall perform engineering services as identified in Exhibit B entitled "Services to be Performed by Engineer." Engineer shall develop a mutually acceptable schedule of work as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineer's Scope of Services under this Agreement may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all work performed. Should the review times take longer than shown on the Work Schedule, through no fault of Engineer, additional time may be authorized by City through a written Supplemental Agreement only if same is requested by a timely written request from Engineer which is approved by City. ARTICLE 3 CONTRACT TERM (1) Term. This Agreement shall be from the date hereof and shall terminate at the close of business on the 10th day of the month of June , 2003 , unless extended by written Supplemental Agreement executed by Engineer and City prior to the date of termination, or as otherwise terminated as provided in Article 20 entitled "Termination." Any work performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably anticipates, that the work under this Agreement will not be completed before the termination date. In that event City may, at its sole discretion, extend the contract term by timely written Supplemental Agreement. Engineer shall allow adequate time for review and approval of his/her /its request for time extension by City prior to expiration of this Agreement. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all services required under this Agreement in the highest professional manner. (3) Notice to Proceed. After execution of this Agreement, Engineer shall not proceed with work delineated in Article 2 entitled "Scope of Services to be Performed by Engineer" and in Exhibit B entitled "Services to be Performed by Engineer" until authorized in writing by City to proceed as provided in Article 7 entitled "Notice to Proceed." 2 City shall pay and Engineer agrees to accept the amount shown below as full compensation for all engineering services performed and to be performed under this Agreement. The amount payable under this Agreement, without modification of the Agreement as provided herein, is the sum of Fifty -Two Thousand and Seven Hundred Dollars and No Cents ($52,700.00) as shown in Exhibit D entitled "Fee Schedule." The lump sum amount payable may be revised only by written Supplemental Agreement in the event of a change in scope, additional complexity from that originally anticipated, or change in character of work as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the work and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B entitled "Services to be Performed by Engineer." Satisfactory progress of work shall be maintained as an absolute condition of payment. The fee herein referenced may be adjusted for additional work requested and performed only if approved by written Supplemental Agreement. ARTICLE 4 COMPENSATION ARTICLE 5 METHOD OF PAYMENT Payments to Engineer for services rendered shall be made while work is in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of work accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of work tasks identified in Exhibit D entitled "Fee Schedule." Progress payments shall be made by City based upon work actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which, notwithstanding anything herein to the contrary, is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory work performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her /its negligence. Engineer's Contract - revised I0-2002/specs master 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which City receives the supplies, materials, equipment, or within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for the supplies, materials, equipment, or services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply to payments made by City in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Agreement or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non - disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED City shall issue a written authorization to proceed with work identified in the Scope of Services. City shall not be responsible for actions by Engineer or any costs incurred by Engineer relating to additional work not included in Exhibit B entitled "Services to be Performed by Engineer." ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Agreement is as follows: Mr. Michael Thane, P.E. Engineer — Public Works Department 2008 Enterprise Drive Round Rock, Texas 78664 (512) 218 -3236 Phone (512) 218 -5563 Fax Engmcah CwtramCDM.rttisd 10- 2002doc 4 City's Designated Representative shall be authorized to act on City's behalf with respect to this project. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineer's services. Engineer's Designated Representative for purposes of this Agreement is as follows: Mr. Allen D. Woelke, P.E. Vice President 9111 Jollyville Road, Suite 105 Austin, Texas 78759 (512) 346 -1100 Phone (512) 345 -1483 Fax ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the work, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the work. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of Engineer's services and work. Should City determine that the progress in production of work does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the work, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to attain program objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the work schedule goals sooner than anticipated. ARTICLE 10 SUSPENSION Should City desire to suspend the work, but not to terminate this Agreement, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty -day notice may be waived in writing by Engineer's Contract- revised 10- 2002/specs master 5 agreement and signature of both parties. The work may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the work. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If City suspends the work, the contract period as determined in Article 3 is not affected and this Agreement will terminate on the date specified unless this Agreement is amended indicating otherwise. City assumes no liability for work performed or costs incurred prior to the date authorized by City for Engineer to begin work, and/or during periods when work is suspended, and/or subsequent to the contract completion date. If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is beyond the scope of this Agreement and as such constitutes extra work, he /she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Agreement will be executed between the parties as provided in Article 13 entitled "Supplemental Agreements." Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Agreement. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the work authorized in this Agreement or any amendments thereto. If City deems it necessary to request changes to previously satisfactorily completed work or parts thereof which involve changes to the original scope of services or character of work under this Agreement, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional work and paid for as specified under Article 11 entitled "Additional Work." Engineer's Contract-cDM -rt,i d 10.200ida ARTICLE 11 ADDITIONAL WORK ARTICLE 12 CHANGES IN WORK Engineer shall make revisions to work authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such work. ARTICLE 13 SUPPLEMENTAL AGREEMENTS The terms of this Agreement may be modified by written Supplemental Agreement if City determines that there has been a significant change in (1) the scope, complexity or character of the service to be performed, or (2) the duration of the work. Any such Supplemental Agreement must be duly authorized by City Council Resolution. Where such City Council authorization is required, Engineer shall not proceed until the appropriate Resolution has been adopted. Additional compensation, if appropriate, shall be identified as provided in Article 4 entitled "Compensation." 6 Both parties must execute any written Supplemental Agreement within the contract period specified in Article 3 entitled "Contract Term." It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until City grants full execution of the written Supplemental Agreement and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory work performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Agreement are the exclusive property of City and shall be famished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Agreement. Engineer, at his/her /its own expense, may retain copies of such documents or any other data which he/she /it has furnished City under this Agreement. Any release of information shall be in conformance with requirements of the Texas Open Records Act. ARTICLE 15 PERSONNEL, EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at his/her /its own expense, quarters for the performance of all services, and adequate and sufficient personnel and equipment to perform the services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the work shall immediately be removed from association with the project when so instructed by City. Engineer certifies that he /she/it presently has adequate qualified personnel in his /her /its employment for performance of the services required under this Agreement, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the work under this Agreement without prior written approval from City. All subcontracts shall include the provisions required in this Agreement and shall be approved as to form, in writing, by City prior to work being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Agreement. ARTICLE 17 EVALUATION OF WORK City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the work performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, Engineer's Contract- revised 10-2002/specs master 7 then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMSBREACR OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Agreement, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. Eagineda Conuaa -CDM -mild IO- 2002doe ARTICLE 20 TERMINATION This Agreement may be terminated before the stated termination date by any of the following conditions. (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all services and obligations described herein. Should City terminate this Agreement as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the work performed by Engineer prior to termination, City shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should City terminate this Agreement under Subsection (4) immediately above, then the amount charged during the thirty (30) day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Agreement or if City terminates this Agreement for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by 8 Engineer in performing the work to the date of default, the amount of work required which was satisfactorily completed to date of default, the value of the work which is usable to City, the cost to City of employing another firm to complete the work required and the time required to do so, and other factors which affect the value to City of the work performed at the time of default. The termination of this Agreement and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Agreement, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Agreement is due to the failure of Engineer to fulfill his/her /its contractual obligations, then City may take over the project and prosecute the work to completion. In such case, Engineer shall be liable to City for any additional costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the scope of services under this Agreement. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Agreement, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her /its compliance. Engineer shall further obtain all permits and licenses required in the performance of the professional services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her /itself and his/her /its agents or employees, performed under this Agreement, which are caused by or which result from error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such activities by Engineer, its agents, or employees. Engineer's Contract-revised 10- 2002/specs master 9 ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her /its work and shall promptly make necessary revisions or corrections resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON - COLLUSION, FINANCIAL INTEREST PROHIBITED (1) Non - collusion. Engineer warrants that he/she /it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Agreement, and that he /she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City reserves and shall have the right to annul this Agreement without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her /its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Agreement is in effect professional liability insurance coverage in the minimum amount of One Million Dollars from a company authorized to do insurance business in Texas and otherwise acceptable to City. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Agreement to maintain during the term of this Agreement, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional mow, Contra.CDM -mind 10-2OOZdoc ARTICLE 26 INSURANCE 10 policy conditions as shown below in Article 26, Section (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Agreement, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: 1. Each policy shall require that thirty (30) days prior to the expiration, cancellation, non - renewal or any material change in coverage, a notice thereof shall be given to City by certified mail to: Engineer's Contract- revised 10- 2002/specs master 11 City Manager, City of Round Rock 221 East Main Street Round Rock, Texas 78664 Engineer shall also notify City, within 24 hours of receipt, of any notices of expiration, cancellation, non - renewal, or material change in coverage it receives from its insurer. 2. Companies issuing the insurance policies shall have no recourse against City for payment of any premiums or assessments for any deductibles which all are at the sole responsibility and risk of Engineer. 3. The Term "City" or "City of Round Rock" shall include all authorities, Boards, Commissions, Departments, and officers of City and the individual members, employees and agents thereof in their official capacities, and/or while acting on behalf of the City of Round Rock. 4. The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self - Insured Retentions of whatever nature. 5. Engineer and City mutually waive subrogation rights each may have against the other for loss or damage, to the extent same is covered by the proceeds of insurance. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with the City. Such Certificates of Insurance are evidenced as Exhibit " F " herein entitled "Certificates ARTICLE 27 COPYRIGHTS City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. ARTICLE 28 SUCCESSORS AND ASSIGNS This Agreement shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Agreement, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Agreement constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Agreement may only be amended or supplemented by mutual agreement of the parties hereto in writing. - ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Agreement. All notices to either party by the other required under this Agreement shall be personally delivered or mailed to such party at the following respective addresses: Engineer's Cmx. -CDM -roved 70- 2002doc ARTICLE 32 NOTICES 12 City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 and to: Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: Allen D. Woelke, P.E. Vice President Camp Dresser & McKee Inc. (CDM) 9111 7ollyville Road, Suite 105 Austin, Texas 78759 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the services for each phase of this Agreement within the agreed Work Schedule may constitute a material breach of this Agreement. Engineer shall be fully responsible for his/her /its delays or for failures to use his/her /its best efforts in accordance with the terms of this Agreement. Where damage is caused to City due to Engineer's failure to perform in these circumstances, City may withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Agreement if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Agreement shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Agreement shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. Engineer's Contract- revised 10- 2002/specs master 13 ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Agreement and that he /she has full and complete authority to enter into this Agreement on behalf of the firm. The above - stated representations and warranties are made for the purpose of inducing City to enter into this Agreement. IN WITNESS WHEREOF, the City of Round Rock has caused this Agreement to be signed in its corporate name by its Mayor, duly authorized to execute the same on its behalf by Resolution No. approved by the City Council on the _19th day of the month of December , 2002 , and Engineer, Camp Dresser & McKee Inc. (CDM) , signing by and through his/her /its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK, TEXAS: By: ATTEST: By: ENGINEER: By: ATTEST: By: Mayor City Secretary Signature of Principal Printed Name: Allen D. Woelke Corporate Secretary E, imda C,mractCDM-rtv:sd 10.2W2 dcc 14 / IA Reb.j• f Now " aeol Texas MBER 13, 2004 LIST OF EXHIBITS ATTACHED (1) Exhibit A "Services to be Performed by City" (2) Exhibit B "Services to be Performed by Engineer" (3) Exhibit C "Work Schedule" (4) Exhibit D "Fee Schedule" (5) Exhibit E "Work Authorizations" (6) Exhibit F "Certificates of Insurance" Engineer's Contract-revised 10- 2002/specs roaster 15 Exhibit A Services to be Performed by City CITY Obligations To enable ENGINEER to complete the ENGINEER's scope of services in Exhibit B and meet the work schedule provided in Exhibit C, CITY is required to provide the following deliverables and /or services to ENGINEER in a timely manner so as not to impede ENGINEER's work schedule provided in Exhibit C: Define Existing City Programs and Codes that Meet MS4 Stormwater Permit Needs Provide documentation to ENGINEER on the City's known activities and costs in the following program areas that directly or indirectly relate to stormwater quality and /or quantity management: • Public education and outreach; • Public participation and involvement; • Illicit discharge detection and elimination; • Construction site runoff control; • Post - construction runoff control; and; • Pollution prevention /good housekeeping. Make pertinent City staff available for participation in workshops that focus on these six program areas (identified above) and for the timely review of draft materials provided by ENGINEER. Provide logistics necessary for planning and conducting meetings, workshops, and the like including identification of meeting site, announcement of meeting times and locations, and distribution of meeting agendas to all participants. Identify and provide relevant municipal code pertinent to storm water quantity management, stormwater quality management, and pollution prevention. Duplicate and disseminate all draft material as needed to City staff (and /or other appropriate participants outside of ENGINEER). Attend meetings with regulatory agencies, as needed. Services Performed byGty Exhibit Adoc Page 1 of 1 Exhibit B Services to be Performed by Engineer Under the aforementioned Agreement, ENGINEER will furnish consulting services to the CII' regarding the development of a stormwater quality management program." 1. Nature of Project Assist CITY with the development of storm water quality management program for its Municipal Separate Stormwater Sewer System (MS4), identification of existing City Programs that meet current stonnwater needs, and develop a stormwater plan for meeting TPDES requirements to be included in CITY's Phase II MS4 stormwater quality permit application. This application is to obtain stormwater permit coverage and must be submitted to the Texas Commission on Environmental Quality (TCEQ) by March 10, 2003 2. ENGINEER Scope of Work and Deliverables A Define Existing City Programs That Meet TPDES Stormwater Permit Needs A.1 ENGINEER will conduct a workshop and separate interviews as needed with CITY staff and other appropriate persons to review stormwater management activities within the City of Round Rock. Activities that assist CITY in meeting TPDES stormwater permitting requirements will be compiled. A.2 Technical memorandum provide to CITY staff detailing the nature and extent of existing stormwater- related programs. A.3 Respond to CITY staff comments on technical memorandum. B Develop Stormwater Quality Management Plan for Meeting TPDES Permit. B.1 This task will develop the appropriate management program for CI to manage stormwater quality in the City of Round Rock. Appropriate is defined as cost - effective, meeting stormwater permitting and community requirements, providing an annual report format, and specifying program implementation schedules and estimated costs for the 5 -year permit term. There are six minimum elements for a stormwater quality management program to be adequate under TPDES stormwater permitting rules. These program elements are: • Public education and outreach; • Public participation and involvement; • Illicit discharge detection and elimination; • Construction site runoff control; Services Performed by Engineer Exhibit Bdac Page 1 of 2 ENGINEER CITY For execution of the scope related to the PROJECT For contractual notification purposes and invoicing For execution of the scope related to the PROJECT For contractual notification purposes and invoicing Roger Schenk CDM 9111 Jollyville Road Suite 105 Austin, TX 78759 512.346.1100 512.345.1483 Allen Woelke CDM 9111 Jolyville Road Suite 105 Austin, TX 78759 512.346.1100 512.345.1483 Michael Thane City of Round Rock 2008 Enterprise Drive Round Rock, TX 78664 5122183236 512.2185563 Michael Thane City of Round Rock 2008 Enterprise Drive Round Rock, TX 78664 512 218 3236 512.218.5563 • Post - construction runoff control; and ■ Pollution prevention /good housekeeping. B.2 Technical memorandums detailing recommended stormwater quality management programs elements: B.2.1 Technical Memorandum No. 1: Public education and outreach; B2.2 Technical Memorandum No. 2: Public participation and involvement; B.2.3 Technical Memorandum No. 3: Illicit discharge detection and elimination; B.2.4 Technical Memorandum No. 4: Pollution prevention /good housekeeping; 13.2.5 Technical Memorandum No. 5: Construction site runoff control; and B.2.6 Technical Memorandum No. 6: Post - construction runoff control. B.3 Draft report detailing recommended stormwater quality management program to meet TPDES permit needs. Respond to comments on technical memoranda, the draft report and produce final stormwater quality management program report. To meet TCEQ requirements, the stormwater quality management program permit application must be submitted to TCEQ by March 10, 2003. 6. Communications Protocols For the duration of the Agreement, unless specifically agreed to in writing otherwise, the following will be the points of contact for ENGINEER and CITY: Page 2 of 2 ENGINEER Deliverable ENGINEER Draft Deliverable Deadline CITY Review and Comment Deadline REGULATORY (TCEQ) Deadline A 02/07/03 02/17/03 03/10/03 B 02/17/03 02/28/03 03/10/03 Exhibit C Work Schedule % Schedule of Work and Deliverables The activities and deliverables associated with the scope of services in Exhibit B will be accomplished within the following schedule: Page 1 of 1 ENGINEER Task Lump Sum Fee Task A 15,500 Task B 37,200 Total 52,700 Exhibit D Fee Schedule Fee Schedule The activities and deliverables associated with the scope of services in item Exhibit B will be accomplished by the following fee schedule: ENGINEER Compensation Fee Schedule Exhibit D.doc Page 1 of 1 Exhibit E Work Authorizations (Reserved) Page 1 of 1 CERTIFICATE OF LIABILITY INSURANCE - EXCESS LIABILITY • • AGGREGATE Limns B WORKERS COMPENSATION AC8376633 -07 01 -01- 02.01 -01 -03 AND Eb PLOVERS' warm EARL ACCIDENT DISEASE- POLICY LARY DISEASE -EACH EVfPUOYEE Date: 11/21/02 PRODUCER ' COMPANIES AFFORDING COVERAGE Aon Risk Services Inc. of Massachusetts • 99 High Street . A Lloyd's of London Boston, MA 02110 B Zurich American Ins,Co. INSURED - C . • amp g e ie• Inc. • it • ' . • 1 T Lg4 0 000 THIS IS TO CERTIFY THAT the Insured named above is inslited by the Companies listed above with respect to the business operations hereinafter described, for the types of instirence and in accordance with the provisions of the standard policies used by the companies, and further hereinafter described. Exceptions to the policies are noted below. CO TYPEOFINSURANCE POLICY EFFECTIVE EXPIRATION LTR NUMBER DATE :DATE B GFSIERALLUBE.fY GL08/6632 -06 01- 01-02 01 -01 -03 GENERAL AGGREGATE 22,000,000 PRODUCTS-00MP/OPACG 52,000.000 PERSONAL &AMMOURY $1,000,000 . EACHOCCURRENCE 51.000,000 . FIREDAASAGE(Arry nn, S 100,000 MED.EXPENSE (Anyone pmon)S 5 • B AUTOMOBILEUABIUTY BAP8376631 - 01 - - 01 - - COMBBIED SINGLE UMr s 1,000,000 BODILY INJURY (Per person) S BODILY INIURY(Pa,cddmt) ea0PERTYDAMAGE S EACH OCCURRENCE $ $ 1,000,000 1,000,000 $ 1,000,000 A PROFESSIGVALI.UBIt1TY QB9800005 01 -01 -99 01 -01 -03 Each Claim /Aggregate $3,000,000 Architects & Engiueers.•E & 0 • DESCFTION OF OPERATIONS /LOCATIONSNEH1CTES1SPECIAL ITEMS/EXCEPTIONS Re: Professional Contract— Starmwater Phase II TPDES Permit Assistance The City of Roand Rock is named as additional Insured with respect to all policies except 'Workers' Compensation and Employers Liability' and 'Professions' Liability'. Shbuld any of the above described policies be cancelled or changed before the expiration date the eo! the Issuing eampoywil mail Ibkty (3O) days written notice to the eatiMcatc holds named below. CERTIFICATE HOLDER: CityMmuger City of Round Rock 221 E. Main Street RoundRecic, Texas 78664 Cenci Inter cORRdce • • SIGN V REOF 01 ZED REPRESENTATIVE Typedmme, Thomas A. Leach Thle: Relationship Manager EXHIBIT "A" Revised 10/2002 DATE: December 13, 2002 SUBJECT: City Council Meeting — December 19, 2002 ITEM: 9.D.2. Consider a resolution authorizing the Mayor to execute an Agreement for Engineering Services with Camp Dresser & McKee, Inc. for the development of a stormwater management program. Resource: Jim Nuse, Chief of Operations /Assistant City Manager Tom Word, Director of Transportation Services Michael Thane, Engineer History: The Phase II Storm Water Management Program requires operators of certain small municipal separate storm sewer systems (MS4s) to develop and implement a storm water program. In an effort to further improve water quality in streams and lakes, the EPA developed the storm water program to control polluted runoff from urban areas. Phase I of the program, issued in 1990, required cities with a population greater than 100,000 to develop a storm water management program. Phase II is the second stage of the EPA's storm water management program requirements. It affects many small cities, some counties and other entities that operate MS4s in urbanized and other densely populated areas. Round Rock is affected by the Phase II rule. To comply with the Phase II general permit requirements, each regulated small MS4 is required to submit a Notice of Intent to obtain storm water permit coverage by March 10, 2003. The initial submission for permit coverage must detail the programs, activities, and measurable goals that will be implemented over the five -year permit term. Reports detailing the progress of the storm water management program must be submitted to the TCEQ on an annual basis for the first permit term. Funding: Cost: $52,700 Source of funds: 2002 Street Operating Budget and Capital Project Funds (Utility) Outside Resources: Camp Dresser & McKee Inc. ImpactBenefit: Preserve, protect, and improve the water resources from polluted storm water runoff, and to further reduce adverse impacts to water quality and aquatic habitat by instituting the use of controls on unregulated storm water discharges. Public Comment: N/A Sponsor: N/A I ; 'ROUND ROCK, TEXAS PURPOSE PASSION. PROSPERITY THE STATE OF TEXAS COUNTY OF WILLIAMSON 2 - o2 - Ja- / -9D) CITY OF ROUND ROCK AGREEMENT FOR ENGINEERING SERVICES WITH Camp Dresser & McKee Inc. (CDM) 1 THIS AG MENT FOR ENGINES G SERVICES ( "Agreement") is made and entered into on this the day of the 'month of Mi3E/ed, 2002 by and between the CITY OF ROUND ROCK, a Texas home -rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas 78664 -5299, (hereinafter referred to as "City "), end Camp Dresser & McKee Inc. (CDM), a Massachusetts Corporation, whose principal place of business is located at One Cambridge Place, 50 Hampshire Street, Cambridge, MA 02139_, (hereinafter called "Engineer"), and such Agreement is for the purpose of contracting for professional engineering services. RECITALS: Contract No. WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW, THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: CONTRACT DOCUMENTS The Contract Documents consist of this Agreement and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Agreement) and all Supplemental Agreements (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Agreement as if attached to this Agreement or repeated herein. ARTICLE 1 SCOPE OF SERVICES TO BE PERFORMED BY CITY City shall perform or provide services as identified in Exhibit A entitled "Services to be Performed by City." ARTICLE 2 SCOPE OF SERVICES TO BE PERFORMED BY ENGINEER Engineer shall perform engineering services as identified in Exhibit B entitled "Services to be Performed by Engineer." Engineer shall develop a mutually acceptable schedule of work as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineer's Scope of Services under this Agreement may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all work performed. Should the review times take longer than shown on the Work Schedule, through no fault of Engineer, additional time may be authorized by City through a written Supplemental Agreement only if same is requested by a timely written request from Engineer which is approved by City. ARTICLE 3 CONTRACT TERM (1) Term. This Agreement shall be from the date hereof and shall terminate at the close of business on the 10th day of the month of June , 2003 , unless extended by written Supplemental Agreement executed by Engineer and City prior to the date of termination, or as otherwise terminated as provided in Article 20 entitled "Termination." Any work performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he /she /it determines, or reasonably anticipates, that the work under this Agreement will not be completed before the termination date. In that event City may, at its sole discretion, extend the contract term by timely written Supplemental Agreement. Engineer shall allow adequate time for review and approval of his/her /its request for time extension by City prior to expiration of this Agreement. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all services required under this Agreement in the highest professional manner. (3) Notice to Proceed. After execution of this Agreement, Engineer shall not proceed with work delineated in Article 2 entitled "Scope of Services to be Performed by Engineer" and in Exhibit B entitled "Services to be Performed by Engineer" until authorized in writing by City to proceed as provided in Article 7 entitled "Notice to Proceed." 2 ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for all engineering services performed and to be performed under this Agreement. The amount payable under this Agreement, without modification of the Agreement as provided herein, is the sum of Fifty -Two Thousand and Seven Hundred Dollars and No Cents ($52,700.00) as shown in Exhibit D entitled "Fee Schedule." The lump sum amount payable may be revised only by written Supplemental Agreement in the event of a change in scope, additional complexity from that originally anticipated, or change in character of work as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the work and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B entitled "Services to be Performed by Engineer." Satisfactory progress of work shall be maintained as an absolute condition of payment. The fee herein referenced may be adjusted for additional work requested and performed only if approved by written Supplemental Agreement. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer for services rendered shall be made while work is in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of work accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of work tasks identified in Exhibit D entitled "Fee Schedule." Progress payments shall be made by City based upon work actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which, notwithstanding anything herein to the contrary, is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory work performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her /its negligence. Engineer's Contract- revised 10- 2002/specs master 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Govemment Code, payment to Engineer will be made within thirty (30) days of the day on which City receives the supplies, materials, equipment, or within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which City receives a correct invoice for the supplies, materials, equipment, or services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply to payments made by City in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Agreement or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non - disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Govemment Code. ARTICLE 7 NOTICE TO PROCEED City shall issue a written authorization to proceed with work identified in the Scope of Services. City shall not be responsible for actions by Engineer or any costs incurred by Engineer relating to additional work not included in Exhibit B entitled "Services to be Performed by Engineer." ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Agreement is as follows: Mr. Michael Thane, P.E. Engineer — Public Works Department 2008 Enterprise Drive Round Rock, Texas 78664 (512) 218 -3236 Phone (512) 218-5563 Fax &plea's Contract -COM- revised 10.2002doc 4 City's Designated Representative shall be authorized to act on City's behalf with respect to this project. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineer's services. Engineer's Designated Representative for purposes of this Agreement is as follows: Mr. Allen D. Woelke, P.E. Vice President 9111 Jollyville Road, Suite 105 Austin, Texas 78759 (512) 346 -1100 Phone (512) 345-1483 Fax ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the work, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the work. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of Engineer's services and work. Should City determine that the progress in production of work does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the work, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to attain program objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the work schedule goals sooner than anticipated. ARTICLE 10 SUSPENSION Should City desire to suspend the work, but not to terminate this Agreement, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty-day notice may be waived in writing by Engineer's Contract-revised 10- 2002/specs master 5 agreement and signature of both parties. The work may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the work. Such sixty -day notice may be waived in writing by agreement and signature of both parties. If City suspends the work, the contract period as determined in Article 3 is not affected and this Agreement will terminate on the date specified unless this Agreement is amended indicating otherwise. City assumes no liability for work performed or costs incurred prior to the date authorized by City for Engineer to begin work, and/or during periods when work is suspended, and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL WORK If Engineer forms a reasonable opinion that any work he /she /it has been directed to perform is beyond the scope of this Agreement and as such constitutes extra work, he /she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Agreement will be executed between the parties as provided in Article 13 entitled "Supplemental Agreements." Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Agreement. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the work authorized in this Agreement or any amendments thereto. ARTICLE 12 CHANGES IN WORK If City deems it necessary to request changes to previously satisfactorily completed work or parts thereof which involve changes to the original scope of services or character of work under this Agreement, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional work and paid for as specified under Article 11 entitled "Additional Work." Engineer shall make revisions to work authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such work. ARTICLE 13 SUPPLEMENTAL AGREEMENTS The terms of this Agreement may be modified by written Supplemental Agreement if City determines that there has been a significant change in (1) the scope, complexity or character of the service to be performed, or (2) the duration of the work. Any such Supplemental Agreement must be duly authorized by City Council Resolution. Where such City Council authorization is required, Engineer shall not proceed until the appropriate Resolution has been adopted. Additional compensation, if appropriate, shall be identified as provided in Article 4 entitled "Compensation." &gioah Contract- COM- revisal IDIO02dcc 6 Both parties must execute any written Supplemental Agreement within the contract period specified in Article 3 entitled "Contract Term." It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until City grants full execution of the written Supplemental Agreement and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory work performed. ARTICLE 14 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Agreement are the exclusive property of City and shall be furnished to City upon request. All documents prepared by Engineer and all documents furnished to Engineer by City shall be delivered to City upon completion or termination of this Agreement. Engineer, at his/her /its own expense, may retain copies of such documents or any other data which he /she /it has furnished City under this Agreement. Any release of information shall be in conformance with requirements of the Texas Open Records Act. ARTICLE 15 PERSONNEL, EOUIPMENT AND MATERIAL Engineer shall furnish and maintain, at his/her /its own expense, quarters for the performance of all services, and adequate and sufficient personnel and equipment to perform the services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the work shall immediately be removed from association with the project when so instructed by City. Engineer certifies that he /she /it presently has adequate qualified personnel in his /her /its employment for performance of the services required under this Agreement, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the work under this Agreement without prior written approval from City. All subcontracts shall include the provisions required in this Agreement and shall be approved as to form, in writing, by City prior to work being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Agreement. ARTICLE 17 EVALUATION OF WORK City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the work performed or being performed hereunder and the premises on which it is being performed. If any review or evaluation is made on the premises of Engineer or a subcontractor, Engineer's Contract - revised 10- 2002/specs master 7 then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Agreement, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Agreement may be terminated before the stated termination date by any of the following conditions. (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all services and obligations described herein. Should City terminate this Agreement as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to Engineer. In determining the value of the work performed by Engineer prior to termination, City shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should City terminate this Agreement under Subsection (4) immediately above, then the amount charged during the thirty (30) day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Agreement or if City terminates this Agreement for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineets Connor -CDM- revised 10.3002dae 8 Engineer in performing the work to the date of default, the amount of work required which was satisfactorily completed to date of default, the value of the work which is usable to City, the cost to City of employing another firm to complete the work required and the time required to do so, and other factors which affect the value to City of the work performed at the time of default. The termination of this Agreement and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Agreement, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Agreement is due to the failure of Engineer to fulfill his/her /its contractual obligations, then City may take over the project and prosecute the work to completion. In such case, Engineer shall be liable to City for any additional costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the scope of services under this Agreement. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Agreement, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her /its compliance. Engineer shall further obtain all permits and licenses required in the performance of the professional services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her /itself and his/her /its agents or employees, performed under this Agreement, which are caused by or which result from error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. Engineer shall also save and hold City harmless from any and all expenses, including but not limited to attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such activities by Engineer, its agents, or employees. Engineer's Contact - revised 10.2002/specs master 9 ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her /its work and shall promptly make necessary revisions or corrections resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON - COLLUSION, FINANCIAL INTEREST PROHIBITED (1) Non - collusion. Engineer warrants that he/she /it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Agreement, and that he /she /it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City reserves and shall have the right to annul this Agreement without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her /its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Agreement is in effect professional liability insurance coverage in the minimum amount of One Million Dollars from a company authorized to do insurance business in Texas and otherwise acceptable to City. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Agreement to maintain during the term of this Agreement, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional Engine&, CO20HQ CDM- ,cv6cd 10 -2002 doc ARTICLE 26 INSURANCE 10 policy conditions as shown below in Article 26, Section (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Agreement, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: 1. Each policy shall require that thirty (30) days prior to the expiration, cancellation, non- renewal or any material change in coverage, a notice thereof shall be given to City by certified mail to: Engineer shall also notify City, within 24 hours of receipt, of any notices of expiration, cancellation, non - renewal, or material change in coverage it receives from its insurer. 2. Companies issuing the insurance policies shall have no recourse against City for payment of any premiums or assessments for any deductibles which all are at the sole responsibility and risk of Engineer. 3. The Term "City" or "City of Round Rock" shall include all authorities, Boards, Commissions, Departments, and officers of City and the individual members, employees and agents thereof in their official capacities, and/or while acting on behalf of the City of Round Rock. 4. The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self- Insured Retentions of whatever nature. 5. Engineer and City mutually waive subrogation rights each may have against the other for loss or damage, to the extent same is covered by the proceeds of insurance. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with the City. Such Certificates of Insurance are evidenced as Exhibit " F " herein entitled "Certificates Engineer's Contract - revised 10- 2002/specs master 11 City Manager, City of Round Rock 221 East Main Street Round Rock, Texas 78664 ARTICLE 27 COPYRIGHTS City shall have the royalty-free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. ARTICLE 28 SUCCESSORS AND ASSIGNS This Agreement shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Agreement, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. Engincd, ContreaCDM.revived I0.2002.doc ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Agreement constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Agreement may only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Agreement. ARTICLE 32 NOTICES All notices to either party by the other required under this Agreement shall be personally delivered or mailed to such party at the following respective addresses: 12 City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 and to: Stephan L. Sheets City Attorney 309 East Main Street , Round Rock, TX 78664 Engineer: Allen D. Woelke, P.E. Vice President Camp Dresser & McKee Inc. (CDM) 9111 Jollyville Road, Suite 105 Austin, Texas 78759 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the services for each phase of this Agreement within the agreed Work Schedule may constitute a material breach of this Agreement. Engineer shall be fully responsible for his/her /its delays or for failures to use his/her /its best efforts in accordance with the terms of this Agreement. Where damage is caused to City due to Engineer's failure to perform in these circumstances, City may withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Agreement if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Agreement shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Agreement shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. Engineer's Contract - revised 10- 2002/specs master 13 The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Agreement and that he /she has full and complete authority to enter into this Agreement on behalf of the firm. The above - stated representations and warranties are made for the purpose of inducing City to enter into this Agreement. IN WITNESS WHEREOF, the City of Round Rock has caused this Agreement to be signed in its o o to name by As Mayor, duly authorized to execute the same on its behalf by Resolution No. J J f. L) approved by the City Council on the _ 19th day of the month of December , 2002 , and Engineer, Camp Dresser & McKee Inc. (CDM) , signing by and through his/her /its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY OF ROUND ROCK, T By: ATTEST: By: City Secretary ENGINEER: By: Signature of Principal Printed Name: Allen D. Woelke ATTEST: By: • Corporate Secretary Eagincda C(m maCDM -miscd 10.2002 dot ARTICLE 34 SIGNATORY WARRANTY 14 1 1• -I I`. Reba. �A * r � — ' i . 1 , Neter I a e f Texas / ' - MBER 13, 2004 LIST OF EXHIBITS ATTACHED (1) Exhibit A "Services to be Performed by City" (2) Exhibit B "Services to be Performed by Engineer" (3) Exhibit C "Work Schedule" (4) Exhibit D "Fee Schedule" (5) Exhibit E "Work Authorizations" (6) Exhibit F "Certificates of Insurance" Engineer's Contract- revised 10- 2002/spccs master 15 Exhibit A Services to be Performed by City CITY Obligations To enable ENGINEER to complete the ENGINEER's scope of services in Exhibit B and meet the work schedule provided in Exhibit C, CITY is required to provide the following deliverables and /or services to ENGINEER in a timely manner so as not to impede ENGINEER's work schedule provided in Exhibit C: Define Existing City Programs and Codes that Meet MS4 Stormwater Permit Needs Provide documentation to ENGINEER on the City's known activities and costs in the following program areas that directly or indirectly relate to stormwater quality and /or quantity management • Public education and outreach; • Public participation and involvement; • Illicit discharge detection and elimination; • Construction site runoff control; • Post - construction runoff control; and; • Pollution prevention /good housekeeping. Make pertinent City staff available for participation in workshops that focus on these six program areas (identified above) and for the timely review of draft materials provided by ENGINEER. Provide logistics necessary for planning and conducting meetings, workshops, and the like including identification of meeting site, announcement of meeting times and locations, and distribution of meeting agendas to all participants. Identify and provide relevant municipal code pertinent to storm water quantity management, stormwater quality management, and pollution prevention. Duplicate and disseminate all draft material as needed to City staff (and /or other appropriate participants outside of ENGINEER). Attend meetings with regulatory agencies, as needed. Services Performed by City Exhibit Adoc Page 1 of 1 Exhibit B Services to be Performed by Engineer Under the aforementioned Agreement, ENGINEER will furnish consulting services to the Crl Y regarding the development of a stormwater quality management program." 1. Nature of Project Assist CITY with the development of storm water quality management program for its Municipal Separate Stormwater Sewer System (MS4), identification of existing City Programs that meet current stormwater needs, and develop a stormwater plan for meeting TPDES requirements to be included in CITY's Phase II MS4 stormwater quality permit application. This application is to obtain stormwater permit coverage and must be submitted to the Texas Commission on Environmental Quality (TCEQ) by March 10, 2003 2. ENGINEER Scope of Work and Deliverables A Define Existing City Programs That Meet TPDES Stormwater Permit Needs A.1 ENGINEER will conduct a workshop and separate interviews as needed with CITY staff and other appropriate persons to review stormwater management activities within the City of Round Rock. Activities that assist CITY in meeting TPDES stormwater permitting requirements will be compiled. A.2 Technical memorandum provide to CITY staff detailing the nature and extent of existing stormwater - related programs. A.3 Respond to CITY staff comments on technical memorandum. B Develop Stormwater Quality Management Plan for Meeting TPDES Permit. B.1 This task will develop the appropriate management program for CITY to manage stormwater quality in the City of Round Rock. Appropriate is defined as cost - effective, meeting stormwater permitting and community requirements, providing an annual report format, and specifying program implementation schedules and estimated costs for the 5 -year permit term. There are six minimum elements for a stormwater quality management program to be adequate under TPDES stormwater permitting rules. These program elements are: ■ Public education and outreach; • Public participation and involvement; • Illicit discharge detection and elimination; • Construction site runoff control; Semen Performed by Engineer Exhibit &doe Page 1 of 2 ENGINEER CITY For execution of the scope related to the PROJECT For contractual notification purposes and invoicing For execution of the scope related to the PROJECT For contractual notification purposes and invoicng Roger Schenk CDM 9111 Jollyville Road Suite 105 Austin, TX 78759 512.346.1100 • 512.345.1483 Allen Woelke CDM 9111 Jollyville Road Suite 105 Austin, TX 78759 512.346.1100 512.345.1483 Michael Thane City of Round Rock 2008 Enterprise Drive Round Rock, TX 78664 512.218.3236 512.218 5563 Michael Thane City of Round Rock 2008 Enterprise Drive Round Rock, TX 78664 512218.3236 512.218.5563 • Post - construction runoff control; and ■ Pollution prevention /good housekeeping. B.2 Technical memorandums detailing recommended stormwater quality management programs elements: B.2.1 Technical Memorandum No. 1: Public education and outreach; B.2.2 Technical Memorandum No. 2: Public participation and involvement; B.2.3 Technical Memorandum No 3• Illicit discharge detection and elimination; B.2.4 Technical Memorandum No. 4: Pollution prevention /good housekeeping; B.2.5 Technical Memorandum No. 5: Construction site runoff control; and B.2.6 Technical Memorandum No. 6: Post - construction runoff control. B.3 Draft report detailing recommended stormwater quality management program to meet TPDES permit needs. Respond to comments on technical memoranda, the draft report and produce final stormwater quality management program report. To meet TCEQ requirements, the stormwater quality management program permit application must be submitted to TCEQ by March 10, 2003. 6. Communications Protocols For the duration of the Agreement, unless specifically agreed to in writing otherwise, the following will be the points of contact for ENGINEER and CITY: Page 2 of 2 ENGINEER Deliverable ENGINEER Draft Deliverable Deadline CITY Review and Comment Deadline REGULATORY (TCEQ) Deadline A 02/07/03 02/17/03 03/10/03 B 02/17/03 02/28/03 03/10/03 Exhibit C Work Schedule Schedule of Work and Deliverables The activities and deliverables associated with the scope of services in Exhibit B will be accomplished within the following schedule: Page 1 of 1 ENGINEER Task Lump Sum Fee Task A 15,500 Task B 37,200 Total 52,700 Exhibit D Fee Schedule Fee Schedule The activities and deliverables associated with the scope of services in item Exhibit B will be accomplished by the following fee schedule: ENGINEER Compensation Fee Schedule Exhibit D.dcc Page 1 of 1 Exhibit E Work Authorizations (Reserved) Page 1 of 1 CERTIFICATE OF LIABILITY INSURANCE CO TYPE OF INSURANCE POLICY EFFECTIVE EXPIRATION LIMITS - LTR NUMBER DATE DATE B GENERAL LIABILITY GLOB /6632 -06 U1 —U1 —U2 01 — 01 — U3 GENERAL AGGREGATE • PRODt1CIS•COMP/OPAGO. PERSONAL & ADV. 1N]URY EACH OCCURRENCE PIREnAMAGE (Any m,, am) - EXCESS LtARILfTY • B WQRX roao' -07 01 -01-02 01- 01- 03sTAnsfosiYLaons AND EMPLOYERS' LIABL!TY EACLACCIDENT DISEASE- POLICY LIMIT DISEASE -EACH EMPLOYEE A PR Nr_ssx ALt.rAEILm' DESCRIPTION OF OPERATIONSILOCATIONSNEiICT .ES/SPECIA HEMS/EXCEPTIONS Re: Professional Contract —Stormwater Phase II TPDES Permit Assistance Cstofb,mr CORR.daa E70DBI' "A" Rcviscd 10/2002 Date: 11/21/02 PRODUCER • COMPANIES AFFORDING COVERAGE Aon Risk Services Inc. of Massachusetts 99 High Street ' A Lloyd's of London Boston, MA 02110 B. Zurich American Ins,Co. INSURED • C amp g M Inc. • naiTRO , — E S .B r Lg31 0000 THIS IS TO CERTIFY THAT the Insured named above b insured by the Companies listed above with respect to the business operations hereinafter described, for the types of insurance and in accordance with the provisions of the standard policies used by the companies, and further hereinafter described. Exceptions to the policies are noted below. s1,UU0,000 x2,000.000 51,000,000 5 1,000,000 . 5 100,000 ' MED. EXPENSE (Any pm pas on) S 5 B AUTOMOB1cELIABILITY BAP8376631 -06 01 -01 -02 01 -01 -03 c °MBINEDSINOLEumn s 1,000,000 BODILY INJURY (Pet person) 5 BODILY lNJURY(Per.cddmt) 5 PROPERr DAMAGE S • EACH OCCURRENCE S A0GREOATE 5 S s 1,000,000 1,00 5 1,000,000 QB9800005 01 -01 -99 01 -01 -03 Each Claim /Aggregate $3,000,000 Architects & Engineers E & 0 Ilia City of Raund Rock is named as addition' insured with respect to all policies except 'Workers' Compensation and Employers' Liability' and 'Professional Liability'. Should any of the above described policies be candled or changed before the expiration date theteor, the issuing company will mail thirty (30) der swift= notice to dm certificate bolder named below. CERTIFICATE HOLDER: City Manager City of Round Rook 221 E. Main Street Round Rock, Texas 7E664 SIGN RE OF - O ZED REPRESENTATIVE Typed Name: Thomas A. Leach Thiel Relationship Manager Mayor Nyle Maxwell Mayor Pro -tem Tom Nielson Council Members Alan McGraw Carrie Pin Scot Knight Isabel Gallahan Gary Coe City Manager Robert L Sennett. Jr City Attorney Stephan L Sheets ROUND ROCK, TEXAS PURPOSE. PASSION. PROSPERITY. January 14, 2003 Mr. Allen D. Woelke, P.E. Vice President Camp Dresser & McKee, Inc. 9111 Jollyville Road, Suite 105 Austin, TX 78759 Dear Mr. Woelke: The Round Rock City Council approved Resolution No. R- 02- 12 -19- 9D2 at their regularly scheduled meeting on December 19, 2002. This resolution approves the agreement for engineering services for the development of a stormwater management program to improve water quality by controlling polluted runoff from urban areas. Enclosed is a copy of the resolution and original agreement for your files. If you have any questions, please do not hesitate to contact Tom Word at 218 -5562. Christine R. Martinez City Secretary Enclosure CITY OF ROUND ROCK 221 East Main Street • Round Rock. Texas 78664 Phone 512 218 5400 • Fax 5;2 218 7087 • www ci round -rock tx as