R-85-723 - 5/23/1985AGREEMENT
FOR
ENGINEERING SERVICES
MADE AND ENTERED INTO by and between the City of Round Rock,
Texas, hereinafter called the "Owner ", and CARLSON S. DIPPEL, INC.,
Consulting Engineers, hereinafter called the "Engineer ".
RECITALS
Owner intends to construct Street and Drainage Improvements as
described in Attachment No. 4 under the C.I.P. Such
improvements are hereinafter referred to as the "Projects ". The
estimated cost for the Projects, including construction costs,
engineering and contingencies, is described in Attachment No. 4.
CONTRACTUAL UNDERTAKINGS
SECTION I
EMPLOYMENT OF ENGINEER
The Owner agrees to employ the Engineer and the Engineer agrees
to perform professional engineering services, in connection with the
Projects as stated in the Sections to follow, and for having rendered
such services, the Owner agrees to pay to the Engineer compensation as
stated in the Sections to follow.
SECTION II
CHARACTER AND EXTENT OF SERVICES
The Engineer shall render the following professional services
necessary for the development of the Projects:
A. PRELIMINARY PHASE
1. Attend preliminary conference with the Cwner regarding the
Projects.
2. Perform preliminary engineering services in connection with
Projects in sufficient detail to indicate clearly the problems
involved and the alternate solutions available to the Owner, to
include preliminary layouts, sketches and cost estimates for the
Projects, and to set forth clearly the Engineer's recommendations. If
called for by the scope of the assignment, prepare a preliminary
engineering report.
-1-
RA
3. When-a written report is prepared, furnish the Owner ten (10)
copies of the preliminary report, including preliminary layouts,
sketches and cost estimates.
B. DESIGN PHASE
1. Establish the scope, and advise the Owner, of any soil and
foundation investigations or any special surveys or special testing
which, in the opinion of the Engineer, may be required for the proper
execution of the Project; and arrange with the Owner for the conduct
of such investigations and tests. (The performance of these
investigations and tests is not a part of the Engineer's basic
services, and compensation therefor is not included in the Basic
Charge; it ray be performed by the Engineer, by agreement with the
Owner, in which case compensation shall be determined by the
applicable portions of Section VI D.)
2. Furnish to the Owner, where required by the circumstances of
the assignment, the engineering data necessary for applications for
routine permits by local, state, and federal authorities (as
distinguished from detailed applications and supporting documents for
government grants -in -aid, state loan programs, planning advances or to
meet the requirements of special programs of the federal government).
3. Perform field surveys to collect information which, in the
opinion of the Engineer, is required in the design of the Projects.
Construction staking for the Construction Improvements is not included
in the Basic Charge.
4. Prepare detailed specifications and contract drawings, in
pencil on paper, for construction authorized by the Owner. These
designs shall in all respects combine the application of sound
engineering principles with a high degree of economy, and shall be
submitted to the applicable state and federal agencies for approval.
5. Prepare detailed cost estimates and proposals of authorized
construction, which shall include summaries of bid items and
quantities which will be based, Gfierever practical on the unit price
system of bidding. The Engineer shall not be required to guarantee
the accuracy of these estimates.
6. Furnish the Owner all necessary copies of approved plans,
specifications, notices to bidders, and proposals. All sets of plans
and specifications in excess of twenty -five (25) are to be paid for
separately. Additional sets will be paid for in accordance with
Attachment No. 3 - Hourly Rate Schedule.
7. Provide information on utilities to be relocated in
connection with the project. The Owner will provide excavation to
determine location and depth of underground water and sewer lines.
Utilities to be relocated by others shall be noted on the plans.
-2-
City -owned utilities to be relocated also shall be noted on the plans.
Where feasible, relocation of City -owned utilities shall be -included
in the construction contract.
8. Provide a letter for the Owner's signature to each utility
operating within the City of Round Rock advising them of the project
and describing any known relocations to be performed by that utility
and setting forth a proposed construction schedule. This Letter and a
complete set of plans shall be delivered to each utility by the
Engineer. The Engineer shall provide timely assistance and location
stakes as necessary for utility relocations to assure that utility
relocations do not delay the project.
9. Provide easement and right -of -way descriptions to the Owner
in conjunction with submission of final plans. These will be provided
in the form of field notes and drawings of the affected properties.
These services will be paid for in accordance with Attachment No. 3 -
Hourly Rate Schedule.
10. Provide field rote descriptions to the Owner for any site(s)
that is required for Owner to acquire that is associated with these
Projects. These descriptions will be' provided within thirty (30) days
after authorization by Owner, barring unforeseen and unusual
difficulties associated with the property. These services will be
paid for in accordance with Attachment No. 3 - Hourly Rate Schedule.
C. CONSTRUCTION PHASE
1. Assist the Owner in the advertisement of the Projects for
bids.
2. Assist the Owner in the opening and tabulating of bids for
construction of the Projects, and recommend to the Owner as to the
proper action on all proposals received.
3. Assist in the preparation of formal Contract Documents for
the contracts.
4. Bake periodic visits to the site (as distinguished from the
continuous services of a resident Project Representative described in
Subparagraph 6 below) to observe the progress and quality of the
executed work and to determine in general if the work is proceeding in
accordance with the Contract Documents. In performing this service,
the Engineer will not be required to make exhaustive or continuous
on -site inspections to check the quality or quantity of the work of
material; he will not be responsible for the techniques and sequences
of construction or the safety precautions incident thereto, and he
will not be responsible or liable in any degree for the contractors'
failure to perform the construction work in accordance with the
Contract Documents. During visits to the construction site and on
the basis of the Engineer's on -site observations as an experienced and
-3-
qualified design professional, he will keep the Owner informed of the
extent of the progress of the work, and advise the Owner of material
and substantial defects and deficiencies in the work of contractors
which are discovered by the Engineer or otherwise brought to the
Engineer's attention in the course of construction, and may, on behalf
of the Owner, exercise whatever rights the Owner may have to
disapprove work and materials as failing to conform to the contract
Documents.
5. Consult and advise with the Owner; issue all instructions to
the contractor requested by the Owner; and prepare routine change
orders as required.
6. If specifically authorized by the Owner in writing, furnish
the services of resident Project Representatives, and other field
personnel for continuous on- the -site observation of construction and
for the performance of required construction layout surveys. (This
service is not a part of the Engineer's basis services, and
compensation therefor is not included in the Basic Charge; if
provided, compensation shall be determined under Section VI D.) The
authority and duties of such Resident Project Representatives are
limited to examining the material furnished and observing the work
done, and to reporting their findings to the Engineer. The Engineer
will use the usual degree of care and prudent judgment in the
selection of competent Project Representatives, and the Engineer will
use diligence to see that the Project Representatives are on the job
to perform their required duties. It is agreed, however, that the
Engineer does not underwrite, guarantee, or insure the work done by
the contractors, and since it is the contractors' responsibility to
perform the work in accordance with the Contract Documents, the
Engineer is not responsible or liable for the contractors' failure to
do so, and, so long as Engineer has exercised the usual degree of care
and prudent judgment in selecting Project Representatives and has used
diligence to see that they are on the job to perform the work, failure
by any Project Representatives of other personnel engaged in
on- the -site observation to discover defects or deficiencies in the
work of the contractors shall never relieve the contractors of
liability therefor or subject the Engineer to any liability for any
such defect or deficiencies.
7. Review samples, catalog data, schedules, shop drawings,
laboratory, shop and mill tests of materials and equipment and other
data which the contractor is required to submit, only for conformance
with the design concept of the Projects and compliance with the
information given by the Contract documents; and assemble written
guarantees which are required by the Contract Documents.
S. Review monthly and final estimates for payments to
contractors, and furnish to the Owner any necessary certifications as
to payments to contractors and suppliers in a form acceptable to the
City.
-4-,
RR
9. Condtict,,in company with the Owner, a final inspection of the
Project for conformance with the Contract Documents, and approve in
writing final payment to the contractors.
10. Revise contract drawings, with the assistance of the resident
Project Representatives, or the Owners representative, to provide
record drawings of the completed Project. Furnish one set of
reproducible drawings and one set of prints of these revised drawings
to the Owner.
SECTION III
AUTHORIZATION OF SERVICES
No professional services of any nature shall be undertaken by the
Engineer under this Agreement until he has received written
authorization from the Owner.
SECTION IV
PERIOD OF SERVICE
THis Agreement shall be effective upon execution by the Owner and
the Engineer, and shall remain in force until terminated under the
provisions hereinafter provided in Section R.
SECTION V
COORDINATION WITH THE OWNER
The Engineer shall hold periodic conferences with the Owner, or
its representatives, to the end that the Project, as perfected, shall
have full benefit of the Owner's experience and knowledge of existing
needs and facilities, and be consistent with its current policies and
construction standards. To implement this coordination, the Owner
shall make available to the Engineer, for use in planning the Project,
all existing plans, maps, field notes, statistics, computations, and
other data in his possession relative to existing facilities and to
the Project.
SECTION VI
THE ENGINEF S COM MPENSATION
For and in consideration of the services to be rendered by the
Engineer, the Owner shall pay, and the Engineer shall receive the
compensation hereinafter set forth, for the Preliminary, Design, and
Construction Phases of the work and for Special Assignments and
Services not included in these phases. All remittances by Owner of
such compensation shall either be mailed or delivered to the
Engineer's office at 2499 Capital of Texas Highway Scuth, Suite 204,
Austin, Texas 78746. Where the compensation is based on a percentage
-5-
RR
of construction cost, the charge for each separate phase shall be
based on the "construction cost" of all work authorized by the Owner
at one time, and handled by the Engineer in accordance with this
Agreement.
"Construction Cost" is defined as the total cost to the Owner for
the execution of the work authorized at one time and handled in each
separate phase of engineering services, excluding fees or other cost
for engineering and legal services, the cost of land, rights -of -way,
legal and administrative expenses; but including the direct cost to
the Owner of all construction contracts, items of construction,
including labor, materials and equipment required for the completed
work (including extras) and the total value at site of project of all
labor, materials, and equipment purchased or furnished directly by
the Owner for the Project.
The aggregate of all sums paid to the Engineer for each Phase of
Construction will equal one hundred percent (100 %) of the basic
compensation determined from the actual total construction costs. If
the designed facilities exceed the available funding after receiving
bids or negotiating a contract price, then the facilities which are
deleted will be paid for at a later date when they are awarded for
construction. These facilities will be considered an individual
period of construction and payment will be in an amount equal to a
percentage of the "construction cost" of this separate Project. For
example: If the available funds will only build ninety percent (90 %)
of the designed facilities, the fee for the awarded construction will
be paid as described herein. When the remaining ten percent (10 %) of
the work is awarded, it will be considered a separate Project and a
percentage from the curve based on the ten percent (10 %) Project
amount will be used to pay the basic compensation. Considering this
as an individual Project, it will be necessary to compensate the
Engineer in this manner because of the extra work involved in the
preparation of separate contract documents, organization of plans,
construction administration on the delayed Project, and the delay in
payment for the Engineering Services rendered.
In the event that proposals for construction of any of the work
authorized in the Design Phase are received within ninety (90) days
after submission of completed contract drawings and specifications to
the Owner by the Engineer, the charge for the corresponding services
in the Design Phase and the charge for the corresponding services in
the Preliminary Phase shall be adjusted to the "construction cost" as
reflected by the lowest acceptable proposal, or lowest bona fide bid,
if no contract is awarded. Where no proposal or bona fide bids are
received, the Engineer's estimates shall be the basis for final
payment for these two phases. No reduction shall be made from the
Basic Charge on account of penalties or liquidated damages or other
sums withheld from contractor's payments.
-6-
RR
A. PRELIMINARY PHASE
Payment for services in the Preliminary Phase shall be made to
the Engineer in a sum equal to a percentage of the "construction cost"
of the work authorized by the Owner in this Phase of the Project.
This percentage for the Preliminary Phase shall be computed as ten
percent (10X) of the Basic Charge, which Basic Charge is defined by
Attachment No. 1.
The classification of the construction work (Classification "A"
or "B ") for the purpose of applying the alternate Basic Charge is that
given in Attachment No. 2 - Classification of Construction Work.
Final Payment for services in the Preliminary Phase shall be
payable upon submission to the Owner of the required report, sketches,
and estimates, and upon his acceptance, which shall be within thirty -
(30) days after submission.
If a written report is not required, this payment will be due
with and in addition to payment stated in the Design Phase.
B. DESIGN PHASE
Payment for services in the Design Phase shall be made to the
Engineer in a sum equal to a percentage of the "construction cost" of
the work authorized by the Owner in this Phase of the Project. This
percentage for the Design Phase shall be computed as seventy -five
percent (75$) of the Basic Charge, which Basic Charge is defined by
Attachment No. 1.
The classification of the construction work (Classification "A"
or "B ") for the purpose of applying the alternate Basic Charge is that
given in Attachment No. 2 - Classification of Construction Work.
Final payment for services authorized in the Design Phase shall
be due upon the completion of these services and upon the Owner's
acceptance, which shall be within thirty (30) days after submission.
When the Project is funded through the sale of municipal bonds or
through grant funds, payments shall not be due until the funds are in
the Owner's possession.
C. CONSTRUCTION PHASE
Payment for services in the Construction Phase shall be made to
the Engineer in a sum equal to a percentage of the "construction cost"
of the work authorized by the Owner in this Phase of the Project.
This p for the Construction Phase shall be computed as
fifteen percent (15X) of the Basis Charge, which Basic Charge is
defined in Attachment No. 1.
-7-
• RR.
The classification of the construction work (Classification "A"
or "B ") is that given in Attachment No. 2 - Classification of
Construction Work.
This sum will be paid in monthly installments in proportion to
the construction work completed, on the basis of the Engineer's
estimates prepared for monthly payments to contractors, plus the
actual value of all materials and equipment purchased or furnished
directly by the Owner for the Project. Upon completion of all work
authorized in the Construction Phase the Engineer will be paid the
remainder of the charge for this Phase.
D. SPECIAL ASSIGNMENTS AND SERVICES NOT INCLUDED IN ABOVE PERCENTAGE
CHARGES
The charges above described in the Preliminary, Design and
Construction Phases shall provide compensation to the Engineer for all
services called for under this Agreement to to be performed by him, or
under his direction, except the services set forth below. These
excluded services and Special Assignments, and the compensation to be
paid by the Owner to the Engineer for their performance, as required,
are as follows:
The following services, if authorized by the Owner (1 through 7),
shall be reimbursed in accordance with Attachment No. 3 - Hourly Rate
Schedule.
1. Services of a resident Project Representative, and other
field personnel as required, for on- the -site observation of
construction.
2. Services for Construction Layout Surveys (Construction
Staking).
3. Land surveys and establishment of boundaries and monuments.
4. Preparation of property or easement descriptions.
5. Preparation of any special reports required for marketing of
bonds.
6. Appearances before regulatory agencies.
7. Special investigations involving detailed consideration of
operation, maintenance and overhead expenses; preparation of rate
schedules; earnings and expense statements; special feasibility
studies; appraisals; valuations; and material audits or inventories
required for certification of force account construction performed by
the Owner.
8. Additional copies of reports and specifications (over 25) and
additional blueprint copies (over 25).
RR
9. Preparation of applications and supporting documents for
government grants, loans or planning advances for public works
projects.
10. Assistance to the Owner as an expert witness in any
litigation with third parties, arising from the development or
construction of the Project.
Basis of Compensation: $100.00 per hour in which Engineer's
presence or his representative is required by Owner; $400.00 per day
minimum charge.
11. Soil and foundation investigations, including test and
analyses of test results.
Basis of Compensation: (a) Furnished by the Owner and
observed by the Engineer in accordance with Attachment No. 3 - Hourly
Rate Schedule, or (b) Owner contract separately with qualified testing
'
12. Detailed mill, shop and /or laboratory inspection of materials
or equipment.
Basis of Compensation: (a) Furnished directly by the "Owner,
or (b) by Engineer in accordance with Attachment No. 3 - Hourly Rate
Schedule.
13. Extra travel required of the Engineer and authorized by the
Owner from Round Rock to points other than the State of Texas in
connection with the Project.
Basis of Compensation: Cost of travel and living expenses
plus a twenty percent (20%) service charge. Cost of labor in
accordance with Attachment No. 3 - Rate Schedule.
14. Services for location stakes associated with the Project as
necessary for utility companies operating within the City Limits of
Round Rock.
Payments to the Engineer for authorized services not in the basic
percentage charges will be made by the Owner, upon presentation of
statements by the Engineer for such services, but not until Bond or
Grant funds are in the Owner's possession.
Should the Owner fail to make payment to the Engineer of the sum
named in any partial or final statement when payment is past due for
more than thirty (30) days, then the Owner shall pay to the Engineer,
in addition to the sum shown as due by such statement, interest
thereon at the current prime rate of banking institutions in Round
Rock, from the date due, as provided herein, until fully paid, which
shall fully liquidate any injury to the Engineer arising from such
delay in payment, but the right is expressly reserved to the Engineer
-9=
RR
in event payments are not promptly made as provided herein, at any
time thereafter to treat the Agreement as terminated by the Owner and
recover compensation as provided by Section X of this Agreement.
SECTION VII
REVISION TO DRAWINGS AND SPECIFICATIONS
The Engineer will make, without expense to the Owner, such
revisions of the preliminary drawings as may be required to meet the
needs of the Owner, but after a definite plan has been approved by the
owner, if a decision is subsequently made by the Owner, which, for its
proper execution, involves extra services and expenses for changes in,
or addition to the drawings, specifications or other documents, or if
the Engineer is put to labor or expense by delays imposed on him from
causes not within his control, such ae by (but not limited to) the
readvertisement for bids or by the delinquency or insolvency of
contractors, the Engineer shall be compensated for such extra services
and expenses, which services and expenses shall not be considered as
covered by the percentage fee stipulated in this Agreement.
Compensation for such extra services shall be in accordance with
Attachment No. 3 - Hourly Rate Schedule. However, no extra
compensation will be granted to the Engineer for correcting errors in
the plans or errors in the design of the Project or for revising
design or plans when such design and plans provide not to be feasible
for construction.
SECTION VIII
OWNERSHIP OF DOCUMENTS
Engineer shall retain ownership of all original documents, plan
designs, and survey notes on all projects that are not completed and
for which Engineer is not compensated regardless of whether the
instruments were copyrighted. Additionally, all such documents for
which Engineer is not compensated Owner will not reuse for extensions
of the original project or new projects unless Owner shall secure the
permission of Engineer and Engineer shall be entitled to further
compensation for the use of such documents.
All original documents, plan designs, and survey notes for
completed or partially completed projects for which Engineer has been
compensated shall be the property of Owner and Engineer and
reproducible copies shall be furnished to the Owner upon request. The
use by either party of such documents is unrestricted.
SECTION IX
ARBITRATION UNDER TEXAS GENERAL ARBITRATION ACT
A. Any controversy hereafter arising between Owner and Engineer
in connection with this Agreement and any liability or claimed
liability created hereunder or incident hereto or pertaining to the
-10-
RR
enforcement of any provision, condition or covenant herein shall be
.submitted to arbitration under the terms of the Texas General
Arbitration Act. Either party may invoke this provision for
arbitration by giving the other party notice in writing demanding that
such controversy be submitted to arbitration, which notice shall also
contain the appointment of an arbitrator by the demanding party. The
party receiving such notice of arbitration must, within five (5) days
after receiving same, mail to the demanding party a notice of
appointment of a second arbitrator. Such two arbitrators shall meet
forthwith and agree in writing upon a third arbitrator, and shall
immediately give the parties written notice of the third arbitrator's
appointment.
B. If the party upon whom the demand for arbitration is served
fails to give the demanding party the required notice of the
appointment of the second arbitrator within the required five (5)
days, the demanding party may apply to the court under Article 226,
Revised Statutes of 1925, to appoint the second arbitrator. If the
first two arbitrators fail to agree upon a third arbitrator within ten
(10) days from the date the second arbitrator was appointed, either
party may apply to the court, under such Article 226, for the
appointment of the third arbitrator.
C. The proceedings of the arbitrators, the award made by the
arbitrators and the endorsement of such awards shall be governed by
the Texas General Arbitration Act, Articles 224 through 236 -6,
inclusive, Revised Statutes of 1925, as amended.
D. This entire Section IX providing for arbitration shall
survive the termination of this Agreement under any of its provisions,
and any controversy between Owner and Engineer existing when the
Agreement terminates shall continue to be subject to arbitration
hereunder.
SECTION X
TERMINATION
Either party to this Agreement may terminate the Agreement by
giving to the other thirty (30) days notice in writing. Upon delivery
of such notice by the Owner to the Engineer, and upon expiration of
the thirty - day period, the Engineer shall discontinue all services in
connection with the performance of this Agreement and shall proceed
to cancel promptly all existing orders and contracts insofar as such
orders or contracts are chargeable to this Agreement. As soon as
practicable after receipt of notice of termination, the Engineer shall
submit a statement, showing in detail the services performed under
this Agreement to the date of termination. The Owner shall then pay
the Engineer promptly that portion of the prescribed charges which the
services actually performed under this Agreement bear to the total
services called for ;under this Agreement, less such payments on
account of the charges as have been previously made. copies of all
RR
completed or completed designs, plans and specifications
prepared under this Agreement shall be delivered to the Owner when and
if this Agreement is terminated, but subject to the restrictions, as
to their use, as set forth in Section VIII.
SECTION XI
ADDRESS OF NOTICES AND COMMUNICATIONS
All notices and communication under this Agreement to be mailed
or delivered to Engineer shall be to the following address:
Carlson & Dippel, Inc.
2499 Capital of Texas Highway - Suite 204
Austin, Texas 78746
All notices and communications under this Agreement to be mailed or
delivered to the Owner shall be to the following address:
City of Round Rock
214 E. Main Street
Round Rock, Texas 78664
SECTION XII
SECTION CAPTIONS
Each Section under the Contractual Undertakings has been supplied
with a caption to serve only as a guide to the contents. The caption
does not control the meaning of any Section or in any way determine
its interpretation or applications.
SECTION XIII
SCHEDULE OF COMPLETION
The Engineer will fulfill the scope of services included in the
Project in a professional and timely manner. The Owner's wishes and
requirements regarding the project will be conveyed through the City's
Director of Public Works, and the Engineer shall confer frequently
with the Director of Public Works throughout the Design Phase of the
Project. The calendar days for completion of the Design Phases are
described in Attachment No. 5 and each shall commence upon written
authorization from the Owner.
SECTION XIV
SUCCESSORS AND ASSIGNS
The Owner and the Engineer each binds himself and his successors,
executors, administrators and assigns to the other party of this
Agreement and to the successors, executors, administrators and assigns
-12--
RR
of such othei party, in respect to all covenants of this Agreement.
Except as above, neither the Owner nor the Engineer shall assign,
sublet or transfer his interest in this Agreement without the written
consent of the other. Nothing herein shall be construed as creating
any public body which may be a party hereto.
EXECUTED in two counterparts (each of which is an original) on
behalf of the Engineer by its President shown below, and on behalf of
the owner b its Mayor (thereunto duly authorized) this the „.q
day of , 191L.
ATTEST:
ATTEST:
Land, City Secretary
CITY OF ROUND ROCK
Mike Robinson, Mayor
CARLSON & DIPPEL, INC.
111
�
I2
11
10
'
0, 4
'
I
fir■
ii i iTh
1
-
i
1
+'
I
1
�
r7
i
1:
�11Q
NOTES:
(1) Construction
Charge el
- Percent" ColumnforCurve " s the
A "or
"Basic
Curve "B" as 1s applicable for $100.000 Construc-
tion Cost line.
(2) Construction Cost below is the work authorized at
one time. However, Where the work is to be accom-
plished in a number of separate construction con-
tracts, then each such project element should be
evaluated on an individual basis. with additional-
compensation to the Engineer.
(3) Curve "A" and Curve "B" are consistent with Curve
"A" and Curve "B" in Manual 45, published by the
American Society of Civil Engineers.
(4) The "Basic Charge - Percent" Column shall be rounded
to the nearest tenth of a percent.
0.00 0.1
nnucrD, umnnu rosT
' • s
s
unotnuc nr nnl l spc
10
' •1
so
100
ATTACHMENT N0. 2
CLASSIFICATION OF CONSTRUCTION WORK
CURVE A will apply to assignments of which the following are typical
examples (payment for design surveys included with below assignments
except where shown otherwise):
Water treatment plants
Sewage and industrial waste treatment plants
Sanitary sewage collection lines under 24 -inch diameter
Water pumping stations
Sewage lift stations
Open - section streets, no curb and gutter, and associated drainage
improvements (NO DESIGN SURVEYS INCLUDED IN BASIC CHARGE)
Curb and gutter, streets and associated drainage improvements
Bridges, box culverts and major drainage structures
Water distribution lines 12" and larger (on Curve "A" due to
profile being required on Plans)
Water storage tank renovation, including repainting, yard piping,
or tank appurtenances
CURVE B will apply to less complicated assignments of which the
following are examples (payment for design surveys included with below
assignments except where shown otherwise):
Sanitary sewage collection lines 24 -inch diameter and over
Water distribution lines under 12"
Water storage tanks (elevated and ground storage and standpipes)
Earthwork
Storm sewers 24 -inch diameter and over
-15-
ATTACHMENT NO. 3
HOURLY RATE SCHEDULE
ITEM DESCRIPTION HOURLY RATE
1. Principals $100.00
2. Registered Engineer - Registered Surveyor $60.00
3. Engineer $50.00
4. Sr. Engineer Technician - Sr. Survey Technician $45.00
5. Engineer Technician - Survey Technician $40.00
6. Drafter $35.00
7. Clerical $25.00
8. Field Party $85.00
9. Senior Planner $55.00
10. Planner $50.00
11. Materials and Outside Services Coat + 20%
-16-
RR Revised 1 -17 -86
ATTACHMENT NO. 4
STREET AND DRAINAGE IMPROVEMENT PROJECTS
STREET
Phase 1
A. Cushing Drive (from Gattis School Road
to Logan Street)
B. School Days Lane (500 LF ± from Cushing
Drive to the east)
C. Sam Bass Road (from Meadows Drive to Creek Bend)
TOTAL CONSTRUCTION COST
ENGINEERING AND CONTINGENCIES (258)
—17—
ESTIMATED COST
$ 380,000
61,000
575,000
$1,016,000
254,000
$1,270,000
RR
ATTACHMENT NO. 5
PROJECT SCHEDULE
DESIGN PHASE
A. Cushing and School Days Lane
CALENDAR_ DAYS
Design 60
City review and bid process 60
120
B. Sam Bass Road
Design 110
City review and bid process 60
170
-18-
Revised 1 -17 -86
RESOLUTION NO. 7134
WHEREAS, engineering services are necessary in order to
design certain improvements to the following streets: Sunset
East, Sam Bass Road, School Days Lane, Logan Street, Cushing
Drive and ✓ Virginia Drive, and
WHEREAS, the engineering firm of Carlson & Dippel, Inc. has
submitted a proposal to provide the needed engineering services,
and
WHEREAS, the City Council wishes to accept said proposal,
Now Therefore,
BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK,
TEXAS
That the Mayor of the City of Round Rock, Texas, is hereby
authorized and directed to execute on behalf of the City, a
proposal submitted by Carlson & Dippel, Inc. to design certain
improvements to said streets, a copy of such proposal being
attached hereto and incorporated herein for all purposes.
RESOLVED this 23rd day of May, 1985.
AT ST:
11 ///L .. m LAIAL
JolfNNE LAND, City Secretary
001RES
MIKE ROBINSON, Mayor
City of Round Rock, Texas