Loading...
R-89-1303 - 7/13/1989WHEREAS, the City of Round Rock, Texas desires an engineering design for Corridor Drive, and WHEREAS, Haynie and Kallman, Inc. has submitted a proposal for engineering services to design Corridor Drive, and WHEREAS, the City Council desires to accept the proposal of Haynie and Kallman, Inc., Now Therefore, BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK, TEXAS That the Mayor is hereby authorized and directed to execute on behalf of the City of Round Rock, Texas, an agreement with Haynie and Kallman, Inc. for the design of Corridor Drive. RESOLVED this 13th day of July, 1989. ATTEST: .rr /112D) j AWL/ JO E LAND, City Secretary C45RESENGIN RESOLUTION NO. /J ®3 /e/ MIKE ROBINSON, Mayor City of Round Rock, Texas DATE: July 10, 1989 SUBJECT: Council Agenda, July 13, 1989 ITEM: 13D. Consider a resolution authorizing the Mayor to enter into a contract with Haynie and Kallman, Inc. for the design of Corridor Drive. STAFF RESOURCE PERSON: Joe Vining, Jim Nuse STAFF RECOMMENDATION: Staff is recommending the authorization of a contract for engineering design work on the extension of Corridor Drive. Although staff does not have a final agreement with all the property owners on how the City is to be repaid, District 14 of SDHPT is requesting the plans prior to their approval of the traffic signal for Corridor Dr. and FM 1325. Therefore, timely completion of these plans can help this project move toward completion this year. ECONOMIC IMPACT: The cost of this project has been approved in the 1989 Capital Budget. March 22, 1989 James R. Nuse, P.E. Director of Public Works City of Round Rock 300 S. Blair Street Round Rock, Texas 78664 Re: Engineering Services Agreement (Revised) Corridor Drive Street and Drainage Improvements Dear Mr. Nuse: Pursuant to your request, enclosed please find two revised originals of page 1 and Attachment No. 1 for insertion in the Engineering Services Agreements (the "Agreement ") for the Corridor Drive Street and Drainage Improvement project which was submitted to you March 9, 1989. The revisions reflect the cost for the eastern one -half of an approximate 1,450 L.F. 60 -foot wide face -to -face curb and gutter street section and all associated drainage improvements rather than the full width project. For your convenience, the changes on page 1 have been "redlined ". If you have any further questions or comments concerning this Agreement, please advise. Cordially, HAYNIE KALLMAN & GRAY, INC. 2 , toiaka St € ven D. Hallman, P.E., R.P.S. SDK /c la Enclosures Haynie eerily, Inc. Consulting Engineers cc: Robert L. Bennett, AICP, City Manager; City of Round Rock icc: A. William Waeltz, Project Manager 12303 Technology Blvd., Suite] Austin,Te us 78727 (512) 2508611 Civil Engineering Consultants Municipal Engineering land Planning Surveying MADE AND ENTERED INTO by and between the CITY OF ROUND ROCK, TEXAS, hereinafter called the "Owner ", and HAYNIE & KALLMAN, INC., Consulting Engineers, hereinafter called the "Engineer ". The Owner intends to construct CORRIDOR DRIVE STREET AND DRAINAGE IMPROVEMENTS, including the eastern one -half of approximately 1,450 L.F. of 60 -foot face -to -face curb and gutter street and all associated drainage improvements from existing Corridor Drive northerly to F.M. 1325 (refer to Attachment No. 1). Such improvements are hereinafter referred to as the "Project ". The estimated cost for the„half -width project is $136,517.40 including construction costs, engineering and contingencies. SECTION I EMPLOYMENT OF ENGINEER The Owner agrees to employ the Engineer and the Engineer agrees to perform professional engineering services in connection with the Project as stated in the Sections to follow, and for having rendered such services, the Owner agrees to pay to the Engineer compensation as stated in the Sections to follow. The Engineer shall render the following professional services necessary for the development of the Project. A. PRELIMINARY PHASE 1. Attend preliminary conference with the Owner regarding the Project. 2. Perform preliminary engineering services in connection with the Project in sufficient detail to indicate clearly the problems involved and the alternate solutions available to the Owner, to include preliminary layouts, sketches, and cost estimates for the Project, and to set forth clearly the Engineer's recommendations. If called for by the scope of the assignment, prepare a preliminary engineering report. ESA CORIDR (Revised 03/22/89) ENGINEERING SERVICES AGREEMENT RECITALS CONTRACTUAL UNDERTAKINGS SECTION II CHARACTER AND EXTENT OF SERVICES -1- 3. When a written report is prepared, furnish the Owner ten (10) copies of the preliminary report, including preliminary layouts, sketches and cost estimates. B. DESIGN PHASE 1. Establish the scope, and advise the Owner, of any soil and foundation investigations or any special surveys or special testing which, in the opinion of the Engineer, may be required for the proper execution of the Project; and arrange with the Owner for the conduct of such investigations and tests. (The performance of these investigations and tests is not a part of the Engineer's basic services, and compensation therefore is not included in the Basic Charge; it may be performed by the Engineer, by agreement with the Owner, in which case compensation shall be determined by the applicable portions of Section VI D.) 2. Furnish to the Owner, where required by the circumstances of the assignment, the engineering data necessary for applications for routine permits by local, state, and federal authorities (as distinguished from detailed applications and supporting documents for government grants -in -aid, state loan programs, planning advances or to meet the requirements of special programs of the federal government). 3. Perform field surveys to collect information which, in the opinion of the Engineer, is required in the design of the Project. Construction staking for the Construction Improvements is not included in the Basic Charge. 4. Prepare detailed specifications and contract drawings, in pencil on paper, for construction authorized by the Owner. These designs shall in all respects combine the application of sound engineering principles with a high degree of economy, and shall be submitted to the applicable local, state, and federal agencies for approval. 5. Prepare detailed cost estimates and proposals of authorized construction, which shall include summaries of bid items and quantities which will be based, wherever practical, on the unit price system of bidding. The Engineer shall not be required to guarantee the accuracy of these estimates. 6. Furnish the Owner all necessary copies of approved plans, specifications, notices to bidders, and proposals. All sets of plans and specifications in excess of twenty -five (25) are to be paid for separately. Additional sets will be paid for in accordance with Attachment No. 4 - Hourly Rate Schedule. -2- 7. Provide information on utilities to be relocated in connection with the Project. The Owner will provide excavation to determine location and depth of underground water and sewer lines. Utilities to be relocated by others shall be noted on the plans. City -owned utilities to be relocated also shall be noted on the plans. Where feasible, relocation of City -owned utilities shall be included in the construction contract. 8. Provide a letter for the Owner's signature to each utility operating within the City of Round Rock advising them of the Project and describing any known relocations to be performed by that utility and setting forth a proposed construction schedule. This letter and a complete set of plans shall be delivered to each utility by the Engineer. The Engineer shall provide timely assistance and location stakes as necessary for utility relocations to assure that utility relocations do not delay the Project. 9. Provide easement and right -of -way descriptions to the Owner in conjunction with submission of final plans. These will be provided in the form of field notes and drawings of the affected properties. These services will be paid for in accordance with Attachment No. 4 - Hourly Rate Schedule. 10. Provide field note descriptions to the Owner for any site(s) that is required for Owner to acquire that is associated with this Project. These descriptions will be provided within thirty (30) days after authorization by Owner, barring unforeseen and unusual difficulties associated with the property. These services will be paid for in accordance with Attachment No. 4 - Hourly Rate Schedule. C. CONSTRUCTION PHASE 1. Assist the Owner in the advertisement of the Project for bids. 2. Assist the Owner in the opening and tabulating of bids for construction of the Project, and recommend to the Owner as to the proper action on all proposals received. 3. Assist in the preparation of formal Contract Documents for the contracts. 4. Make periodic visits to the site (as distinguished from the continuous services of a Resident Project Representative described in Subparagraph 6 below) to observe the progress and quality of the executed work and to determine, in general, if the work is proceeding in accordance with the Contract Documents. In performing this service, the Engineer will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the work or -3-- material; he will not be responsible for the techniques and sequences of construction or the safety precautions incident thereto, and he will not be responsible or liable in any degree for the Contractor's failure to perform the construction work in accordance with the Contract Documents. During visits to the construction site, and on the basis of the Engineer's on -site observations as an experienced and qualified design professional, he will keep the Owner informed of the extent of the progress of the work, and advise the Owner of material and substantial defects and deficiencies in the work of Contractors which are discovered by the Engineer or otherwise brought to the Engineer's attention in the course of construction, and may, on behalf of the Owner, exercise whatever rights the Owner may have to disapprove work and materials as failing to conform to the Contract Documents. 5. Consult with and advise the Owner; issue all instructions to the Contractor requested by the Owner; and prepare routine change orders as required. 6. If specifically authorized by the Owner in writing, furnish the services of Resident Project Representatives, and other field personnel for continuous on -the -site observation of construction and for the performance of required construction layout surveys. (This service is not a part of the Engineer's basic services, and compensation therefore is not included in the Basic Charge; if provided, compensation shall be determined under Section VI D.) The authority and duties of such Resident Project Representatives are limited to examining the material furnished and observing the work done, and to reporting their findings to the Engineer. The Engineer will use the usual degree of care and prudent judgment in the section of competent Project Representatives, and the Engineer will use diligence to see that the Project Representatives are on the job to perform their required duties. It is agreed, however, that the Engineer does not underwrite, guarantee, or insure the work done by the Contractors, and since it is the Contractor's responsibility to perform the work in accordance with the Contract Documents, the Engineer is not responsible or liable for the Contractor's failure to do so, and, so long as the Engineer has exercised the usual degree of care and prudent judgment in selecting Project Representatives and has used diligence to see that they are on the job to perform the work, failure by any Project Representatives or other personnel engaged in on- the -site observation to discover defects or deficiencies in the work of the Contractors shall never relieve the Contractors of liability therefore or subject the Engineer to any liability for such defects or deficiencies. 7. Review samples, catalog data, schedules, shop drawings, laboratory, shop and mill tests of materials and equipment and other data which the Contractor is required to submit, only for conformance with the design concept of the Project and compliance with the information given by the Contract Documents; and assemble written guarantees which are required by the Contract Documents. -4- 8. Review monthly and final estimates for payments to Contractors, and furnish to the Owner any necessary certifications as to payments to Contractors and Suppliers. 9. Conduct, in company with the Owner, a final inspection of the Project for conformance with the design concept of the Project and compliance with the Contract Documents, and approve in writing final payment to the Contractors. 10. Revise contract drawings, with the assistance of the Resident Project Representatives and the Owner's representatives, to provide record drawings of the completed Project. Furnish one set of reproducible drawings and one set of prints of these revised drawings to the Owner. SECTION III AUTHORIZATION OF SERVICES No professional services of any nature shall be undertaken by the Engineer under this Agreement until he has received authorization from the Owner. SECTION IV PERIOD OF SERVICE This Agreement shall be effective upon execution by the Owner and the Engineer, and shall remain in force until terminated under the provisions hereinafter provided in Section X. SECTION V COORDINATION WITH THE OWNER The Engineer shall hold a 10% and 40% Design Review Conference with the Owner, or its representatives, to the end that the Project, as perfected, shall have full benefit of the Owner's experience and knowledge of existing needs and facilities, including preliminary line routings, approved manufacturers of materials and equipment, and other pertinent items relative to the Project and updated cost estimates, and consistent with its current policies and construction standards. To implement this coordination, the Owner shall make available to the Engineer, for use in planning the Project, all existing plans, maps, field notes, statistics, computations, and other data in his possession relative to existing facilities and to the Project. -5- SECTION VI THE ENGINEER'S COMPENSATION For and in consideration of the services to be rendered by the Engineer, the Owner shall pay, and the Engineer shall receive the compensation hereinafter set forth, for the Preliminary, Design, and Construction Phases of the work and for Special Assignments and Services not included in these phases. All remittances by Owner of such compensation shall either be mailed or delivered to the Engineer's office in Round Rock, Williamson County, Texas. Where the compensation is based on a percentage of construction cost, the charge for each separate phase shall be based on the "Construction Cost" of all work authorized by the Owner at one time, and handled by the Engineer in accordance with this Agreement. "Construction Cost" is defined as the total cost to the Owner for the execution of the work authorized at one time and handled in each separate phase of engineering services, excluding fees or other cost for engineering and legal services, the cost of land, rights -of -way, legal and administrative expenses; but including the direct cost to the Owner of all construction contracts, items of construction, including labor, materials, and equipment required for the completed work (including extras) and the total value at site of Project of all labor, materials, and equipment purchased or furnished directly by the Owner for the Project. The aggregate of all sums paid to the Engineer for each phase of construction will equal one hundred percent (100%) of the basic compensation determined from the actual total construction costs. If the designed facilities exceed the available funding after receiving bids or negotiating a contract price, then the facilities which are deleted will be paid for at a later date when they are awarded for construction. These facilities will be considered an individual period of construction and payment will be in an amount equal to a percentage of the "construction cost" of this separate Project. For example: If the available funds will only build 90% of the designed facilities, the fee for the awarded construction will be paid as described herein. When the remaining 10% of the work is awarded, it will be considered a separate Project and a percentage from the curve based on the 10% Project amount will be used to pay the basic compensation. Considering this as an individual Project, it will be necessary to compensate the Engineer in this manner because of the extra work involved in the preparation of separate contract documents, organization of plans, construction administration on the delayed Project, and the delay in payment for the Engineering Services rendered. In the event that proposals for construction of any of the work authorized in the Design Phase are received within 90 days after submission of completed contract drawings and specifications to the Owner by the Engineer, the charge for the corresponding services in the -6- Design Phase and the charge for the corresponding services in the Preliminary Phase shall be adjusted to the "construction cost" as reflected by the lowest acceptable proposal, or lowest bona fide bid, if no contract is awarded. Where no proposal or bona fide bids are received, the Engineer's estimates shall be the basis for final payment for these two phases. No reduction shall be made from the Basic Charge on account of penalties or liquidated damages or other sums withheld from Contractor's payments. A. PRELIMINARY PHASE Payment for services in the Preliminary Phase shall be made to the Engineer on an hourly basis. See Attachment No. 4 - Hourly Rate Schedule. Final payment for services in the Preliminary Phase shall be payable upon submission to the Owner of the required report, sketches, and estimates, and upon his acceptance, which shall be within thirty (30%) days after submission. B. DESIGN PHASE Payment for services in the Design Phase shall be made to the Engineer in a sum equal to a percentage of the "construction cost" of the work authorized by the Owner in this Phase of the Project. This percentage for the Design Phase shall be computed as eighty -five percent (85%) of the Basic Charge, which Basic Charge is defined by Attachment No. 2, less fees paid for Preliminary Phase. The classification of the construction work (Classification "A" or "B ") for the purpose of applying the alternate Basic Charge is that given in Attachment No. 3 - Classification of Construction Work. This sum will be paid in installments in proportion to the engineer's estimate of work completed at the 10% and 40% "complete" periods and 100% upon submission of completed plans to the Owner, up to 85% of the total Basic Charge. Payment for services authorized in the Design Phase shall be based upon the Engineer's Preliminary Estimate of the "construction cost" of the work. This Design Phase payment shall then be adjusted to the actual "construction cost" within thirty (30) days after the project is awarded and the Owner and Contractor have executed the Contract Documents. C. CONSTRUCTION PHASE Payment for services in the Construction Phase shall be made to the Engineer in a sum equal to a percentage of the "construction cost" of the work authorized by the Owner in this Phase of the Project. This -7- percentage for the Construction Phase shall be computed as fifteen percent (15 %) of the Basic Charge, which Basic Charge is defined in Attachment No. 2. The classification of the construction work (Classification "A" or "B ") is that given in Attachment No. 3 - Classification of Construction Work. This sum will be paid in monthly installments in proportion to the construction work completed, on the basis of the Engineer's estimates prepared for monthly payments to contractors, plus the actual value of all materials and equipment purchased or furnished directly by the Owner for the Project. Upon completion of all work authorized in the Construction Phase, the Engineer will be paid the remainder of the charge for this Phase. D. SPECIAL ASSIGNMENTS AND SERVICES NOT INCLUDED IN ABOVE PERCENTAGE CHARGES The charges above described in the Preliminary, Design and Construction Phases shall provide compensation to the Engineer for all services called for under this Agreement to be performed by him, or under his direction, except the services set forth below. These excluded services and Special Assignments, and the compensation to be paid by the Owner to the Engineer for their performance, as required, are as follows: The following services (1 through 8), if authorized by the Owner, shall be reimbursed in accordance with Attachment No. 4 - Hourly Rate Schedule. 1. Services of a Resident Project Representative, and other field personnel as required, for on- the -site observation of construction. 2. Services for Design Surveys if not included in Basic Charge. 3. Services for Construction Layout Surveys (Construction Staking). 4. Land surveys and establishment of boundaries and monuments. 5. Preparation of property or easement descriptions. 6. Preparation of any special reports required for marketing of bonds. 7. Appearance before regulatory agencies. -8- 8. Special investigations involving detailed consideration of operation, maintenance and overhead expenses; preparation of rate schedules; earnings and expense statements; special feasibility studies; appraisals; valuations; and material audits or inventories required for certification of force account construction performed by the Owner. 9. Additional copies of reports and specifications (over 25) and additional blue print copies (over 25). 10. Preparation of applications and supporting documents for government grants, loans or planning advances for public works projects. 11. Assistance to the Owner as an expert witness in any litigation with third parties, arising from the development or construction of the Project. 12. Soil and foundation investigations, as required for the design of this Project and for Trench Safety Design, including test and analyses of test results. Basis of Compensation: (a) Furnished by the Owner and observed by the Engineer in accordance with Attachment No. 4 - Hourly Rate Schedule, or (b) Owner contract separately with qualified testing firm. 13. Detailed mill, shop and /or laboratory inspection of materials or equipment. Basis of Compensation: (a) Furnished directly by the Owner, or (b) By Engineer in accordance with Attachment No. 4 - Hourly Rate Schedule. 14. Extra travel required of the Engineer and authorized by the Owner from Round Rock to points other than the State of Texas in connection with the Project. Basis of Compensation: Cost of travel and living expenses plus a twenty percent (208) service charge. Cost of labor in accordance with Attachment No. 4 - Hourly Rate Schedule. 15. Services for location stakes associated with the Project as necessary for utility companies operating within the City Limits of Round Rock. Payments to the Engineer for authorized services not in the basic percentage charges will be made by the Owner, upon presentation of statements by the Engineer for such services, but not until Bond or Grant funds are in the Owner's possession. -9- Should the Owner fail to make payment to the Engineer of the sum names in any partial or final statement when payment is past due for more than thirty (30) days, then the Owner shall pay to the Engineer, in addition to the sum shown as due by such statement, interest thereon at the current prime rate of banking institutions in Round Rock, from the date due, as provided herein, until fully paid, which shall fully liquidate any injury to the Engineer arising from such delay in payment, but the right is expressly reserved to the Engineer in event payments are not promptly made as provided herein, at any time thereafter to treat the Agreement as terminated by the Owner and recover compensation as provided by Section X of this Agreement. SECTION VII REVISION TO DRAWINGS AND SPECIFICATIONS The Engineer will make, without expense to the Owner, such revisions of the preliminary drawings as may be required to meet the needs of the Owner, but after a definite plan has been approved by the Owner, if a decision is subsequently made by the Owner, which, for its proper execution, involves extra services and expenses for changes in, or addition to the drawings, specifications or other documents, or if the Engineer is put to labor or expense by delays imposed on him from causes not within his control, such as by (but not limited to) the readvertisement for bids or by the delinquency or insolvency of Contractors, the Engineer shall be compensated for such extra services and expenses, which services and expenses shall not be considered as covered by the percentage fee stipulated in this Agreement. Compensation for such extra services shall be in accordance with Attachment No. 4 - Hourly Rate Schedule. However, no extra compensation will be granted to the Engineer for correcting errors in the plans or errors in the design of the Project or for revising design or plans when such design and plans prove not to be feasible for construction. SECTION VIII OWNERSHIP OF DOCUMENTS Engineer shall retain ownership of all original documents, plan designs, and survey notes on all projects that are not completed and for which Engineer is not compensated regardless of whether the instruments were copyrighted. Additionally, all such documents for which Engineer is not compensated Owner will not reuse for extensions of the original project or new projects unless Owner shall secure the permission of Engineer and Engineer shall be entitled to further compensation for the use of such documents. All original documents, plan designs, and survey notes for completed or partially completed projects for which Engineer has been -10- compensated shall be the property of Owner and Engineer and reproducible copies shall be furnished to the Owner upon request. The use by either party of such documents is unrestricted. SECTION IX ARBITRATION UNDER TEXAS GENERAL ARBITRATION ACT A. Any controversy hereafter arising between Owner and Engineer in connection with this Agreement and any liability or claimed liability created hereunder or incident hereto or pertaining to the enforcement of any provision, condition or covenant herein shall be submitted to arbitration under the terms of the Texas General Arbitration Act. Either party may invoke this provision for arbitration by giving the other party notice in writing demanding that such controversy be submitted to arbitration, which notice shall also contain the appointment of an arbitrator by the demanding party. The party receiving such notice of arbitration must, within five (5) days after receiving same, mail to the demanding party a notice of appointment of a second arbitrator. Such two arbitrators shall meet forthwith and agree in writing upon a third arbitrator, and shall immediately give the parties written notice of the third arbitrator's appointment. B. If the party upon whom the demand for arbitration is served fails to give the demanding party the required notice of the appointment of the second arbitrator within the required five (5) days, the demanding party may apply to the court under Article 226, Revised Statutes of 1925, to appoint the second arbitrator. If the first two arbitrators fail to agree upon a third arbitrator within ten (10) days from the date the second arbitrator was appointed, either party may apply to the court, under such Article 225, for the appointment of the third arbitrator. C. The proceedings of the arbitrators, the award made by the arbitrators and the endorsement of such awards shall be governed by the Texas General Arbitration Act, Articles 224 through 238 -6, inclusive, Revised Statutes of 1925, as amended. D. This entire Section IX providing for arbitration shall survive the termination of this Agreement under any of its provisions, and any controversy between Owner and Engineer existing when the Agreement terminates shall continue to be subject to arbitration hereunder. SECTION X TERMINATION Either party to this Agreement may terminate the Agreement by giving to the other thirty (30) days notice in writing. Upon delivery of such notice by the Owner to the Engineer, and upon expiration of the thirty -day period, the Engineer shall discontinue all services in connection with the performance of this Agreement and shall proceed to cancel promptly all existing orders and contracts insofar as such orders or contracts are chargeable to this Agreement. As soon as practicable after receipt of notice of termination, the Engineer shall submit a statement, showing in detail the services performed under this Agreement to the date of termination. The Owner shall then pay the Engineer promptly that portion of the prescribed charges which the services actually performed under this Agreement bear to the total services called for under this Agreement, less such payments on account of the charges as have been previously made. Copies of all completed or partially completed designs, plans and specifications prepared under this Agreement shall be delivered to the Owner when and if this Agreement is terminated, but subject to the restrictions, as to their use, as set forth in Section VIII. SECTION XI ADDRESS OF NOTICES AND COMMUNICATION All notices and communication under this Agreement to be mailed or delivered to Engineer shall be to the following address: Haynie 6 Xallman, Inc. Consulting Engineers 309 East Main Street Round Rock, Texas 78664 All notices and communication under this Agreement to be mailed or delivered to the Owner shall be to the following address: City of Round Rock 221 E. Main Street Round Rock, Texas 7B664 SECTION XII SECTION CAPTIONS Each Section under the Contractual Undertakings has been supplied with a caption to serve only as a guide to the contents. The caption does not control the meaning of any Section or in any way determine its interpretation or application. -12- The Engineer will felfill the scope of services included in the Project in a professional and timely manner. The Owner's wishes and requirements regarding the Project will be conveyed through the City's Director of Public Works, with whom the Engineer shall confer frequently throughout the Design Phase of the Project. The date for completion of the Design Phase is ninety (90) calendar days following execution of this Agreement. SECTION XIV SUCCESSORS AND ASSIGNS The Owner and thy Engineer each binds himself and his successors, executors, administrators, and assigns to the other party of this Agreement and to the successors, executors, administrators, and assigns of such other party, in respect to all covenants of this Agreement. Except as above, neither the Owner nor the Engineer shall assign, sublet or transfer his interest in this Agreement without the written consent of the other. Nothing herein shall be construed as creating any public body which may be a party hereto. EXECUTED in two counterparts (each of which is an original) on behalf of the Engineer by its Vice President shown below, and on behalf of the Owner by its Mayor (thereunto duly authorized) this the day of , 198 Attest: Joanne Land, City Secretary Attest: Cheryl At strong SECTION XIII SCHEDULE OF .COMPLETION CITY OF ROUND ROCK Mike Robinson, Mayor HAYNIE & KALLMAN, INC. Steven D. Kallman, P.E., R.P.S. Vice President -13- 54 4174 ATTACHMENT NO. 1 SUMMARY OF PRELIMINARY COST ESTIMATE FOR CORRIDOR DRIVE STREET AND DRAINAGE IMPROVEMENTS 1. Eastern one -half of approximately 1,450 L.F. of 60 -foot wide face -to -face curb and gutter street, including all associated appurtenances @ $113,764.50 20% Engineering and %.ontingencies 22,752.90 TOTAL ESTIMATED PROJECT COST $136,517.40 ATTACHMENT NO. 3 CLASSIFICATION OF CONSTRUCTION WORK CURVE A will apply to assignments of which the following are typical examples (payment for design surveys included with below assignments except where shown otherwise): Water treatment plants Sewage and industrial waste treatment plants Sanitary sewage collection lines under 24 -inch diameter Water pumping stations Sewage lift stations Open- section streets, no curb and gutter, and associated drainage improvements (NO DESIGN SURVEYS INCLUDED IN BASIC CHARGE) Curb and gutter, streets and associated drainage improvements Bridges, box culverts and major drainage structures Water distribution lines 12" and larger (on Curve "A" due to profile being required on Plans) Water storage tank renovation, including re- painting, yard piping, or tank appurtenances CURVE B' will apply to less complicated assignments of which the following are examples (payment for design surveys included with below assignments except where shown otherwise): Sanitary sewage collection lines 24" diameter and over Water distribution lines under 12" Water storage tanks (elevated, ground storage and standpipes) Earthwork Storm sewers 24" diameter and over NOTE& (1) When CensMictlon Colt Is ruder $100,000, the reins. • owsable basis of compensation. � Gasfruction cost below Is the work authorized at one time. , where the work is to be accomplished in a number of separate construction contracts. Men each such prefect element should be evaluated on an Individual basis, with additional compensation to the Engineer. (3) The Basic Charge presented below represents median cem- pensation. The appropriate compensation for any given assign. 14 la la 11 10 • • 7 a a1111111■1111 �uuu11111 _.I11111 •.II1111 1111111111111 IN1111111111 1 11111111111111 111111•11111111 111uiu111i_ aii1111 �$UI1111! � ■11111111 1■1111111111111111 11•u111111111110IM 1111 �.. ■1111��UU� _.uu1111_&I ■lI111 MINNIlll_st. 1111 �.��1111 ■► 1111 111111111111111111■2 ■��111 111111111111 0.mI1111 11111111111111 101111111111111 ���� 1•111111111111 M11111111 �SII1111 �RIU1111 1111111111111 �uuu1111 11111111111111 111111111111111 MINI 11 MINIM 11111111111111 ��1111111 - �lu1111 111111111111111 _ _J �11au1111 la4 MUM MINIM 1111i1111111 ∎1111111e111111 11111111111111 111UI1.111I_ 1111111 O111111111111 1111.I.IIi:!1111111111..::!I1 _ 111111111111111 111111111I1111•12■111 111m■■I111 111111111111111 11111111111111 •1ii1111 11111111111111 11111111111111 0.01 0.01 0.1 CONSTRUCTION COST 0.0 emit may my obese or below the curve, depending upon csm Pini�• (4) Compensation ler alteration perk should be increased by at Nast enedhkd above Me median mien Illustrated. (5) Curve A and Curve 0 ire es nstent with Curve A and Curve It in Manual nears. New curves MI be luued subsequent revision m published by ASCE. s . MILLIONS OF DOLLARS 10 10 ,n.0 ATTACHMENT NO. 4 HAYNIE & KALLMAN, INC. HOURLY RATE SCHEDULE CLASSIFICATION HOURLY RATE 1. Registered Professional Engineer $ 75 2. Registered Public Surveyor $ 60 3. Project Manager /Hydrologist $ 55 4. Engineer -in- Training (E.I.T.) $ 45 5. Land Planner $ 50 6. Survey Crew Coordinator $ 40 7. Project Representative (includes Vehicle and Equipment) $ 40 8. Design Technician $ 35 9. Drafter $ 30 10. Survey Calculation Technician $ 40 11. Technical Support Personnel $ 30 12. Secretarial Personnel $ 25 13. Four Man Survey Crew (includes Vehicle and Equipment) $ 80 14. Three Man Survey Crew (includes Vehicle and Equipment) $ 75 15. Two Man Survey Crew (includes Vehicle and Equipment) $ 65 16. Reimbursement for Direct Non -Labor Expenses and Sub - Contract Expenses - Cost Plus 20% Revised 1 -9 -89 March 22, 1989 James R. Nuse, P.E. Director of Public Works City of Round Rock 300 S. Blair Street Round Rock, Texas 78664 Re: Engineering Services Agreement (Revised) Corridor Drive Street and Drainage Improvements Dear Mr. Nuse: Pursuant to your request, enclosed please find two revised originals of page 1 and Attachment No. 1 for insertion in the Engineering Services Agreements (the "Agreement ") for the Corridor Drive Street and Drainage Improvement project which was submitted to you March 9, 1989. The revisions reflect the cost for the eastern one -half of an approximate 1,450 L.F. 60 -foot wide face -to -face curb and gutter street section and all associated drainage improvements rather than the full width project. For your convenience, the changes on page 1 have been "redlined ". If you have any further questions or comments concerning this Agreement, please advise. Cordially, HAYNIE HALLMAN & GRAY, INC. j6 LJ i 6/(Lce.-5_ St ven D. Hallman, P.E., R.P.S. Haynie Kaman &Gray, Inc. Consubing Engineers SDK /c la Enclosures cc: Robert L. Bennett, AICP, City Manager: City of Round Rock icc: A. William Waeltz, Project Manager 12303 Technology Blvd., Suite.) Ausun,Taras 78727 5121 25043611 Civil Engineering Consultanis Municipal Engineering land Plmning Surveying ENGINEERING SERVICES AGREEMENT MADE AND ENTERED INTO by and between the CITY OF ROUND ROCK, TEXAS, hereinafter called the "Owner ", and HAYNIE & KALLMAN, INC., Consulting Engineers, hereinafter called the "Engineer ". RECITALS The Owner intends to construct CORRIDOR DRIVE STREET AND DRAINAGE IMPROVEMENTS, including the eastern one -half of approximately 1,450 L.F. of 60 -foot face -to -face curb and gutter street and all associated drainage improvements from existing Corridor Drive northerly to F.M. 1325 (refer to Attachment No. 1). Such improvements are hereinafter referred to as the "Project ". The estimated cost for the„half -width project is including construction costs, engineering and contingencies. ESA CORIDR (Revised 03/22/89) CONTRACTUAL UNDERTAKINGS SECTION I EMPLOYMENT OF ENGINEER The Owner agrees to employ the Engineer and the Engineer agrees to perform professional engineering services in connection with the Project as stated in the Sections to follow, and for having rendered such services, the Owner agrees to pay to the Engineer compensation as stated in the Sections to follow. SECTION II CHARACTER AND EXTENT OF SERVICES The Engineer shall render the following professional services necessary for the development of the Project. A. PRELIMINARY PHASE 1. Attend preliminary conference with the Owner regarding the Project. 2. Perform preliminary engineering services in connection with the Project in sufficient detail to indicate clearly the problems involved and the alternate solutions available to the Owner, to include preliminary layouts, sketches, and cost estimates for the Project, and to set forth clearly the Engineer's recommendations. If called for by the scope of the assignment, prepare a preliminary engineering report. 3. When a written report is prepared, furnish the Owner ten (10) copies of the preliminary report, including preliminary layouts, sketches and cost estimates. B. DESIGN PHASE 1. Establish the scope, and advise the Owner, of any soil and foundation investigations or any special surveys or special testing which, in the opinion of the Engineer, may be required for the proper execution of the Project; and arrange with the Owner for the conduct of such investigations and tests. (The performance of these investigations and tests is not a part of the Engineer's basic services, and compensation therefore is not included in the Basic Charge; it may be performed by the Engineer, by agreement with the Owner, in which case compensation shall be determined by the applicable portions of Section VI D.) 2. Furnish to the Owner, where required by the circumstances of the assignment, the engineering data necessary for applications for routine permits by local, state, and federal authorities (as distinguished from detailed applications and supporting documents for government grants -in -aid, state loan programs, planning advances or to meet the requirements of special programs of the federal government). 3. Perform field surveys to collect information which, in the opinion of the Engineer, is required in the design of the Project. Construction staking for the Construction Improvements is not included in the Basic Charge. 4. Prepare detailed specifications and contract drawings, in pencil on paper, for construction authorized by the Owner. These designs shall in all respects combine the application of sound engineering principles with a high degree of economy, and shall be submitted to the applicable local, state, and federal agencies for approval. 5. Prepare detailed cost estimates and proposals of authorized construction, which shall include summaries of bid items and quantities which will be based, wherever practical, on the unit price system of bidding. The Engineer shall not be required to guarantee the accuracy of these estimates. 6. Furnish the Owner all necessary copies of approved plans, specifications, notices to bidders, and proposals. All sets of plans and specifications in excess of twenty -five (25) are to be paid for separately. Additional sets will be paid for in accordance with Attachment No. 4 - Hourly Rate Schedule. -2- 7. Provide information on utilities to be relocated in connection with the Project. The Owner will provide excavation to determine location and depth of underground water and sewer lines. Utilities to be relocated by others shall be noted on the plans. City -owned utilities to be relocated also shall be noted on the plans. Where feasible, relocation of City -owned utilities shall be included in the construction contract. S. Provide a letter for the Owner's signature to each utility operating within the City of Round Rock advising them of the Project and describing any known relocations to be performed by that utility and setting forth a proposed construction schedule. This letter and a complete set of plans shall be delivered to each utility by the Engineer. The Engineer shall provide timely assistance and location stakes as necessary for utility relocations to assure that utility relocations do not delay the Project. 9. Provide easement and right - of-way descriptions to the Owner in conjunction with submission of final plans. These will be provided in the form of field notes and drawings of the affected properties. These services will be paid for in accordance with Attachment No. 4 - Hourly Rate Schedule. 10. Provide field note descriptions to the Owner for any site(s) that is required for Owner to acquire that is associated with this Project. These descriptions will be provided within thirty (30) days after authorization by Owner, barring unforeseen and unusual difficulties associated with the property. These services will be paid for in accordance with Attachment No. 4 - Hourly Rate Schedule. C. CONSTRUCTION PHASE 1. Assist the Owner in the advertisement of the Project for bids. 2. Assist the Owner in the opening and tabulating of bids for construction of the Project, and recommend to the Owner as to the proper action on all proposals received. 3. Assist in the preparation of formal Contract Documents for the contracts. 4. Make periodic visits to the site (as distinguished from the continuous services of a Resident Project Representative described in Subparagraph 6 below) to observe the progress and quality of the executed work and to determine, in general, if the work is proceeding in accordance with the Contract Documents. In performing this service, the Engineer will not be required to make exhaustive or continuous on -site inspections to check the quality or quantity of the work or -3- material; he will not be responsible for the techniques and sequences of construction or the safety precautions incident thereto, and he will not be responsible or liable in any degree for the Contractor's failure to perform the construction work in accordance with the Contract Documents. During visits to the construction site, and on the basis of the Engineer's on -site observations as an experienced and qualified design professional, he will keep the Owner informed of the extent of the progress of the work, and advise the Owner of material and substantial defects and deficiencies in the work of Contractors which are discovered by the Engineer or otherwise brought to the Engineer's attention in the course of construction, and may, on behalf of the Owner, exercise whatever rights the Owner may have to disapprove work and materials as failing to conform to the Contract Documents. 5. Consult with and advise the Owner; issue all instructions to the Contractor requested by the Owner= and prepare routine change orders as required. 6. If specifically authorized by the Owner in writing, furnish the services of Resident Project Representatives, and other field personnel for continuous on- the -site observation of construction and for the performance of required construction layout surveys. (This service is not a part of the Engineer's basic services, and compensation therefore is not included in the Basic Charge; if provided, compensation shall be determined under Section VI D.) The authority and duties of such Resident Project Representatives are limited to examining the material furnished and observing the work done, and to reporting their findings to the Engineer. The Engineer will use the usual degree of care and prudent judgment in the section of competent Project Representatives, and the Engineer will use diligence to see that the Project Representatives are on the job to perform their required duties. It is agreed, however, that the Engineer does not underwrite, guarantee, or insure the work done by the Contractors, and since it is the Contractor's responsibility to perform the work in accordance with the Contract Documents, the Engineer is not responsible or liable for the Contractor's failure to do so, and, so long as the Engineer has exercised the usual degree of care and prudent judgment in selecting Project Representatives and has used diligence to see that they are on the job to perform the work, failure by any Project Representatives or other personnel engaged in on- the -site observation to discover defects or deficiencies in the work of the Contractors shall never relieve the Contractors of liability therefore or subject the Engineer to any liability for such defects or deficiencies. 7. Review samples, catalog data, schedules, shop drawings, laboratory, shop and mill tests of materials and equipment and other data which the Contractor is required to submit, only for conformance with the design concept of the Project and compliance with the information given by the Contract Documents; and assemble written guarantees which are required by the Contract Documents. -4- 8. Review monthly and final estimates for payments to Contractors, and furnish to the Owner any necessary certifications as to payments to Contractors and Suppliers. 9. Conduct, in company with the Owner, a final inspection of the Project for conformance with the design concept of the Project and compliance with the Contract Documents, and approve in writing final payment to the Contractors. 10. Revise contract drawings, with the assistance of the Resident Project Representatives and the Owner's representatives, to provide record drawings of the completed Project. Furnish one set of reproducible drawings and one set of prints of these revised drawings to the Owner. SECTION III AUTHORIZATION OF SERVICES . No professional services of any nature shall be undertaken by the Engineer under this Agreement until he has received authorization from the Owner. SECTION IV PERIOD OF SERVICE This Agreement shall be effective upon execution by the Owner and the Engineer, and shall remain in force until terminated under the provisions hereinafter provided in Section X. SECTION V COORDINATION WITH THE OWNER The Engineer shall hold a 10% and 40% Design Review Conference with the Owner, or its representatives, to the end that the Project, as perfected, shall have full benefit of the Owner's experience and knowledge of existing needs and facilities, including preliminary line routings, approved manufacturers of materials and equipment, and other pertinent items relative to the Project and updated cost estimates, and consistent with its current policies and construction standards. To implement this coordination, the Owner shall make available to the Engineer, for use in planning the Project, all existing plans, maps, field notes, statistics, computations, and other data in his possession relative to existing facilities and to the Project. -5- SECTION VI THE ENGINEER'S COMPENSATION For and in consideration of the services to be rendered by the Engineer, the Owner shall pay, and the Engineer shall receive the compensation hereinafter set forth, for the Preliminary, Design, and Construction Phases of the work and for Special Assignments and Services not included in these phases. All remittances by Owner of such compensation shall either be mailed or delivered to the Engineer's office in Round Rock, Williamson County, Texas. Where the compensation is based on a percentage of construction cost, the charge for each separate phase shall be based on the "Construction Cost" of all work authorized by the Owner at one time, and handled by the Engineer in accordance with this Agreement. "Construction Cost" is defined as the total cost to the Owner for the execution of the work authorized at one time and handled in each separate phase of engineering services, excluding fees or other cost for engineering and legal services, the cost of land, rights -of -way, legal and administrative expenses; but including the direct cost to the Owner of all construction contracts, items of construction, including labor, materials, and equipment required for the completed work (including extras) and the total value at site of Project of all labor, materials, and equipment purchased or furnished directly by the Owner for the Project. The aggregate of all sums paid to the Engineer for each phase of construction will equal one hundred percent (100%) of the basic compensation determined from the actual total construction costs. If the designed facilities exceed the available funding after receiving bids or negotiating a contract price, then the facilities which are deleted will be paid for at a later date when they are awarded for construction. These facilities will be considered an individual period of construction and payment will be in an amount equal to a percentage of the "construction cost" of this separate Project. For example: If the available funds will only build 90% of the designed facilities, the fee for the awarded construction will be paid as described herein. When the remaining 10% of the work is awarded, it will be considered a separate Project and a percentage from the curve based on the 10% Project amount will be used to pay the basic compensation. Considering this as an individual Project, it will be necessary to compensate the Engineer in this manner because of the extra work involved in the preparation of separate contract documents, organization of plans, construction administration on the delayed Project, and the delay in payment for the Engineering Services rendered. In the event that proposals for construction of any of the work authorized in the Design Phase are received within 90 days after submission of completed contract drawings and specifications to the Owner by the Engineer, the charge for the corresponding services in the -6- Design Phase and the charge for the corresponding services in the Preliminary Phase shall be adjusted to the "construction cost" as reflected by the lowest acceptable proposal, or lowest bona fide bid, if no contract is awarded. Where no proposal or bona fide bids are received, the Engineer's estimates shall be the basis for final payment for these two phases. No reduction shall be made from the Basic Charge on account of penalties or liquidated damages or other sums withheld from Contractor's payments. A. PRELIMINARY PHASE Payment for services in the Preliminary Phase shall be made to the Engineer on an hourly basis. See Attachment No. 4 - Hourly Rate Schedule. Final payment for services in the Preliminary Phase shall be payable upon submission to the Owner of the required report, sketches, and estimates, and upon his acceptance, which shall be within thirty (30%) days after submission. B. DESIGN PHASE Payment for services in the Design Phase shall be made to the Engineer in a sum equal to a percentage of the "construction cost" of the work authorized by the Owner in this Phase of the Project. This percentage for the Design Phase shall be computed as eighty -five percent (85%) of the Basic Charge, which Basic Charge is defined by Attachment No. 2, less fees paid for Preliminary Phase. The classification of the construction work (Classification "A" or "B") for the purpose of applying the alternate Basic Charge is that given in Attachment No. 3 - Classification of Construction Work. This sum will be paid in installments in proportion to the engineer's estimate of work completed at the 10% and 40% "complete" periods and 100% upon submission of completed plans to the Owner, up to 85% of the total Basic Charge. Payment for services authorized in the Design Phase shall be based upon the Engineer's Preliminary Estimate of the "construction cost" of the work. This Design Phase payment shall then be adjusted to the actual "construction cost" within thirty (30) days after the project is awarded and the Owner and Contractor have executed the Contract Documents. C. CONSTRUCTION PHASE Payment for services in the Construction Phase shall be made to the Engineer in a sum equal to a percentage of the "construction cost" of the work authorized by the Owner in this Phase of the Project. This -7- percentage for the Construction Phase shall be computed as fifteen percent (15%) of the Basic Charge, which Basic Charge is defined in Attachment No. 2. The classification of the construction work (Classification "A" or "B ") is that given in Attachment No. 3 - Classification of Construction Work. This sum will be paid in monthly installments in proportion to the construction work completed, on the basis of the Engineer's estimates prepared for monthly payments to contractors, plus the actual value of all materials and equipment purchased or furnished directly by the Owner for the Project. Upon completion of all work authorized in the Construction Phase, the Engineer will be paid the remainder of the charge for this Phase. D. SPECIAL ASSIGNMENTS AND SERVICES NOT INCLUDED IN ABOVE PERCENTAGE CHARGES The charges above described in the Preliminary, Design and Construction Phases shall provide compensation to the Engineer for all services called for under this Agreement to be performed by him, or under his direction, except the services set forth below. These excluded services and Special Assignments, and the compensation to be paid by the Owner to the Engineer for their performance, as required, are as follows: The following services (1 through 8), if authorized by the Owner, shall be reimbursed in accordance with Attachment No. 4 - Hourly Rate Schedule. 1. Services of a Resident Project Representative, and other field personnel as required, for on- the -site observation of construction. 2. Services for Design Surveys if not included in Basic Charge. 3. Services for Construction Layout Surveys (Construction Staking). 4. Land surveys and establishment of boundaries and monuments. 5. Preparation of property or easement descriptions. 6. Preparation of any special reports required for marketing of bonds. 7. Appearance before regulatory agencies. -8- S. Special investigations involving detailed consideration of operation, maintenance and overhead expenses; preparation of rate schedules; earnings and expense statements; special feasibility studies; appraisals; valuations; and material audits or inventories required for certification of force account construction performed by the Owner. 9. Additional copies of reports and specifications (over 25) and additional blue print copies (over 25). 10. Preparation of applications and supporting documents for government grants, loans or planning advances for public works projects. 11. Assistance to the Owner as an expert witness in any litigation with third parties, arising from the development or construction of the Project. 12. Soil and foundation investigations, as required for the design of this Project and for Trench Safety Design, including test and analyses of test results. Basis of Compensation: (a) Furnished by the Owner and observed by the Engineer in accordance with Attachment No. 4 - Hourly Rate Schedule, or (b) Owner contract separately with qualified testing firm. 13. Detailed mill, shop and /or laboratory inspection of materials or equipment. Basis of Compensation: (a) Furnished directly by the Owner, or (b) By Engineer in accordance with Attachment No. 4 - Hourly Rate Schedule. 14. Extra travel required of the Engineer and authorized by the Owner from Round Rock to points other than the State of Texas in connection with the Project. Basis of Compensation: Cost of travel and living expenses plus a twenty percent (20%) service charge. Cost of labor in accordance with Attachment No. 4 - Hourly Rate Schedule. 15. Services for location stakes associated with the Project as necessary for utility companies operating within the City Limits of Round Rock. Payments to the Engineer for authorized services not in the basic percentage charges will be made by the Owner, upon presentation of statements by the Engineer for such services, but not until Bond or Grant funds are in the Owner's possession. -9- Should the Owner fail to make payment to the Engineer of the sum names in any partial or final statement when payment is past due for more than thirty (30) days, then the Owner shall pay to the Engineer, in addition to the sum shown as due by such statement, interest thereon at the current prime rate of banking institutions in Round Rock, from the date due, as provided herein, until fully paid, which shall fully liquidate any injury to the Engineer arising from such delay in payment, but the right is expressly reserved to the Engineer in event payments are not promptly made as provided herein, at any time thereafter to treat the Agreement as terminated by the Owner and recover compensation as provided by Section X of this Agreement. SECTION VII REVISION TO DRAWINGS AND SPECIFICATIONS The Engineer will make, without expense to the Owner, such revisions of the preliminary drawings as may be required to meet the needs of the Owner, but after a definite plan has been approved by the Owner, if a decision is subsequently made by the Owner, which, for its proper execution, involves extra services and expenses for changes in, or addition to the drawings, specifications or other documents, or if the Engineer is put to labor or expense by delays imposed on him from causes not within his control, such as by (but not limited to) the readvertisement for bids or by the delinquency or insolvency of Contractors, the Engineer shall be compensated for such extra services and expenses, which services and expenses shall not be considered as covered by the percentage fee stipulated in this Agreement. Compensation for such extra services shall be in accordance with Attachment No. 4 - Hourly Rate Schedule. However, no extra compensation will be granted to the Engineer for correcting errors in the plans or errors in the design of the Project or for revising design or plans when such design and plans prove not to be feasible for construction. SECTION VIII OWNERSHIP OF DOCUMENTS Engineer shall retain ownership of all original documents, plan designs, and survey notes on all projects that are not completed and for which Engineer is not compensated regardless of whether the instruments were copyrighted. Additionally, all such documents for which Engineer is not compensated Owner will not reuse for extensions of the original project or new projects unless Owner shall secure the permission of Engineer and Engineer shall be entitled to further compensation for the use of such documents. All original documents, plan designs, and survey notes for completed or partially completed projects for which Engineer has been -10- compensated shall be the property of Owner and Engineer and reproducible copies shall be furnished to the Owner upon request. The use by either party of such documents is unrestricted. SECTION IX ARBITRATION UNDER TEXAS GENERAL ARBITRATION ACT A. Any controversy hereafter arising between Owner and Engineer in connection with this Agreement and any liability or claimed liability created hereunder or incident hereto or pertaining to the enforcement of any provision, condition or covenant herein shall be submitted to arbitration under the terms of the Texas General Arbitration Act. Either party may invoke this provision for arbitration by giving the other party notice in writing demanding that such controversy be submitted to arbitration, which notice shall also contain the appointment of an arbitrator by the demanding party. The party receiving such notice of arbitration must, within five (5) days after receiving same, mail to the demanding party a notice of appointment of a second arbitrator. Such two arbitrators shall meet forthwith and agree in writing upon a third arbitrator, and shall immediately give the parties written notice of the third arbitrator's appointment. B. If the party upon whom the demand for arbitration is served fails to give the demanding party the required notice of the appointment of the second arbitrator within the required five (5) days, the demanding party may apply to the court under Article 226, Revised Statutes of 1925, to appoint the second arbitrator. If the first two arbitrators fail to agree upon a third arbitrator within ten (10) days from the date the second arbitrator was appointed, either party may apply to the court, under such Article 225, for the appointment of the third arbitrator. C. The proceedings of the arbitrators, the award made by the arbitrators and the endorsement of such awards shall be governed by the Texas General Arbitration Act, Articles 224 through 238 -6, inclusive, Revised Statutes of 1925, as amended. D. This entire Section IX providing for arbitration shall survive the termination of this Agreement under any of its provisions, and any controversy between Owner and Engineer existing when the Agreement terminates shall continue to be subject to arbitration hereunder. SECTION X TERMINATION Either party to this Agreement may terminate the Agreement by giving to the other thirty (30) days notice in writing. Upon delivery of such notice by the Owner to the Engineer, and upon expiration of the thirty -day period, the Engineer shall discontinue all services in connection with the performance of this Agreement and shall proceed to cancel promptly all existing orders and contracts insofar as such orders or contracts are chargeable to this Agreement. As soon as practicable after receipt of notice of termination, the Engineer shall submit a statement, showing in detail the services performed under this Agreement to the date of termination. The Owner shall then pay the Engineer promptly that portion of the prescribed charges which the services actually performed under this Agreement bear to the total services called for under this Agreement, less such payments on account of the charges as have been previously made. Copies of all completed or partially completed designs, plans and specifications prepared under this Agreement shall be delivered to the Owner when and if this Agreement is terminated, but subject to the restrictions, as to their use, as set forth in Section VIII. SECTION XI ADDRESS OF NOTICES AND COMMUNICATION All notices and communication under this Agreement to be mailed or delivered to Engineer shall be to the following address: Haynie & Kallman, Inc. Consulting Engineers 309 East Main Street Round Rock, Texas 78664 All notices and communication under this Agreement to be mailed or delivered to the Owner shall be to the following address: City of Round Rock 221 E. Main Street Round Rock, Texas 78664 SECTION XII SECTION CAPTIONS Each Section under the Contractual Undertakings has been supplied with a caption to serve only as a guide to the contents. The caption does not control the meaning of any Section or in any way determine its interpretation or application. -12-- SECTION XIII SCHEDULE OF , OMPLETION The Engineer will fulfill the scope of services included in the Project in a professional and timely manner. The Owner's wishes and requirements regarding the Project will be conveyed through the City's Director of Public works, with whom the Engineer shall confer frequently throughout the Design Phase of the Project. The date for completion of the Design Phase is ninety (90) calendar days following execution of this Agreement. SECTION XIV SUCCESSORS AND ASSIGNS The Owner and the Engineer each binds himself and his successors, executors, administrators, and assigns to the other party of this Agreement and to the successors, executors, administrators, and assigns of such other party, in respect to all covenants of this Agreement. Except as above, neither the Owner nor the Engineer shall assign, sublet or transfer his interest in this Agreement without the written consent of the other. Nothing herein shall be construed as creating any public body which may be a party hereto. EXECUTED in two counterparts (each of which is an original) on behalf of the Engineer by its Vice President shown below, and on behalf of the Owner by its Mayor (thereunto duly authorized) this the day of , 1989. Attest: Joanne Land, City Secretary Mike Robinson, Mayor Attest: HAYNIE & KALLMAN, INC. Cheryl strong Steven D. Kallman, P.E., R.P.S. Vice President CITY OF ROUND ROCK -13- ATTACHMENT NO. 1 SUMMARY OF PRELIMINARY COST ESTIMATE FOR CORRIDOR DRIVE STREET AND DRAINAGE IMPROVEMENTS 1. Eastern one -half of approximately 1,450 L.F. of 60 -foot wide face -to -face curb and gutter street, including all associated appurtenances @ 20% Engineering and 1.ontingencies TOTAL ESTIMATED PROJECT COST $113,764.50 22,752.90 $136,517.40 ATTACHMENT NO. 3 CLASSIFICATION OF CONSTRUCTION WORK CURVE A will apply to assignments of which the following are typical examples (payment for design surveys included with below assignments except where shown otherwise): Water treatment plants Sewage and industrial waste treatment plants Sanitary sewage collection lines under 24 -inch diameter Water pumping stations Sewage lift stations Open- section streets, no curb and gutter, and associated drainage improvements (NO DESIGN SURVEYS INCLUDED IN BASIC CHARGE) Curb and gutter, streets and associated drainage improvements Bridges, box culverts and major drainage structures Water distribution lines 12" and larger (on Curve "A" due to profile being required on Plans) Water storage tank renovation, including re- painting, yard piping, or tank appurtenances CURVE B" will apply to less complicated assignments of which the following are examples (payment for design surveys included with below assignments except where shown otherwise): Sanitary sewage collection lines 24" diameter and over Water distribution lines under 12" Water storage tanks (elevated, ground storage and standpipes) Earthwork Storm sewers 24" diameter and over NOTES: (1) rearm won Cat Is wider $100.000, use rah* • hireable basis of conmemalion. (2) ta:slrudien cost below Is the wort autharbed al one thee. However, where the work is to be accomplished in a number of separate s be ev lual.. en an contracts, i individual each with �1 compensation to the Engineer. (3)1 Basic Charge presented below represents median com- pensation. The appropriate compensation k► soy given assign - 14 12 13 u 1e • e 7 • • 4 1•uuI1111 �aII1111 �RII1111 �uiu1111_�UuI �R��1111 �UUI1111 111111111111111111.11111111111111111 �11■�1111\ ∎��1111111 �Uii1111�1��NU �mui1111��uuI �uau1111 , ■u1111 .111111111111 111: 1111 �.ii1111���l► 1111 ��11111111!� ■115111 � ► 1B11111� i711111 1 0U��1111 111111111111111 - ulu1111 � �auu1111 1 11111111 � �UUI1111 1 �Rlu1111 111111111111111 •111111111111 11111111111111 � 1M 1111 11111111111111 �a��1111 11111.1111111111 1•111111111111 1111111111111 1111111111111111 � aui1111 011111111111 111111111111111 11111111111111 11•111111111111 /u MINIM - � \1111I ��UN11111 �R1 11111 �� 1111 ' 1 1 1 `'� �uuu11i.—�Ua !1 MI 11 ����1111���i;111��� - U111111 �r._-1 1111 1111 �� ' 11111111��11�1111 ff....- MI r■ 11•U•u1111 11111111111111 11111111111111 111111111111111 1111111111111111 11111111111111 0.01 0.01 e.1 as 1 e MILLIONS OF DOLLARS wad may vary above or below the curer, depending upon oar- plasRy. (4) cun:peaetlew far alludka work should be Increased by at Mast emMhbd above the median eampeosatiun gbntwtsd. n consisted r (3) Curve A and Curs S an with Cue A and Calve • in Manuel CIS, published by the Amok= Society of Civil Emil- ar nes. New curves wain be issued as subsequent revisions are published by ASCE. 10 40 100 ATTACHMENT NO. 4 HAYNIE 6 RALLMAN, INC. HOURLY RATE SCHEDULE CLASSIFICATION HOURLY RATE 1. Registered Professional Engineer $ 75 2. Registered Public Surveyor $ 60 3. Project Manager /Hydrologist $ 55 4. Engineer -in- Training (E.I.T.) $ 45 5. Land Planner $ 50 6. Survey Crew Coordinator $ 40 7. Project Representative (includes Vehicle and Equipment) $ 40 B. Design Technician $ 35 9. Drafter $ 30 10. Survey Calculation Technician $ 40 11. Technical Support Personnel $ 30 12. Secretarial Personnel $ 25 13. Four Man Survey Crew (includes Vehicle and Equipment) $ 80 14. Three Man Survey Crew (includes Vehicle and Equipment) $ 75 15. Two Man Survey Crew (includes Vehicle and Equipment) $ 65 16. Reimbursement for Direct Non -Labor Expenses and Sub - Contract Expenses - Cost Plus 208 Revised 1 -9 -89