Loading...
R-98-06-25-10A2 - 6/25/1998Mayor Charles Culpepper Mayor Pro-tem Earl Palmer Commit Members Robert Sttuba Rod Morgan Rick Stewart Martha Own Jimmy Joseph City Manager Robert L Bennett. Jr. City Attorney Stephan L Sheets CITY OF ROUND ROCK July 7, 1998 Mr. Allen Woelke, P.E. Camp Dresser & McKee, Inc. 9111 Jollyville Road, Suite 105 Austin, Texas 78759 Dear Mr. Woelke: Sincerely, Joanne Land Assistant City Manager/ City Secretary Enclosures Fax: 512 -218 -7097 c eanwizi huriet I$00- 7352989 TDD 1-800-735-2988 voice 221 East Mate Street Rotmd Rock. Texas 78664 512-218-5400 The Round Rock City Council approved Resolution No. R- 98- 06-25- 10A2 at their regularly scheduled meeting on June 25, 1998. Enclosed is a copy of the resolution and original contract for your files. If you have any questions, please do not hesitate to contact me. WHEREAS, the City of Round Rock desires to retain engineering services for Water Treatment Plant Improvements involving the sludge lagoon system and a disinfection basin, and WHEREAS, Camp Dresser & McKee Inc. has submitted an agreement to provide said services, and WHEREAS, the City Council desires to enter into said agreement with Camp Dresser & McKee Inc., Now Therefore BE IT RESOLVED BY THE COUNCIL OF THE CITY OF ROUND ROCK, TEXAS, That the Mayor is hereby authorized and directed to execute on behalf of the City an agreement with Camp Dresser & McKee Inc. for engineering services for Water Treatment Plant Improvements involving the sludge lagoon system and a disinfection basin, a copy of said agreement being attached hereto and incorporated herein for all purposes. The City Council hereby finds and declares that written notice of the date, hour, place and subject of the meeting at which this Resolution was adopted was posted and that such meeting was open to the public as required by law at all times during which this Resolution and the subject matter hereof were discussed, considered and formally acted upon, all as required by the Open Meetings Act, Chapter 551, Texas Government Code, as amended, and the Act. RESOLVED this 25th day of June, 4 98 CHARLES CULPEPPER, Mayor City of Round Rock, Texas ` ,Aii//LL_' iL_ APL/ I LAND, City Secretary 13, IIPD0C8\ =S=am \890629A2.WGD /eag RESOLUTION NO. R- 98- 06- 25 -10A2 • STATE OF TEXAS COUNTY OF WILLIAMSON THIS CONTRACT FOR ENGINEERING SERVICES ( "Contract ") is made by and between the City of Round Rock, 221 E. Main St., Round Rock, Texas 78664, hereinafter called "City" and Camp Dresser & McKee Inc. , having its principal business address at One Cambridge Center. Cambridge MA 02142 hereinafter called "Engineer" for the purpose of contracting for engineering services. WITNESSETH Contract No. WHEREAS, Government Code, Chapter 2254, Subchapter A, "Professional Services Procurement Act" provides for the procurement of professional services of engineers; and WHEREAS, Resolution No. establishes the City's policies and procedures for contracting for engineering services; and WHEREAS, the City desires to contract for engineering services described as follows: 1998 - WTP Disinfection Basin and Washwater Recovery Improvements Provide plans and specifications for the construction of a new washwater recovery basin. transfer/backwash water return /sludge pump station and ancillary improvements. Prepare the Construction Contract Documents to include the Disinfection Basin designed under a separate Professional Services Agreement. AKINSFAWPD mom AGREEMENT NOW, THEREFORE, the City and the Engineer, in consideration of the mutual covenants and agreements herein contained, do hereby mutually agree as follows: ARTICLE 1 SCOPE OF SERVICES TO BE PROVIDED BY CITY The City will fumish items and perform those services for fulfillment of the Contract as identified in Attachment A - Services to be Provided by the City, attached hereto and made a part of this Contract. Page I of 11 ARTICLE 2 SCOPE OF SERVICES TO BE PROVIDED BY ENGINEER The Engineer shall perform those engineering services for fulfillment of the Contract as identified in Attachment B - Services to be Provided by the Engineer, attached hereto and made a part of this Contract. The Engineer shall prepare a schedule of work identified as Attachment C - Work Schedule, attached hereto and made a part of this Contract. The Work Schedule shall contain a complete schedule so that the Engineer's Scope of Services under this Contract can be accomplished within the specified time and contract cost. The Work Schedule will provide specific work sequence and definite review times by the City and the Engineer of the work performed. If the review time should take longer than shown on the work schedule, through no fault of the Engineer, additional contract time will be authorized by the City through a supplemental agreement if requested by a timely written request from the Engineer and approved by the City. ARTICLE 3 CONTRACT PERIOD After execution of this Contract, the Engineer shall not proceed with the work outlined under Article 2 until authorized in writing by the City to proceed as provided in Article 6. This Contract shall terminate at the close of business on October 1. 1999 unless extended by written supplemental agreement duly executed by the Engineer and the City prior to the date of termination, as provided in Article 11 - Supplemental Agreements, or otherwise terminated as provided in Article 19 - Termination. Any work performed or cost incurred after the date of termination shall be ineligible for reimbursement. The Engineer shall notify the City in writing as soon as possible if it determines, or reasonably anticipates, that the work under this Contract cannot be completed before the termination date, and the City may, at its sole discretion, extend the contract period by timely supplemental agreement as provided in Article 11 - Supplemental Agreements. The Engineer shall allow adequate time for review and approval of the request for time extension by the City prior to expiration of this Contract. ARTICLE 4 COMPENSATION The City shall pay and the Engineer agrees to accept the lump sum amount shown below as full compensation for the engineering services to be performed under this Contract. The lump sum amount payable under this Contract without modification of the Contract is $ 143.020.00 as shown in Attachment D - Fee Schedule. The lump sum amount payable may be revised by supplemental agreement in the event of a change in scope, additional complexity from that originally anticipated or character of work as authorized by the City. The Engineer shall prepare and submit to the City monthly progress reports in sufficient detail to support the progress of the work and in support of invoice requesting monthly payment. A32069FA.WPD 08011e0) Page 2 of 11 Any preferred format will be identified in Attachment B. Satisfactory progress of work shall be maintained as a condition of payment. The fee may be adjusted if additional work is approved by supplemental agreement and performed by the Engineer. ARTICLE 5 METHOD OF PAYMENT Payments to the Engineer for services rendered will be made while work is in progress. The Engineer will prepare and submit to the City, no more frequently than once per month, a progress report stating the percent completion of the work accomplished during the billing period and to date, and one original and one copy of a certified invoice in a form acceptable to the City). The submittal shall also include the progress assessment report, identified as Attachment H -2. Payment of the lump sum fee will be in proportion to the percent completion of the work tasks identified in Attachment D - Fee Schedule. Upon receipt and approval of each statement, the City shall make a good faith effort to pay the amount which is due and payable within thirty (30) days. The City shall reserve the right to withhold payment pending verification of satisfactory work performed. The Engineer must submit adequate proof to the City that the task was completed. The certified statements shall show the total amount earned to the date of submission and the amount due and payable as of the date of the current statement. Final payment does not relieve the Engineer of the responsibility of correcting any errors and/or omissions resulting from its negligence. ARTICLE 6 NOTICE TO PROCEED The City will issue a written authorization to proceed with the work identified in the scope of services. The City shall not be responsible for actions by the Engineer or any costs incurred by the Engineer relating to additional work not included in Attachment B - Services to be Provided by the Engineer. ARTICLE 7 PROGRESS The Engineer shall, from time to time during the progress of the work, confer with the City. The Engineer shall prepare and present such information as may be pertinent and ne•ssary, or as may be requested by the City, in order to evaluate features of the work. At the request of the City or the Engineer, conferences shall be provided at the Engineer's office, the office of the City, or at other locations designated by the City. These conferences shall also include evaluation of the Engineer's services and work when requested by the City. Should the City determine that the progress in production of work does not satisfy the Work Schedule, the City shall review the work Schedule with the Engineer to determine corrective action needed. Page 3 of 11 The Engineer shall promptly advise the City in writing of events which have a significant impact upon the progress of the work, including: (1) problems, delays, adverse conditions which will materially affect the ability to attain program objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods; this disclosure will be accompanied by statement of the action taken, or contemplated, and any City assistance needed to resolve the situation; and (2) favorable developments or events which enable meeting the work schedule goals sooner than anticipated. Should the City desire to suspend the work, but not terminate the Contract, this may be done by thirty (30) calendar days verbal notification followed by written confirmation from the City to that effect. The thirty day notice may be waived in writing by both parties. The work may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from the City to resume the work. The sixty day notice may be waived in writing by both parties. If the City suspends the work, the contract period as determined in Article 3 is not affected and the Contract will terminate on the date specified unless the Contract is amended. The City assumes no liability for work performed or costs incurred prior to the date authorized by the City to begin work, during periods when work is suspended, or subsequent to the contract completion date. If the Engineer is of the opinion that any work it has been directed to perform is beyond the scope of this Contract and constitutes extra work, it shall promptly notify the City in writing. In the event the City finds that such work does constitute extra work and exceeds the maximum amount payable, the City shall so advise the Engineer and a written supplemental agreement will be executed between the parties as provided in Article 11. The Engineer shall not perform any proposed additional work or incur any additional costs prior to the execution, by both parties, of a supplemental agreement. The City shall not be responsible for actions by the Engineer or any costs incurred by the Engineer relating to additional work not directly associated with the performance of the work authorized in this Contract or as amended. If the City finds it necessary to request changes to previously satisfactorily completed work or parts thereof which involve changes to the original scope of services or character of work under the Contract, the Engineer shall make such revisions if requested and as directed by the City. This will be considered as additional work and paid for as specified under Article 9 - Additional Work. A32013SFA.WPD (aerate) ARTICLE 8 SUSPENSION ARTICLE 9 ADDITIONAL WORK ARTICLE 10 CHANGES IN WORK Page 4 of 11 The Engineer shall make such revisions to the work authorized in this Contract which has been completed as are necessary to correct errors appearing therein, when required to do so by the City. No additional compensation shall be paid for this work. A32086FAWPD (maoe7 ARTICLE 11 SUPPLEMENTAL AGREEMENTS The terms of this Contract may be modified by supplemental agreement if the City determines that there has been a significant change in (1) the scope, complexity or character of the service to be performed; or (2) the duration of the work. Additional compensation, if appropriate, shall be identified as provided in Article 4. Any supplemental agreement must be executed by both parties within the contract period specified in Article 3 - Contract Period. It is understood and agreed that no claim for extra work done or materials furnished shall be made by the Engineer until full execution of the supplemental agreement and authorization to proceed is granted by the City. The City reserves the right to withhold payment pending verification of satisfactory work performed. ARTICLE 12 OWNERSHIP OF DOCUMENTS All data, basic sketches, charts, calculations, plans, specifications, and other documents created or collected under the terms of this Contract are the exclusive property of the City and shall be furnished to the City upon request. All documents prepared by the Engineer and all documents fumished to the Engineer by the City shall be delivered to the City upon completion or termination of this Contract. The Engineer, at its own expense, may retain copies of such documents or any other data which it has furnished the City under this Contract. Release of information shall be in conformance with the Texas Open Records Act. ARTICLE 13 PERSONNEL, EQUIPMENT AND MATERIAL The Engineer shall furnish and maintain, at its own expense, quarters for the performance of all services, and adequate and sufficient personnel and equipment to perform the services as required. All employees of the Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of the Engineer who, in the opinion of the City, is incompetent, or whose conduct becomes detrimental to the work, shall immediately be removed from association with the project when so instructed by the City. The Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the services required under this Contract, or will be able to obtain such personnel from sources other than the City. The Provider may not change the Project Manager without prior consent of the City. Page 5 of 11 ARTICLE 14 SUBCONTRACTING The Engineer shall not assign, subcontract or transfer any portion of the work under this Contract without prior written approval from the City. All subcontracts shall include the provisions required in this Contract and shall be approved as to form, in writing, by the City prior to work being performed under the subcontract. No subcontract relieves the Engineer of any responsibilities under this Contract. ARTICLE 15 EVALUATION OF WORK The City and any authorized representatives, shall have the right at all reasonable times to review or otherwise evaluate the work performed or being performed hereunder and the premises in which it is being performed. If any review or evaluation is made on the premises of the Engineer or a subprovider, the Engineer shall provide and require its subproviders to provide all reasonable facilities and assistance for the safety and convenience of the City or USDOT representatives in the performance of their duties. ARTICLE 16 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by the City before final report is issued. The City's comments on the Engineer's preliminary report will be addressed in the final report. ARTICLE 17 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of Contract terms or breach of contract by the Engineer shall be grounds for termination of the Contract and any increased cost arising from the Engineer's default, breach of contract or violation of contract terms shall be paid by the Engineer. ARTICLE 18 TERMINATION The Contract may be terminated before the stated termination date by any of the following conditions. a9203SF.WPO (Nowa) (1) By mutual agreement and consent, in writing of both parties. (2) By the City by notice in writing to the Engineer as a consequence of failure by the Engineer to perform the services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. Page 6 of 11 (4) By the City for reasons of its own and not subject to the mutual consent of the Engineer upon not less than thirty (30) days written notice to the Engineer. (5) By satisfactory completion of all services and obligations described herein. Should the City terminate this Contract as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to the Engineer. In determining the value of the work performed by the Engineer prior to termination, the City shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should the City terminate this Contract under (4) of the paragraph identified above, the amount charged during the thirty (30) day notice period shall not exceed the amount charged during the preceding thirty (30) days. If the Engineer defaults in the performance of this Contract or if the City terminates this Contract for fault on the part of the Engineer, the City will give consideration to the actual costs incurred by the Engineer in performing the work to the date of default, the amount of work required which was satisfactorily completed to date of default, the value of the work which is usable to the City, the cost to the City of employing another firm to complete the work required and the time required to do so, and other factors which affect the value to the City of the work performed at the time of default. The termination of this Contract and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of the City and the Engineer under this Contract, except the obligations set forth in Article 19 of this Contract. If the termination of this Contract is due to the failure of the Engineer to fulfill its contract obligations, the City may take over the project and prosecute the work to completion. In such case, the Engineer shall be liable to the City for any additional cost occasioned the City. The Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of the procurement made by the Engineer in support of the scope of services under this Contract. P3208SFAWPD 0 1 ARTICLE 19 COMPLIANCE WITH LAWS The Engineer shall comply with all applicable Federal, State and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Contract, including, without limitation, worker's compensation laws, minimum and maximum salary and wage statutes and regulations, and licensing laws and regulations. When required, the Engineer shall furnish the City with satisfactory proof of its compliance therewith. ARTICLE 20 INDEMNIFICATION The Engineer shall save harmless the City and its officers and employees from all claims and liability which are caused by or a result from negligent acts, errors or omissions of the Engineer, its Page 7 of 11 agents or employees in the performance of services under this Contract. The Engineer shall also save harmless the City from any and all expense, including, but not limited to, attorney fees which may be incurred by the City in litigation or otherwise resisting said claim or liabilities which may be imposed on the City as a result of such activities by the Engineer, its agents, or employees. The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer's responsibility for all questions arising from design errors and/or omissions will be determined by the City. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed. The responsible Engineer shall sign, seal and date all appropriate engineering submissions to the City in accordance with the Texas Engineering Practice Act and the Rules of the State Board of Registration for Professional Engineers. The Engineer warrants that it has not employed or retained any company or persons, other than a bona fide employee working solely for the Engineer, to solicit or secure this Contract and that it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, the City shall have the right to annul this Contract without liability or, in its discretion, to deduct from the contract price or compensation, or otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. The Engineer shall fumish the City a properly completed Certificate of Insurance approved by the City prior to beginning work under this Contract and shall maintain such insurance through the contract period. The completed Certificate of Insurance shall be attached hereto and identified as Attachment G. AMO58PAWPD mom) ARTICLE 21 ENGINEER'S RESPONSIBILITY ARTICLE 22 ENGINEER'S SEAL ARTICLE 23 NONCOLLUSION ARTICLE 24 INSURANCE Page 8 of 11 ARTICLE 25 INSPECTION OF ENGINEER'S BOOKS AND RECORDS AND AUDIT REQUIREMENTS The City shall have the exclusive right to examine the books and records of the Engineer for the purpose of checking the amount of work performed by the Engineer at the time of contract termination. The Engineer shall maintain all books, documents, papers, accounting records and other evidence pertaining to cost incurred and shall make such materials available at its office during the contract period and for four (4) years from the date of final payment under this Contract or until pending litigation has been completely and fully resolved, whichever occurs last. The City or any of its duly authorized representatives, shall have access to any and all books, documents, papers and records of the Engineer which are directly pertinent to this Contract for the purpose of making audits, examinations, excerpts and transcriptions. ARTICLE 26 DEBARMENT, SUSPENSION AND DISCIPLINARY ACTION The Engineer warrants that the representations included in the Debarment Certification (Negotiated Contracts) submitted with the offer to provide services are current and still valid. ARTICLE 27 COPYRIGHTS The City shall have the royalty free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use any reports developed by the Engineer for governmental purposes. The Engineer agrees to comply with the Special Provision "Computer Graphics Files for Document and Information Exchange," if determined by the City to be applicable to this Contract and if so stated in Attachment B and attached hereto. The Engineer, and the City, do hereby bind themselves, their successors, executors, administrators and assigns to each other party of this agreement and to the successors, executors, administrators, and assigns of such other party in respect to all covenants of this Contract. The Engineer shall not assign, subcontract or transfer its interest in this Contract without the prior written consent of the City. a320e9r0.WPD laaoa¢e, ARTICLE 28 COMPUTER GRAPHICS FILES ARTICLE 29 SUCCESSORS AND ASSIGNS Page 9 of 11 ARTICLE 30 SEVERABILITY In the event any one or more of the provisions contained in this Contract shall for any reason, be held to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability shall not affect any other provision thereof and this Contract shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. ARTICLE 31 PRIOR CONTRACT SUPERSEDED This Contract constitutes the sole and only agreement of the parties hereto and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. ARTICLE 32 NOTICES All notices to either party by the other required under this Contract shall be personally delivered or mailed to such party at the following respective address: with copy to: n3206SFAWPD wows) City of Round Rock Attn.: City Manager 221 E. Main St. Round Rock, TX 78664 Stephan L. Sheets City Attorney 309 E. Main St. Round Rock, Texas 78664 Camp Dresser & McKee Inc. Attn.: Allen D. Woelke, P.E. 9111 Jollyville Road, Suite 105 Austin, TX 78759 ARTICLE 33 SIGNATORY WARRANTY The undersigned signatory or signatories for the Engineer hereby represent and warrant that the signatory is an officer of the organization for which he or she has executed this Contract and that he or she has full and complete authority to enter into this Contract on behalf of the firm. The above - stated representations and warranties are made for the purpose of inducing the City to enter into this Contract. Page 10 of 11 IN WITNESS HEREOF, the City and the Engineer have executed these presents in duplicate. Camp Dresser & McKee Inc. THE ENGINEER By: Signature City o By: Allen D. Woelke P.E. Associate Title Printed Name Date A22066FAWPD (mows) �un o�c Charles Cul ppe , Mayor LIST OF ATTACHMENTS Attachment A - Services to be Provided by the City of Round Rock Attachment B - Services to be Provided by the Engineer Attachment C - Work Schedule, if applicable Attachment D - Fee Schedule Attachment E - Work Authorizations, if applicable Attachment F - Supplemental Work Authorizations, if applicable Attachment G - Certificate of Insurance, if applicable Page 11 of 11 ATTACHMENT A SERVICES TO BE PROVIDED BY THE CITY OF ROUND ROCK The City of Round Rock will furnish to the Engineer the following items /information: 1. Designate a person to act as City's representative with respect to the services to be performed or furnished by the Engineer. This representation will have authority to transmit instructions, receive information, interpret and define City's policies and decisions with respect to Engineer's services. 2. Provide all criteria and full information as to City's requirements for the project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and furnish copies of all design and construction standards which City will require to be included in the Drawings and Specifications. 3. Assist Engineer by placing all available information pertinent to the Project, including previous reports and any other data relative to the design or construction of the Project at the Engineer's disposal. 4. Furnish to Engineer, as requested for performance of basic services or as required by the Contract Documents, the following: a. Data prepared by or services of others, including without limitation explorations and tests of subsurface conditions at or contiguous to the site, drawings of physical conditions in or relating to existing surface of subsurface structures at or contiguous to the site; b. The services of an independent testing laboratory to perform all inspections, tests and approvals of samples, materials and equipment; c. Environmental assessments, audits, investigations and impact statements, and other relevant environmental or cultural studies as to the Project, the site and adjacent areas; d. Provide as required by the Contract Documents, engineering surveys and staking to enable Contractor to proceed with the layout of the work, and other special field surveys; e. Arrange for access to and make all provisions for Engineer to enter upon public and private property as required for Engineer to perform services under this Agreement; f. Examine all alternate solutions, studies, reports, sketches, Drawings, Specifications, proposals and other documents presented by Engineer; g. Provide such accounting, bond and financial advisory, independent cost estimating and insurance counseling services and such legal services as City may require or Engineer may reasonably request with regard to legal issues pertaining to the Project; A -1 h. Provide labor and safety equipment to open and protect manholes and/or to operate valves and hydrants as required by the Engineer; and Give prompt notice to Engineer whenever City observes or otherwise becomes aware of any development that affects the scope or time of performance or fumishing of Engineer's services, or any defect or nonconformance in Engineer's services in the work of any Contractor. A -2 DESIGN PHASE ATTACHMENT B ER C T I BE PR I VIDED t Y THE ENGINEE Prepare detailed specifications and contract drawings, in AutoCAD format (Release 12) for construction authorized by the Owner. The specifications and drawings will be prepared under one construction contract. The design shall, in all respects, combine the application of sound engineering principles with a high degree of economy. 2. Prepare a letter to submit the construction plans and specifications to the TNRCC for their review and approval. 3. Prepare a revised CT study to be submitted to the TNRCC for their review and approval. 4. Furnish the Owner with all necessary copies of approved plans, specifications, notices to bidders, and proposals. 5. Provide information on utilities to be relocated in connection with the project. The Owner will provide excavation to determine location and depth of underground water and sewer lines. Utilities to be relocated by others shall be noted on the plans. City-owned utilities to he relocated shall also be noted on the plans. Where feasible, relocation of City -owned utilities shall be included in the construction contract. 6. Provide detailed plans and specifications for the Washwater Recovery Improvements. Include the plans and specifications for the Disinfection Basin prepared under a separate Professional Services Agreement in the Construction Contract Documents for bidding. The design will generally consist of the following: a. Site work associated with both facilities, including grading, drainage and paving improvements. b. Yard piping associated with both facilities. c. Structural, mechanical and electrical improvements associated with the disinfection basin. d. Mechanical and electrical improvements associated with the required chlorine and ammonia feed revisions. e. Structural, mechanical and electrical improvements associated with the washwater recovery basin. f. Structural, mechanical and electrical improvements associated with the transfer/ washwater recycle/sludge pump station, including modifications to the existing sludge pump station. B -1 7. A preliminary list of drawings is as follows: a. The following list is preliminary and is subject to change at the discretion of the Engineer: 1. Cover Sheet 2. General Notes / Abbreviations / Sheet Index 3. Hydraulic Profile 4. Water Treatment Plant Schematic 5. Site Location Plan 6. Site Demolition Plan 7. Site Grading, Drainage and Paving Plan 8. Yard Piping Plan 9. Yard Piping Profiles and Details 10. Washwater Recovery Basin Mechanical Plan and Section 11. Washwater Recovery Basin Mechanical Details 12. Washwater, Sludge and Transfer Pump Station Mechanical Plan and Section 13. Washwater, Sludge and Transfer Pump Station Mechanical Details 14. Sludge Pump Station Pump Mechanical Modifications 15. Disinfection Basin Mechanical Plan and Section 16. Chlorine System Mechanical Plan and Details 17. Ammonia System Mechanical Plan and Details 18. Washwater Recovery Basin Structural Plan and Section 19. Washwater Recovery Basin Structural Details 20. Washwater, Sludge and Transfer Pump Station Structural Plan and Section 21. Washwater, Sludge and Transfer Pump Station Structural Details 22. Disinfection Basin Structural Plan and Section 23. Disinfection Basin Structural Section and Details 24. Electrical Symbols, Abbreviations and General Notes 25. Electrical Site Plan 26. Electrical One -Line Diagram 27. Washwater Recovery Basin Electrical Plan 28. Washwater, Sludge and Transfer Pump Station Electrical Plan 29. Disinfection Basin Electrical Plan 30. Chlorine and Ammonia System Electrical Plan 31. Electrical Details 32. Process and Instrumentation Diagrams, Symbols and Legend 33. Washwater Recovery Basin Process and Instrumentation Diagram 34. Washwater, Sludge and Transfer Pump Station Process and Instrumentation Diagram 35. Disinfection Basin Process and Instrumentation Diagram 36. Instrumentation Loop Diagram 8. Prepare and submit, on behalf of the Owner, an Edwards Aquifer site plan amendment application for the proposed construction. B -2 CONSTRUCTION PHAS 1. Assist the Owner in the advertisement of the Project for bids. 2. Assist the Owner in the opening and tabulating of bids for construction of the Project, and recommend to the Owner as to the proper action on all proposals received. 3. Assist in the preparation of formal Contract Documents for the contracts. 4. Make bi- weekly visits to the site, not to exceed two hours on -site each (on average), (as distinguished from the continuous services of a resident Project Representative) to observe the progress and quality of the executed work and to determine in general if the work is proceeding in accordance with the Contract Documents. In performing this service, the Engineer will not be required to make exhaustive or continuous on -site inspections to check the quality or quantity of the work or material; he will not be responsible for the techniques and sequences of construction or the safety precautions incident thereto; and he will not be responsible or liable in any degree for the contractors' failure to perform the construction work in accordance with the Contract Documents. During visits to the construction site, and on the basis of the Engineer's on -site observations as an experienced and qualified design professional, he will keep the Owner informed of the extent of the progress of the work, and advise the Owner of material and substantial defects and deficiencies in the work of contractors which are discovered by the Engineer or otherwise brought to the Engineer's attention in the course of construction, and may, on behalf of the Owner, exercise whatever rights the Owner may have to disapprove work and materials as failing to conform to the Contract Documents. 5. Consult and advise with the Owner; issue all instructions to the contractor requested by the Owner; and prepare routine change orders as required. 6. Review samples, catalog data, schedules, shop drawings, laboratory, shop and mill tests of materials and equipment and other data which the contractor is required to submit, only for conformance with the design concept of the Project and compliance with the information given by the Contract Documents; and assemble written guarantees which are required by the Contract Documents. 7. Review monthly and final estimates for payments to contractors, and furnish to the Owner any necessary certifications as to payments to contractors and suppliers in a form acceptable to the City. 8. Conduct, in company with the Owner, a final inspection of the Project for conformance with the design concept of the Project and compliance with the Contract Documents, and approve in writing final payment to the contractors. 9. Revise contract drawings, with the assistance of the resident Project Representatives, or the Owner's representative, to provide record drawings of the completed Project. Furnish one set of reproducible drawings and one set of prints of these revised drawings to the Owner. Engineer shall also deliver to the Owner record drawings in AutoCAD format using no version higher than Release 12. B -3 City is aware of the potential errors that may arise through the electronic copying of the floppy disk and AutoCAD disk. The reproducible drawings of the record drawings shall take precedence over the electronic copy because the data stored in electronic media can deteriorate or be modified inadvertently, and because the information contained on the electronic copy may not include all information included in the specifications of the final plans. B-4 ATTACHMENT C WORK SCHEDULE Based on a Notice to Proceed date of June 29, 1998, the estimated delivery and completion dates for the project are as follows: PHASE I AND PHASE 11 PLANT MODIFICATIONS 75% Complete Plans and Specifications — August 14, 1998 City Review Complete — August 22, 1998 100% Complete Plans and Specifications — September 4, 1998 Advertisement Date — September 13, 1998 Bid Date — October 13, 1998 Council Award — November 12, 1998 Begin Construction — December 1, 1998 Construction Complete — July 22, 1999 C -1 ATTACHMENT D FEE SCHEDULE TNRCC WPAP Amendment $ 5,000.00 Plans and Specifications $110,420.00 Bidding Phase $ 6,900.00 Construction Phase $ 20,700.00 TOTAL $143,020.00 D -1 DATE: June 22,1998 SUBJECT: City Council Meeting - June 25, 1998 ITEM: 10.A.2. Consider a resolution authorizing the Mayor to execute a contract with Camp Dresser & McKee, Inc for engineering services for Water Treatment Plant Improvements involving changes to existing sludge lagoon system and bidding documents for the chlorine contact disinfection basin. The improvements to the sludge lagoon system were identified under the recently completed Engineering Analysis dated May 8, 1998. The disinfection basin will enhance reliability of the disinfection process, especially for chloramines. The engineering contract is for $143,020.00. Staff Resource Person: Jim Nuse, Public Works Director.