Loading...
CM-07-04-050FROM SBC AUSTIN CMC (FRI) 3. 30' 07 7:46/ST. 7:46/NO. 4860711939 P 2 AT&T Texas CWOTS Record # 1528T07 .t �kgtr�� aca March 30, 2007 Dear Mr. Stablein: This letter is in regards to your request for Southwestern Bell Telephone, L.P. to perform construction services for you. Enclosed please find an Application and Letter of Agreement for Construction Services. This application describes the work that you have requested along with the associated charges for us to perform the work. We require advance payment for the full amount quoted on the application. The advance payment requirement will be waived for Federal, State, County or City governmental entities in good standing. Both the signed APPLICATION (with an original ink signature) and the advance payment must be received by our office before we can proceed on your behalf. Our mailing address for these documents is listed below: Southwestern Bell Telephone, L.P. Attn: Custom Work Order Department 817 W. North Loop Blvd. Room 200 Austin, Texas 78756 Payment will be accepted via US Postal Service, Over Night Mail Service, or Courier. No payment or contract may be hand delivered for security reasons. Thank you for our understanding. If you decide not to proceed with this work, please call our office at 512-870-4944 so that we may cancel your request. Please refer to the CWOTS record number at the top of this letter and your application to assist us in locating your file. Our tax identification number is: 43-0529710 Requests for a W-9 Tax form need to be faxed to: 314-206-5704 Sincerely, Karen Benton Manager -Custom Work Order Department Southwestern Beli Telephone, L.P. (512) 870-4944 C - 01- 04.—OsD FROM SBC AUSTIN CMC (FRI) 3. 30' 07 7:46/ST. 7:46/NO.4860711939 P 3 AT&T Texas Page 1 at&t APPLICATION and LETTER OF AGREEMENT FOR CONSTRUCTION SERVICES March 30, 2007 BILL TO: City of Round Rock WORK SITE LOCATION: DESCRIPTION OF CONSTRUCTION SERVICES TO BE PERFORMED: CWOTS Record Number: 1528T07 At Hesters Crossing at the IH35 north bound frontage road The work will consist of lowering the fiber cable. LABOR EXPENSE: $21,382.95 MATERIAL. EXPENSE: $4,252.80 OVERHEAD EXPENSE: $0 TARIFF/ LICENSE AGREEMENT EXPENSE: $0 ESTIMATED CHARGE FOR CONSTRUCTION SERVICES: ESTIMATED COST: $25,635.75 *** (Actual charges may exceed this estimated cost.) *** Applicant requests that Southwestern Bell Telephone, L.P. d/b/a AT&T Texas, (hereafter'SWBT") perform the above-described construction services on the Applicant's behalf. Applicant agrees to pay the charge(s) indicated above for such services plus applicable taxes. The work is to be done on an "Actual Cost" basis, all charge(s) will be computed in accordance with Southwestern Bell Telephone, L.P.'s ordinary accounting practices and will include allocated costs for labor, engineering, materials, transportation, motor vehicles, tool and supply expenses and sundry billings from sub -contractors and suppliers for work and materials related to the job. The Applicant affirms that the cost estimate furnished by the Telephone Company has been considered only as an estimate of approximate costs and that the actual costs incurred by the Telephone Company in doing the work at the particular time and location might be higher. Said estimated cost is subject to change due to any number of factors including, but not limited to, changing conditions in the field, weather delays, or changes in the scope of the work. ESTIMATED PRICE DOTE The above estimated price is guaranteed for 60 days from March 30, 2007. If the charges are not accepted within 60 days the order will be cancelled and a new order will need to be placed. The second estimate may be higher than the estimated price set out above. PAYMENT Applicant agrees to make an advance payment of $25,635.75 prior to commencement of the work. Charges for construction services and applicable taxes will be billed on a special bill separate from the bill that Applicant receives for telephone service. Applicant, its agents, servants. or employees agree to make payment on change orders within thirty (30) days of the date of signature on the change order. Failure to make payment within the designated thirty (30) day time period will operate to cancel the change order and Southwestern Bell Telephone, L.P., will cease all work activity on the project until payment is made. When the Parties agree to Interval Billing *, the balance of the Contract Price or Actual Cost (as applicable) will be made in monthly payments. If the Actual Cost made varies from the Estimated Cost, then a correcting adjustment will be made in the last payment. If the parties cannot agree to interval Billing, Applicant will make an advanced payment as indicated above. * Applicable to orders over $25,000 and work will take 6 or more months to complete. FROM SBC AUSTIN CMC at&t TAXES (FRI) 3. 30' 07 7:47/ST. 7:46/NO, 4860711939 P 4 AT&T Texas Page 2 Applicant will pay and indemnify SWBT against all sales, use and other taxes (excluding income and franchise taxes), including fees, levies, other similar charges, interest and penalties imposed upon and paid by or assessed on SWBT by reason of its sale and installation of material and provision of construction services under this Application except to the extent a valid tax exemption certificate is provided by Applicant to SWBT prior to the delivery of material and provisioning of construction services. STOP WORK ORDER In the event that Applicant issues a stop work order, or places the project "on hold", at an y he progress of the work, said stop work order or request to "hold" work must be issued in writingand mustnt during bedelivered via certified mail, return receipt requested to Karen Benton, 817 W. North Loop Blvd., Room 200, Austin, TX 78756. If Applicant issues a stop work order, or a request to "hold" work, the contract price quoted herein will remain valid until sixty (60) days from the date of the stop work or "hold" work order. At the expiration of the sixty (60) days, the contract price quoted herein will expire and a new contract price will be determined and provided, in writing, to Applicant. The new contract price may be higher than the contract price quoted in this custom work order. If, after issuing a stop work, or "hold" work order, Applicant elects to cancel the contract, Applicant must inform Southwestern Bell 'Telephone, L.P., in wilting of the cancellation. Southwestern Bell Telephone, L.P., will deduct any expenses incurred in performing the work from Applicant's advance payment and refund any remaining funds to Applicant. Under no circumstances will Southwestern Bell Telephone, L.P., be responsible to Applicant for any alleged damages or additional expenses incurred by Applicant as a result of a stop work order or an order to "hold" work on the project. CANCELLATION If the Applicant cancels the work prior to completion, Applicant must notify Southwestern Bell Telephone, L.P., in writing of said cancellation. if Applicant elects to cancel the work prior to completion, Applicant agrees to pay Southwestern Bell Telephone, L.P. for the costs it has incurred in starting performance under the contract. If Applicant has made an advance payment, Southwestern Bell Telephone L.P. will deduct its costs and expenses incurred as of the date of Applicant's notice of cancellation from the amount of the advance payment. Any amount remaining will be refunded to Applicant. CHANGES IN SCOPE OF WORK OR CHANGES IN FIELD CONDITIONS Should concealed conditions exist, including conditions that may exist below the surface of the ground, or if conditions exist that could not have been anticipated by Southwestern Bell Telephone, L.P. at the time of this agreement, Southwestern Bell Telephone, L.P., will be entitled to additional funds and/or additional time to complete the work. Southwestern Bell Telephone, LP. will request such additional funding and/or additional time through a request for a change order. Conditions that may materially alter the scope of the work and/or the cost associated with the work include but are not limited to conditions that exist below the surface of the ground and could not have been anticipated at the time of the price quote, above ground barriers, Acts of God affecting the progress or sequencing of the work, labor disputes, and other conditions or circumstances that Southwestern Bell telephone, L.P., could not reasonably anticipate at the time of providing the above referenced price quote to Applicant. FROM SBC AUSTIN CMC atett (FRI) 3. 30' 07 7:47/ST. 7:46/NO. 4860711939 P 5 AT&T Texas Page 3 Should Applicant or its agents, servants. or employees order or seek changes in the scope of the work, Southwestern Bell Telephone, L.P. is entitled to seek from Applicant, its agents, servants, or employees, additional funds as necessary to perform the work, and additional time, as necessary to complete the work. Said request for additional funds and/or additional time will be through change order Alt change orders will be in writing. All change orders will be submitted and accepted by Applicant, its agents, servants or employees, before Southwestem Bell Telephone, L.P., proceeds to execute the work or, if work has been initiated on the project, continues with executing the work except in an emergency endangering life or property. Applicant, its agents, servants or employees, are deemed to have accepted the terms of any change order by signing where indicated on the change order. Under no circumstances will Southwestern Bell Telephone. L.P.'s request for a change order be deemed or used as evidence of decay on the project. Nor will any change order issued in this project be used to charge Southwestern Bell Telephone, L.P. with responsibility for any alleged decay on the project. NO DAMAGE FOR DELAY Under no circumstances will Southwestern Bell Telephone, L.P. be held liable to Applicant, Applicant's agents, employees or contractors, for any alleged delay on the project that forms the basis for this agreement for construction services. TIME TO COMPLETE Any representation by Southwestern Bell Telephone, L.P., its agents, servants or employees that the project, or any additional work authorized by change order, will be complete by a certain date or certain time period is strictly an estimate and not binding on Southwestern Bell Telephone, L.P., its agents, servants, or employees. All estimated completion dates are subject to changing conditions in the field, changes In the scope of the work, relocation of existing utilities not within Southwestern Bell Telephone, L.P.'s control, Acts of God, weather delays, labor disputes, vendor/contractor disputes, and other conditions or circumstances that Southwestem Bell Telephone, L.P., its agents, servants, or employees, could not reasonably anticipate at the time of the estimate. CHOICE OF LAW AND ARBITRATION Should any dispute arise between the parties concerning the subject matter of this agreement, or any term contained therein, the parties agree that the dispute or claim shall be submitted to binding arbitration before the American Arbitration Association. The parties further agree that the prevailing party in any such dispute will be entitled to recover attorney's fees and costs of arbitration. Texas law governs the application of this agreement and all terms contained therein. INDEMNIFICATION AND HOLD HARMLESS Applicant, its agents, servants, and employees hereby agree to indemnify and hold harmless Southwestern Bell Telephone, L.P., and its employees, agents and contractors, from and against any and all claims, costs, expenses, judgments or actions for damage to property or injury or death to persons, and/or arising from or relating to the work that is the subject of this agreement, to the extent any such claims are caused by the negligent acts or omissions of the Applicant, its agents, servants, or employees. FROM SBC AUSTIN CMC at&t ENTIRE AGREEMENT (FRI) 3. 30' 07 7:47/ST. 7:46/NO. 4860711939 P 6 AT&T Texas Page 4 The parties agree that the terms set forth herein constitute the entire agreement and there are no other agreements regarding the project that is the subject of this agreement between the parties. MODIFICATION & NOTICE Any modification to this agreement must be made in writing and signed by both parties. ys,Q F4)l E Any party to this agreement may provide the other party with notice of any fact or condition by providingsuch.•' information in writing and serving said writing via certified mail, retum receipt requested ACCEPTED FOR CUSTOMER: orized Signature r R- . 'o shi• to Company or Individual 1. - Company: edC--� tet' Ko tura- ROCK Printed Name: uZiryies R. ki use, Pe . Date:_ aQo- ACCEPTED FOR SOUTHWESTERN BELL TELEPHONE, L.P.: Title: Manager -Custom Work Order Department Company: Southwestern Bell Telephone, L.P, Printed Name: Karen Benton Date: March $0, 2007 DATE: April 2, 2007 SUBJECT: City Manager - April 6, 2007 ITEM: Action authorizing the City Manager to execute an Application and Letter of Agreement for Construction Services with Southwestern Bell Telephone, L.P. for the relocation of telephone facilities along IH 35 east of Hester's Crossing Bridge. Department: Transportation Services Staff Person: Thomas G. Martin, P.E., Director Justification: Relocation of telephone facilities are required to proceed with IH 35 Frontage Road Collector/Distributor and Hester's Crossing Bridge Replacement project. Funding: Cost: $ 25,635.75 (not exceed amount) Source of funds: 4B -Round Rock Transportation System Development Corporation Outside Resources: Southwestern Bell Telephone, L.P. d/b/a AT&T Texas Background Information: The IH 35 Frontage Road Collector/Distributor and Hester's Crossing Bridge Replacement project will improve access to businesses, reduce the congestion created by the closure of two IH 35 exit ramps and two IH 35 entrance ramps, which was required by the construction of SH 45, and improve traffic flow through the Hester's Crossing intersections with the frontage roads and BI 35 / S. Mays Street. Funding for these improvements is included in the Transportation Capital Improvement Program, which is funded by the 1h cent sales tax established for the purpose of transportation system improvements that support economic development. Public Comment: N/A Blue Sheet Format Updated 01/20/04