CM-10-10-219ROUND ROCK, TEXAS
PURPOSE. PASSION. PROSPERITY.
Item Caption:
Approval Date:
City Manager Approval Summary Sheet
Consider executing a Contract for Engineering Services with Kasberg, Patrick & Associates,
LP for the East Main Street Park Wastewater Improvements.
11/5/10
Department: Infrastructure Development and Construction Management (IDCM)
Project Manager: Jeff Bell
Item Summary:
Due to the re -development of the Sam Bass Ball field's property, it is necessary to replace and relocate the
existing wastewater lines that serve the property. The existing lines are in poor condition and are located
underneath the proposed building structures. This resolution is for engineering services that will include
the preparation of construction plans and specifications and assistance in the bidding process and
construction phases listed in the contract. The project will consist of abandoning approximately 3,000 feet
of existing clay wastewater line and replacing with approximately 2,000 feet of 8 inch SDR 26 sewer pipe.
Public Health and Safety Strategic Initiative
Goal 28.0 "Protect public health and protect the environment through proper waste
Strategic Plan Relevance: disposal"
Cost: $30,500
Source of Funds: Self Financed Wastewater Construction
ROUND ROCK, TEXAS
PURPOSE. PASSION PROSPERITY
CITY OF ROUND ROCK
CONTRACT FOR ENGINEERING SERVICES
FIRM: I(ASBERG, PATRICK & ASSOCIATES. LP ("Engineer")
ADDRESS: 1 South Main, Temple, Texas 76501
PROJECT: East Main Street Park Wastewater Improvements
THE STATE OF TEXAS
COUNTY OF WILLIAMSON
THIS CONTRACT FOR ENGINEERING SERVICES ("Contract") is made and entered into on
this the54 day of .(VOt)EMBEK, 2010 by and between the CITY OF ROUND ROCK, a Texas home -
rule municipal corporation, whose offices are located at 221 East Main Street, Round Rock, Texas
78664-5299, (hereinafter referred to as "City"), and Engineer, and such Contract is for the purpose of
contracting for professional engineering services.
RECITALS:
WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled
"Professional Services Procurement Act" provides for the procurement by municipalities of services of
professional engineers; and
WHEREAS, City and Engineer desire to contract for such professional engineering services; and
WHEREAS, City and Engineer wish to document their agreement concerning the requirements
and respective obligations of the parties;
NOW, THEREFORE, WITNESSETH:
That for and in consideration of the mutual promises contained herein and other good and
valuable considerations, and the covenants and agreements hereinafter contained to be kept and
perfonned by the respective parties hereto, it is agreed as follows:
Engineering Services Contract Rev. 05/10
0199.7154; 00206503 00192831
W W02EMAIN
1
CONTRACT DOCUMENTS
The Contract Documents consist of this Contract and any exhibits attached hereto (which
exhibits are hereby incorporated into and made a part of this Contract) and all Supplemental Contracts
(as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all
are as fully a part of this Contract as if attached to this Contract or repeated herein.
ARTICLE 1
CITY SERVICES
City shall perform or provide services as identified in Exhibit A entitled "City Services."
ARTICLE 2
ENGINEERING SERVICES
Engineer shall perforin Engineering Services as identified in Exhibit B entitled "Engineering
Services."
Engineer shall perform the Engineering Services in accordance with the Work Schedule as
identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete
schedule so that the Engineering Services under this Contract may be accomplished within the specified
time and at the specified cost. The Work Schedule shall provide specific work sequences and definite
review times by City and Engineer of all Engineering Services. Should the review times or Engineering
Services take longer than shown on the Work Schedule, through no fault of Engineer, Engineer may
submit a timely written request for additional time, which shall be subject to the approval of the City
Manager.
ARTICLE 3
CONTRACT TERM
(1) Term. The Engineer is expected to complete the Engineering Services described herein in
accordance with the above described Work Schedule. If Engineer does not perform the Engineering
Services in accordance with the Work Schedule, then City shall have the right to terminate this Contract
as set forth below in Article 20. So long as the City elects not to terminate this Contract, it shall continue
from day to day until such time as the Engineering Services are completed. Any Engineering Services
performed or costs incurred after the date of termination shall not be eligible for reimbursement.
Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably
anticipates, that the Engineering Services will not be completed in accordance with the Work Schedule.
(2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance,
and agrees to undertake all necessary efforts to expedite the performance of Engineering Services
required herein so that construction of the project will be commenced and completed as scheduled. In
this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer
shall proceed with sufficient qualified personnel and consultants necessary to fully and timely
accomplish all Engineering Services required under this Contract in a professional manner.
2
(3) Notice to Proceed. After execution of this Contract, Engineer shall not proceed with
Engineering Services until authorized in writing by City to proceed as provided in Article 7.
ARTICLE 4
COMPENSATION
City shall pay and Engineer agrees to accept the amount shown below as full compensation for
the Engineering Services performed and to be performed under this Contract.
The amount payable under this Contract, without modification of the Contract as provided
herein, is the sum of Thirty Thousand, Five Hundred and No/100 Dollars ($30,500.00) as shown in
Exhibit D. The lump sum amount payable shall be revised equitably only by written Supplemental
Contract in the event of a change in Engineering Services as authorized by City.
Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support
the progress of the Engineering Services and to support invoices requesting monthly payment. Any
preferred format of City for such monthly progress reports shall be identified in Exhibit B. Satisfactoiy
progress of Engineering Services shall be an absolute condition of payment.
The fee herein referenced may be adjusted for additional Engineering Services requested and
performed only if approved by written Supplemental Contract.
ARTICLE 5
METHOD OF PAYMENT
Payments to Engineer shall be made while Engineering Services are in progress. Engineer shall
prepare and submit to City, not more frequently than once per month, a progress report as referenced in
Article 4 above. Such progress report shall state the percentage of completion of Engineering Services
accomplished during that billing period and to date. Simultaneous with submission of such progress
report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a
form acceptable to City. This submittal shall also include a progress assessment report in a form
acceptable to City.
Progress payments shall be made in proportion to the percentage of completion of Engineering
Services identified in Exhibit D. Progress payments shall be made by City based upon Engineering
Services actually provided and performed. Upon timely receipt and approval of each statement, City
shall make a good faith effort to pay the amount which is due and payable within thirty (30) days. City
reserves the right to withhold payment pending verification of satisfactory Engineering Services
performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its
determination, that tasks were completed.
The certified statements shall show the total amount earned to the date of submission and shall
show the amount due and payable as of the date of the current statement. Final payment does not relieve
Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her/its
negligence.
3
ARTICLE 6
PROMPT PAYMENT POLICY
In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer
will be made within thirty (30) days of the day on which the performance of services was complete, or
within thirty (30) days of the day on which City receives a correct invoice for services, whichever is
later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law)
for payments not made in accordance with this prompt payment policy; however, this policy does not
apply in the event:
A. There is a bona fide dispute between City and Engineer concerning the supplies,
materials, or equipment delivered or the services perforined that causes the payment to be
late; or
B. The terms of a federal contract, grant, regulation, or statute prevent City from making a
timely payment with federal funds; or
C. There is a bona fide dispute between Engineer and a subcontractor or between a
subcontractor and its supplier concerning supplies, materials, or equipment delivered or
the Engineering Services performed which causes the payment to be late; or
D. The invoice is not mailed to City in strict accordance with instructions, if any, on the
purchase order, or this Contract or other such contractual agreement.
City shall document to Engineer the issues related to disputed invoices within ten (10) calendar
days of receipt of such invoice. Any non -disputed invoices shall be considered correct and payable per
the terms of Chapter 2251, V.T.C.A., Texas Government Code.
ARTICLE 7
NOTICE TO PROCEED
The Engineer shall not proceed with any task listed on Exhibit B until the City has issued a
written Notice to Proceed regarding such task. The City shall not be responsible for work performed or
costs incurred by Engineer related to any task for which a Notice to Proceed has not been issued.
ARTICLE 8
PROJECT TEAM
City's Designated Representative for purposes of this Contract is as follows:
Jeff Bell
Project Manager
2008 Enterprise Drive
Round Rock, Texas 78664
Telephone Number (512) 801-4461
Fax Number (512) 218-5563
Email Address jbell@round-rock.tx.us
4
City's Designated Representative shall be authorized to act on City's behalf with respect to this
Contract. City or City's Designated Representative shall render decisions in a timely manner pertaining
to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential
progress of Engineering Services.
Engineer's Designated Representative for purposes of this Contract is as follows:
Thomas D. Valle, P.E.
Partner
1 South Main
Temple, Texas 76501
Telephone Number (254) 773-3731
Fax Number (254) 773-6667
Email Address tvalle@kpaengineers.com
ARTICLE 9
PROGRESS EVALUATION
Engineer shall, from time to time during the progress of the Engineering Services, confer with
City at City's election. Engineer shall prepare and present such information as may be pertinent and
necessary, or as may be requested by City, in order for City to evaluate features of the Engineering
Services. At the request of City or Engineer, conferences shall be provided at Engineer's office, the
offices of City, or at other locations designated by City. When requested by City, such conferences shall
also include evaluation of the Engineering Services,
Should City determine that the progress in Engineering Services does not satisfy the Work
Schedule, then City shall review the Work Schedule with Engineer to determine corrective action
required.
Engineer shall promptly advise City in writing of events which have or may have a significant
impact upon the progress of the Engineering Services, including but not limited to the following:
(1) Problems, delays, adverse conditions which may materially affect the ability to meet the
objectives of the Work Schedule, or preclude the attainnent of project Engineering Services
units by established time periods; and such disclosure shall be accompanied by statement of
actions taken or contemplated, and City assistance needed to resolve the situation, if any;
and
(2) Favorable developments or events which enable meeting the Work Schedule goals sooner
than anticipated.
5
ARTICLE 10
SUSPENSION
Should City desire to suspend the Engineering Services, but not to terminate this Contract, then
such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification
followed by written confirmation to that effect. Such thirty -day notice may be waived in writing by
agreement and signature of both parties. The Engineering Services may be reinstated and resumed in
full force and effect within sixty (60) days of receipt of written notice from City to resume the
Engineering Services. Such sixty-day notice may be waived in writing by agreement and signature of
both parties. If this Contract is suspended for more than thirty (30) days, Engineer shall have the option
of terminating this Contract.
If City suspends the Engineering Services, the contract period as determined in Article 3, and
the Work Schedule, shall be extended for a time period equal to the suspension period.
City assumes no liability for Engineering Services performed or costs incurred prior to the date
authorized by City for Engineer to begin Engineering Services, and/or during periods when Engineering
Services is suspended, and/or subsequent to the contract completion date.
ARTICLE 11
ADDITIONAL ENGINEERING SERVICES
If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is
beyond the scope of this Contract and as such constitutes extra work, he/she/it shall promptly notify
City in writing. In the event City finds that such work does constitute extra work and exceeds the
maximum amount payable, City shall so advise Engineer and a written Supplemental Contract will be
executed between the parties as provided in Article 13. Engineer shall not perform any proposed
additional work nor incur any additional costs prior to the execution, by both parties, of a written
Supplemental Contract. City shall not be responsible for actions by Engineer nor for any costs incurred
by Engineer relating to additional work not directly associated with the performance of the Engineering
Services authorized in this Contract or any amendments thereto.
ARTICLE 12
CHANGES IN ENGINEERING SERVICES
If City deems it necessary to request changes to previously satisfactorily completed Engineering
Services or parts thereof which involve changes to the original Engineering Services or character of
Engineering Services under this Contract, then Engineer shall make such revisions as requested and as
directed by City. Such revisions shall be considered as additional Engineering Services and paid for as
specified under Article 11.
Engineer shall make revisions to Engineering Services authorized hereunder as are necessary to
correct errors appearing therein, when required to do so by City. No additional compensation shall be
due for such Engineering Services.
6
ARTICLE 13
SUPPLEMENTAL CONTRACTS
The terms of this Contract may be modified by written Supplemental Contract if City
determines that there has been a significant change in (1) the scope, complexity or character of the
Engineering Services, or (2) the duration of the Engineering Services. Any such Supplemental Contract
must be duly authorized by the City. Engineer shall not proceed until the Supplemental Contract has
been executed. Additional compensation, if appropriate, shall be identified as provided in Article 4.
It is understood and agreed by and between both parties that Engineer shall make no claim for
extra work done or materials furnished until the City authorizes full execution of the written
Supplemental Contract and authorization to proceed. City reserves the right to withhold payment
pending verification of satisfactory Engineering Services performed.
ARTICLE 14
USE OF DOCUMENTS
All documents, including but not limited to drawings, specifications and data or programs stored
electronically, (hereinafter referred to as "Instruments of Service") prepared by Engineer and its
subcontractors are related exclusively to the services described in this Contract and are intended to be
used with respect to this Project. However, it is expressly understood and agreed by and between the
parties hereto that all of Engineer's designs under this Contract (including but not limited to tracings,
drawings, estimates, specifications, investigations, studies and other documents, completed or partially
completed), shall be the property of City to be thereafter used in any lawful manner as City elects. Any
such subsequent use made of documents by City shall be at City's sole risk and without liability to
Engineer, and, to the extent permitted by law, City shall indemnify, defend and hold harmless Engineer
from all claims, damages, losses and expenses, including but not limited to attorneys fees, resulting
therefrom.
By execution of this Contract and in confirmation of the fee for services to be paid under this
Contract, Engineer hereby conveys, transfers and assigns to City all rights under the Federal Copyright
Act of 1976 (or any successor copyright statute), as amended, all common law copyrights and all other
intellectual property rights acknowledged by law in the Project designs and work product developed
under this Contract. Copies may be retained by Engineer. Engineer shall be liable to City for any loss or
damage to any such documents while they are in the possession of or while being worked upon by
Engineer or anyone connected with Engineer, including agents, employees, Engineers or subcontractors.
All documents so lost or damaged shall be replaced or restored by Engineer without cost to City.
Upon execution of this Contract, Engineer grants to City permission to reproduce Engineer's
work and documents for purposes of constructing, using and maintaining the Project, provided that City
shall comply with its obligations, including prompt payment of all sums when due, under this Contract.
Engineer shall obtain similar permission from Engineer's subcontractors consistent with this Contract. If
and upon the date Engineer is adjudged in default of this Contract, City is permitted to authorize other
similarly credentialed design professionals to reproduce and, where permitted by law, to make changes,
corrections or additions to the work and documents for the purposes of completing, using and
maintaining the Project.
7
City shall not assign, delegate, sublicense, pledge or otherwise transfer any permission granted
herein to another party without the prior written contract of Engineer. However, City shall be permitted
to authorize the contractor, subcontractors and material or equipment suppliers to reproduce applicable
portions of the Instruments of Service appropriate to and for use in their execution of the Work.
Submission or distribution of Instruments of Service to meet official regulatory requirements or for
similar purposes in connection with the Project is permitted. Any unauthorized use of the Instruments of
Service shall be at City's sole risk and without liability to Engineer and its Engineers.
Prior to Engineer providing to City any Instruments of Service in electronic form or City
providing to Engineer any electronic data for incorporation into the Instruments of Service, City and
Engineer shall by separate written contract set forth the specific conditions governing the format of such
Instruments of Service or electronic data, including any special limitations not otherwise provided in this
Contract. Any electronic files are provided by Engineer for the convenience of City, and use of them is
at City's sole risk. In the case of any defects in electronic files or any discrepancies between them and
any hardcopy of the same documents prepared by Engineer, the hardcopy shall prevail. Only printed
copies of documents conveyed by Engineer shall be relied upon.
Engineer shall have no liability for changes made to the drawings by other engineers subsequent
to the completion of the Project. Any such change shall be sealed by the engineer making that change
and shall be appropriately marked to reflect what was changed or modified.
ARTICLE 15
PERSONNEL, EQUIPMENT AND MATERIAL
Engineer shall furnish and maintain, at its own expense, quarters for the performance of all
Engineering Services, and adequate and sufficient personnel and equipment to perform the Engineering
Services as required. All employees of Engineer shall have such knowledge and experience as will
enable thein to perform the duties assigned to them. Any employee of Engineer who, in the opinion of
City, is incompetent or whose conduct becomes detrimental to the Engineering Services shall
immediately be removed from association with the project when so instructed by City. Engineer
certifies that it presently has adequate qualified personnel in its employment for performance of the
Engineering Services required under this Contract, or will obtain such personnel from sources other
than City. Engineer may not change the Project Manager without prior written consent of City.
ARTICLE 16
SUBCONTRACTING
Engineer shall not assign, subcontract or transfer any portion of the Engineering Services under
this Contract without prior written approval from City. All subcontracts shall include the provisions
required in this Contract and shall be approved as to form, in writing, by City prior to Engineering
Services being performed under the subcontract. No subcontract shall relieve Engineer of any
responsibilities under this Contract.
8
ARTICLE 17
EVALUATION OF ENGINEERING SERVICES
City, or any authorized representatives of it, shall have the right at all reasonable tunes to review
or otherwise evaluate the Engineering Services performed or being performed hereunder and the
premises on which it is being performed. If any review or evaluation is made on the premises of
Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all
reasonable facilities and assistance for the safety and convenience of City or other representatives in the
performance of their duties.
ARTICLE 18
SUBMISSION OF REPORTS
All applicable study reports shall be submitted in preliminary form for approval by City before
any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any
final report.
ARTICLE 19
VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT
Violation of contract terms or breach of contract by Engineer shall be grounds for termination of
this Contract, and any increased costs arising from Engineer's default, breach of contract, or violation
of contract terms shall be paid by Engineer.
ARTICLE 20
TERMINATION
This Contract may be terminated as set forth below.
(1) By mutual agreement and consent, in writing, of both parties.
(2) 13y City, by notice in writing to Engineer, as a consequence of failure by Engineer to
perform the Engineering Services set forth herein in a satisfactory manner.
(3) By either party, upon the failure of the other party to fulfill its obligations as set forth
herein.
(4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon
not less than thirty (30) days' written notice to Engineer.
(5) By satisfactory completion of all Engineering Services and obligations described herein.
Should City terminate this Contract as herein provided, no fees other than fees due and payable
at the time of termination shall thereafter be paid to Engineer. In determining the value of the
Engineering Services performed by Engineer prior to termination, City shall be the sole judge.
Compensation for Engineering Services at termination will be based on a percentage of the Engineering
9
Services completed at that time. Should City terminate this Contract under Subsection (4) immediately
above, then the amount charged during the thirty -day notice period shall not exceed the amount charged
during the preceding thirty (30) days.
If Engineer defaults in the performance of this Contract or if City terminates this Contract for
fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer
in performing the Engineering Services to the date of default, the amount of Engineering Services
required which was satisfactorily completed to date of default, the value of the Engineering Services
which are usable to City, the cost to City of employing another firm to complete the Engineering
Services required and the time required to do so, and other factors which affect the value to City of the
Engineering Services performed at the time of default.
The termination of this Contract and payment of an amount in settlement as prescribed above
shall extinguish all rights, duties, and obligations of City and Engineer under this Contract, except the
obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this
Contract is due to the failure of Engineer to fulfill his/her/its contractual obligations, then City may take
over the project and prosecute the Engineering Services to completion. In such case, Engineer shall be
liable to City for any additional and reasonable costs incurred by City.
Engineer shall be responsible for the settlement of all contractual and administrative issues
arising out of any procurements made by Engineer in support of the Engineering Services under this
Contract.
ARTICLE 21
COMPLIANCE WITH LAWS
(1) Compliance. Engineer shall comply with all applicable federal, state and local laws,
statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or
administrative bodies or tribunals in any manner affecting the performance of this Contract, including
without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws
and regulations. Engineer shall furnish City with satisfactory proof of his/her/its compliance.
Engineer shall further obtain all permits and licenses required in the performance of the
Engineering Services contracted for herein.
(2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the
Engineering Services performed hereunder. City is qualified for exemption pursuant to the provisions
of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act.
ARTICLE 22
INDEMNIFICATION
Engineer shall save and hold harmless City and its officers and employees from all claims and
liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this
Contract, which are caused by or which result from the negligent error, omission, or negligent act of
Engineer or of any person employed by Engineer or under Engineer's direction or control.
10
Engineer shall also save and hold City harmless from any and all expenses, including but not
limited to reasonable attorneys fees which may be incurred by City in litigation or otherwise defending
claims or liabilities which may be imposed on City as a result of such negligent activities by Engineer,
its agents, or employees.
ARTICLE 23
ENGINEER'S RESPONSIBILITIES
Engineer shall be responsible for the accuracy of his/her/its Engineering Services and shall
promptly make necessary revisions or corrections to its work product resulting from errors, omissions,
or negligent acts, and same shall be done without compensation. City shall determine Engineer's
responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be
relieved of responsibility for subsequent correction of any such errors or omissions in its work product,
or for clarification of any ambiguities until after the construction phase of the project has been
completed.
ARTICLE 24
ENGINEER'S SEAL
The responsible engineer shall sign, seal and date all appropriate engineering submissions to
City in accordance with the Texas Engineering Practice Act and the rules of the State Board of
Registration for Professional Engineers.
ARTICLE 25
NON -COLLUSION. FINANCIAL INTEREST PROHIBITED
(1) Non -collusion. Engineer warrants that he/she/it has not employed or retained any company
or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this
Contract, and that he/she/it has not paid or agreed to pay any company or engineer any fee,
commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting
from the award or making of this Contract. For breach or violation of this warranty, City reserves and
shall have the right to annul this Contract without liability or, in its discretion and at its sole election, to
deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee,
commission, percentage, brokerage fee, gift or contingent fee.
(2) Financial Interest Prohibited. Engineer covenants and represents that Engineer,
his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest,
direct or indirect, in the purchase or sale of any product, materials or equipment that will be
recommended or required for the construction of the project.
ARTICLE 26
INSURANCE
(1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire
term while this Contract is in effect professional liability insurance coverage in the minimum amount of
One Million Dollars per claim from a company authorized to do insurance business in Texas and
11
otherwise acceptable to City. Engineer shall also notify City, within twenty-four (24) hours of receipt, of
any notices of expiration, cancellation, non -renewal, or material change in coverage it receives from its
insurer.
(2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of
Engineer, Engineer shall require each subconsultant performing work under this Contract to maintain
during the term of this Contract, at the subconsultant's own expense, the same stipulated minimum
insurance required in Article 26, Section (1) above, including the required provisions and additional
policy conditions as shown below in Article 26, Section (3).
Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order
to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance
for the duration of this Contract, and shall have the responsibility of enforcing these insurance
requirements among its subconsultants. City shall be entitled, upon request and without expense, to
receive copies of these certificates of insurance.
(3) Insurance Policy Endorsements. Each insurance policy shall include the following
conditions by endorsement to the policy:
(a) Each policy shall require that thirty (30) days prior to the expiration, cancellation, non-
renewal or reduction in limits by endorsement a notice thereof shall be given to City by
certified mail to:
City Manager, City of Round Rock
221 East Main Street
Round Rock, Texas 78664
(b) The policy clause "Other Insurance" shall not apply to any insurance coverage currently
held by City, to any such future coverage, or to City's Self -Insured Retentions of
whatever nature.
(4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained
by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum
coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit E herein
entitled "Certificates of Insurance."
ARTICLE 27
COPYRIGHTS
City shall have the royalty -free, nonexclusive and irrevocable right to reproduce, publish or
otherwise use, and to authorize others to use, any reports developed by Engineer for governmental
purposes.
12
ARTICLE 28
SUCCESSORS AND ASSIGNS
This Contract shall be binding upon and inure to the benefit of the parties hereto, their
successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any
interest in this Contract, in whole or in part, by operation of law or otherwise, without obtaining the
prior written consent of City.
ARTICLE 29
SEVERABILITY
In the event any one or more of the provisions contained in this Contract shall for any reason be
held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or
unenforceability shall not affect any other provision thereof and this Contract shall be construed as if
such invalid, illegal or unenforceable provision had never been contained herein.
ARTICLE 30
PRIOR AGREEMENTS SUPERSEDED
This Contract constitutes the sole agreement of the parties hereto, and supersedes any prior
understandings or written or oral contracts between the parties respecting the subject matter defined
herein. This Contract may only be amended or supplemented by mutual agreement of the parties hereto
in writing.
ARTICLE 31
ENGINEER'S ACCOUNTING RECORDS
Records pertaining to the project, and records of accounts between City and Engineer, shall be
kept on a generally recognized accounting basis and shall be available to City or its authorized
representatives at mutually convenient times. The City reserves the right to review all records it deems
relevant which are related to this Contract.
ARTICLE 32
NOTICES
All notices to either party by the other required under this Contract shall be personally delivered
or mailed to such party at the following respective addresses:
City:
City of Round Rock
Attention: City Manager
221 East Main Street
Round Rock, TX 78664
13
and to:
Stephan L. Sheets
City Attorney
309 East Main Street
Round Rock, TX 78664
Engineer:
Thomas D. Valle, P.E.
Partner
1 South Main
Temple, Texas 76501
ARTICLE 33
GENERAL PROVISIONS
(1) Tinie is of the Essence. Engineer understands and agrees that time is of the essence and
that any failure of Engineer to complete the Engineering Services for each phase of this Contract within
the agreed Work Schedule may constitute a material breach of this Contract. Engineer shall be fully
responsible for his/her/its delays or for failures to use his/her/its reasonable efforts in accordance with
the terms of this Contract and the Engineer's standard of performance as defined herein. Where damage
is caused to City due to Engineer's negligent failure to perfonn City may accordingly withhold, to the
extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal
rights or remedies.
(2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Contract if
prevented from performing any of their obligations hereunder by reasons for which they are not
responsible or circumstances beyond their control. However, notice of such impediment or delay in
performance must be timely given, and all reasonable efforts undertaken to mitigate its effects.
(3) Enforcement and Venue. This Contract shall be enforceable in Round Rock, Williamson
County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or
all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas.
This Contract shall be governed by and construed in accordance with the laws and court decisions of
the.Stateof Texas.
(4) Standard of Performance. The standard of care for all professional engineering,
consulting and related services performed or furnished by Engineer and its employees under this
Contract will be the care and skill ordinarily used by members of Engineer's profession practicing
under the same or similar circumstances at the same time and in the same locality. Excepting Articles
25 and 34 herein, Engineer makes no warranties, express or implied, under this Contract or otherwise,
in connection with the Engineering Services.
14
(5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction
cost provided by Engineer are made on the basis of information available to Engineer and on the basis
of Engineer's experience and qualifications and represents its judgment as an experienced and qualified
professional engineer. However, since Engineer has no control over the cost of labor, materials,
equipment or services furnished by others, or over the contractor(s') methods of determining prices, or
over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or
actual project or construction cost will hot vary from opinions of probable cost Engineer prepares.
(6) Opinions and Determinations. Where the terms of this Contract provide for action to be
based upon opinion, judgment, approval, review, or determination of either party hereto, such terms are
not intended to be and shall never be construed as permitting such opinion, judgment, approval, review,
or determination to be arbitrary, capricious, or unreasonable.
ARTICLE 34
SIGNATORY WARRANTY
The undersigned signatory for Engineer hereby represents and warrants that the signatory is an
officer of the organization for which he/she has executed this Contract and that he/she has full and
complete authority to enter into this Contract on behalf of the firm. The above -stated representations
and warranties are made for the purpose of inducing City to enter into this Contract.
IN WITNESS WHEREOF, the City of Round Rock has caused this Contract to be signed in its
corporate name by its duly authorized City Manager or Mayor, as has Engineer, signing by and through
its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and
representatives for the faithful and full performance of the terms and provisions hereof.
CITY OF ROUND ROCK, TEXAS
By:
ATTEST:
By:
Qm(S R A(ctse, P.-:
G rY Ailocgoic2M
Sara L. White, City Secretary
KASBER 'AT ICK & ASSOCIATES, LP
By:
Signature of Princi aI
Printed Name: �
/4 �a
er
15
APP' 0 ED AS TO 'ORM:
1i►Iii
Stepha ¶l
J
Sheets, City Attorney
LIST 01? EXHIBITS ATTACHED
(1) Exhibit A City Services
(2) Exhibit B Engineering Services
(3) Exhibit C Work Schedule
(4) Exhibit D Fee Schedule
(5) Exhibit E Certificates of Insurance
EXHIBIT A
City Services
The City of Round Rock will furnish to the Engineer the following items/infonnation:
1. Record drawings and documents pertaining to projects in the area, including
easement documents, construction plans, test records, aerial photography,
topography, system maps, etc.
2. Proposed site layout for Round Rock Social Services Center, including any site
and or future requirements.
EXHIBIT B
Engineering Services
The following is a list of services that will be performed by Kasberg, Patrick &
Associates, LP for the Final Design Engineering for Proposed East Main Street Park
Wastewater Improvements:
Design Phase
1. Attend preliminary conference with the City regarding the requirements for the
project.
2. Design Surveys detailing the existing park area including seven existing manholes
and the cleanouts for the house on the northwest corner and the retirement home
on the northeast corner of the project site.
3. Incorporate as -built drawings received from the City of Round Rock and verify
the location of service connections in conjunction with survey data.
4. Prepare preliminary alignment based on proposed site layout of the Round Rock
Social Services Center.
5. Meet with the City to review preliminary alignment (approximately 30% Plan
sheets).
6. Prepare Final Plans, Specifications and Contract Documents for the referenced
improvements in accordance with TCEQ requirements.
7. Meet with City to review 90% Plans, Specifications and Contract Documents.
8. Incorporate changes or revisions as a result of review comments made by the City
of Round Rock Staff.
9. Prepare Final Opinion of Probable Cost.
10. Prepare field notes for the City's use in acquiring a single easement along the
wastewater alignment within the Round Rock Social Services site.
11. Prepare twenty (20) copies of the Final Design Engineering Plans and Contract
Documents and Technical Specifications Book and deliver to the City of Round
Rock.
Bidding Phase
1. Solicit bidders by making phone calls and sending e-mails and faxes to qualified
contractors.
2. Conduct Pre -Bid conference.
3. Address contractor questions and/or clarifications through issuance of Addenda.
4. Conduct Bid Opening.
5. Review bids and prepare detailed bid tabulation.
6. Review Contractor references, financial information and current workload
order to make recommendation of award.
7. Prepare Letter of Recommendation and submit with Bid Tabulation.
8. Attend City Council meeting at which construction contract is awarded to address
any questions that arise in regards to the project and/or contractor.
EXHIBIT B (continued)
Construction Phase
1. Prepare 7 copies of confirmed Plan Sets and Technical Specifications (including
addenda items).
2. Conduct Pre -Construction conference.
3. Conduct weekly project site visits to observe construction activities in general
conformance with Contract Documents.
4. Conduct monthly construction progress meetings and prepare minutes of the
meeting.
5. Review submittals.
6. Conduct final walk through.
7. Prepare final punch list.
8. Develop record drawings.
Note: Inspection of the TCEQ Edwards Aquifer Map indicates that the entirety of the
project area is Located within the Edwards Aquifer Transition Zone. We contacted
Mr. Russ Alexander at TCEQ and he confirmed that while the project is near the
Recharge/Transition Zone boundary (within a quarter mile), it is entirely within the
Transition Zone. As such, preparation and submittal of a Sewage Collection System
(SCS) report in accordance with TCEQ Chapter 213 Regulations is not required and has
not been included in this scope.
EXHIBIT C
Work Schedule
Week of: Milestone:
November 23, 2010 City Council Approval
November 29, 2010 Notice to Proceed. Survey Work Begins.
December 6, 2010 30% Plan Review Meeting
December 20, 2010 90% Plan Review Meeting
January 3, 2011 100% Plans submitted to City of Round Rock
January 17, 2011 Public Notice/ Advertising / Plans Available
February 7, 2001 Bids Received at City Hall
February 21, 2011 City Awards Contract
March 21, 2011 Pre -Construction Conference
May 23, 2011 Construction Substantially Complete (60 days)
May 30, 2011 Final Project Acceptance
EXHIBIT D
Fee Schedule
Cost Component, Hours
Total
Hours
Senior Project Manager 30
Project Engineer 80
P
Eng Tech 86
86
Admin/Clerical 8
Cost Component, Dollars
Direct Direct
Hourly Labor Indirect Total
Rate Cost Cost Cost
Senior Project Manager $ 49.04 $ 1,471.20 $ 1,996.57 $ 3,467.77
PIProject Engineer $ 42.88 $ 3,430.40 $ 4,655.40 $ 8,085.80
$ 27.50 $ 1,540.00 $ 2,089.93 $ 3,629.93
Eng Tech $ 24.51 $ 2,107.86 $ 2,860.58 $ 4,968.44
Admin/Clerical $ 17.25 $ 138.00 $ 187.28 $ 325.28
$ 8,687.46 $11,789.75 $ 20,477.21
Profit @ 12%
Expenses
Phone, Fax, Postage, Copies
Travel Expenses
Total Expenses
$ 2,457.27
$ 915.52
$ 800.00
$ 1,715.52
KPA Lump Sum Fee Summary
Direct Labor
Indirect Costs (135.71%)
Direct Costs
Profit @ 12%
SUBTOTAL KPA Fee
Subconsultant Fee Summary
Design Survey (hourly not to exceede - by Inland Geodetics, LP)
Field Notes for Easements (per Each - by Inland Geodetics, LP)
SUBTOTAL Surveying Sub
TOTAL PROJECT FEES
$ 8,687.46
$ 11,789.75
$ 1,715.52
$ 2,457.27
$ 24,650.00
$ 3,850.00
$ 2,000.00
$ 5,850.00
$ 30,500.00
EXHIBIT E
Certificates of Insurance
Attached Behind This Page
ACORD,, CERTIFICATE OF
LIABILITY INSURANCE
DATEILINADNYYTY)
7/1/2010
OF NFORMATION
CERTIFICATE
EXTEND OR
POLICIES BELOW.
_TYEFofIRU A�E_
PRODUCER
McLaughlin Brunson Insurance Agency, LLP
6600 LBJ Freeway, Suite 220
Donee TX 75240
1234) 503-1212 12141 503.8099
__ _ _ __. —._____�...—_. �___—
POLICY NUMBER
THIS CERTIFICATE IS ISSUED AS A MATTER
ONLY AND CONFERS NO RIGHTS UPON THE
HOLDER. THIS CERTIFICATE DOES NOT AMEND,
ALTER THE COVERAGE AFFORDED BY THE
INSURERS AFFUFLDING COVERAGE
NAIC N
INSURED
Xaaberg, Patrick h Aaaociatea, LP
One South Hain
Temple TX 76501
1
•
INSURER A- Beazley Insurance Company, Inc
37540
INSURFRB•
INSURER C:
INSURE/i0...._,__—
INSURER E.
•
EACH OCCURRENCE_
_ ,_
COVERAGES
TETE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REOUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT V1TH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRISED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED AY PAID CLAIMS.
3 TR
UW
_TYEFofIRU A�E_
POLICY NUMBER
EFFECTIVE
DATE MIILODryrL
POLICY ENRRATION
DATE 1M94,Offyl
-"-_IPOLICY
LIMITS
GENERAL LIABILITY
EACH OCCURRENCE_
S
C0.IMERCW. GENEfUlll001tIrY
"L�iLard ldhTTT€b ..—__
�._�__.__.
-•-,--)
CLAIMMADE Ej OCCUR
LEO EXP TANDna Prism)
3 `___� _
_--__...__.__...��_
PERSONAL b AOV INAIRY
3
GEtlORlt AGGREGATE
5
GENL
1
AGGREGATE 1438APPLIES PER:
POLICY flr s [^ILOC
PROOUCTS•COLIP/OP AGO
$
AUTOMOOIIO
LIABILITY
COMBWE03NGLE LIMO
ANY AUTO
1EaatrvlatQ
s
ALL OYNE0 AUC
BOUAY INJURY-'—
SCHEOULEDAUTC6
(Pe,pwsoi
S
^_
IIIRf•DAUfOS
...__.._.__.............__._,_
�__._
KM Y INJURY
NON -OWNED AUTOS
(Per arnsem)
S
PROPERTY DAAUGE
(Pet 8 *1 nt)
S
GARAGE LIA&CITY
AUTO ONLY • E AACCIolNT
S
ANYAVIU
OTHER nun EA ACC
S-••-"_
AUTO OM Y: AGG
S
EXCESS/1MB RETIALIABILITY
EACH OCCURRENCE
S
____I OCCUR r l 1 CLAQeS /ODE
AGGREGATE .__ _3____.__.
...
DEOUCTIOIE
RETENTION S
3
WORKERS COMPENSATION AND
E MPLOYFRS' LA0R.11Y
_I µ1 CY1tSJ J c(e�
_ , ___
ANY PROPRIETOR/PART
OFFICER M t01ER EXCLUDED?
E.l EACH ACCIDENT __
S _
` y� T
I Ys. de1&beltdel
E.L. [NSEASE • EA EMPLOYEE
5
E.L. DISEASE • POLICY LIMIT
S
S�ECIALPR0WSI0NS caber
A
OTHER ProConsional Liab.
V15U3Q100303
7/1/2010
7/1/2011
$ 1,000,000 Per Claim/
Annual Aggrage te
DESCRIPTION Of OPERATIONS /LOCATIONS I VEHICLES I EXCLUSIONS AO 0E0 BY ENDORSEMENT I SPECIAL PROVISIONS
The claims made profeaaional liability coverage is the tote) aggregate limit for all claims
presented within the policy period and io oubject 00 a deductible.
Master Certificate
.1
SHOULD ANY Of 1 ne ABOVE OESCR)D ED POLICIES 8E CANCELLED BEFORE 71t{ EY1•IRATION
OATS THeneor. THE ISSUING INSURER WILL ENDEAVOR TO MAIL _AG_ DAYS MUTTER
NOTICE TO THE CER0f16A1E 11010ER NAMED 10 WE LEFT, BLT 1A1l0RE TO 00 SO Slim L
IOIPOSE 3,10 08UOATto)I 011 LIADt3i9 OF ANY 10310 UPON PIE INSURER, ITS A0ENT5 oft
REPRESENTATIVES.
t pp
AU191003200 REPRESENTATNE Fji)i,!iLrlrs (II:N.j
1 t11
OACORD CORPORATION 1988
Page 2 of 2
CERTIFICATE OF LIABILITY INSURANCE Date: June 24 201...9
TDI number required. Please refer to the
PRODUCER: Texas Dept of Insurance website: fltto:l/www.tdi.state.tx.us/
Purifpv & Companv insurance
PO Box 1088
Temple, TX 78503
Phone; 254.7736844 Email
patrmpurifovjilsurance.c4m
INSURED:
Kesbera. Patrick a Associates. LP; KasberQ. Patrick &
Associates. GP: Main One South. LP Main One South GP
1 Seud1 Main Street
Temple. TX 78501
Phone: 254-773-3731 E-mail: dwalters irokeneingers.com
COMPANIES AFFORDING COVERAGE
TDI
A Hartford Lloyds Insurance Company
93503
Undenvriters insurance Company
60400
oHartford
THIS IS TO CERTIFY THAT the insured named above Is it sured by the Companies listed above with respect to the business operations
hereinafter described, for the types of Insurance and In accordance with the provisions of the standard policies used by the companies,
and further hereinafter described. Exceptions to the policies are noted below,
CO
LTR
TYPE OF POLICY EFFECTIVE EXPIRATION
INSURANCE NUMBER DATE DATE
LIMITS
GENERAL LIABILITY 65SBAPT9851 8/1/10 8/1/11 GENERAL AGGREGATE $ 2,000,000
PRODUCTS-COMP/OP AGG. $2.000,000
PERSONAL & ADV. INJURY $1,000,000
EACH OCCURRENCE $1,000400
FIRE DAMAGE (Any one fire) $300,000
MER. EXPENSE (Any one person) $10,000
AUTOMOBILE LIABILITY 65UECUY7761 8/1/10 811/11 COMBINED SINGLE LIMIT $1,000,000 '—
BODILY INJURY (Per person) $
BODILY INJURY (Per accident) $
PROPERTY DAMAGE $
EXCESS LIABILITY 65SBAPT9861 8/1/10 811/11 w.. EACH OCCURRENCE $1.000,000
AGGREGATE S1,000,000
WORKERS' COMPENSATION
AND EMPLOYERS' LIABILITY
65WECGF1815 8/1/10
PROFESSIONAL LIABILITY
BUILDERS' RISK INSURANCE
OR INSTALLATION INSURANCE
STATUTORY LIMITS $ yes
EACH ACCIDENT $500,000
8/1/11 DISEASE - POLICY LIMIT $500,000
DISEASE - EACH EMPLOYEE $500,000
DESCRIPTION OF OPERATIONS/LOCATIONSNEHICLESISPECIAL ITEMS/EXCEPTIONS
The City of Round Rock is named as additional Insured with respect to ail policies except 'Workers' Compensation and Employers'
Liability' and 'Professional Liability'. Should any of the above described policies be cancelled or changed before the expiration date
thereof, the issuing company will mail thirty (3D) days written notice to the certificate holder named below.
CERTIFICATE HOLDER: City Manager
City of Round Rock SIGNATURE OF AGENT LICE NSED`l TAT; 'OF TEXAS
221 E. Main Street
Round Rock, Texas 78664
128384
00650 -• 1.2008
Typed Name: Mack A. Purifov, AAI, CIC
Title: Owner
Page 2
Certificate of Liability Insurance