Loading...
CM-13-04-039ROUND ROCK, TEXAS NYI'OSF. PASSION PROSPFARY City of Round Rock Agenda Item Summary Agenda Number: Title: Consider executing a Contract for Engineering Services with Page Southerland Page, LLC for the Downtown Land and Parking Lots Project. Type: City Manager Item Governing Body: City Manager Approval Agenda Date: 4/19/2013 Dept Director: Gary Hudder Cost: $33,340.00 Indexes: General Self -Financed Construction Attachments: ESC w -Page Southerland Page for Downtown Land Parking Lots Text of Legislative File CM -13-04-039 Engineering services for design and construction plans for the new parking lot at the southwest corner of Lampasas and Liberty Streets. Work to be included is design of the new parking lot and preparation of plans, specifications and estimate. Staff recommends approval City of Round Rock Page 1 Printed on 4/18/2013 LEGAL DEPARTMENT APPROVAL FOR CITY COUNCIL/CITY MANAGER ACTION Required for Submission of ALL City Council and City Manager Items Department Name: Transportation Project Mgr/Resource: Todd Keltgen Council Action: ORDINANCE Agenda Wording Project Name: Downtown Land and Parking Lots ContractorNendor: Page Southerland Page, LLP n RESOLUTION [] City Manager Approval CMA Wording Consider executing a Contract for Engineering Services with Page Southerland Page, LLC for the Downtown Land and Parking Lots Project. Attorney Approval EAttorney Notes/Comments Date O:lwdox\SCCInts10199\13801MISC100272221.XLS Updated 6/3/08 ROUND ROCK, TEXAS F OSE PASSION PROSPERITY CITY OF ROUND ROCK CONTRACT FOR ENGINEERING SERVICES FIRM: PAGE SOUTHERLAND PAGE, LLP ("Engineer") ADDRESS: 400 West Caesar Chavez Street, Suite 500, Austin, TX 78701 PROJECT: Downtown Land and Parking Lots THE STATE OF TEXAS COUNTY OF WILLIAMSON § T I CONTRACT FOR ENGINEERING SERVICES ("Contract") is made and entered into on this the 1day of1 , 2013 by and between the CITY OF ROUND ROCK, a Texas home - rule municipal corpora ion, whose offices are located at 221 East Main Street, Round Rock, Texas 78664-5299, (hereinafter referred to as "City"), and Engineer, and such Contract is for the purpose of contracting for professional engineering services. RECITALS: WHEREAS, V.T.C.A., Government Code §2254.002(2)(A)(vii) under Subchapter A entitled "Professional Services Procurement Act" provides for the procurement by municipalities of services of professional engineers; and WHEREAS, City and Engineer desire to contract for such professional engineering services; and WHEREAS, City and Engineer wish to document their agreement concerning the requirements and respective obligations of the parties; NOW, THEREFORE, WITNESSETH: That for and in consideration of the mutual promises contained herein and other good and valuable considerations, and the covenants and agreements hereinafter contained to be kept and performed by the respective parties hereto, it is agreed as follows: Engineering Services Contract 0199.1380; 00272022 1 CM- '3 - - 039 Rev. 05/10 00192831 CONTRACT DOCUMENTS The Contract Documents consist of this Contract and any exhibits attached hereto (which exhibits are hereby incorporated into and made a part of this Contract) and all Supplemental Contracts (as defined herein in Article 13) which are subsequently issued. These form the entire contract, and all are as fully a part of this Contract as if attached to this Contract or repeated herein. ARTICLE 1 CITY SERVICES City shall perform or provide services as identified in Exhibit A entitled "City Services." ARTICLE 2 ENGINEERING SERVICES Engineer shall perform Engineering Services as identified in Exhibit B entitled "Engineering Services." Engineer shall perform the Engineering Services in accordance with the Work Schedule as identified in Exhibit C entitled "Work Schedule." Such Work Schedule shall contain a complete schedule so that the Engineering Services under this Contract may be accomplished within the specified time and at the specified cost. The Work Schedule shall provide specific work sequences and definite review times by City and Engineer of all Engineering Services. Should the review times or Engineering Services take longer than shown on the Work Schedule, through no fault of Engineer, Engineer may submit a timely written request for additional time, which shall be subject to the approval of the City Manager. ARTICLE 3 CONTRACT TERM (1) Term. The Engineer is expected to complete the Engineering Services described herein in accordance with the above described Work Schedule. If Engineer does not perfonn the Engineering Services in accordance with the Work Schedule, then City shall have the right to terminate this Contract as set forth below in Article 20. So long as the City elects not to terminate this Contract, it shall continue from day to day until such time as the Engineering Services are completed. Any Engineering Services performed or costs incurred after the date of termination shall not be eligible for reimbursement. Engineer shall notify City in writing as soon as possible if he/she/it determines, or reasonably anticipates, that the Engineering Services will not be completed in accordance with the Work Schedule. (2) Work Schedule. Engineer acknowledges that the Work Schedule is of critical importance, and agrees to undertake all necessary efforts to expedite the performance of Engineering Services required herein so that construction of the project will be commenced and completed as scheduled. In this regard, and subject to adjustments in the Work Schedule as provided in Article 2 herein, Engineer shall proceed with sufficient qualified personnel and consultants necessary to fully and timely accomplish all Engineering Services required under this Contract in a professional manner. 2 (3) Notice to Proceed. After execution of this Contract, Engineer shall not proceed with Engineering Services until authorized in writing by City to proceed as provided in Article 7. ARTICLE 4 COMPENSATION City shall pay and Engineer agrees to accept the amount shown below as full compensation for the Engineering Services performed and to be performed under this Contract. The amount payable under this Contract, without modification of the Contract as provided herein, is the sum of Thirty -Three Thousand Three Hundred Forty and No/100 Dollars ($33,340.00) as shown in Exhibit D. The lump sum amount payable shall be revised equitably only by written Supplemental Contract in the event of a change in Engineering Services as authorized by City. Engineer shall prepare and submit to City monthly progress reports in sufficient detail to support the progress of the Engineering Services and to support invoices requesting monthly payment. Any preferred format of City for such monthly progress reports shall be identified in Exhibit B. Satisfactory progress of Engineering Services shall be an absolute condition of payment. The fee herein referenced may be adjusted for additional Engineering Services requested and performed only if approved by written Supplemental Contract. ARTICLE 5 METHOD OF PAYMENT Payments to Engineer shall be made while Engineering Services are in progress. Engineer shall prepare and submit to City, not more frequently than once per month, a progress report as referenced in Article 4 above. Such progress report shall state the percentage of completion of Engineering Services accomplished during that billing period and to date. Simultaneous with submission of such progress report, Engineer shall prepare and submit one (1) original and one (1) copy of a certified invoice in a form acceptable to City. This submittal shall also include a progress assessment report in a form acceptable to City. Progress payments shall be made in proportion to the percentage of completion of Engineering Services identified in Exhibit D. Progress payments shall be made by City based upon Engineering Services actually provided and performed. Upon timely receipt and approval of each statement, City shall make a good faith effort to pay the amount which is due and payable within thirty (30) days. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. Engineer has the responsibility to submit proof to City, adequate and sufficient in its determination, that tasks were completed. The certified statements shall show the total amount earned to the date of submission and shall show the amount due and payable as of the date of the current statement. Final payment does not relieve Engineer of the responsibility of correcting any errors and/or omissions resulting from his/her/its negligence. 3 ARTICLE 6 PROMPT PAYMENT POLICY In accordance with Chapter 2251, V.T.C.A., Texas Government Code, payment to Engineer will be made within thirty (30) days of the day on which the performance of services was complete, or within thirty (30) days of the day on which. City receives a correct invoice for services, whichever is later. Engineer may charge a late fee (fee shall not be greater than that which is permitted by Texas law) for payments not made in accordance with this prompt payment policy; however, this policy does not apply in the event: A. There is a bona fide dispute between City and Engineer concerning the supplies, materials, or equipment delivered or the services performed that causes the payment to be late; or B. The terms of a federal contract, grant, regulation, or statute prevent City from making a timely payment with federal funds; or C. There is a bona fide dispute between Engineer and a subcontractor or between a subcontractor and its supplier concerning supplies, materials, or equipment delivered or the Engineering Services performed which causes the payment to be late; or D. The invoice is not mailed to City in strict accordance with instructions, if any, on the purchase order, or this Contract or other such contractual agreement. City shall document to Engineer the issues related to disputed invoices within ten (10) calendar days of receipt of such invoice. Any non -disputed invoices shall be considered correct and payable per the terms of Chapter 2251, V.T.C.A., Texas Government Code. ARTICLE 7 NOTICE TO PROCEED The Engineer shall not proceed with any task listed on Exhibit B until the City has issued a written Notice to Proceed regarding such task. The City shall not be responsible for work performed or costs incurred by Engineer related to any task for which a Notice to Proceed has not been issued. ARTICLE 8 PROJECT TEAM City's Designated Representative for purposes of this Contract is as follows: Todd Keltgen Operations Manager 2008 Enterprise Drive Round Rock, Texas 78664 Telephone Number (512) 218-5583 Fax Number (512) 218-5563 Email Address toddk@roundrocktexas.gov 4 City's Designated Representative shall be authorized to act on City's behalf with respect to this Contract. City or City's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by Engineer in order to avoid unreasonable delay in the orderly and sequential progress of Engineering Services. Engineer's Designated Representative for purposes of this Contract is as follows: James C. Alvis, P.E. Vice President, Director of Civil Engineering 400 West Caesar Chavez Street, Suite 500 Austin, TX 78701 Telephone Number (512) 472-6721 Fax Number (512) 472-3211 Email Address jalvis@pspaec.com ARTICLE 9 PROGRESS EVALUATION Engineer shall, from time to time during the progress of the Engineering Services, confer with City at City's election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be requested by City, in order for City to evaluate features of the Engineering Services. At the request of City or Engineer, conferences shall be provided at Engineer's office, the offices of City, or at other locations designated by City. When requested by City, such conferences shall also include evaluation of the Engineering Services. Should City determine that the progress in Engineering Services does not satisfy the Work Schedule, then City shall review the Work Schedule with Engineer to determine corrective action required. Engineer shall promptly advise City in writing of events which have or may have a significant impact upon the progress of the Engineering Services, including but not limited to the following: (1) Problems, delays, adverse conditions which may materially affect the ability to meet the objectives of the Work Schedule, or preclude the attainment of project Engineering Services units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and City assistance needed to resolve the situation, if any; and (2) Favorable developments or events which enable meeting the Work Schedule goals sooner than anticipated. 5 ARTICLE 10 SUSPENSION Should City desire to suspend the Engineering Services, but not to terminate this Contract, then such suspension may be effected by City giving Engineer thirty (30) calendar days' verbal notification followed by written confirmation to that effect. Such thirty -day notice may be waived in writing by agreement and signature of both parties. The Engineering Services may be reinstated and resumed in full force and effect within sixty (60) days of receipt of written notice from City to resume the Engineering Services. Such sixty-day notice may be waived in writing by agreement and signature of both parties. If this Contract is suspended for more than thirty (30) days, Engineer shall have the option of terminating this Contract. If City suspends the Engineering Services, the contract period as determined in Article 3, and the Work Schedule, shall be extended for a time period equal to the suspension period. City assumes no liability for Engineering Services performed or costs incurred prior to the date authorized by City for Engineer to begin Engineering Services, and/or during periods when Engineering Services is suspended, and/or subsequent to the contract completion date. ARTICLE 11 ADDITIONAL ENGINEERING SERVICES If Engineer forms a reasonable opinion that any work he/she/it has been directed to perform is beyond the scope of this Contract and as such constitutes extra work, he/she/it shall promptly notify City in writing. In the event City finds that such work does constitute extra work and exceeds the maximum amount payable, City shall so advise Engineer and a written Supplemental Contract will be executed between the parties as provided in Article 13. Engineer shall not perform any proposed additional work nor incur any additional costs prior to the execution, by both parties, of a written Supplemental Contract. City shall not be responsible for actions by Engineer nor for any costs incurred by Engineer relating to additional work not directly associated with the performance of the Engineering Services authorized in this Contract or any amendments thereto. ARTICLE 12 CHANGES IN ENGINEERING SERVICES If City deems it necessary to request changes to previously satisfactorily completed Engineering Services or parts thereof which involve changes to the original Engineering Services or character of Engineering Services under this Contract, then Engineer shall make such revisions as requested and as directed by City. Such revisions shall be considered as additional Engineering Services and paid for as specified under Article 11. Engineer shall make revisions to Engineering Services authorized hereunder as are necessary to correct errors appearing therein, when required to do so by City. No additional compensation shall be due for such Engineering Services. 6 ARTICLE 13 SUPPLEMENTAL CONTRACTS The terms of this Contract inay be modified by written Supplemental Contract if City determines that there has been a significant change in (1) the scope, complexity or character of' the Engineering Services, or (2) the duration of the Engineering Services. Any such Supplemental Contract must be duly authorized by the City. Engineer shall not proceed until the Supplemental Contract has been executed. Additional compensation, if appropriate, shall be identified as provided in Article 4. It is understood and agreed by and between both parties that Engineer shall make no claim for extra work done or materials furnished until the City authorizes full execution of the written Supplemental Contract and authorization to proceed. City reserves the right to withhold payment pending verification of satisfactory Engineering Services performed. ARTICLE 14 USE OF DOCUMENTS All documents, including but not limited to drawings, specifications and data or programs stored electronically, (hereinafter referred to as "Instruments of Service") prepared by Engineer and its subcontractors are related exclusively to the services described in this Contract and are intended to be used with respect to this Project. However, it is expressly understood and agreed by and between the parties hereto that all of Engineer's designs under this Contract (including but not limited to tracings, drawings, estimates, specifications, investigations, studies and other documents, completed or partially completed), shall be the property of City to be thereafter used in any lawful manner as City elects. Any such subsequent use made of documents by City shall be at City's sole risk and without liability to Engineer, and, to the extent permitted by law, City shall indemnify, defend and hold harmless Engineer from all claims, damages, losses and expenses, including but not limited to attorneys fees, resulting therefrom. By execution of this Contract and in confirmation of the fee for services to be paid under this Contract, Engineer hereby conveys, transfers and assigns to City all rights under the Federal Copyright Act of 1976 (or any successor copyright statute), as amended, all common law copyrights and all other intellectual property rights acknowledged by law in the Project designs and work product developed under this Contract. Copies may be retained by Engineer. Engineer shall be liable to City for any loss or damage to any such documents while they are in the possession of or while being worked upon by Engineer or anyone connected with Engineer, including agents, employees, Engineers or subcontractors. All docutnents so lost or damaged shall be replaced or restored by Engineer without cost to City. Upon execution of this Contract, Engineer grants to City perinission to reproduce Engineer's work and documents for purposes of constructing, using and maintaining the Project, provided that City shall comply with its obligations, including prompt payment of all sums when due, under this Contract. Engineer shall obtain similar permission from Engineer's subcontractors consistent with this Contract. If and upon the date Engineer is adjudged in default of this Contract, City is permitted to authorize other similarly credentialed design professionals to reproduce and, where permitted by law, to make changes, corrections or additions to the work and documents for the purposes of completing, using and maintaining the Project. 7 City shall not assign, delegate, sublicense, pledge or otherwise transfer any permission granted herein to another party without the prior written contract of Engineer. However, City shall be permitted to authorize the contractor, subcontractors and material or equipment suppliers to reproduce applicable portions of the Instruments of Service appropriate to and for use in their execution of the Work. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is permitted. Any unauthorized use of the Instruments of Service shall be at City's sole risk and without liability to Engineer and its Engineers. Prior to Engineer providing to City any Instruments of Service in electronic form or City providing to Engineer any electronic data for incorporation into the Instruments of Service, City and Engineer shall by separate written contract set forth the specific conditions governing the format of such Instruments of Service or electronic data, including any special limitations not otherwise provided in this Contract. Any electronic files are provided by Engineer for the convenience of City, and use of them is at City's sole risk. In the case of any defects in electronic files or any discrepancies between them and any hardcopy of the same documents prepared by Engineer, the hardcopy shall prevail. Only printed copies of documents conveyed by Engineer shall be relied upon. Engineer shall have no liability for changes made to the drawings by other engineers subsequent to the completion of the Project. Any such change shall be sealed by the engineer snaking that change and shall be appropriately marked to reflect what was changed or modified. ARTICLE 15 PERSONNEL, EQUIPMENT AND MATERIAL Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services, and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable thein to perform the duties assigned to them. Any employee of Engineer who, in the opinion of City, is incompetent or whose conduct becomes detrimental to the Engineering Services shall immediately be removed from association with the project when so instructed by City. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than City. Engineer may not change the Project Manager without prior written consent of City. ARTICLE 16 SUBCONTRACTING Engineer shall not assign, subcontract or transfer any portion of the Engineering Services under this Contract without prior written approval from City. All subcontracts shall include the provisions required in this Contract and shall be approved as to form, in writing, by City prior to Engineering Services being performed under the subcontract. No subcontract shall relieve Engineer of any responsibilities under this Contract. 8 ARTICLE 17 EVALUATION OF ENGINEERING SERVICES City, or any authorized representatives of it, shall have the right at all reasonable times to review or otherwise evaluate the Engineering Services performed or being performed hereunder and the premises on which it is being perfonned. If any review or evaluation is made on the premises of Engineer or a subcontractor, then Engineer shall provide and require its subcontractors to provide all reasonable facilities and assistance for the safety and convenience of City or other representatives in the performance of their duties. ARTICLE 18 SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by City before any final report is issued. City's comments on Engineer's preliminary reports shall be addressed in any final report. ARTICLE 19 VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer's default, breach of contract, or violation of contract terms shall be paid by Engineer. ARTICLE 20 TERMINATION This Contract may be terminated as set forth below. (1) By mutual agreement and consent, in writing, of both parties. (2) By City, by notice in writing to Engineer, as a consequence of failure by Engineer to perform the Engineering Services set forth herein in a satisfactory manner. (3) By either party, upon the failure of the other party to fulfill its obligations as set forth herein. (4) By City, for reasons of its own and not subject to the mutual consent of Engineer, upon not less than thirty (30) days' written notice to Engineer. (5) By satisfactory completion of all Engineering Services and obligations described herein. Should City terminate this Contract as herein provided, no fees other than fees due and payable at the time of tennination shall thereafter be paid to Engineer. In determining the value of the Engineering Services performed by Engineer prior to termination, City shall be the sole judge. Compensation for Engineering Services at termination will be based on a percentage of the Engineering 9 Services completed at that time. Should City terminate this Contract under Subsection (4) immediately above, then the amount charged during the thirty -day notice period shall not exceed the amount charged during the preceding thirty (30) days. If Engineer defaults in the performance of this Contract or if City terminates this Contract for fault on the part of Engineer, then City shall give consideration to the actual costs incurred by Engineer in performing the Engineering Services to the date of default, the amount of Engineering Services required which was satisfactorily completed to date of default, the value of the Engineering Services which are usable to City, the cost to City of employing another firm to complete the Engineering Services required and the time required to do so, and other factors which affect the value to City of the Engineering Services performed at the time of default. The termination of this Contract and payment of an amount in settlement as prescribed above shall extinguish all rights, duties, and obligations of City and Engineer under this Contract, except the obligations set forth herein in Article 21 entitled "Compliance with Laws." If the termination of this Contract is due to the failure of Engineer to fulfill his/her/its contractual obligations, then City may take over the project and prosecute the Engineering Services to completion. In such case, Engineer shall be liable to City for any additional and reasonable costs incurred by City. Engineer shall be responsible for the settlement of all contractual and administrative issues arising out of any procurements made by Engineer in support of the Engineering Services under this Contract. ARTICLE 21 COMPLIANCE WITH LAWS (1) Compliance. Engineer shall comply with all applicable federal, state and local laws, statutes, codes, ordinances, rules and regulations, and the orders and decrees of any court, or administrative bodies or tribunals in any manner affecting the performance of this Contract, including without limitation, minimum/maximum salary and wage statutes and regulations, and licensing laws and regulations. Engineer shall furnish City with satisfactory proof of his/her/its compliance. Engineer shall further obtain all permits and licenses required in the performance of the Engineering Services contracted for herein. (2) Taxes. Engineer will pay all taxes, if any, required by law arising by virtue of the Engineering Services performed hereunder. City is qualified for exemption pursuant to the provisions of Section 151.309 of the Texas Limited Sales, Excise, and Use Tax Act. ARTICLE 22 INDEMNIFICATION Engineer shall save and hold harmless City and its officers and employees from all claims and liabilities due to activities of his/her/itself and his/her/its agents or employees, performed under this Contract, which are caused by or which result from the negligent error, omission, or negligent act of Engineer or of any person employed by Engineer or under Engineer's direction or control. 10 Engineer shall also save and hold City harmless from any and all expenses, including but not limited to reasonable attorneys fees which may be incurred by City in litigation or otherwise defending claims or liabilities which may be imposed on City as a result of such negligent activities by Engineer, its agents, or employees. ARTICLE 23 ENGINEER'S RESPONSIBILITIES Engineer shall be responsible for the accuracy of his/her/its Engineering Services and shall promptly make necessary revisions or corrections to its work product resulting from errors, omissions, or negligent acts, and same shall be done without compensation. City shall determine Engineer's responsibilities for all questions arising from design errors and/or omissions. Engineer shall not be relieved of responsibility for subsequent correction of any such errors or omissions in its work product, or for clarification of any ambiguities until after the construction phase of the project has been completed. ARTICLE 24 ENGINEER'S SEAL The responsible engineer shall sign, seal and date all appropriate engineering submissions to City in accordance with the Texas Engineering Practice Act and the rules of the State Board of Registration for Professional Engineers. ARTICLE 25 NON -COLLUSION. FINANCIAL INTEREST PROHIBITED (1) Non -collusion. Engineer warrants that he/she/it has not employed or retained any company or persons, other than a bona fide employee working solely for Engineer, to solicit or secure this Contract, and that he/she/it has not paid or agreed to pay any company or engineer any fee, commission, percentage, brokerage fee, gifts, or any other consideration, contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City reserves and shall have the right to annul this Contract without liability or, in its discretion and at its sole election, to deduct from the contract price or compensation, or to otherwise recover, the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. (2) Financial Interest Prohibited. Engineer covenants and represents that Engineer, his/her/its officers, employees, agents, consultants and subcontractors will have no financial interest, direct or indirect, in the purchase or sale of any product, materials or equipment that will be recommended or required for the construction of the project. ARTICLE 26 INSURANCE (1) Insurance. Engineer, at Engineer's sole cost, shall purchase and maintain during the entire term while this Contract is in effect professional liability insurance coverage in the minimum amount of One Million Dollars per claim from a company authorized to do insurance business in Texas and 11 otherwise acceptable to City. Engineer shall also notify City, within twenty-four (24) hours of receipt, of any notices of expiration, cancellation, non -renewal, or material change in coverage it receives from its insurer. (2) Subconsultant Insurance. Without limiting any of the other obligations or liabilities of Engineer, Engineer shall require each subconsultant performing work under this Contract to maintain during the term of this Contract, at the subconsultant's own expense, the same stipulated minimum insurance required in Article 26, Section (1) above, including the required provisions and additional policy conditions as shown below in Article 26, Section (3). Engineer shall obtain and monitor the certificates of insurance from each subconsultant in order to assure compliance with the insurance requirements. Engineer must retain the certificates of insurance for the duration of this Contract, and shall have the responsibility of enforcing these insurance requirements among its subconsultants. City shall be entitled, upon request and without expense, to receive copies of these certificates of insurance. (3) Insurance Policy Endorsements. Each insurance policy shall include the following conditions by endorsement to the policy: (a) Engineer shall notify City thirty (30) days prior to the expiration, cancellation, non- renewal or any material change in coverage, and such notice thereof shall be given to City by certified mail to: City Manager, City of Round Rock 221 East Main Street Round Rock, Texas 78664 (b) The policy clause "Other Insurance" shall not apply to any insurance coverage currently held by City, to any such future coverage, or to City's Self -Insured Retentions of whatever nature. (4) Cost of Insurance. The cost of all insurance required herein to be secured and maintained by Engineer shall be borne solely by Engineer, with certificates of insurance evidencing such minimum coverage in force to be filed with City. Such Certificates of Insurance are evidenced as Exhibit E herein entitled "Certificates of Insurance." ARTICLE 27 COPYRIGHTS City shall have the royalty -free, nonexclusive and irrevocable right to reproduce, publish or otherwise use, and to authorize others to use, any reports developed by Engineer for governmental purposes. 12 ARTICLE 28 SUCCESSORS AND ASSIGNS This Contract shall be binding upon and inure to the benefit of the parties hereto, their successors, lawful assigns, and legal representatives. Engineer may not assign, sublet or transfer any interest in this Contract, in whole or in part, by operation of law or otherwise, without obtaining the prior written consent of City. ARTICLE 29 SEVERABILITY In the event any one or more of the provisions contained in this Contract shall for any reason be held to be invalid, illegal or unenforceable in any respect, then such invalidity, illegality or unenforceability shall not affect any other provision thereof and this Contract shall be construed as if such invalid, illegal or unenforceable provision had never been contained herein. ARTICLE 30 PRIOR AGREEMENTS SUPERSEDED This Contract constitutes the sole agreement of the parties hereto, and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein. This Contract inay only be amended or supplemented by mutual agreement of the parties hereto in writing. ARTICLE 31 ENGINEER'S ACCOUNTING RECORDS Records pertaining to the project, and records of accounts between City and Engineer, shall be kept on a generally recognized accounting basis and shall be available to City or its authorized representatives at mutually convenient times. The City reserves the right to review all records it deems relevant which are related to this Contract. ARTICLE 32 NOTICES All notices to either party by the other required under this Contract shall be personally delivered or mailed to such party at the following respective addresses: City: City of Round Rock Attention: City Manager 221 East Main Street Round Rock, TX 78664 13 and to: Stephan L. Sheets City Attorney 309 East Main Street Round Rock, TX 78664 Engineer: James C. Alvis, P.E. Vice President, Director of Civil Engineering 400 West Caesar Chavez Street, Suite 500 Austin, TX 78701 ARTICLE 33 GENERAL PROVISIONS (1) Time is of the Essence. Engineer understands and agrees that time is of the essence and that any failure of Engineer to complete the Engineering Services for each phase of this Contract within the agreed Work Schedule may constitute a material breach of this Contract. Engineer shall be fully responsible for his/her/its delays or for failures to use his/her/its reasonable efforts in accordance with the terms of this Contract and the Engineer's standard of perforniance as defined herein. Where damage is caused to City due to Engineer's negligent failure to perform City may accordingly withhold, to the extent of such damage, Engineer's payments hereunder without waiver of any of City's additional legal rights or remedies. (2) Force Majeure. Neither City nor Engineer shall be deemed in violation of this Contract if prevented from performing any of their obligations hereunder by reasons for which they are not responsible or circumstances beyond their control. However, notice of such impediment or delay in performance must be timely given, and all reasonable efforts undertaken to mitigate its effects. (3) Enforcement and Venue. This Contract shall be enforceable in Round Rock, Williamson County, Texas, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein, exclusive venue for same shall lie in Williamson County, Texas. This Contract shall be governed by and construed in accordance with the laws and court decisions of the State of Texas. (4) Standard of Performance. The standard of care for all professional engineering, consulting and related services performed or furnished by Engineer and its employees under this Contract will be the care and skill ordinarily used by members of Engineer's profession practicing under the same or similar circumstances at the same time and in the same locality. Excepting Articles 25 and 34 herein, Engineer makes no warranties, express or implied, under this Contract or otherwise, in connection with the Engineering Services. 14 (5) Opinion of Probable Cost. Any opinions of probable project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer's experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s') methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual project or construction cost will not vary from opinions of probable cost Engineer prepares. (6) Opinions and Determinations. Where the terms of this Contract provide for action to be based upon opinion, judgment, approval, review, or determination of either party hereto, such terms are not intended to be and shall never be construed as permitting such opinion, judgment, approval, review, or determination to be arbitrary, capricious, or unreasonable. ARTICLE 34 SIGNATORY WARRANTY The undersigned signatory for Engineer hereby represents and warrants that the signatory is an officer of the organization for which he/she has executed this Contract and that he/she has full and complete authority to enter into this Contract on behalf of the firm. The above -stated representations and warranties are made for the purpose of inducing City to enter into this Contract. IN WITNESS WHEREOF, the City of Round Rock has caused this Contract to be signed in its corporate naive by its duly authorized City Manager or Mayor, as has Engineer, signing by and through its duly authorized representative(s), thereby binding the parties hereto, their successors, assigns and representatives for the faithful and full performance of the terms and provisions hereof. CITY= ; • ' D R EXA By: �/ -eve IN m ..• ts, City Attorney Wol 441/44A OraSiSfitlb Sara L. White, City Clerk PAGE SOUTHERLAND PAGE, LLP By: Signature of Principal Printed Name: Page Southeriand Page, LLP. By: PSP Architects . Its: General BY Robert E Burke Its: Principal 15 LIST OF EXHIBITS ATTACHED (1) Exhibit A City Services (2) Exhibit II Engineering Services (3) Exhibit C Work Schedule (4) Exhibit D Fee Schedule (5) Exhibit E Certificates of Insurance EXHIBIT A City Services The City of Round Rock will furnish to the Engineer the following items/information: 1. Surveying. 2. Pavement sections will be based on Geotech recommendations provided by the City. 3. Timely review and approval of submitted information. 4. Timelines relating to critical submission dates. 5. Citizen and Property Owner contacts, coordination, and communication efforts. 6. Texas Dept. of Licensing and Regulation (TDLR) accessibility consultant review fees and registration and close out fees are by the City for Americans with Disabilities Act (ADA) compliance. 7. Project management. 8. City coordinates construction site meetings to run subsequent to meetings on the SWDT San Saba Street project. 9. Payment of fees to any Regulatory Authority having jurisdiction. EXHIBIT B Engineering Services Scope of Basic Civil Engineering Design Services: Civil Engineering services for design and construction plans for the New Parking Lot at the Southwest Corner of Lampasas and Liberty Streets (Block 22, Lots 12, 13, 14, and 15 - sum 22,489 sf) are outlined following. The preparation of Permit/Construction Documents and Specifications will be based on City approved Schematic Design documents and includes Basic Civil Engineering Design services as follows: Site Demolition Plan, Site Erosion Sedimentation Control Plan, Site Layout (curb and gutter, walks, driveways, dumpster pad). Site Grading Plan and Paving Plan, Site Lighting Plan and Detail, Site and ROW 5' concrete sidewalks (Accessible Routes in ROW adj. to site), Existing and Proposed Drainage Area Maps, Storm Drain Pian (also showing irrigation sleeves), Profile of new Storm Drain in R.O.W. to M.H. (at existing 30") Detention and Water Quality Facilities in vaults, and TCEQ Water Pollution Abatement Plan (WPAP) Permit Services. The concrete sidewalks in the ROW are expected to be temporary until they are replaced by work proposed for the SE Downtown Project Improvements. No new curb and gutter is proposed in the ROW PSP will coordinate Americans with Disabilities Act (ADA) registration with Accessibility Consultant at the time the drawings are completed. Fees for Accessibility Consultant services and ADA registration fees are to be paid by the City. Site buffer landscaping will be indicated in generic form in conformance to City code with the understanding that Landscape and Irrigation plans and details are to be provided by others. Construction activities in portions of Williamson County first became regulated under the Texas Commission on Environmental Quality (TCEQ) Edwards Aquifer Protection Program (EAPP) in 1986. PSP proposes to seek grandfathering of pre-existing impervious cover based on Sanborn Maps going back to the 1880's. PSP also proposes to request a waiver from the requirement to provide a Geologic Site Assessment (GSA) based on continuous development and use of the property over this extended period of time. The Scope of our Fee Proposal for the Basic Civil Engineering Design services for the improvements within the above defined parking lot area includes: 1. Pavement sections will be based on Geotech recommendations provided by City. 2. Analysis and Design of the Stormwater runoff collection, detention, and conveyance for the site improvements will be provided to the nearest connection to the existing system. Page 1 of 2 3. The only offsite drainage improvements included are those to connect any proposed site piping to the existing nearby connection point. 4. Submittal and coordination associated with the City of Round Rock TCEQ EAPP Water Pollution Abatement Plan (WPAP) application. 5. Preparation of Public Works Review Documents. 6. Construction Documents. 7. Provide drawings and assist Owner with selection of TAS/TDLR consultant (provided by Owner) for registration and review of project. 8. Construction Services: Conduct Environmental Site Pre -Construction Meeting, Attend on-site construction review meetings (to be coordinated with the times for the South West Downtown San Saba and West Liberty project meetings), Review submittals and shop drawings, Respond to Request for Information's (RFI's), Address design clarifications and issue Architects Supplemental Information's (ASI's). 9. Record Drawings. 10. Project Close Out. The following services are not included in the scope of the Basic Design Services. It is anticipated these services; are not required, are additional services, or are provided by others: 1. Bid Packages or Bid Assistance. 2. Zoning and Re -Subdivision. 3. Environmental Assessments. 4. Water, Wastewater or Dry Utilities Duct Line Assignments or Design. 5. Preparation of easement dedication/vacation exhibits (by Licensed Surveyor). 6. FEMA Flood Plain Analysis / Letter of Map Revisions. 7. Geologic Site Assessment (GSA). 8. Geotechnical Analysis/Reports and supplemental information. 9. Pavement section recommendations (provided by Owner). 10. Transportation Studies or Traffic Impact Analysis. 11.Tree, Topographical and Boundary Survey (provided by Owner). 12. Landscape and Irrigation Design (provided by Owner). 13.Site Furnishings, Signage and Graphics. 14. Changes or Additions to the Basic Design Services initiated by the Owner other than these described above. 15. Changes or Additions to the Basic Design Services resulting from unforeseen field conditions encountered during construction. 16. Permitting associated with the USF&W. 17.Off-Site Roadway or Drainage Improvements not described above. 18. Design of Retaining Walls over 4 feet tall (Structural Design required). 19. City, State or other Governing Agency Fees (note EAPP fee is $3,000). Page 2 of 2 EXHIBIT C Work Schedule ESTIMATED PROJECT SCHEDULE We propose to perform the detailed design concurrently with submittal of initial drawings for pursuit of the TCEQ WPAP permit. We believe we can submit a WPAP application to TCEQ EAPP in two to three weeks after authorization to proceed. We believe we can provide 90% construction drawings to the City for final review in four to five weeks. TCEQ is allowed a 60 day review period after the date submittal is made with fees paid. Estimated time from project start to final TCEQ approval is 12 weeks. TOTALS 000000000a coovsysys030 T.. GO to N ER M 44 C 0 0 0 0 0 0 0 0 0 .000000000. c o 0 c 0 0 0 0 0 0 R!9 to, vs 69 el 69 69 69 69 '44 vs 0 0 1 t 4- 0 i 0 0 0 0 0 0 0 0 0 0 4g1 O O O O O O O O 069 069 609 b09 0 0 69 6°1 069 69 0060 0 0 O CO Total Loaded Labor Cost $1,760.00 $18,700.00 $0.00 $0.00 $0.00 $880.00 $8,800.00 $2400.00 $0.00 O 1 44 Total Labor Hours 16 170 0 0 0 8 80 16 0 29 Task Task 1: Schematic Design/ 30% plans Task 2 Detail Design 60%, Constr. Doc'.s 90% to 100% plans Task 3: Constr. Ph. - Bid and Award Services Task 4: Constr. Ph. - Constr. Admin. (coord. w/ SWDT) Task 5: Constr. Ph. - Weekly Meetings (coord. w/ SWDT) Task 6: Constr. Ph. - Final Project Close Out Task 7:: Permitting Services - (TCEQ, City) Task 8:: Project Management - (e.g. meetings, accounting, etc Task 9: Direct Expenses (mail, mylars, repro., mileage, tolls, etc GRAND TOTAL: EXHIBIT E Certificates of Insurance Attached Behind This Page Client#:161180 PAGESOUT ACORD. CERTIFICATE OF LIABILITY INSURANCE DATE WOO/MY) WDD/YYY`n 4/04/2013OO/ THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDMONAL INSURED, the policy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER USI Southwest 7600-B N. Cap of Tx Hwy. #200 Austin, Texas 78731 harm Debra Wylie V+' 0. 0, 512-651-4159 I FAX No): 512-467-0113 M;� ADDRESS: INSURERS) AFFORDING COVERAGE NAIC 1 INSURER A; Ace American Insurance Company 22667 INSURED Page Southeriand Page, L.L.P 400 W. Cesar Chavez, #500 Austin, Texas 78701 INSURER a : IINNSURERc; EACH OCCURRENCE SURER O : RAA3igo Tel rep) INSURER E : MED EXP (Any one person) INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN RE��D��UC�pEppDD BY PA(cIIDD CLAIMS. fir TYPE OF INSURANCE ADDINSSRL VNO POUCY NUMBER (MLrIDDY)YYYY) (LIh11PD/YYYY) LIMITS GENERAL — LABILttY COMMERCIAL GENERAL LABILITY EACH OCCURRENCE $ RAA3igo Tel rep) $ MED EXP (Any one person) 5 CLAIMS -MADE . OCCUR PERSONAL & ADV INJURY $ GENERAL AGGREGATE $ PRODUCTS-COMP/OP AGO S GENL AGGREGATE LIMIT APPLIES PER: I GA ICY I l JECT 1 ( I LOC $ AUTOMOBILE — LIABILITY ANY AUTO ALL OWNEO ps SCHEDULED AUTOS Amos � aBWNEOSINGLE Lem a BODILY INJURY (Par person) 8 BODILY INJURY (Par Sodded) 8 PROPERTY DAMAGE (Per _i S UMBRELLAUAe EXCESS LAB OCCUR MS -MADE EACH OCCURRENCE $ AGGREGATE $ 8 DEO 1 RETENTION $ WORKERS COMPENSATION AND EMPLOYERS' LJABIUTY YIN NIA WC STAID- ( 10TH - TORY I RUTS FR E.L.EACH ACCIDENT $ ANDY, PROPRIETOftIPARTTNERIEXECU IVE OFyu(Mandatory k•IBNEH) UDED�E.L. If dew*, under DESCRIPTION OF OPERATIONS below DISEASE - EA EMPLOYEE $ E.L. DISEASE - POLICY LIMIT $ A Professional Liab Claims Made Pol. EONG21674151 Retro: 01/01/98 03/01/2013 03/01/201 $5,000,000 per claim $5,000,000 anni aggr. DESCRIPTION OF OPERATIONS 1 LOCATIONS I VEHICLES (Attach ACORD 101, Additions! Remarks Schedule, H mora space M required) RE Project #113004.01, City of Round Rock, 408 East Lampasas Parking Lot. This Certificate Is Issued In respects to above referenced. " Supplemental Name '• Page 8outherland Page, L.L.P (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION City of Round Rock 2008 Enterprise Drive Round Rock, TX 78664 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ®1988.2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) 1 of 2 The ACORD name and logo aro registered marks of ACORD #S9559166/M9415039 ABVZP SCRIPTIONS(Continued from Page 1 PageSoutherlandPage Michael J. Dattilo II Services for Page Southerland Page Page Southerland Page, L.L.P. PSP Architects -Engineers, Inc. PSP Architects Bricker+Cannady Architects, Inc. PSP -SVP, Inc. PageSoutherlandPage-Colorado, LLC Christopher Carvell Architects, P.C. Page Southerland Page Engineers, PC dba PSP Engineers, PC Page Southerland Page Architects, PC Page Southerland Page Architects, PC IC Disc Page Southerland Page International LLC SAGITTA 25.3 (2010105) 2 of 2 #895591601M9415039 A� Rd CERTIFICATE OF LIABILITY INSURANCE ia�2NDO/ ) 013 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION 18 WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER INBURICA 3721 Executive Center Dr # 200 Austin TX 78731 MALT Jody Robinson, CIC, CISR, ACSR /Irn, . sin, (512) 381-8371 1 WCe.. $101: m8) 852-936T AoDRess:jrobinsontlINSURICA.corn INSURERS) AFFOROING COVERAGE HMCo INsunERA3iartford Casualty Ins. Co. 29424 INSURED Page Southerland Page, LLP 400 W. Cesar Chavez St. #500 Austin TX 78701 INSURER 5 : 65UUHOX2750 INSURER C: INSURERD: S 1,000,000 INSURER E : S 300,000 INSURERF: $ 10,000 COVERAGES CERTIFICATE NUMBER:12/13 Austin Master REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWTHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. IRSR LTR TYPE OF INSURANCE ADDL IN SUER D. POLICY NUMBER PO OL Y tP LIMITS A GENERAL — X LIABIUTY COMMERCIAL GENERAL LIABILITY 65UUHOX2750 12/31/201212/31/2013 EACH OCCURRENCE S 1,000,000 PRD E TO EMISES o damxa) S 300,000 LIED EXP (Any oneporaon) $ 10,000 ICLAIMS-MADE X OCCUR PERSONAL & ADV INJURY $ 1,000,000 GENERAL AGGREGATE S 2,000,000 PRODUCTS - COMP/OP AO0 S 2,000,000 GEHL AGGREGATE LIMIT APPLES PER: ��El LOC —I POLICY Ii1. 1 A AUTOMOBILE LX X UABIUTY ANY AUTO ALL OWED AUTOS !TIRED AUTOS X SCHEOIA.ED AUTOS NOVO D AUT 651)VNUX2750 12/31/201212/31/2013 03M_ BINED SINGLE L rc S 1,000,000 _ BODILY INJURY (Per person) S sway INJURY(Pereadden° $ PROPERTY DAMAGE /Per soldenll—S S A X UMBRELLA UAB EXCESS UAB X OCCLR MAIMS -MADE 65XNU2Q6273 12/31/2012 12/31/2013yy$ EACH OCCURRENCE $ 10,000,000 AGGREGATE $ 10,000,000 DEO 1 X 1RETENTION$ 10,000 A WORKERSCOMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE Q OFFICERAIEMSER EXCLUDED? (Mandalory N NH) Nyyea, daaalbe under DESCRIPTION OF OPERATIONS Meow NIA 65W5N03315 12/31/2012 12/31/2013 X I IORYSTAUNU- I ION - ER E.L. EACH ACCIDENT S 1,000,000 E.L. DISEASE -EA EMPLOYEES 1,000,000 EL DISEASE -POLICY LIMIT 8 1,000,00R DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Addf ionel Remarks Sehedute, E more epee* 1e required) RE: Project No. 113004.01 - City of Round Rock - 408 East Lampasas Parking Lot. 855 ATTACHED. CANCELLATION City of Round Rook 2008 Enterprise Drive Round Rook, TX 78664 , SHOULD ANY OF THE ABOVE DESCRIBED POLICES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Davin Stewart/JNOVAE ,444t4t .ttA.1�Cf ACORD 26 (2010105) INRf215/MU m 01988-2010 ACORD CORPORATION. All rights reserved. Tho A1`ARf1 name and Irvin aro ranletorarl Inn dm of Af:ARfT COMMENTS/REMARKS PAGE SOUTHERLAND PAGE, LLP - The General Liability policy includes a blanket automatic additional insured endorsement HG0001 06/05 that provides additional insured status for On -Going & Completed Operations with Primary and Noncontributory wording to the certificate holder only when when the named insured has agreed in a written contract or agreement to provide such status. -The Automobile policy includes as an additional insured anyone liable for the conduct of an Insured but only to the extent of that liability as an additional insured. -The General Liability, Automobile and Workers Compensation policies includes a blanket waiver of subrogation endorsement that provides this feature only when the named insured has agreed in a written contract or agreement to provide such status. OFREMARK COPYRIGHT 2000, AMS SERVICES INC. COMMENTS/REMARKS COMPLETE NAMED INSURED: Page Southerland Page, LP Page Southerland Page, LLP Pagesoutherlandpage Page Southerland Page PSP. LLP PSP Architects -Engineers, Inc. Carvell Pagesoutherlandpage Page Southerland Page -Colorado, LLC Page Southerland Page International, LLC -Delaware, LLC Page Southerland Page International, Ltd. -British Virgin Islands Co Page Southerland Page Engineers, P.C. DBA PSP Engineers, P.C. Page Southerland Page Architects, P.C. Page Southerland Page Engineers, P.C. Page Southerland Page Services International, Inc. OFREMARK COPYRIGHT 2000, AMS SERVICES INC.